Amendment A003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

N/A

PAGE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE NO. 5. PROJECT NO. (If applicable)

A003 12/16/2024 N/A AK PFH 58(1), Neck Lake Road Reconstruction: NPOWI HWY. TO

MARINE ACCESS FACILITY JCT.

6. ISSUED BY CODE N/A 7. ADMINISTERED BY (If other than Item 6) CODE N/A

Department of Transportation Federal Highway Administration 610 East Fifth Street Vancouver WA 98661-3801

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and Zip Code) 9A. AMENDMENT OF SOLICITATION NO.

X 69056725B000001

9B. DATED (SEE ITEM 11)

11/18/2024

10A. MODIFICATION OF CONTRACT/ORDER NO.

N/A

10B. DATED (SEE ITEM 13)

CODE: N/A FACILITY CODE: N/A

N/A

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

| X | The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

(_X ) is extended, ( ) is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

N/A

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A THIS CHANGE ORDER IS ISSUED PURSUANT TO (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN

ITEM 10A.

N/A

B THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (Such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

N/A

C THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

N/A

D OTHER (Specify type of modification and authority)

N/A

E. IMPORTANT: Contractor n/a is not, n/a is required to sign this document and return n/a copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

AK PFH 58(1), Neck Lake Road Reconstruction: NPOWI HWY. TO MARINE ACCESS FACILITY JCT.

See page 2

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15a. NAME AND TITLE OF SIGNER (Type or print) 15a. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

N/A

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY_________________________________________ BY N/A___________________________ N/A (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION NOT USABLE

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

Amendment No. A003, dated 12/16/2024 Project No AK PFH 58(1)

Solicitation No. 69056725B000001 Project Name: Neck Lake Road

Reconstruction: NPOWI HWY. TO MARINE

ACCESS FACILITY JCT.

REVISIONS ARE AS FOLLOWS:

SF 1442, SOLICITATION, OFFER, AND AWARD

Page A-3, Block 13A. Revises bid opening date from 12/18/2024 to 01/08/202.

CONTRACT CLAUSES

Page C-27. Revises FAR Clauses 52.211-10 Commencement, Prosecution, and

Completion of Work (Apr 1984) Alternate I (Apr 1984). Revises notice to proceed date from

02/07/2025 to 02/28/2025.

ENCLOSURES

Pages:

A-3

C-27

New bid opening date: 01/08/2025

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

Federal Highway Administration

FHWA WESTERN FED LANDS DIVISION

610 E FIFTH STREET

Vancouver WA 98661

690567

FEDERAL HIGHWAY ADMINISTRATION

Western Federal Lands Highway Div.

610 E Fifth Street Vancouver, WA 98661

a. NAME

ACQUISITIONS

b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

360-619-7520

See Block 10 x

11/18/2024

1. SOLICITATION NO.

69056725B000001

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

This solicitation is designated AK PFH 58(1), Neck Lake Road Reconstruction: NPOWI

HWY. TO MARINE ACCESS FACILITY JCT.

IN STRICT ACCORDANCE WITH:

Federal Acquisition Regulations (FAR) and Transportation Acquisition Regulations

(TAR)

General Wage Decision

Special Contract Requirements

Standard Specifications for Construction of Roads and Bridges on Federal Highway Projects, FP-14

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 calendar days and complete it within ________________ ________________ calendar days after receiving

* Page A-5

________________________ 12/18/2024

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

A-3

01/08/2025

Revised by Amendment A003 rebekah.webb Cross-Out

C-27

Revised by Amendment A003 Contract Clauses

Project: AK PFH 58(1), Neck Lake Road Reconstruction: NPOWI HWY. TO MARINE ACCESS

FACILITY JCT.

(i) Meet the agency’s requirements;

(ii) Could be modified to meet the agency’s requirements; or

(iii) Could meet the agency’s requirements if those requirements were modified to a reasonable extent; and

(2) Determine the extent to which commercial products, commercial services, or nondevelopmental items could be incorporated at the component level.

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984) Alternate I

(Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 10/31/2026 subject to such extensions as may be authorized. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 02/07/2025. 02/28/2025. The completion date will be extended by the number of calendar days after the above date that the contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

52.211-12 Liquidated Damages—Construction (Sep 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the

Contractor shall pay liquidated damages to the Government in the amount of: See Special Contract

Requirements, Subsection 108.04.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.211-18 Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract.

Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

52.214-26 Audit and Records – Sealed Bidding (Jun 2020)

(a)As used in this clause, “records” includes books, documents, accounting procedures and practices, and other data, regardless of type and regardless of whether such items are in written form, in the form of computer data, or in any other form.

(b) Certified cost or pricing data. If the Contractor has been required to submit certified cost or pricing data in connection with the pricing of any modification to this contract, the Contracting Officer, or an authorized representative of the Contracting Officer, in order to evaluate the accuracy, completeness, and