Amendment 0003 USCG OPC.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Block 14 (Description of Amendment/Modification): Solicitation NO: N4008526R0001, Design-Bid-Build, USCG Offshore Patrol Cutters (OPC) Homeport Pier, Naval Station Newport, Newport RI

SEE SF 30 BLOCK 14 CONTINUATION PAGE.

ALL CORRESPONDENCE REGARDING THIS SOLICITATION SHALL BE DIRECTED VIA EMAIL TO KRISTY GERREK AT KRISTY.L.

GERREK.CIV@US.NAVY.MIL.

This amendment is issued to incorporate the following:

1. Provide continuation sheet for drawings and specifications (Enclosed)

2. Provide Word Copies for Attachment C - Construction Experience Project Data Sheet, Attachment D - Past Performance Questionnaire, Attachment E - Historical Small Business Utilization, and Updated Attachment F - SB Participation Commitment Document (attached separately)

3. Provide Updated Attachment H - UCCG OPC Pier Price Proposal Form REV 2 (attached separately)

4. Provide Attachment P - Spc 100 Final Specs Appendix F - Soil GW Sed Sampling Reports (attached separately)

5. Provide Attachment Q - Spc 100 Final Specs Appendix D - (With Placeholders) (attached separately)

6. Provide Attachment R - 26 08 00 - Electrical Shore Ties CSTO (Rev B) - Section 2.4.6 Testing (attached separately)

7. Provide Attachment S - Pier 1 - Amendment 003 Drawings (attached separately)

8. Provide Attachment T - REF(m) Existing Pier 1 Drawings 1 of 2 (attached separately)

9. Provide Justification & Approvals (J&As) (attached separately)

10. Update Clauses and Provisions (Enclosed)

11. Provide PPI Responses (Enclosed)

Section 00 21 00 - Instructions

The following clauses were modified:

52.215-1Instructions to Offerors-Competitive Acquisition. (Deviation 2026-O0038)Feb 2026

52.233-2Service of Protest. (Deviation 2026-O0038)Feb 2026

Section 00 45 00 - Representations and Certifications

The following clauses were modified:

52.209-7Information Regarding Responsibility Matters. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

INFORMATION REGARDING RESPONSIBILITY MATTERS (FEB 2026) (DEVIATION 2026-O0038)

(a) . As used in this provision-Definitions

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability ( , e.g.

Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity ( , general manager; plant manager; head of a division or business segment; and similar positions).e.g.

N4008526R00010003

(b) The offeror has does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

52.209-13Violation of Arms Control Treaties or Agreements-Certification. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION (FEB 2026) (DEVIATION 2026-O0038)

(a) This provision does not apply to acquisitions at or below the simplified acquisition threshold or to acquisitions of commercial products and commercial services as defined in Federal Acquisition Regulation 2.101.

(b) . [ ]Certification Offeror shall check either (1) or (2).

The Offeror certifies that-(1)

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices /under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; or

The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.(2)

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there. Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If such activity might have occurred, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of non-compliance is equivalent to a determination of violation.

However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

(3) If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or is a significant factor in the determination in the report that one or more of these foreign countries is in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. Review the narrative for any such findings reflecting a determination of violation or non-adherence related to those foreign countries in the report, including the finding itself, and to the extent necessary, the conduct giving rise to the compliance or adherence concerns, the analysis of compliance or adherence concerns, and efforts to resolve compliance or adherence concerns.

(4) The Offeror may submit any questions with regard to this report by email to NDAA1290Cert@state.gov. To the extent feasible, the Department of State will respond to such email inquiries within 3 business days.

(d) Do not submit an offer unless-

(1) A certification is provided in paragraph (b)(1) of this provision and submitted with the offer; or

(2) In accordance with paragraph (b)(2) of this provision, the Offeror provides with its offer information that the President of the United States has

(i) Waived application under 22 U.S.C. 2593e(d) or (e); or

(ii) Determined under 22 U.S.C. 2593e(g)(2) that the entity has ceased all activities for which measures were imposed under 22 U.S.C. 2593e(b).

(e) . The certification in paragraph (b)(1) of this provision is a material representation of fact upon which reliance was placed when Remedies making award. If the Government later determines that the Offeror knowingly submitted a false certification, in addition to other remedies available to the Government, such as suspension or debarment, the Contracting Officer may terminate any contract resulting from the false certification.

(End of provision)

Section 00 70 00 - Conditions of the Contract

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Reference

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data-Modifications.

(Deviation 2026-O0038)

Feb 2026

52.215-13 Subcontractor Certified Cost or Pricing Data-Modifications. (Deviation 2026- O0038)

Feb 2026

Requirements for Certified Cost or Pricing Data and Data Other Than

52.215-21 Certified Cost or Pricing Data-Modifications. (Deviation 2026-O0038) Feb 2026

52.222-90 Addressing DEI Discrimination by Federal Contractors. (Deviation 2026- O0038)

Apr 2026

52.228-11 Pledges of Assets (DEVIATION 2020-O0016) Feb 2021 Deviation 2020-O0016 Apr 2020 52.232-23 Assignment of Claims. May 2014 52.240-92 Security Requirements. (Deviation 2026-O0038) Feb 2026

FAR Clauses Incorporated by Full Text

52.243-7 Notification of Changes. (Deviation 2026-O0038) (Feb 2026)

NOTIFICATION OF CHANGES (FEB 2026) (DEVIATION 2026-O0038)

(a) Definitions.

Contracting Officer, as used in this clause, does not include any representative of the Contracting Officer.

Specifically Authorized Representative (SAR), as used in this clause, means any person the Contracting Officer has designated by written notice (a copy shall be provided to the Contractor) that shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority.

(b) The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a Notice.

change to this contract. Except for changes identified in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing promptly, within (to be negotiated) calendar days from the date that the Contractor identifies any Government ____ conduct that the Contractor regards as a change to the contract terms and conditions. Examples of conduct that may be regarded as a change to terms and conditions include actions, inactions, and written or oral communications. On the basis of the most accurate information available to the Contractor, the notice shall state-

(1) The date, nature, and circumstances of the conduct regarded as a change;

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

(3) The identification of any documents and the substance of any oral communication involved in such conduct;

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including-

(i) What line items have been or may be affected by the alleged change;

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;

(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be caused by the alleged change;

(iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and

(6) The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.

(c) Following submission of the notice required by paragraph (b) of this clause, the Contractor shall diligently continue Continued performance.

performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance. However, if the Contractor regards the direction or communication as a change as described in paragraph (b) of this clause, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing promptly and copies furnished to the Contractor and to the Contracting Officer. The Contracting Officer shall promptly countermand any action which exceeds the authority of the SAR.

(d) The Contracting Officer shall promptly, within (to be negotiated) calendar days after receipt of notice, respond to Government response. ____ the notice in writing. In responding, the Contracting Officer shall either-

(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;

(2) Countermand any communication regarded as a change;

(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or

(4) In the event the Contractor's notice information is inadequate to make a decision under (1), (2), or (3) of paragraph (d) of this clause, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.

.(e) Equitable adjustments

If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase (1) or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-

(i) In the contract price or delivery schedule or both; and

(ii) In such other provisions of the contract as may be affected.

(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in paragraphs(b) and (c) of this clause.

Note: The phrases contract price and cost wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof.

(End of clause)

DFARS Clauses Incorporated by Reference

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

252.204-7000 Disclosure of Information. Oct 2016

The following clauses were modified:

52.204-7System for Award Management-Registration. (Deviation 2026-O0038)Feb 2026

52.204-10Reporting Executive Compensation and First-Tier Subcontract Awards. (Deviation 2026-O0038)Feb

52.204-13System for Award Management-Maintenance. (Deviation 2026-O0038)Feb 2026

52.204-90Offeror Identification. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

OFFEROR IDENTIFICATION (FEB 2026) (DEVIATION 2026-O0038)

If the Offeror will not have an active Federal Government contracts registration in the System for Award Management (https://www.sam.gov) when submitting its offer, it shall complete paragraphs (c) and (d) of this provision and include its responses with its offer.

(a) . As used in this provision-Definitions

Commercial and Government Entity (CAGE) code has the meaning provided in the clause at FAR 52.204-91, Contractor Identification, of this solicitation.

Common parent means that corporate entity that owns or controls an affiliated group of corporations that files its Federal income tax returns on a consolidated basis, and of which the offeror is a member.

Electronic Funds Transfer (EFT) indicator means a bank account identifier to establish additional System for Award Management records for identifying alternative EFT accounts (see part 32) for the same entity.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest-level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. There may be more than one immediate owner (e.g., joint ventures).

Predecessor means an entity whose assets were acquired by the offeror or another entity (most often through merger or acquisition) and whose affairs are now carried out by the offeror or the other entity under a new name.

Taxpayer Identification Number means the number required by the Internal Revenue Service (IRS) to be used by the offeror to report income tax and other returns. It may be either a Social Security Number or an Employer Identification Number.

Unique entity identifier (UEI) has the meaning provided in the clause at FAR 52.204-91, Contractor Identification, of this solicitation.

(b) Unique entity identifier (UEI).

(1) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "Unique Entity Identifier" followed by the UEI that identifies the Offeror's name and address exactly as stated in the offer. The Offeror shall also enter its EFT indicator, if applicable.

(2) If the Offeror does not have a UEI, it shall go to https://www.sam.gov to obtain one. The Government will independently validate the existence and uniqueness of the Offeror before assigning a UEI.

(c) . The Offeror shall provide with its offer the following information that is necessary to comply with debt collection Taxpayer identification requirements of 31 U.S.C. 7701(c) and 3325(d); reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M; and the implementing IRS regulations:

(1) Taxpayer identification number (TIN)

TIN: ;____

TIN has been applied for; or

TIN is not required because:

Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;

Offeror is an agency or instrumentality of a foreign government; or

Offeror is an agency or instrumentality of the Federal Government.

(2) Type of organization.

Sole proprietorship;

Partnership;

Corporate entity (not tax-exempt);

Corporate entity (tax-exempt);

Government entity (Federal, State, or local);

Foreign government;

International organization per 26 CFR 1.6049-4; or

Other.

(3) Common parent.

Offeror is not owned or controlled by a common parent as defined in paragraph (a) of this provision; or

Name and TIN of common parent:

Name: ____

TIN: ____

(4) The TIN provided in paragraph (c)(1) of this provision may be matched with IRS records to verify the accuracy of the Offeror's TIN. The Government may use the TIN to collect and report on any delinquent amounts arising out of the Offeror's relationship with the Government (31 U.S.

C. 7701(c)(3)).

(d) Commercial and Government Entity (CAGE) code.

(1) The Offeror shall provide its CAGE code with its offer with its name and location address or otherwise include it prominently in its offer. The CAGE code shall be for that name and location address. Insert the word "CAGE" before the code. The Offeror may obtain a CAGE code as indicated in the following table.

If the Offeror is… Then…

Located in the United States or its outlying areas Submit a request to the DLA CAGE Branch via https://cage.dla.mil

Located outside the United States and its outlying areas and its country is a member of the North Atlantic Treaty Organization (NATO) or a sponsored nation

Contact the appropriate National Codification Bureau ( https://www.

nato.int/structur/ac/135/about/contacts)

Located outside the United States and its outlying areas and its country is not a member of NATO or a sponsored nation

Contact the NATO Support and Procurement Agency (NSPA) ( https://eportal.nspa.nato.int /AC135Public/scage/CageList.aspx)

(2) The Offeror shall provide the CAGE code and legal business name (Do not use a "doing business as" name) for-

(i) Its immediate owner(s), if any;

(ii) Its highest-level owner, if any; and

(iii) Any predecessor(s), or predecessor of an Offeror's predecessor, that held a Federal contract or grant within the last three years.

Owner Type CAGE Code Legal Business Name

Immediate owner ____ ____

Highest-level owner ____ ____

Predecessor* ____ ____

* Predecessor CAGE code may be marked "Unknown."

(3) If the Offeror has more than one immediate owner (such as a joint venture), give the information for each owner (or joint venture participant).

If the Offeror has more than one predecessor, provide information for each predecessor in reverse chronological order.

(End of provision)

52.204-91Contractor Identification. (Deviation 2026-O0038)Feb 2026

52.209-6Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (Deviation 2026-O0038)Feb 2026

52.209-9Updates of Publicly Available Information Regarding Responsibility Matters. (Deviation 2026-O0038) Feb 2026

52.209-10Prohibition on Contracting With Inverted Domestic Corporations. (Deviation 2026-O0038)Feb 2026

52.210-1Market Research. (Deviation 2026-O0038)Feb 2026

52.215-2Audit and Records-Negotiation. (Deviation 2026-O0038)Feb 2026

52.215-8Order of Precedence-Uniform Contract Format. (Deviation 2026-O0038)Feb 2026

52.216-1Type of Contract. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

Type of Contract (Feb 2026) (Deviation 2026-O0038)

The Government contemplates award of a resulting from this solicitation.Firm Fixed Price (FFP) Design-Bid-Build Construction Contract

(End of provision)

52.217-4Evaluation of Options Exercised at Time of Contract Award. (Deviation 2026-O0038)Feb 2026

52.217-5Evaluation of Options. (Deviation 2026-O0038)Feb 2026

52.219-4Notice of Price Evaluation Preference for HUBZone Small Business Concerns. (Deviation 2026- O0038)Feb 2026 hereby reads as follows:

NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS CONCERNS (FEB 2026) (DEVIATION 2026- O0038)

Evaluation preference.(a)

Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except-(1)

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(b) . A HUBZone small business concern may choose to waive the evaluation preference. If the concern waives Waiver of evaluation preference the preference, the factor will be added to its offer for evaluation purposes.

Offeror chooses to waive the evaluation preference.

(c) A HUBZone joint venture agrees that, in the performance of the contract, at least 40 percent of the aggregate work performed by Joint venture.

the joint venture shall be completed by the HUBZone small business parties to the joint venture. Work performed by the HUBZone small business parties to the joint venture must be more than administrative functions.

(End of provision)

52.219-8Utilization of Small Business Concerns. (Deviation 2026-O0038)Feb 2026

52.219-9Small Business Subcontracting Plan. (Deviation 2026-O0038) (Alternate II)Feb 2026Alternate IIFeb

52.219-16Liquidated Damages-Subcontracting Plan. (Deviation 2026-O0038)Feb 2026

52.219-28Postaward Small Business Program Rerepresentation. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

POSTAWARD SMALL BUSINESS PROGRAM REREPRESENTATION (FEB 2026) (DEVIATION 2026-O0038)

(a) . As used in this clause-Definitions

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(2) , as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, Affiliates or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was a small business concern, a small disadvantaged business concern, or a joint venture that was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(d) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition-

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation(s) required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting officer in writing within the timeframes specified in paragraph (b) of this clause, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it is, is not a small business concern under NAICS Code assigned to contract number.____ ____

(2) [ .] The Contractor represents Complete only if the Contractor represented itself as a small business concern in paragraph (g)(1) of this clause that it is, is not, a small disadvantaged business concern as defined in .13 CFR 124.1001

(3) . The Contractor represents that it is, is not a Women-owned small business (WOSB) joint venture eligible under the WOSB Program joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [ The Contractor shall enter the name and unique entity ____ identifier of each party to the joint venture: __.]

(4) . The Contractor represents that it is, is not a joint Economically disadvantaged women-owned small business (EDWOSB) joint venture venture that complies with the requirements of 13 CFR 127.506(a) through (c). [ The Contractor shall enter the name and unique entity identifier ____ of each party to the joint venture: __ .]

(5) . The Contractor represents that it Service-disabled veteran-owned small business (SDVOSB) joint venture eligible under the SDVOSB Program is, is not an SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402. [ The ____ Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(6) [ ] The HUBZone joint venture eligible under the HUBZone Program. Complete only if the offeror is a HUBZone small business concern.

offeror represents, as part of its offer, that It is, is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [ The Contractor shall enter the name and unique entity identifier of each party to the joint venture: .] Each HUBZone small business ____ concern participating in the HUBZone joint venture must be certified as a HUBZone concern. [ Contractor to sign and date and insert authorized ____ signer's name and title.]

(End of clause)

52.222-3Convict Labor. (Deviation 2026-O0038)Feb 2026

52.222-5Construction Wage Rate Requirements-Secondary Site of the Work. (Deviation 2026-O0038)Feb 2026

52.222-6Construction Wage Rate Requirements. (Deviation 2026-O0038)Feb 2026

52.222-7Withholding of Funds. (Deviation 2026-O0038)Feb 2026

52.222-8Payrolls and Basic Records. (Deviation 2026-O0038)Feb 2026

52.222-10Compliance with Copeland Act Requirements. (Deviation 2026-O0038)Feb 2026

52.222-11Subcontracts (Labor Standards). (Deviation 2026-O0038)Feb 2026

52.222-14Disputes Concerning Labor Standards. (Deviation 2026-O0038)Feb 2026

52.222-33Notice of Requirement for Project Labor Agreement. (Deviation 2026-O0038)Feb 2026

52.222-34Project Labor Agreement. (Deviation 2026-O0038)Feb 2026

52.222-35Equal Opportunity for Veterans. (Deviation 2026-O0038)Feb 2026

52.222-36Equal Opportunity for Workers with Disabilities. (Deviation 2026-O0038)Feb 2026

52.222-37Employment Reports on Veterans. (Deviation 2026-O0038)Feb 2026

52.222-40Notification of Employee Rights Under the National Labor Relations Act. (Deviation 2026-O0038) Feb 2026

52.222-50Combating Trafficking in Persons. (Deviation 2026-O0038)Feb 2026

52.222-54Employment Eligibility Verification. (Deviation 2026-O0038)Feb 2026

52.222-55Minimum Wages for Contractor Workers Under Executive Order 14026. (Deviation 2026-O0038)Feb

52.222-62Paid Sick Leave Under Executive Order 13706. (Deviation 2026-O0038)Feb 2026

52.223-1Biobased Product Certification. (Deviation 2026-O0038)Feb 2026

52.223-2Reporting of Biobased Products Under Service and Construction Contracts. (Deviation 2026-O0038) Feb 2026

52.223-3Hazardous Material Identification and Safety Data. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

HAZARDOUS MATERIAL IDENTIFICATION AND SAFETY DATA (FEB 2026) (DEVIATION 2026-O0038)

(a) , as used in this clause, includes any material defined as hazardous under the latest version of Federal Standard No. 313 Hazardous material (including revisions adopted during the term of the contract).

(b) The Offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract. The hazardous material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number. This information shall also be included on the Safety Data Sheet submitted under this contract.

Material (If none, insert )None Identification No.

(c) This list must be updated during performance of the contract whenever the Contractor determines that any other material to be delivered under this contract is hazardous.

(d) The apparently successful offeror agrees to submit, for each item as required prior to award, a Safety Data Sheet, meeting the requirements of 29 CFR 1910.1200(g) and the latest version of Federal Standard No. 313, for all hazardous material identified in paragraph (b) of this clause. Data shall be submitted in accordance with Federal Standard No. 313, whether or not the apparently successful offeror is the actual manufacturer of these items. Failure to submit the Safety Data Sheet prior to award may result in the apparently successful offeror being considered nonresponsible and ineligible for award.

(e) If, after award, there is a change in the composition of the item(s) or a revision to Federal Standard No. 313, which renders incomplete or inaccurate the data submitted under paragraph (d) of this clause, the Contractor shall promptly notify the Contracting Officer and resubmit the data.

(f) Neither the requirements of this clause nor any act or failure to act by the Government shall relieve the Contractor of any responsibility or liability for the safety of Government, Contractor, or subcontractor personnel or property.

(g) Nothing contained in this clause shall relieve the Contractor from complying with applicable Federal, State, and local laws, codes, ordinances, and regulations (including the obtaining of licenses and permits) in connection with hazardous material.

(h) The Government's rights in data furnished under this contract with respect to hazardous material are as follows:

(1) To use, duplicate and disclose any data to which this clause is applicable. The purposes of this right are to-

(i) Apprise personnel of the hazards to which they may be exposed in using, handling, packaging, transporting, or disposing of hazardous materials;

(ii) Obtain medical treatment for those affected by the material; and

(iii) Have others use, duplicate, and disclose the data for the Government for these purposes.

(2) To use, duplicate, and disclose data furnished under this clause, in accordance with subparagraph (h)(1) of this clause, in precedence over any other clause of this contract providing for rights in data.

(3) The Government is not precluded from using similar or identical data acquired from other sources.

(End of clause)

52.223-11Ozone-Depleting Substances. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

OZONE-DEPLETING SUBSTANCES (FEB 2026) (DEVIATION 2026-O0038)

(a) . As used in this clause-Definition

Ozone-depleting substance means any substance the Environmental Protection Agency designates in 40 CFR part 82 as-

(1) Class I, including, but not limited to, chlorofluorocarbons, halons, carbon tetrachloride, and methyl chloroform; or

(2) Class II, including, but not limited to, hydrochlorofluorocarbons.

(b) Requirement. In accordance with 40 CFR 82.84(a)(5), the Contractor shall label products that contain or are manufactured with ozone-depleting substances in the manner and to the extent required by 42 U.S.C. 7671j(b), (c), (d), and (e) and 40 CFR part 82, subpart E, as follows:

Warning: Contains (or manufactured with, if applicable) * , a substance(s) which harm(s) public health and environment by destroying ozone ____ in the upper atmosphere.

* The Contractor shall insert the name of the substance(s).

(End of clause)

52.223-23Sustainable Products. (Deviation 2026-O0038)Feb 2026

52.225-11Buy American-Construction Materials under Trade Agreements. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

BUY AMERICAN-CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (FEB 2026) (DEVIATION 2026-O0038)

(a) . As used in this clause-Definitions

Caribbean Basin country construction material means a construction material that-

(1) Is wholly the growth, product, or manufacture of a Caribbean Basin country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

Commercially available off-the-shelf (COTS) item-

(1) Means any item of supply (including construction material) that is-

(i) A commercial product (as defined in paragraph (1) of the definition of "commercial product" at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means-

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain.

The list of critical components is at FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Designated country means any of the following countries:

(1) A World Trade Organization Government Procurement Agreement (WTO GPA) country (Armenia, Aruba, Australia, Austria, Belgium, Bulgaria, Canada, Croatia, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland, Israel, Italy, Japan, Korea (Republic of), Latvia, Liechtenstein, Lithuania, Luxembourg, Malta, Moldova, Montenegro, Netherlands, New Zealand, North Macedonia, Norway, Poland, Portugal, Romania, Singapore, Slovak Republic, Slovenia, Spain, Sweden, Switzerland, Taiwan, Ukraine, or United Kingdom);

(2) A Free Trade Agreement (FTA) country (Australia, Bahrain, Chile, Colombia, Costa Rica, Dominican Republic, El Salvador, Guatemala, Honduras, Korea (Republic of), Mexico, Morocco, Nicaragua, Oman, Panama, Peru, or Singapore);

(3) A least developed country (Afghanistan, Angola, Bangladesh, Benin, Bhutan, Burkina Faso, Burundi, Cambodia, Central African Republic, Chad, Comoros, Democratic Republic of Congo, Djibouti, Equatorial Guinea, Eritrea, Ethiopia, Gambia, Guinea, Guinea-Bissau, Haiti, Kiribati, Laos, Lesotho, Liberia, Madagascar, Malawi, Mali, Mauritania, Mozambique, Nepal, Niger, Rwanda, Samoa, Sao Tome and Principe, Senegal, Sierra Leone, Solomon Islands, Somalia, South Sudan, Tanzania, Timor-Leste, Togo, Tuvalu, Uganda, Vanuatu, Yemen, or Zambia); or

(4) A Caribbean Basin country (Antigua and Barbuda, Aruba, Bahamas, Barbados, Belize, Bonaire, British Virgin Islands, Curacao, Dominica, Grenada, Guyana, Haiti, Jamaica, Montserrat, Saba, St. Kitts and Nevis, St. Lucia, St. Vincent and the Grenadines, Sint Eustatius, Sint Maarten, or Trinidad and Tobago).

Designated country construction material means a construction material that is a WTO GPA country construction material, an FTA country construction material, a least developed country construction material, or a Caribbean Basin country construction material.

Domestic construction material means-

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if-

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic.

Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material.

The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign.