S02 Liquidated Damages 833CM3030_CNNC FCA Corrections CONS.pdf
PDF 89 KB Posted
- Solicitation number
- 36C78626R0058
About this file
This document is a Liquidated Damages Formulation for a construction contract at Camp Nelson National Cemetery (833-030) to correct FCA deficiencies. The estimated daily liquidated damages total $1,375.00 per calendar day of delay, calculated based on civilian rates effective January 1, 2026. The daily amount comprises costs for an NCA Contracting Officer (GS-13) at $75 for 1 hour, a Design & Construction Service Project Manager (GS-14) at $100 for 1 hour, and a Government-Retained Inspector (GSA) at $150 for 8 hours. The contractor is obligated to pay this amount for each calendar day required to complete construction work past the scheduled completion date. The liquidated damages formulation is compensatory in nature and established in accordance with Federal Acquisition Regulation 36.206, though the Government retains the right to pursue actual damages that are distinguishable and separate from the liquidated damages amount if the contractor fails to complete work within the specified timeframe.
View the file
Other files
Show all 28
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
LIQUIDATED DAMAGES FORMULATION
Camp Nelson National Cemetery 833-030, Correct FCA Deficiencies
1. Estimated liquidated damages for NCA Contracting, Design & Construction Service (DCS), and Government-Retained Inspector are as follows. Civilian rates based on General Schedule Locality Pay Tables effective 01 Jan 2026.
Classification Grade Rate Hours Total NCA Contracting Officer GS-13 $75 1 $75 Legal Officer NA NA NA NA DCS Project Manager GS-14 $100 1 $100 Govt Retained Inspector GSA $150 8 $1200 Total Daily LD Amount $1,375.00
2. The Contractor shall pay liquidated damages to the Government in the amount of $1,375.00 for each calendar day of delay until the work is completed or accepted. Numbers derived from historical trends associated with time required to perform additional contract administration. The purpose of Liquidated Damages is compensatory only. The Government retains the right to seek actual damages so far as they are distinguishable and separate due to Contractor not completing the work within the time specified in the contract.
3. Liquidated Damages as detailed above are in accordance with Federal Acquisition Regulation
36.206 and will be assessed for each calendar day required to complete the construction work on this project past the scheduled completion date.
File details come from the government source that posted it. Updated .