N4008526R00040014 SF 30.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Block 14 (Description of Amendment/Modification): N40085-26-R-0004, Design-Bid-Build (DBB), P1102 WEAPONS MAGAZINE &

ORDNANCE OPERATIONS FACILITY, NAVAL SUBMARINE BASE, NEW LONDON, CONNECTICUT

SECTION SF30 BLOCK 14 CONTINUATION PAGE

ALL CORRESPONDENCE REGARDING THIS SOLICITATION SHALL BE DIRECTED VIA EMAIL TO ANGIE CLIFTON AT ANGELA.J.

CLIFTON2.CIV@US.NAVY.MIL.

This amendment is issued to incorporate the following:

1. Provide continuation sheet for Specifications (enclosed)

2. Provide Updated Commencement. Prosecution, and Completion of Work (enclosed) 3, Provide Updated Specifications (attached separately)

4. Update Clauses and Provisions (enclosed)

5. Provide additional PPI responses (enclosed)

Section 00 70 00 - Conditions of the Contract

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Full Text

52.211-12 Liquidated Damages-Construction. (Tailored) (Sep 2000)

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of for each calendar day of delay for Milestone 1, for each calendar day of delay for Milestone 2,$29,752.70 $66,607.65 for each calendar day of delay for Milestone 3, for each calendar day of delay for Milestone 4, for each calendar$31,766.73 $56,416.32 $42,486.36 day of delay for Milestone 5, and for each calendar day of delay for Milestone 6 until the work is completed or accepted.$29,752.70

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Please reference chart below. Liquidated Damages:

Number of Days Liquidated Damages

Milestone 1 694 calendar days $29,752.70 per calendar day

Milestone 2 310 calendar days $66,607.65 per calendar day

Milestone 3 650 calendar days $31,766.73 per calendar day

N4008526R00040014

Milestone 4 366 calendar days $56,416.32 per calendar day

Milestone 5 486 calendar days $42,486.36 per calendar day

Milestone 6 694 calendar days $29,752.70 per calendar day

(End of clause)

The following clauses were deleted:

FAR Clauses Incorporated by Full Text

52.211-12 Liquidated Damages-Construction. (Tailored) (Sep 2000)

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of for each calendar day of delay for Milestone 1, for each calendar day of delay for Milestone 2,$31,766.73 $66,607.65 for each calendar day of delay for Milestone 3, for each calendar day of delay for Milestone 4, for each calendar$31,766.73 $56,416.32 $72,450.43 day of delay for Milestone 5, and for each calendar day of delay for Milestone 6 until the work is completed or accepted.$31,766.73

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Please reference chart below. Liquidated Damages:

Number of Days Liquidated Damages

Milestone 1 650 calendar days $31,766.73 per calendar day

Milestone 2 310 calendar days $66,607.65 per calendar day

Milestone 3 650 calendar days $31,766.73 per calendar day

Milestone 4 366 calendar days $56,416.32 per calendar day

Milestone 5 285 calendar days $72,450.43 per calendar day

Milestone 6 650 calendar days $31,766.73 per calendar day

(End of clause)

Section 00 73 00 - Supplementary Conditions

The following attachments were added:

Amend 0014 Continuation Page Amend 0014 Spec 1667770

SECTION SF30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

The following have been added by full text:

AMENDMENT 0014

This amendment is issued to incorporate the following:

1. Provide continuation sheet for specifications (enclosed)

2. Provide Updated Commencement, Prosecution, and Completion of Work (enclosed)

3. Provide Updated Specifications (attached separately)

4. Update Clauses and Provisions (enclosed)

5. Provide additional PPI Responses (enclosed)

1. Provide continuation sheet for Specifications (enclosed)

SPECIFICATIONS:

PROJECT TABLE OF CONTENTS

REPLACE the following sections with the attached sections to accompany this Amendment.

01 14 00 WORK RESTRICTIONS

SECTION 01 14 00 WORK RESTRICTIONS

1.3 Special Scheduling Requirements

DELETE text “(c) complete the entire work ready for use not later than 1,737 calendar days” and REPLACE with text “(c) complete the entire work ready for use not later than 1,982 calendar days.”

Milestone 1 – Phase 1A: DELETE “650 calendar days” and REPLACE with: “694 calendar days” Milestone 5 – Phase 3: DELETE “285 calendar days” and REPLACE with: “486 calendar days” Milestone 6 – Work in Areas D, E, F, G, H, I, J & K: DELETE “650 calendar days” and REPLACE with: “694 calendar days”

-- End of Amendment --

2. Provide Updated Commencement, Prosecution, and Completion of Work (enclosed)

COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

The Contractor shall be required to (a) commence work under this contract within fifteen (15) calendar days after the date the Contractor receives notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 1,982 calendar days. The time stated for completion shall include final cleanup of the premises.

*The calendar days to complete this contract includes the 15 calendar days for submission and approval of performance and payment bonds after the contract award.

3. Provide Updated Specifications (attached separately)

4. Update Clauses and Provisions (enclosed)

5. Provide Updated and additional PPI Responses (enclosed)

PPI # Page Section Paragraph Question Response

Can the Milestone 1 construction duration be extended to provide sufficient time to complete OPS building?

Duration of Milestone 1 revised per amendment 0014.

Can the Milestone 5 construction duration be extended to provide sufficient time to complete the six CLWS earth-covered magazines?

Duration of Milestone 5 revised per amendment 0014.

9324 VIRGINIA AVENUE, NORFOLK VA 23511-0395

NORFOLK, VA 23511-0395

UNITED STATES

Angela Clifton, Email: angela.j.clifton2.civ@us.navy.mil Telephone: 757-341-0692 AdminBy:

SCD: PAS: