Amend 0014 Spec 1667770.pdf

P-1102 Weapons Magazine & Ordnance Operations Facility 1667770 29 September 2026

SECTION 01 14 00

WORK RESTRICTIONS

11/22

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. DEPARTMENT OF DEFENSE (DOD)

DESR 6055.09, Edition 1 (2019) Defense Explosive Safety Regulation 6055.09, Edition 1

NEW LONDON INSTRUCTION

SUBASE 8020.IG SUBASE NEW LONDON INSTRUCTION 8020.IG

1.2 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel

Personnel List

Phasing Plan ; G

1.3 SPECIAL SCHEDULING REQUIREMENTS

All ground disturbance and work in the wetlands will be restricted for 90 days after award in order to obtain both the NPDES and wetlands permit approvals.

All work must be phased in such a way as to minimize impacts to installation weapons handling operations. The new Operations must be constructed, and all staff relocated from the existing Operations Building (B524) into the new operations Building as early as possible in the construction phasing. Physical security requirements (fencing, cameras, intrusion detection/access control, etc.) for the weapons compound (magazine area/compound) and all existing magazines still in operation must be maintained or provided by the contractor. During all phases of construction, the Government shall maintain access control to all magazines that are still in operation; the contractor shall maintain separate construction entrances independent from the weapons compound (magazine area/compound) secured entry. Prior to the start of construction and within 15 days of contract award, provide a Phasing Plan for review and approval by the Contracting Officer and the Weapons Officer. A preliminary Phasing Plan has been provided on the Civil drawings to help

SECTION 01 14 00 Page 1 inform the contractor of phasing requirements.

The Construction Phasing drawings indicate which magazines are to be demolished during the respective construction phasing. The other magazines not indicated for demolition must remain operational during the corresponding construction phase. Each phase has a separate milestone and activity completion date in the schedule.

The Contractor shall be required to (a) commence work under this contract within fifteen (15) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 1,982 calendar days. The time stated for completion shall include final cleanup of the site

The calendar days for the milestones are as follows:

Milestone # Title Time for Completion

Milestone 1 Phase 1A 694 calendar days

Milestone 2 Phase 1B 310 calendar days

Milestone 3 Phase 1C 96 calendar days

Milestone 4 Phase 2 366 calendar days

Milestone 5 Phase 3 486 calendar days

Milestone 6 Work in Areas D, E, F, G, H, I, J & K

694 calendar days

The milestones are described as follows:

Milestone 1 (Phase 1A):

No construction activities or demolition associated with the existing magazines in Phase 1A can be performed until government receives Request to Terminate Existing Site Approval from NOSSA. Please allow 14 days for government to receive approval.

Work includes but is not limited to provide temporary construction access and security fencing to ensure a secure perimeter around existing magazines to remain in place during Phase 1 operations (Magazines A94-A97, A100-A104, A105-A109, A113 and A114). Demolition of existing magazines A98, A99, A110 and A111 and including associated pavements and utilities. Install temporary sediment Traps 1 and 3.

Rock blasting and excavation for Ordnance Operations Facility and near Magazines A98, A99, A110 and A111. Construct north and south wetlands per wetland mitigation drawing package east of Magazines A105 through A111. Construct permanent storm water Facility A East of EXST-001 (A114). Maintain treatment chambers offline until final site stabilization. Ordnance Operations Facility construction including site preparation, drainage infrastructure, utility installation, access road, and parking lot. Convert temporary sediment Trap 1 to permanent storm water facility. Maintain treatment chambers offline until final site stabilization.

Milestone 2 (Phase 1B): Work includes but is not limited to install

SECTION 01 14 00 Page 2 temporary sediment Trap 2. Reroute and demolish existing utilities necessary to construct Type H magazine. Site preparation, utility installation, and construct Type H magazine. Convert temporary sediment Trap 2 to permanent storm water facility. Maintain treatment chambers offline until final site stabilization.

Milestone 3 (Phase 1C): Work includes but is not limited to demolition of existing Building 524, utilities and pavements.

Milestone 4 (Phase 2):

No construction activities or demolition associated with the existing magazines in Phase 2 can be performed until government receives Request to Terminate Existing Site Approval from NOSSA. Please allow 14 days for government to receive approval.

Work includes but is not limited to maintain temporary construction access and provide temporary security fencing to ensure a secure perimeter around existing magazines to remain in place during Phase 2 operations (A100-A104, A105-A109, A113, A114, and Type H-001).

Demolish pavement west of EXT-002 (A113), install temporary sediment Trap 4. Demolish existing magazines A94, A95, A96 and A97 including associated pavements and utilities. Rock blasting and excavation for Type G magazines near magazines A94, A95, A96 and A97. Construct Type G magazines (Type G-001 and Type G-002) adjacent to EXT-002 (A113), including associated pavements and utilities. Replace EXST-002 ground ring during pavement demolition and replacement associated with Type G magazine construction. Site preparation, including utility installation and construction of Sentry Building. Installation of power and telecommunications equipment and intrusion detection system in Sentry Building.

Milestone 5 (Phase 3):

No construction activities or demolition associated with the existing magazines in Phase 3 can be performed until government receives Request to Terminate Existing Site Approval from NOSSA. Please allow 14 days for government to receive approval.

Work includes but is not limited to provide temporary construction access and security fencing to ensure a secure perimeter around existing magazines to remain in place during Phase 3 operations (A113, A114, Type H-001, Type G-001, and Type G-002). Demolish existing pavement East of Magazine A105 and install temporary sediment Trap 5.

Demolish existing magazines A100 to A104 and A105 to A109 including associated pavements and utilities. Construct six (6) CLWS magazines including utilities and associated pavement. Ensure Type H magazine is complete and operational and EXT-001 is empty prior to demolition and replacement of EXST-001 concrete apron. Replace EXT-001 ground ring during pavement demolition and replacement. Demolish existing Building 393 including associated utilities and pavements. Ensure power equipment and intrusion detection system have been relocated and are operational prior to demolition of Building 393.

Milestone 6 (Remainder of Work): The remainder of work not listed in the previous milestones including but not limited to work in Areas D, E, F, G, H, I, J, and K located on the Site Drawing Sheet C-003. Work for milestone 6 is be performed concurrently with Milestone 1.

SECTION 01 14 00 Page 3

1.3.1 Termination of Existing Magazine Operations Between Construction Phases

No construction activities or demolition associated with the existing magazines in Phases 1A, 2, and 3 can be performed until government receives Request to Terminate Existing Site Approval from NOSSA. Please allow 14 days for government to receive approval for each of the aforementioned Phases.

1.3.2 Goose Run Golf Course

The Contractor will be working within a portion of Goose Rune Golf Course. Trenching and installation of new underground utilities are to be conducted within the following time period:

a. 01 November through 30 March

Do not enter the golf course grounds without prior approval of the Contracting Officer and golf course management. All work within the golf course will require a minimum of 30 calendar day advance notice and can not proceed without written authorization from the Contracting Officer and golf course management.

1.3.3 Procedure for Blasting During Construction

Blasting operations are to be conducted in accordance with SUBASE 8020.IG and specification 31 23 06.00 BLASTING - SURFACE.

1.3.4 Time of Year Restriction on Tree Clearing and Blasting

Tree clearing and rock blasting will not be permitted during nesting times of sensitive and endangered species. Tree clearing restrictions is between April 01 and October 31, and blasting restrictions is between April 01 and October 31, due to the presence of habitat for the northern long eared and tricolored bat.

All work associated with the removal or disturbance of vegetation (tree removal, pruning, etc.) is prohibited between April 01 and October 31 of any given year. All timber removed from the project site shall become the property of the Contractor. The Contractor shall reimburse the Government for the value of the timber. The Contractor shall submit payment to the Contracting Officer by cashier's or certified check in the amount of $988.00 made payable to the U.S. Treasury. Payment shall be made no less than five (5) days prior to the start of land clearing operations. See the Temporary Environmental Control specifications 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS and 31 11 00 CLEARING AND GRUBBING, paragraph 3.3.1 for additional requirements.

1.3.5 Wetland Permitting

The contractor is responsible for complying with the wetland permit as NAVFAC's representative. No work within the wetland limits is permitted (including laydown) until the wetland permit is received. A copy of approved permit is to be submitted tot he Public Works New London Environment (PW NLON EV) Division.

The contractor is responsible for completing and submitting all required monitoring and inspection reports. Any natural resource damage claim resulting from construction is the sole responsibility of the construction

SECTION 01 14 00 Page 4 contractor at no additional cost to the government. A copy of any monitoring or inspection reports require by this permit are to be submitted to the Public Works New London Environment (PW NLON EV) Division.

1.3.6 Ribbon Snake Mitigation Plan

The limits of disturbance extend into known habitat of State Protected Species. The contractor serves as the environmental monitor for this effort to ensure that the measures described in the Eastern Ribbon Snake Construction Impact Protection Plan are implemented properly. All work must be completed (and scheduled) in accordance with the contractor provided Ribbon Snake Mitigation Plan. Schedule an meeting with Public Works New London Environment (PW NLON EV) Division a minimum of 21 calendar days in advance of executing the mitigation plan to review the plan and discuss any questions/concerns that might hinder or threaten full plan compliance. The Construction Impact Protection Plan is included as an attachment to these specifications.

1.4 CONTRACTOR ACCESS AND USE OF PREMISES

1.4.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear appropriate personal protective equipment (PPE) in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Ensure all Contractor equipment, include delivery vehicles, are clearly identified with their company name.

Occupants of any construction trailers near the job site must be directly involved with the project construction. Administrative personnel are not permitted in job site trailers and must be located outside of all installation inhabited building distance (IBD) arcs. Any windows utilized in construction trailers must meet the criteria of OP5 para 8 - 4.1.11.

Brake rooms must be outside the IBD as well.

1.4.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.4.1.2 Installation Access

Obtain access to Navy installations through participation in the Defense Biometrics Identification System (DBIDS). Requirements for Contractor employee registration, and transition for employees currently under Navy Commercial Access Control System (NCACS), are available at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/ .

No fees are associated with obtaining a DBIDS credential.

Participation in the DBIDS is not mandatory, and Contractor personnel may apply for One-Day Passes at the Base Visitor Control Office to access an installation.

SECTION 01 14 00 Page 5 https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS

1.4.1.2.1 Registration for DBIDS

Registration for DBIDS is available at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/ .

Procedure includes:

a. Present a letter or official award document (i.e. DD Form 1155 or SF 1442) from the Contracting Officer, that provides the purpose for access, to the base Visitor Control Center representative.

b. Present valid identification, such as a passport or Real ID Act-compliant state driver's license.

c. Provide completed SECNAV FORM 5512/1 to the base Visitor Control Center representative to obtain a background check. This form is available for download at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/ .

d. Upon successful completion of the background check, the Government will complete the DBIDS enrollment process, which includes Contractor employee photo, fingerprints, base restriction and several other assessments.

e. Upon successful completion of the enrollment process, the Contractor employee will be issued a DBIDS credential, and will be allowed to proceed to worksite.

1.4.1.2.2 DBIDS Eligibility Requirements

Throughout the length of the contract, the Contractor employee must continue to meet background screen standards. Periodic background screenings are conducted to verify continued DBIDS participation and installation access privileges. DBIDS access privileges will be immediately suspended or revoked if at any time a Contractor employee becomes ineligible.

An adjudication process may be initiated when a background screen failure results in disqualification from participation in the DBIDS, and Contractor employee does not agree with the reason for disqualification.

The Government is the final authority.

1.4.1.2.3 DBIDS Notification Requirements

a. Immediately report instances of lost or stolen badges to the Contracting Officer.

b. Immediately collect DBIDS credentials and notify the Contracting Officer in writing under the following circumstances:

(1) An employee has departed the company without having properly returned or surrendered their DBIDS credentials.

(2) There is a reasonable basis to conclude that an employee, or former employee, might pose a risk, compromise, or threat to the safety or security of the Installation or anyone therein.

1.4.1.2.4 One-Day Passes

Personnel applying for One-Day passes at the Base Visitor Control Office

SECTION 01 14 00 Page 6 are subject to daily mandatory vehicle inspection, and will have limited access to the installation. The Government is not responsible for any cost or lost time associated with obtaining daily passes or added vehicle inspections incurred by non-participants in the DBIDS.

1.4.1.3 NCACS Identification Badges and Installation Access

Application for and use of badges will be as directed. Obtain access to the installation by participating in the Navy Commercial Access Control System (NCACS), or by obtaining passes each day from the Base Pass and Identification Office. Costs for obtaining passes through the NCACS are the responsibility of the Contractor. One-day passes, issued through the Base Pass and Identification Office, will be furnished without charge.

Furnish a completed EMPLOYMENT ELIGIBILITY VERIFICATION (DHS FORM I-9) form for all personnel requesting badges. This form is available at http://www.uscis.gov/portal/site/uscis by searching or selecting Employment Verification (Form I-9). Immediately report instances of lost or stolen badges to the Contracting Officer.

a. NCACS Program: NCACS is a voluntary program in which Contractor personnel who enroll, and are approved, are subsequently granted access to the installation for a period up to one year, or the length of the contract, whichever is less, and are not required to obtain a new pass from the Base Pass and Identification Office for each visit.

The Government performs background screening and credentialing.

Throughout the year the Contractor employee will continue to meet background screening standards. Periodic background screenings are conducted to verify continued NCACS participation and installation access privileges. Under the NCACS program, no commercial vehicle inspection is required, other than for Random Anti-Terrorism Measures (RAM) or in the case of an elevation of Force Protection Conditions (FPCON). Information on costs and requirements to participate and enroll in NCACS is available at http://www.rapidgate.com or by calling 1-877-727-4342. Contractors should be aware that the costs incurred to obtain NCACS credentials, or costs related to any means of access to a Navy Installation, are not reimbursable. Any time invested, or price(s) paid, for obtaining NCACS credentials will not be compensated in any way or approved as a direct cost of any contract with the Department of the Navy.

b. One-Day Passes: Participation in the NCACS is not mandatory, and if the Contractor chooses to not participate, the Contractor's personnel will have to obtain daily passes, be subject to daily mandatory vehicle inspection, and will have limited access to the installation.

The Government will not be responsible for any cost or lost time associated with obtaining daily passes or added vehicle inspections incurred by non-participants in the NCACS.

The following documents will be required to be presented for base access:

a. Verified license

b. Passport

c. Birth Certificate with SSN card

1.4.1.4 Gate Information

Contractors/Commercial vehicles must use Commercial Gate 7 (CVIS) located

SECTION 01 14 00 Page 7 separately from main gate between the hours of 5:45am - 1:30pm, Monday through Friday. Closed weekends and holidays. Phone number: 860-694-4360

1.4.1.5 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.4.2 Working Hours

Regular working hours will consist of a 9 hour period, between 6:30 a.m.

and 4:30 p.m. Monday through Friday, excluding Government holidays.

1.4.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer.

1.4.4 Occupied and Existing Buildings

The Contractor shall be working in existing building and around existing buildings which are occupied. Do not enter the buildings without prior approval of the Contracting Officer.

The Government will remove and relocate other Government property in the areas of the buildings scheduled to receive work.

1.4.5 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in paragraph WORK OUTSIDE REGULAR HOURS.

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, and security systems are considered utility cutovers pursuant to the paragraph WORK OUTSIDE REGULAR HOURS.

d. Operation of Station Utilities: The Contractor must not operate nor disturb the setting of control devices in the station utilities system, including water, sewer, electrical, and steam services. The Government will operate the control devices as required for normal conduct of the work. The Contractor must notify the Contracting Officer giving reasonable advance notice when such operation is required.

SECTION 01 14 00 Page 8

e. Connection to Existing Sanitary Sewer Line: Provide positive verification that the existing line conveys sanitary sewer; verify line is not incorrectly connected to a storm drain. Obtain Installation's Sanitary Sewer Connection Permit 2 weeks prior to connection and in accordance with Section 33 30 00 SANITARY SEWERAGE.

1.5 SECURITY REQUIREMENTS

Contract Clause FAR 52.204-2 Security Requirements and Alternate II and the following apply:

Installation Security Requirements.

1.5.1 Personnel List

Submit for approval, at least 15 days prior to the desired date of entry, an original alphabetical list of personnel who require entry into Government property to perform work on the project. Furnish for each person:

a. Name

b. Citizenship

c. Company employee works for

"I hereby certify that all personnel on this list are either born U.S.

citizens, naturalized U.S. citizens with the naturalization number shown."

Signature/Firm Name

1.5.1.1 Citizenship Requirements

Aliens are not allowed on the project site. Work under this contract is restricted to U.S. citizens.

1.6 EXPLOSIVE SAFETY TRAINING

Contractor personnel shall participate in explosive safety training set forth on the requirements of DESR 6055.09, Edition 1 , "Ammunition and Explosives Safety Standards". Coordinate with Naval Submarine Base New London on training requirements and scheduling.

Existing ordnance magazines will remain in service during construction.

Construction activities shall not impact ordnance operations.

1.6.1 Hazards of Electromagnetic Radiation to Ordnance (HERO)

All contractor personnel must adhere to HERO requirements associated with the use of mobile and hand-held transmitters. Coordinate with Naval Submarine Base New London safety personnel on training and guidance.

1.6.2 Explosive Safety Requirements

All work must be conducted in accordance with Navy Explosive Safety Requirements for working within explosive arcs and conducting blast operations. No explosives may be brought and stored on the Installation without the approval of the Installation Explosive Safety Officer.

SECTION 01 14 00 Page 9

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

SECTION 01 14 00 Page 10