N4008526R0005 Amendment 0009.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Block 14 (Description of Amendment/Modification): SOLICITATION NUMBER N40085-26-R-0005, DESIGN-BID-BUILD (DBB) P1112 B72

RESILIENCY IMPROVEMENTS, PORTSMOUTH NAVAL SHIPYARD (PNSY), KITTERY, MAINE

The proposal due date of 16 June 2026 NLT 2:00 PM EDT remains unchanged.

The Amendment is issued to incorporate the following:

1. Provide revisions to FAR 52.211-12 and include FAR 52.222-90.

Section 00 70 00 - Conditions of the Contract

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Reference

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

52.222-90 Addressing DEI Discrimination by Federal Contractors. (Deviation 2026-O0040, Revision 1)

Apr 2026

The following clauses were modified:

52.211-12Liquidated Damages-Construction.Sep 2000 hereby reads as follows:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amounts listed in the table below for each calendar day of delay until the work is completed or accepted.

Milestone Time for Completion Liquidated Damages

Milestone A (Temp ASW, CWIS, Accessory Structure, B242)

Start Date: Contract Award

Completion Date: 365 calendar days from Contract Award

$593.69

Milestone B (Discharge between B238 and B178)

Start Date: Contract Award

Completion Date: 365 calendar days from Contract Award

$126.34

Milestone C (Outfall and above ground piping)

Start Date: Contract Award + 730 calendar days

Completion Date: 900 calendar days from Contract Award

$63.17

N4008526R00050009

Milestone D (Remainder of all other work)

Start Date: Contract Award

Completion Date: 900 calendar days from Contract Award

$3,694.81

*Milestones in accordance with Attachment "GC100A_Milestones and Coordination Requirements_20260528" posted to SAM.gov and included via Amendment 0008.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

N4008526R00050009

9324 VIRGINIA AVENUE, NORFOLK VA 23511-0395

NORFOLK, VA 23511-0395

UNITED STATES

James Godwin, Email: james.a.godwin41.civ@us.navy.mil Telephone: 7573411999 AdminBy:

SCD: PAS: