W912GB-17-R-0020-00011.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Various Base Improvements Mihail Kogalniceanu, Romania

1. CONTRACT ID CODE PAGE OF PAGES

1 95

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 22-Aug-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912GB-17-R-0020

X 9B. DATED (SEE ITEM 11)

09-May-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

22-Aug-2017

CODE

CONTRACTING DIVISION

US ARMY CORPS OF ENGINEERS

KONRAD ADENAUER RING 39

D-65187 WIESBADEN GERMANY

WIESBADEN 65187

W912GB 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912GB-17-R-0020

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SECTION 00 00 00 - PROCUREMENT AND CONTRACTING REQUIRMENTS

SUMMARY OF CHANGES

SECTION 00 00 00 - PROCUREMENT AND CONTRACTING REQUIRMENTS

The required response date/time has changed from 28-Aug-2017 04:00 PM to 05-Sep-

2017 04:00 PM.

The required performance has changed from Project: Various Base Improvements Mihail Kogalniceanu (MK) Air Base, Romania1. Construction Magnitude is between $25,000,000.00 to $100,000,000.002. NAICS Code is 236220 -- Commercial and Institutional Building Construction3. Volume I (Technical) Revised Proposals are due on 28 August 2017 by 16:00 Hours Central European Summer Time (CEST). Volume II (Price) Revised Proposals are due on 28 August 2017 by 16:00 Hours Central European Summer Time (CEST). Proposals shall be received at U.S. Army Corps of Engineers – Europe District, Contracting Division in accordance with solicitation.Contractors are required to submit all questions to Mr. Jefferey Ball via email at Jefferey.A.Ball@usace.army.mil and Ms. Kristina Morrow at kristina.morrow@usace.army.mil to Project: Various Base Improvements Mihail Kogalniceanu (MK) Air Base, Romania1. Construction Magnitude is between $25,000,000.00 to $100,000,000.002. NAICS Code is 236220 -- Commercial and Institutional Building Construction3. Volume I and Volume II Proposals are due on 05 September 2017 by 16:00 Hours Central European Summer Time (CEST). Proposals shall be received at U.S. Army Corps of Engineers – Europe District, Contracting Division in accordance with solicitation.Contractors are required to submit all questions to Mr. Jefferey Ball via email at Jefferey.A.Ball@usace.army.mil and Ms. Kristina Morrow at kristina.morrow@usace.army.mil.

The following have been deleted:

AMENDMENT 01

FOLLOW ON SITE VISIT

SITE VISIT PRE-PROPOSAL BRIEF

SECTION 00 01 10 - TABLE OF CONTENTS

The following have been modified:

TABLE OF CONTENTS

TABLE OF CONTENTS

(All Information Presented in this Table of Contents is Incorporated into this Solicitation)

SECTION TITLE

Section 00 00 00 Procurement and Contract Requirements

Section 00 01 10 Table of Contents

Section 00 10 00 Solicitation, Contract Line Item Number (CLIN) Schedule

Section 00 21 00 Instructions

Section 00 45 00 Representations and Certifications

Section 00 70 00 Conditions of the Contract

Section 00 71 00 Contracting Definitions

Section 00 72 00 General Conditions

Section 00 73 00 Supplementary Conditions

Section 01 00 00 General Requirements

Please Note as of Amendment 11 (Post Closing): Section 01 00 00 now includes SOW Revised 21 August 2017, FSC Explanation of Variances, and MI Explanation of Variances.

Department of the Army, Safety and Health Requirements Manual No. EM 385-1-1, November 2014.

(Available online at: http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1- 1.pdf OR http://www.usace.army.mil/SafetyandOccupationalHealth.aspx) Specifications

USACE Specifications

00 73 15 General Conditions (05-15) 00 73 15.15 Time Extension for Unusually Severe Weather 00 73 16.03 01 Special Conditions for Projects in Romania 01 00 15 Design After Award 01 32 01.00 10 Project Schedule 01 33 00 Submittal Procedures 01 35 26 Safety and Occupational Health Requirements (05-15) 01 35 26.10 Additional Saftey and Occupational Helath Requirements for Projects in the European

Union 01 45 01 USACE Quality Control 01 45 01.10 USACE Quality Control System (QCS) 01 78 00 Completion Procedures 01 78 23 Operation and Maintenance Data 02 41 00 Demolition and Deconstruction 02 82 14.00 10 Asbestos Hazard Control Activities EP 310-16a Construction Project Signs

Statement of Work (SOW) Attachments

Attachment A: Design Analysis Multi Modal Improvements Fuel Storage Capacity Cargo Apron

Attachment B: Structural Design Analysis & Calculations Multi Modal Improvements Fuel Storage Capacity

Attachment C: Fire Protection Concept Multi Modal Improvements Fuel Storage Capacity

Attachment D: Calculations

Attachment D1: Calculations (Lighting Interior and Exterior) Multi Modal Improvements Fuel Storage Capacity

Cargo Apron

Attachment D2: Calculations (Lighting Railhead Area) Multi Modal Improvements

Attachment D3: Calculations (Semirigid & Rigid Pavement Calculations) Multi Modal Improvements Fuel Storage Capacity

Cargo Apron

Attachment D4: Calculations (Electrical Power Calculations) Multi Modal Improvements

Attachment D5: Calculations (HVAC Flows Calculations) Multi Modal Improvements

Attachment E: Drawings – 35% Design

Attachment E1: Design Drawings 35% Multi Modal Improvements

Attachment E2: Design Drawings 35% Fuel Storage Capacity

Attachment E3: Design Drawings 35% Cargo Apron

Revised Retention Pond Location Drawings 23 JUNE 2017

Attachment F: Site Surveys

Attachment F1: Site Surveys GEORADAR PLANS Multi Modal Improvements Fuel Storage Capacity

Cargo Apron

Attachment F2: Site Surveys GEORADAR REPORT

Multi Modal Improvements Fuel Storage Capacity

Cargo Apron Attachment F3: Site Surveys GEOTECH REPORT

Multi Modal Improvements Fuel Storage Capacity

Cargo Apron

Attachment F4: Site Surveys TOPOGRAPH PLANS Multi Modal Improvements Fuel Storage Capacity

Cargo Apron

Attachment F5: Site Surveys TOPOGRAPH REPORT Multi Modal Improvements Fuel Storage Capacity

Cargo Apron

Attachment G: Contractor Documents (Submittal Register) Multi Modal Improvements Fuel Storage Capacity Cargo Apron

Attachment H: Additional Drawings Amendment 11 (Post Closing)

Attachment H1: FSC 001 – FSC 001

Attachment H2: FSC 001 – FSC X001

Attachment H3: FSC 001 – FSC X002

Attachment H4: 170809 MI GC Scope Modification

Attachment H5: 170809 MI GE Scope Modification

Attachment H6: 170814 MI GE Modification Annex 1

THE INFORMATION IN THE ATTACHMENTS IS FOR INFORMATIONAL PURPOSES ONLY. THE

DESIGNER OF RECORD WILL BE RESPONSIBLE FOR PROVIDING THE COMPLETE DOCUMENTS

AS OUTLINED IN SECTION 6.2.2 “DESIGN SUBMITTAL” AND REQUIRED TECHNICAL CODES.

Instruction to Offerors Attachments:

Attachment 1: Experience Overview Sheet Revised Dated 08 August 2017

Attachment 2: Experience Information Sheet

Attachment 3: Past Performance Questionnaire

Attachment 4: Price Schedule (Excel) Revised Dated 14 August 2017

Attachment 5: Resume Revised Dated 23 June 2017

Attachment 6: Letter of Commitment

Attachment 7: Camp MK Location (GPS Coordinates)

Attachment 8: MK Base Access Request Form

Attachment 9: MK Commercial Vehicle Access Request

Attachment 10: VAT Form Instructions for Point of Sale Exemption

Attachment 11: VAT Form

Attachment 12: Pre-Proposal Conference Slides

Attachment 13: Pre-Proposal Conference Sign-In Roster

Attachment 14: Revised SOW With Track Changes Dated 21 August 2017

Attachment 15: Urbanism Cerificate

SECTION 00 10 00 - SOLICITATION, CONTRACT LINE ITEM NUMBER (CLIN) SCHEDULE

CLIN 2001

The CLIN extended description has changed from:

Fuel Storage Capacity (FSC) MK Air Base Romania Base Line ItemsBase Line Items: The following base line items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Scope of Work (SOW), Solicitation / Request for Proposal, and Base Contract. It also includes preparation of all documents, submittals, and schedules;

inspections; and compliance with all technical, quality control, administrative, regulatory, permitting and safety requirements. All work shall be performed in accordance with these documents.Period of Performance: A single Notice to Proceed will be issued for all awarded work. All work shall be completed within the number of calendar days indicated in each line item from the date of the Notice to Proceed. Included in the total Period of Performance is a period of up to 120 calendar days during which the host nation Ministry of Defense will review the 100% design submittals and provide review comments to the US government. Only upon completion of the host nation Ministry of Defense (MOD) review, will the designs be approved for construction.Liquidated Damages: Liquidated damages shall be assessed in the amount of €3.166,00 per calendar day of delay beyond the required completion date of the contract.

To:

Fuel Storage Capacity (FSC) MK Air Base Romania Base Line ItemsBase Line Items: The following base line items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Scope of Work (SOW), Solicitation / Request for Proposal, and Base Contract. It also includes preparation of all documents, submittals, and schedules;

inspections; and compliance with all technical, quality control, administrative, regulatory, permitting and safety requirements. All work shall be performed in accordance with these documents.Period of Performance: A single Notice to Proceed will be issued for all awarded work. All work shall be completed within the number of calendar days indicated in each line item from the date of the Notice to Proceed. Included in the total Period of Performance is a period of up to 120 calendar days during which the host nation Ministry of Defense will review the 100% design submittals and provide review comments to the US government. Only upon completion of the host nation Ministry of Defense (MOD) review, will the designs be approved for construction.Liquidated Damages: Liquidated damages shall be assessed in the amount of €849.00 per calendar day of delay beyond the required completion date of the contract.

SUBCLIN 2001AA

The CLIN description has changed from A/E-provided Service to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

A/E-provided Service: All work and labor required to provide a Geotechnical Survey for the project site.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

To:

SCLIN Deleted - Do Not Price

SUBCLIN 2001BA

The CLIN description has changed from A/E-provided Service to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

A/E-provided Service: All work and labor required to provide a Topographical Survey for the project site.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

To:

SCLIN Deleted - Do Not Price

SUBCLIN 2001CA

The CLIN extended description has changed from:

Aircraft Fuel Storage Facility, Aircraft Fuel Truck Loading Facility, and Fuel Truck Parking Area (Design): All work and labor required to design Aircraft Fuel Storage Facility, Aircraft Fuel Truck Loading Facility, and Fuel Truck Parking Area.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

To:

Aircraft Fuel Storage Facility, Aircraft Fuel Truck Loading Facility, and Fuel Truck Parking Area (Design): All work and labor required to design Aircraft Fuel Storage Facility, Aircraft Fuel Truck Loading Facility, and Fuel Truck Parking Area, including all work and labor required to complete Geotechnical Survey and Topographical Survey. This includes the revisions for both only the Base design items as clarified in the "Explanation of Variances" and drawing FSC 001 for the Fuel Storage Capacity.All work on this base line item shall be completed within 310 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 2001CB

The CLIN extended description has changed from:

Aircraft Fuel Storage Facility (Construction): All work, materials, and labor required to construct Aircraft Fuel Storage Facility containing: Aircraft Fuel Storage Tank, Fuel Containment System, 2 Tanks 1.892M Liters / 499,985 Gallon each), and Alt. Fuel Delivery Connection. Including supporting facilities: Electric Service, Water, Sewer, Paving, Walks, Curbs and Gutters, Storm Drainage Site Improvement, Information Systems.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

To:

Aircraft Fuel Storage Facility (Construction): All work, materials, and labor required to construct Aircraft Fuel Storage Facility containing: Aircraft Fuel Storage Tank, Fuel Containment System, 2 Tanks at +/- .945M Liters (+/- 250,000 gallons), and Alt. Fuel Delivery Connection. Including supporting facilities: Electric Service, Water, Sewer, Paving, Walks, Curbs and Gutters, Storm Drainage Site Improvement, Information Systems.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 2001CC

The CLIN extended description has changed from:

Aircraft Fuel Truck Loading Facility (Construction): All work, materials, and labor required to construct Aircraft Fuel Truck Loading Facility containing: Distribution Piping, Pipe Bollards including supporting facilities: Electric Service, Water, Sewer, Paving, Walks, Curbs and Gutters, Storm Drainage, Site Improvement, Information Systems.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

To:

Aircraft Fuel Truck Loading Facility (Construction): All work, materials, and labor required to construct Aircraft Fuel Truck Loading Facility containing: Distribution Piping, Pipe Bollards including supporting facilities and all utilitiesAll work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 2001CD

The CLIN extended description has changed from:

Fuel Truck Parking Area (Construction) All work, materials, and labor required to construct Fuel Truck Parking Area including supporting facilities: Water, Sewer Paving, Walks, Curbs and Gutters, Storm Drainage, and Site Improvement.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

To:

Fuel Truck Parking Area (Construction) All work, materials, and labor required to construct Fuel Truck Parking Area with 12 spaces including supporting facilities: Water, Sewer Paving, Walks, Curbs and Gutters, Storm Drainage, and Site Improvement. All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 2001DA

The CLIN extended description has changed from:

Fueling/POL, Support Building (Design): All work and labor required to design Fueling/POL, Support Building.All work on this base line item shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed.

To:

Fueling/POL, Support Building (Design): All work and labor required to design Fueling/POL, Support Building.All work on this base line item shall be completed within 310 calendar days from the date of the issuance of the Notice to Proceed.

CLIN 2002

The CLIN type priced has been deleted.

The CLIN description has changed from Demolition of Existing Structures to Option Items FSC MK Air

Base.

The CLIN extended description has changed from:

(Construction) - All work, materials, and labor required to remove any existing structures as outlined in the scope of work.

To:

Option Items: The following Line items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Scope of Work (SOW), Solicitation / Request for Proposal, and Base Contract. It also includes preparation of all documents, submittals, and schedules; inspections; and compliance with all technical, quality control, administrative, regulatory, permitting and safety requirements. All work shall be performed in accordance with these documents. Award of Options: The Government will award any options at the time of award of the base work. If an option is exercised, it must also be completed within the number of calendar days stated in the optional line item being exercised. Period of Performance: A single Notice to Proceed will be issued for all awarded work. All work shall be completed within the number of calendar days indicated in each line item from the date of the Notice to Proceed. Included in the total Period of Performance is a period of up to 120 calendar days during which the host nation Ministry of Defense will review the 100% design submittals and provide review comments to the US government. Only upon completion of the host nation Ministry of Defense (MOD) review, will the designs be approved for construction. Liquidated Damages: Liquidated damages shall be assessed in the amount of €849.00 per calendar day of delay beyond the required completion date of the contract.

The option status has changed from Option to No Status.

The FOB Destination has been deleted.

The FSC code Y1BZ has been deleted.

The PROG code C20 has been deleted.

The WSC Equipment code 000 has been deleted.

The SIC code 1500 has been deleted.

The NAICS code 236220 has been deleted.

The MDAP/MAIS Code 000 has been deleted.

CLIN 3001

The CLIN extended description has changed from:

Multimodal Improvements (MI) MK Air Base, Romania Base Line ItemsBase Line Items: The following base line items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Scope of Work (SOW), Solicitation / Request for Proposal, and Base Contract. It also includes preparation of all documents, submittals, and schedules;

inspections; and compliance with all technical, quality control, administrative, regulatory, permitting and safety requirements. All work shall be performed in accordance with these documents.Period of Performance: A single Notice to Proceed will be issued for all awarded work. All work shall be completed within the number of calendar days indicated in each line item from the date of the Notice to Proceed. Included in the total Period of Performance is a period of up to 120 calendar days during which the host nation Ministry of Defense will review the 100% design submittals and provide review comments to the US government. Only upon completion of the host nation Ministry of Defense (MOD) review, will the designs be approved for construction.Liquidated Damages: Liquidated damages shall be assessed in the amount of €3.166,00 per calendar day of delay beyond the required completion date of the contract.

To:

Multimodal Improvements (MI) MK Air Base, Romania Base Line ItemsBase Line Items: The following base line items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Scope of Work (SOW), Solicitation / Request for Proposal, and Base Contract. It also includes preparation of all documents, submittals, and schedules;

inspections; and compliance with all technical, quality control, administrative, regulatory, permitting and safety requirements. All work shall be performed in accordance with these documents.Period of Performance: A single Notice to Proceed will be issued for all awarded work. All work shall be completed within the number of calendar days indicated in each line item from the date of the Notice to Proceed. Included in the total Period of Performance is a period of up to 120 calendar days during which the host nation Ministry of Defense will review the 100% design submittals and provide review comments to the US government. Only upon completion of the host nation Ministry of Defense (MOD) review, will the designs be approved for construction.Liquidated Damages: Liquidated damages shall be assessed in the amount of €849.00 per calendar day of delay beyond the required completion date of the contract.

SUBCLIN 3001CA

The CLIN extended description has changed from:

Site Roads, Utilities and Transformer Station (Design): All work and labor required to design Site Roads, utilities and and transformer station and connection to existing Substation on the TFOSAll work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

To:

Site Roads, Utilities and Transformer Station (Design): All work and labor required to design Site Roads, utilities and and transformer station and electrical connections as described in drawing MI GE 001, including all work and labor required to complete Geotechnical Survey and Topographical Survey. All work on this base line item shall be completed within 210 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001CB

Site Roads, Streets and Walkways (Construction): All work, materials, and labor required to construct Site Roads including: Paving, Walks, Curbs, and Gutter, and Site Improvement.All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

Site Roads, Streets and Walkways (Construction): All work, materials, and labor required to construct Site Roads including: Paving, Walks, Curbs, and Gutter, and Site Improvement. The road will consist of three layers: aggregate subbase courses, Portland cement-stabilized base courses and aggregate base courses (crushed and compacted stone, best mix) as described for the base in "Summary of Scope Revisions" for the Multi Modal Improvements.All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001CC

Site Utilities (Construction): All work, materials, and labor required to construct Site Utilities including: Electric Service, Water, Sewer, Storm Drainage, and Information Systems. All work on this base line item shall be

Site Utilities (Construction): All work, materials, and labor required to construct Site Utilities including: Electric Service, Water, Sewer, Storm Drainage, and Information Systems as described in the Summary of Scope Revisions and drawing MI GE 001. All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001CD

The CLIN description has changed from Transformer Station Connect Construction to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

Transformer Station and Connection to existing Substation on the TFOS (Construction): All work, materials, and labor required to construct Transformer Station including: Electric Service.All work on this base line item shall be

SCLIN Deleted - Do Not Price

SUBCLIN 3001DA

The CLIN description has changed from Rail load /off-load facility Design to RLOLF, VWF, EG (Design).

The CLIN extended description has changed from:

Rail load /off-load facility (Railhead), Vehicle Wash Facility and Entrance Gate, (Design): All work and labor required to design Railhead and Vehicle Wash Facility.All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

Rail load /off-load facility (Railhead), Vehicle Wash Facility and Entrance Gate, (Design): All work and labor required to design Railhead and Vehicle Wash Facility.All work on this base line item shall be completed within 210

SUBCLIN 3001DB

Rail load /off-load facility Railhead (Construction): All work, materials, and labor required to construct Railhead containing: RR Tracks w/Ties and Ballast, Railhead Apron/Service Lane, Concrete Hardstand, Loading/Unloading Dock/Ramp, At-Grade Rail Crossing, and Rail Switch.Including supporting facilities: Electric Service, Water, Sewer, Storm Drainage, Site Improvement, and Information Systems.All work on this base line item shall be

Rail load /off-load facility Railhead (Construction): All work, materials, and labor required to construct Railhead containing: RR Tracks w/Ties and Ballast, Railhead Apron/Service Lane, Concrete Hardstand, Loading/Unloading Dock/Ramp, At-Grade Rail Crossing, and Rail Switch.ncluding supporting facilities: Electric Service, Water, Sewer, Storm Drainage, Site Improvement, and Information Systems.All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001DD

Vehicle Wash Facility (Construction) All work, materials, and labor required to construct Vehicle Wash Facility containing of: Vehicle Wash Facility, Wash Support Building, Wash Support Bldg. Vapor Barrier, Wash Facility Apron, Gravity Oil/Grease Sep., and Water and Grit SeparatorIncluding supporting facilities: Electric Service, Water, Sewer, and Storm Drainage.All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

Vehicle Wash Facility (Construction) All work, materials, and labor required to construct Vehicle Wash Facility containing of: Vehicle Wash Facility, Wash Support Building, Wash Support Bldg. Vapor Barrier, Wash Facility Apron, Gravity Oil/Grease Sep., and Water and Grit Separator Including supporting facilities: Electric Service, Water, Sewer, and Storm Drainage.All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001EA

Ready Building (Design): All work and labor required to design one building (referred to as the Ready Building) containing all functions of:-Ready Building-A/DACG with Overhead Protection-Shipping and Receiving and Cargo Operations Building-Overhead Protection, Pallet Area-Staging Marshalling Areaand an exterior:-Open Storage Area, Installation and Generator StationAll work on this base line item shall be completed within 1050 calendar days from the date of the issuance of the Notice to Proceed.

Ready Building (Design): All work and labor required to design one building (referred to as the Ready Building) containing all functions of: -Ready Building-A/DACG with Overhead Protection -Shipping and Receiving and Cargo Operations Building -Overhead Protection, Pallet Area -Staging Marshalling Area and an exterior: -Open Storage Area, Installation and Generator Station Reference drawings MI RB 001, MI RB X001 and MI RB X002 for clarifications. All work on this base line item shall be completed within 270 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001EC

Open Storage Area, Installation (Construction): All work, materials, and labor required to construct Open Storage Area, Installation, including supporting facilities: Storm Drainage.All work on this base line item shall be completed

Open Storage Area, Installation (Construction): All work, materials, and labor required to construct Open Storage Area, Installation, including supporting facilities: Storm Drainage. Site Improvement, Information Systems.

Reference drawing MI RB 001 for clarification. All work on this base line item shall be completed within 810

SUBCLIN 3001ED

Staging Marshalling Area (Construction): All work, materials, and labor required to construct a staging marshalling areaAll work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

Staging Marshalling Area (Construction): All work, materials, and labor required to construct a staging marshalling area Reference drawing MI RB 001 for clarification. All work on this base line item shall be completed within 810

SUBCLIN 3001FA

The CLIN description has changed from A/E-provided Service to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

A/E-provided Service: All work and labor required to provide LEED Services for the Ready Building (Enhanced Commissioning)All work on this base line item shall be completed within 1050 calendar days from the date of the

SUBCLIN 3001GA

The CLIN description has changed from Fencing Sys. Staging Marshalling Design to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

Fencing System for the Staging Marshalling Area (Design) All work and labor required to design Fencing System for the Staging Marshalling Area at the RailheadAll work on this base line item shall be completed within 810

SUBCLIN 3001HA

The CLIN description has changed from Alternative water Connection (Design) to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

Alternative water Connection (Design): All work and labor required to design Alternative Water Connection to the PFOS.All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001JA

The CLIN description has changed from Backup Generator (Design) to A/E provided Service (LEED Services).

The CLIN extended description has changed from:

Backup Generator (Design): All work and labor required to design Backup Generator for Rail Head, Fueling Area and Cargo Apron.All work on this base line item shall be completed within 810 calendar days from the date of the

A/E provided Service (LEED Services): All work and labor required to provide LEED Services for the Ready Building (v4 Base Services in Design and Construction Phases incl. Pre Assessment, Energy Modeling, Fundamental Commissioning, Fees, etc.)All work on this base line item shall be completed within 1050 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001KA

The CLIN description has changed from Alt Electrical Utility Connection Design to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

Alternative Electrical Utility Connection (Design): All work and labor required to design alternative electrical utility connection of Transformer Station to existing Electrical Sub Station on PFOS in lieu of the requirement to connect to transformer in base bid. All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

SUBCLIN 3001LA

The CLIN description has changed from Enlargement of service lane Design to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

Enlargement of service lane, movement platform and railway (Design): All work and labor required to design enlargement of service lane, movement platform and railwayAll work on this base line item shall be completed

SUBCLIN 3001MA

The CLIN description has changed from A/E provided Service (LEED Services) to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

A/E provided Service (LEED Services): All work and labor required to provide LEED Services for the Ready Building (v4 Base Services in Design and Construction Phases incl. Pre Assessment, Energy Modeling, FundamentalCommissioning, Fees, etc.)All work on this base line item shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed.

CLIN 3002

Multimodal Improvements (MI) MK Air Base, Romania Optional Line ItemsOptional Line Items: The following optional line items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Scope of Work (SOW), Solicitation / Request for Proposal, and Base Contract. It also includes preparation of all documents, submittals, and schedules;

inspections; and compliance with all technical, quality control, administrative, regulatory, permitting and safety requirements. All work shall be performed in accordance with these documents.Award of Options: The Government reserves the right to award any options within 120 calendar days following issuance of Notice to Proceed (NTP) for the base work. If an option is exercised, it must be completed within the number of calendar days stated in the optional line item being exercised.Period of Performance: A single Notice to Proceed will be issued for all awarded work. All work shall be completed within the number of calendar days indicated in each line item from the date of the Notice to Proceed. Included in the total Period of Performance is a period of up to 120 calendar days during which the host nation Ministry of Defense will review the 100% design submittals and provide review comments to the US government. Only upon completion of the host nation Ministry of Defense (MOD) review, will the designs be approved for construction.Liquidated Damages: Liquidated damages shall be assessed in the amount of €3.166,00 per calendar day of delay beyond the required completion date of the contract.

Multimodal Improvements (MI) MK Air Base, Romania Optional Line ItemsOptional Line Items: The following optional line items include providing all labor, materials, equipment, and services necessary to complete the design and construction of the work identified in the attached Plans, Specifications, Scope of Work (SOW), Solicitation / Request for Proposal, and Base Contract. It also includes preparation of all documents, submittals, and schedules;

inspections; and compliance with all technical, quality control, administrative, regulatory, permitting and safety requirements. All work shall be performed in accordance with these documents.Award of Options: The Government reserves the right to award any options within 120 calendar days following issuance of Notice to Proceed (NTP) for the base work. If an option is exercised, it must be completed within the number of calendar days stated in the optional line item being exercised.Period of Performance: A single Notice to Proceed will be issued for all awarded work. All work shall be completed within the number of calendar days indicated in each line item from the date of the Notice to Proceed. Included in the total Period of Performance is a period of up to 120 calendar days during which the host nation Ministry of Defense will review the 100% design submittals and provide review comments to the US government. Only upon completion of the host nation Ministry of Defense (MOD) review, will the designs be approved for construction.Liquidated Damages: Liquidated damages shall be assessed in the amount of €849.00 per calendar day of delay beyond the required completion date of the contract.

SUBCLIN 3002AA

The CLIN description has changed from Fence Sys Staging Marshalli Construction to Fencing (Design/Construction).

The CLIN extended description has changed from:

Fencing System for the Staging Marshalling Area at the Railhead (Construction): All work, materials, and labor required to construct Fencing System at the Railhead.The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

FFencing System to include entrance gate Around the Concrete Hardstand at the Railhead (Design AND Construction): All work, materials, and labor required to design and construct a Fencing System to include entrance gate Around the Concrete Hardstand. Refer to drawing CX007.The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002BA

The CLIN description has changed from Alt water Connection (Construction) to Alt water Connect (Design/Construction).

Alternative Water Connection (Construction) All work, materials, and labor required to construct Alternative Water

Connection to the PFOS. Refer to plan GE001.The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

Alternative Water Connection (Design AND Construction) All work, materials, and labor required to design and construct Alternative Water Connection to the PFOS. Refer to plan GE001.The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002CA

The CLIN description has changed from Backup Generator (Construction) to Backup Generator (Design/Construction).

The CLIN extended description has changed from:

Backup Generator (Construction) All work, materials, and labor required to provide Backup Generator Station for Rail Head, Fueling Area and Cargo Apron.The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

Backup Generator (Design & Construction): All work and labor required to design 1 diesel generator of 500kVA for the ready buildingThe Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002DA

The CLIN description has changed from Alt Elec Utility Connect Construction to SCLIN Deleted - Do Not Price.

The CLIN extended description has changed from:

Alternative Electrical Utility Connection (Construction): All work, materials, and labor required to construct alternative electrical utility connection of Transformer Station to existing Electrical Sub Station on PFOS in lieu of the requirement to connect to transformer in base bid. Refer to plan GE001.The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date

The option status has changed from Option to No Status.

SUBCLIN 3002EA

The CLIN description has changed from Enlargement service lane Construction to Enlargement service lane Design/Construc.

The CLIN extended description has changed from:

Enlargement of service lane, movement platform and railway (Construction): All work and labor required to construction enlargement of service lane, movement platform and railwayThe Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date

Enlargement of service lane, movement platform and railway (Design & Construction): All work and labor required to design and construct enlargement of service lane, movement platform and railwayThe Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work.

Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002EB

The CLIN description has changed from Demolition of Existing Structures to Demolition Structures (Design/Constructi.

The CLIN extended description has changed from:

(Construction) - All work, materials, and labor required to remove any existing structures as outlined in the scope of work.

Demolition of Existing Structures(Design & Construction)-All work, materials and labor required to remove any existing structures as outlined in Scope of Work. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 500 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002EC

The CLIN description has changed from Relocate two (2) Above Ground Fuel Lines to Relocate 2 Fuel Lines (Design/Constructi.

The CLIN extended description has changed from:

All work, materials, and labor required to relocate two (2) above ground existing, active fuel lines as outlined in the scope of work.

Relocating two above ground active fuel lines(Design & Construction)- All work, materials and labor rwquired to remove any two above ground existing active fuel lines as outlined in the Scope of Work. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 2002AA is added as follows:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

2002AA

OPTION AFSF, AFTLF, FTPA (Design/Construct)

FFP

Aircraft Fuel Storage Facility, Aircraft Fuel Truck Loading Facility, and Fuel Truck Parking Area (Design & Construction): All work and labor required to design and construct Aircraft Fuel Storage Facility, Aircraft Fuel Truck Loading Facility, and Fuel Truck Parking Area, including all work and labor required to complete Geotechnical Survey and Topographical Survey. This includes the revisions for both only the Base design items as clarified in the "Explanation of Variances" and drawing FSC 001 for the Fuel Storage Capacity. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed for the base items.

FOB: Destination

NET AMT

SUBCLIN 2002BA is added as follows:

2002BA

OPTION Demolition (Design/Construction)

FFP

Demolition of Existing Structures(Design & Construction)-All work, materials and labor required to remove any existing structures as outline in Scope of Work. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 500 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 2002CA is added as follows:

2002CA

OPTION 1 add tank at +/- 250,000g Design/Constr

FFP

One (1) additional tank at +/- 250,000 gallons each (Design & Construction) - All work, materials and labor required to furnish and install an additional tank with approximatley 250,000 gallon capacity, bringing the overall storage capacity of the project to three (3) 250,000 gallon tanks, or approximately 750,000 gallons total as described in the Summary of Scope Revisions document and drawing FSC X001.

Should the Government exercise this optional line item all work shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 2002DA is added as follows:

2002DA

OPTION 1 add tank at +/- 250,000g Design/Constr

FFP

One (1) additional tank at +/- 250,000 gallons each (Design & Construction) - All work, materials and labor required to furnish and install an additional tank with approximatley 250,000 gallon capacity, bringing the overall storage capacity of the project to four (4) 250,000 gallon tanks, or approximately 1,000,000 gallons total as described in the Summary of Scope Revisions document and drawing FSC X002. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 1090 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002ED is added as follows:

3002ED

OPTION Electr connect ETS1(Design/Construction)

FFP

Electrical connection to ETS1(Design & Construction): All work, material and labor of the electrical connection for the Railhead Area in the manhole south of the Fuel Storage Capacity project to ETS1 and the electrical connection of the NTS to ETS1. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar

SUBCLIN 3002EE is added as follows:

3002EE

OPTION Electr connect ETS2 (Design/Construction

FFP

Electrical connection to ETS2 (Design & Construction): All work, material and labor of the electrical connection for the Railhead Area in the manhole south of the Fuel Storage Capacity project to ETS2 and the electrical connection of the NTS to ETS1. The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002EF is added as follows:

3002EF

OPTION A/E-provided Service

FFP

A/E-provided Service: All work and labor required to provide LEED Services for the Ready Building (Enhanced Commissioning) The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the issuance of the Notice to Proceed for the base items.

SUBCLIN 3002EG is added as follows:

3002EG

OPTION Add Rows 4 Umbrellas Design/Construction

FFP

Additional Row of Four Umbrellas (Design and Construction): All work, material and labor required to add one additional row of four (4) umbrellas to the South Side of the Ready Building (400 additional sqm). The Government reserves the right to exercise this option within 120 calendar days of issuance of the Notice to Proceed for the base items work. Should the Government exercise this optional line item all work shall be completed within 810 calendar days from the date of the

SUBCLIN 3002EH is…