Solicitation Amendment N4008525R26390008 SF 30.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Block 14 (Description of Amendment/Modification): The amendment is issued to incorporate the following:

1. Revised Proposal Due Date

2. Issue Discussion Questions to Invited Offerors in the Competitive Range (emailed separately)

3. Include Attachment F - Small Business Participation Commitment (attached separately)

4. Include Attachment G - Individual Small Business Subcontracting Plan (attached separately)

5. Provide Wage Determination (enclosed)

6. Provide Justification & Approval (J&A) (attached separately)

7. Provide clauses and provisions (enclosed)

Section 00 00 00 - Procurement and Contracting Requirements

The following changes have been made:

INFORMATION FROM TO

Contract Description

SOLICITATION NO. N4008525r2639, DESIGN-BID-

BUILD, P-222: MQ-25 AIRCRAFT

LAYDOWNFACILITIES, NAVAL STATION

NORFOLK, NORFOLK, VIRGINIAThis acquisition is being solicited on an unrestricted basis with full and open competition. All correspondence regarding this solicitation shall be directed via email to Catharine Keeling at catharine.a.keeling.civ@us.navy.mil.

Description of Work: A. Constructs a two-story annex to support existing high bay hangar facility, Building LP48. Annex will consist of 01 and 02 spaces constructed of reinforced concrete masonry unit (CMU) walls and a combination of masonry and metal panel veneer. Annex spaces will include maintenance shops, secured storage spaces, Unmanned Carrier Aviation Mission Control System (UMCS) spaces, Weapons Training Unit (WTU) operational trainer and applied instruction space, Aerial Refueling Storage (ARS) Workcenter with overhead bridge crane, mission equipment support areas and other equipment rooms and personnel support areas. Facility includes controlled areas.B. Constructs a Ground Based Detection and Avoidance (GBDAA) System radar tower with electrical and fiber optic tie-ins to existing installation infrastructure and/or outside plant upgrades as required with connection to Air Traffic Control (ATC) tower.C. Renovates Existing LP48 hangar and provides multiple additions. The additions include: a one-story addition on the ground floor for the tool room, a one-story addition to the ground floor for the battery charging and storage spaces, and two one-story additions to the second floor for expansion to include the RCS Shelter and Command functions. A stair and catwalk are constructed over the existing hangar for placement of antennas supporting the MQ-25 mission, shop spaces, crew spaces, command suite, administrative areas and repair the existing high bay Vertical Lift Fabric Door (VLFD). Renovation includes plumbing, electrical, fire protection and HVAC repairs.

SOLICITATION NO. N4008525R2639, DESIGN-

BID-BUILD, P-222: MQ-25 AIRCRAFT

LAYDOWNFACILITIES, NAVAL STATION

NORFOLK, NORFOLK, VIRGINIAThis acquisition is being solicited on an unrestricted basis with full and open competition. All correspondence regarding this solicitation shall be directed via email to Catharine Keeling at catharine.a.keeling.civ@us.navy.mil.

Description of Work: A. Constructs a two-story annex to support existing high bay hangar facility, Building LP48. Annex will consist of 01 and 02 spaces constructed of reinforced concrete masonry unit (CMU) walls and a combination of masonry and metal panel veneer. Annex spaces will include maintenance shops, secured storage spaces, Unmanned Carrier Aviation Mission Control System (UMCS) spaces, Weapons Training Unit (WTU) operational trainer and applied instruction space, Aerial Refueling Storage (ARS) Workcenter with overhead bridge crane, mission equipment support areas and other equipment rooms and personnel support areas. Facility includes controlled areas.B. Constructs a Ground Based Detection and Avoidance (GBDAA) System radar tower with electrical and fiber optic tie-ins to existing installation infrastructure and/or outside plant upgrades as required with connection to Air Traffic Control (ATC) tower.C. Renovates Existing LP48 hangar and provides multiple additions. The additions include: a one-story addition on the ground floor for the tool room, a one-story addition to the ground floor for the battery charging and storage spaces, and two one-story additions to the second floor for expansion to include the RCS Shelter and Command functions. A stair and catwalk are constructed over the existing hangar for placement of antennas supporting the MQ-25 mission, shop spaces, crew spaces, command suite, administrative areas and repair the existing high bay Vertical Lift Fabric Door (VLFD). Renovation includes plumbing, electrical, fire protection and HVAC repairs.

Response Due Date 31 Mar 2026 09 Jun 2026

Section 00 20 00 - Instructions for Procurements

N4008525R26390008

Miscellaneous text in this section has been added to:

Amendment 0008

This amendment is issued to incorporate the following:

1. Revised Proposal Due Date

2. Issue Discussion Questions to Invited Offerors in the Competitive Range (emailed separately)

3. Include Attachment F - Small Business Participation Commitment (attached separately)

4. Include Attachment G - Individual Small Business Subcontracting Plan (attached separately)

5. Provide Wage Determination (enclosed)

6. Provide Justification & Approval (J&A) (attached separately)

7. Provide clauses and provisions (enclosed)

1.The proposals for Offerors in the Competitive range are due on 09 June 2026 by 2.00PM ET.

2. Discussion Questions issued to Invited Offerors in the Competitive Range (emailed separately).

3. Attachment F - Small Business Participation Commitment is provided with this amendment (attached separately).

4. Attachment G - Individual Small Business Subcontracting Plan is provided with this amendment (attached separately).

5. Wage Determination VA20260160 05/18/2026

"General Decision Number: VA20260160 05/18/2026

State: Virginia

Construction Types: Building

Counties: Virginia Counties of Norfolk*

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories)

* Designates Independent City

Modification Number Publication Date 1 01/30/2026 2 05/18/2026

ASBE0024-006 10/01/2024

Rates Fringes

ASBESTOS WORKER/HEAT & FROST INSULATOR - MECHANICAL

(DUCT, PIPE & MECHANICAL SYSTEM INSULATION) A.

PAID HOLIDAYS: NEW YEAR'S DAY, MARTIN LUTHER KING

DAY, MEMORIAL DAY, INDEPENDENCE DAY, LABOR DAY,

VETERANS' DAY, THANKSGIVING DAY,THE DAY AFTER

THANKSGIVING AND CHRISTMAS DAY PROVIDED THE

EMPLOYEE WORKS THE REGULAR WORK DAY BEFORE AND

AFTER THE PAID HOLIDAY..............................$ 40.77 20.17

BOIL0045-003 01/01/2025

Rates Fringes

BOILERMAKER.........................................$ 38.97 27.39

ELEC0080-010 06/01/2025

Rates Fringes

ELECTRICIAN: INCLUDES LOW VOLTAGE WIRING AND ALARM

INSTALLATION. A. WORKMEN SHALL TAKE OFF 1 HOUR

WITH PAY, AT THE DISCRETION OF THE EMPLOYER, ON

STATE AND NATIONAL ELECTION DAYS; TUESDAY FOLLOWING

THE FIRST MONDAY IN NOVEMBER, PROVIDED THEY ARE

QUALIFIED AND VOTE..................................$ 36.85 14.13

ELEV0052-005 01/01/2025

Rates Fringes

ELEVATOR MECHANIC A. PAID HOLIDAYS: NEW YEAR'S DAY,

MEMORIAL DAY, INDEPENDENCE DAY, LABOR DAY,

VETERANS' DAY, THANKSGIVING DAY, THE FRIDAY AFTER

THANKSGIVING DAY AND CHRISTMAS DAY. B. VACATIONS:

6% MEN UNDER 5 YEARS BASED ON REGULAR HOURLY RATE

AND 8% MEN OVER 5 YEARS BASED ON REGULAR HOURLY

RATE FOR ALL HOURS WORKED...........................$ 52.06 38.44

ENGI0147-019 06/01/2025

Rates Fringes

POWER EQUIPMENT OPERATOR (CRANES UNDER 90 TONS).....$ 39.99 18.05

POWER EQUIPMENT OPERATOR (CRANES 90 TONS & OVER

CAPACITY; TOWER & CLIMBING CRANES WITH CONTROLS 100

FT. ABOVE GROUND)...................................$ 40.99 18.05

IRON0028-006 05/01/2023

Rates Fringes

IRONWORKER, RIGGER..................................$ 30.22 17.56

IRON0028-007 05/01/2024

Rates Fringes

IRONWORKER: STRUCTURAL AND ORNAMENTAL...............$ 31.00 18.28

PLUM0110-008 11/01/2025

Rates Fringes

PLUMBER.............................................$ 36.92 18.25

PIPEFITTER (INCLUDES HVAC PIPE, UNIT AND

TEMPERATURE CONTROLS INSTALLATIONS).................$ 36.92 18.25

SUVA2013-043 01/11/2016

Rates Fringes

TRUCK DRIVER: DUMP TRUCK...........................$ 15.50 0.75

TILE SETTER.........................................$ 27.80 10.25

TILE FINISHER.......................................$ 23.40 0.00

SPRINKLER FITTER (FIRE SPRINKLERS)..................$ 18.91 4.67

SHEET METAL WORKER, INCLUDES HVAC DUCT INSTALLATION.$ 20.98 2.62

ROOFER..............................................$ 18.40 2.31

PAINTER: SPRAY.....................................$ 18.10 5.43

PAINTER (BRUSH AND ROLLER)..........................$ 16.92 0.00

OPERATOR: ROLLER...................................$ 16.25 4.88

OPERATOR: LOADER...................................$ 21.28 3.17

OPERATOR: FORKLIFT.................................$ 19.40 7.00

OPERATOR: BULLDOZER................................$ 18.07 3.50

OPERATOR: BOBCAT/SKID STEER/SKID LOADER............$ 18.95 4.03

OPERATOR: BACKHOE/EXCAVATOR/TRACKHOE...............$ 18.57 1.19

LABORER: COMMON OR GENERAL, INCLUDING DEMOLITION....$ 11.28 1.89

LABORER: PIPELAYER.................................$ 12.40 1.86

LABORER: MASON TENDER - CEMENT/CONCRETE............$ 12.96 3.12

LABORER: MASON TENDER - BRICK......................$ 14.82 3.34

IRONWORKER, REINFORCING.............................$ 27.18 4.13

GLAZIER.............................................$ 19.36 4.68

CEMENT MASON/CONCRETE FINISHER......................$ 20.02 2.00

CAULKER.............................................$ 18.49 1.33

CARPENTER, INCLUDES ACOUSTICAL CEILING

INSTALLATION, DRYWALL HANGING, AND FORM WORK........$ 19.80 3.98

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Note: Executive Order 13658 generally applies to contracts subject to the Davis-Bacon Act that were awarded on or between January 1, 2015 and January 29, 2022, and that have not been renewed or extended on or after January 30, 2022. Executive Order 13658 does not apply to contracts subject only to the Davis-Bacon Related Acts regardless of when they were awarded. If a contract is subject to Executive Order 13658, the contractor must pay all covered workers at least $13.65 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract from May 11, 2026, through December 31, 2026. The applicable Executive Order minimum wage rate will be adjusted annually.

Additional information on contractor requirements and worker protections under Executive Order 13658 is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (iii)).

The body of each wage determination lists the classifications and wage rates that have been found to be prevailing for the type(s) of construction and geographic area covered by the wage determination. The classifications are listed in alphabetical order under rate identifiers indicating whether the particular rate is a union rate (current union negotiated rate), a survey rate, a weighted union average rate, a state adopted rate, or a supplemental classification rate.

Union Rate Identifiers

A four-letter identifier beginning with characters other than SU, UAVG, SA, or SC denotes that a union rate was prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2024. PLUM is an identifier of the union whose collectively bargained rate prevailed in the survey for this classification, which in this example would be Plumbers.

0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. The date, 07/01/2024 in the example, is the effective date of the most current negotiated rate.

Union prevailing wage rates are updated to reflect all changes over time that are reported to WHD in the rates in the collective bargaining agreement (CBA) governing the classification.

Union Average Rate Identifiers

The UAVG identifier indicates that no single rate prevailed for those classifications, but that 100% of the data reported for the classifications reflected union rates. EXAMPLE:

UAVG-OH-0010 01/01/2024. UAVG indicates that the rate is a weighted union average rate. OH indicates the State of Ohio.

The next number, 0010 in the example, is an internal number used in producing the wage determination. The date, 01/01/2024 in the example, indicates the date the wage determination was updated to reflect the most current union average rate.

A UAVG rate will be updated once a year, usually in January, to reflect a weighted average of the current rates in the collective bargaining agreements on which the rate is based.

Survey Rate Identifiers

The SU identifier indicates that either a single non-union rate prevailed (as defined in 29 CFR 1.2) for this classification in the survey or that the rate was derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As a weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SUFL2022-007 6/27/2024. SU indicates the rate is a single non-union prevailing rate or a weighted average of survey data for that classification. FL indicates the State of Florida. 2022 is the year of the survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. The date, 6/27/2024 in the example, indicates the survey completion date for the classifications and rates under that identifier.

SU wage rates typically remain in effect until a new survey is conducted. However, the Wage and Hour Division (WHD) has the discretion to update such rates under 29 CFR 1.6(c)(1).

State Adopted Rate Identifiers

The SA identifier indicates that the classifications and prevailing wage rates set by a state (or local) government were adopted under 29 C.F.R 1.3(g)-(h). Example: SAME2023-007 01/03/2024. SA reflects that the rates are state adopted. ME refers to the State of Maine. 2023 is the year during which the state completed the survey on which the listed classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination.

The date, 01/03/2024 in the example, reflects the date on which the classifications and rates under the SA identifier took effect under state law in the state from which the rates were adopted.

WAGE DETERMINATION APPEALS PROCESS

1) Has there been an initial decision in the matter? This can be:

a) a survey underlying a wage determination

b) an existing published wage determination

c) an initial WHD letter setting forth a position on a wage determination matter

d) an initial conformance (additional classification and rate) determination On survey related matters, initial contact, including requests for summaries of surveys, should be directed to the WHD Branch of Wage Surveys. Requests can be submitted via email to davisbaconinfo@dol.gov or by mail to:

Branch of Wage Surveys Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210 Regarding any other wage determination matter such as conformance decisions, requests for initial decisions should be directed to the WHD Branch of Construction Wage Determinations.

Requests can be submitted via email to BCWD-Office@dol.gov or by mail to:

Branch of Construction Wage Determinations Wage and Hour Division

U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2) If an initial decision has been issued, then any interested party (those affected by the action) that disagrees with the decision can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Requests for review and reconsideration can be submitted via email to dba.reconsideration@dol.gov or by mail to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210 The request should be accompanied by a full statement of the interested party's position and any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210.

END OF GENERAL DECISION"

6. One (1) Justification & Approval (J&A) is provided with this amendment (attached separately).

J&A ML-26-50 25R2639 P222 ILDFA_Redacted

7. Applicable Clauses and Provisions are updated with this amendment (Enclosed).

Section 00 21 00 - Instructions

The following clauses were modified:

52.215-1Instructions to Offerors-Competitive Acquisition. (Deviation 2026-O0038)Feb 2026 Date Changed From: Nov 2021 To: Feb 2026

52.233-2Service of Protest. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

Date Changed From: Sep 2006 To: Feb 2026

Section 00 45 00 - Representations and Certifications

The following clauses were modified:

52.209-7Information Regarding Responsibility Matters. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

INFORMATION REGARDING RESPONSIBILITY MATTERS (FEB 2026) (DEVIATION 2026-O0038)

(a) . As used in this provision-Definitions

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability ( , e.g.

Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity ( , general manager; plant manager; head of a division or business segment; and similar positions).e.g.

(b) The offeror has does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

Date Changed From: Oct 2018 To: Feb 2026

52.209-13Violation of Arms Control Treaties or Agreements-Certification. (Deviation 2026-O0038)Feb 2026 hereby reads as follows:

VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION (FEB 2026) (DEVIATION 2026-O0038)

(a) This provision does not apply to acquisitions at or below the simplified acquisition threshold or to acquisitions of commercial products and commercial services as defined in Federal Acquisition Regulation 2.101.

(b) . [ ]Certification Offeror shall check either (1) or (2).

The Offeror certifies that-(1)

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices /under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; or

The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.(2)

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there. Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If such activity might have occurred, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of non-compliance is equivalent to a determination of violation.

However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

(3) If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or is a significant factor in the determination in the report that one or more of these foreign countries is in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. Review the narrative for any such findings reflecting a determination of violation or non-adherence related to those foreign countries in the report, including the finding itself, and to the extent necessary, the conduct giving rise to the compliance or adherence concerns, the analysis of compliance or adherence concerns, and efforts to resolve compliance or adherence concerns.

(4) The Offeror may submit any questions with regard to this report by email to NDAA1290Cert@state.gov. To the extent feasible, the Department of State will respond to such email inquiries within 3 business days.

(d) Do not submit an offer unless-

(1) A certification is provided in paragraph (b)(1) of this provision and submitted with the offer; or

(2) In accordance with paragraph (b)(2) of this provision, the Offeror provides with its offer information that the President of the United States has

(i) Waived application under 22 U.S.C. 2593e(d) or (e); or

(ii) Determined under 22 U.S.C. 2593e(g)(2) that the entity has ceased all activities for which measures were imposed under 22 U.S.C. 2593e(b).

(e) . The certification in paragraph (b)(1) of this provision is a material representation of fact upon which reliance was placed when Remedies making award. If the Government later determines that the Offeror knowingly submitted a false certification, in addition to other remedies available to the Government, such as suspension or debarment, the Contracting Officer may terminate any contract resulting from the false certification.

(End of provision)

Date Changed From: Nov 2021 To: Feb 2026

Section 00 70 00 - Conditions of the Contract

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Reference

Number Title Effective Date Alternate/ Deviation

Variation Effective Date

52.204-14 Service Contract Reporting Requirements. (Deviation 2026-O0038) Feb 2026

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data-Modifications. (Deviation 2026-O0038)

Feb 2026

52.215-15 Pension Adjustments and Asset Reversions. (Deviation 2026-O0038) Feb 2026

52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pensions. (Deviation 2026-O0038)

Feb 2026

52.215-19 Notification of Ownership Changes. (Deviation 2026-O0038) Feb 2026

52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data-Modifications. (Deviation 2026-O0038)

Feb 2026

52.215-22 Limitations on Pass-Through Charges-Identification of Subcontract Effort. (Deviation 2026-O0038)

Feb 2026

52.215-23 Limitations on Pass-Through Charges. (Deviation 2026-O0038) Feb 2026

52.222-4 Contract Work Hours and Safety Standards-Overtime Compensation. (Deviation 2026- O0038)

Feb 2026

52.222-32 Construction Wage Rate Requirements-Price Adjustment (Actual Method). (Deviation 2026-O0038)

Feb 2026

52.222-90 Addressing DEI Discrimination by Federal Contractors. (Deviation 2026-O0040, Revision 1)

Apr 2026

52.223-1 Biobased Product Certification. (Deviation 2026-O0038) Feb 2026

52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners. (Deviation 2026-O0038)

Feb 2026

52.236-17 Layout of Work. (Deviation 2026-O0038) Feb 2026 52.240-92 Security Requirements. (Deviation 2026-O0038) Feb 2026

FAR Clauses Incorporated by Full Text

52.209-2 Prohibition on Contracting With Inverted Domestic Corporations-Representation.

(Deviation 2026-O0038)

(Feb 2026)

PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS-REPRESENTATION (FEB 2026) (DEVIATION 2026-O0038)

(a) . As used in this clause-Definitions

Inverted domestic corporation means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395 (b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

Subsidiary means an entity in which more than 50 percent of the entity is owned-

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

(b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-3(b) applies or the requirement is waived in accordance with the procedures at 9.108-5.

(c) . The Offeror represents that-Representation

(1) It is, is not an inverted domestic corporation; and

(2) It is, is not a subsidiary of an inverted domestic corporation.

(End of provision)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (Deviation 2026-O0038)

(Feb 2026)

REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY

FEDERAL LAW (FEB 2026) (DEVIATION 2026-O0038)

(a) The Government will not enter into a contract with any corporation that-

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that-

(1) It is is not a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is is not a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

(End of provision)

52.215-6 Place of Performance. (Deviation 2026-O0038) (Feb 2026)

PLACE OF PERFORMANCE (FEB 2026) (DEVIATION 2026-O0038)

(a) The offeror or respondent, in the performance of any contract resulting from this request for proposals, intends, does not intend [check ] to use one or more plants or facilities located at a different address from the address of the offeror or respondent as indicated in this applicable block proposal or response to request for information.

(b) If the offeror or respondent checks "intends" in paragraph (a) of this provision, it shall insert in the following spaces the required information:

Place of Performance (Street Address, City, State, County, ZIP Code)

Name and Address of Owner and Operator of the Plant or Facility if Other than Offeror or Respondent

(End of provision)

52.217-7 Option for Increased Quantity-Separately Priced Line Item. (Mar 1989)

OPTION FOR INCREASED QUANTITY-SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within [insert in the clause the period ____ of time in which the Contracting Officer has to exercise the option]. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

(End of clause)

52.219-1 Small Business Program Representations. (Deviation 2026-O0038) (Feb 2026)

SMALL BUSINESS PROGRAM REPRESENTATIONS (FEB 2026) (DEVIATION 2026-O0038)

(a) . As used in this provision-Definitions

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127, and the concern is certified by SBA or an approved third-party certifier in accordance with 13 CFR 127.300. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

HUBZone small business concern means a small business concern that meets the requirements described in 13 CFR 126.200, is certified by the Small Business Administration (SBA) and designated by SBA as a HUBZone small business concern in the Small Business Search (SBS) ( 13 CFR 126.103).

Service-disabled veteran-owned small business (SDVOSB) concern eligible under the SDVOSB Program means an SDVOSB concern that is designated in the System for Award Management (SAM) as certified by the Small Business Administration (SBA) in accordance with 13 CFR 128.300.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (b) of this provision.

(2) , as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, Affiliates or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

Small disadvantaged business concern means a small business concern that-

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by one or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraph (1) of this definition.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127) means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States, and the concern is certified by SBA or an approved third-party certifier in accordance with 13 CFR 127.300.

(b)

The North American Industry Classification System (NAICS) code for this acquisition is [insert NAICS code].(1) ____

(2) The small business size standard is [insert size standard].____

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce ( , nonmanufacturer), is 500 employees, or 150 employees for information i.e.

technology value-added resellers under NAICS code 541519, if the acquisition-

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(c) Representations.

The offeror represents as part of its offer that-(1)

(i) it is, is not a small business concern; or

(ii) It is, is not a small business joint venture that complies with the requirements of 13 CFR 121.103(h) and 13 CFR 125.8(a) and (b). [____ The offeror shall enter the name and unique entity identifier of each party to the joint venture: __.]________

(2) [ The offeror represents that it Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] is, is not a women-owned small disadvantage business concern.

(3) The offeror represents as part of its offer that it is, Women-owned small business (WOSB) joint venture eligible under the WOSB Program.

is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [ The offeror shall enter the name and unique ____ entity identifier of each party to the joint venture: __.]

(4) The offeror represents as part of its offer that it is, Economically disadvantaged women-owned small business (EDWOSB) joint venture.

is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [ The offeror shall enter the name and unique entity ____ identifier of each party to the joint venture: __.]

(5) . [ ]. The offeror SDVOSB joint venture eligible under the SDVOSB Program Complete only if the offeror is certified as a SDVOSB concern represents as part of its offer that it is, is not a SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402. [ The offeror shall enter the name and unique entity identifier of each party to the joint venture:__.]____

(6) [ ] The HUBZone joint venture eligible under the HUBZone Program. Complete only if the offeror is a HUBZone small business concern.

offeror represents, as part of its offer, that it is, is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [ The offeror shall enter the name and unique entity identifier of each party to the joint venture: __.] Each HUBZone small business ____ concern participating in the HUBZone joint venture must be certified as a HUBZone concern.

(d) Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a business concern that is small, HUBZone small, small Notice.

disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, will be-

(1) Punished by imposition of fine, imprisonment, or both;

(2) Subject to administrative remedies, including suspension and debarment; and

(3) Ineligible for participation in programs conducted under the authority of the Act.

(End of provision)

52.243-7 Notification of Changes. (Deviation 2026-O0038) (Feb 2026)

NOTIFICATION OF CHANGES (FEB 2026) (DEVIATION 2026-O0038)

(a) Definitions.

Contracting Officer, as used in this clause, does not include any representative of the Contracting Officer.

Specifically Authorized Representative (SAR), as used in this clause, means any person the Contracting Officer has designated by written notice (a copy shall be provided to the Contractor) that shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority.

(b) The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a Notice.

change to this contract. Except for changes identified in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing promptly, within (to be negotiated) calendar days from the date that the Contractor identifies any Government ____ conduct that the Contractor regards as a change to the contract terms and conditions. Examples of conduct that may be regarded as a change to terms and conditions include actions, inactions, and written or oral communications. On the basis of the most accurate information available to the Contractor, the notice shall state-

(1) The date, nature, and circumstances of the conduct regarded as a change;

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

(3) The identification of any documents and the substance of any oral communication involved in such conduct;

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including-

(i) What line items have been or may be affected by the alleged change;

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;

(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be caused by the alleged change;

(iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and

(6) The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.

(c) Following submission of the notice required by paragraph (b) of this clause, the Contractor shall diligently continue Continued performance.

performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance. However, if the Contractor regards the direction or communication as a change as described in paragraph (b) of this clause, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing promptly and copies furnished to the Contractor and to the Contracting Officer. The Contracting Officer shall promptly countermand any action which exceeds the authority of the SAR.

(d) The Contracting Officer shall promptly, within (to be negotiated) calendar days after receipt of notice, respond to Government response. ____ the notice in writing. In responding, the Contracting Officer shall either-

(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;

(2) Countermand any communication regarded as a change;

(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or

(4) In the event the Contractor's notice information is inadequate to make a decision under (1), (2), or (3) of paragraph (d) of this clause, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.

.(e) Equitable adjustments

If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase (1) or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-

(i) In the contract price or delivery schedule or both; and

(ii) In such other provisions of the contract as may be affected.

(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property.