2-PAF180200-Specs_SIGNED.pdf

FEC HAWAII

WORK ORDER NO. 1606003

SPECIFICATIONS

For

FY20 MCON Project PAF180200 Asia Pacific Resiliency – Jet Fuel Storage Tanks

At the

Royal Australian Air Force (RAAF) Base Tindal, Australia

PREPARED BY:

HDR Engineering, Inc.

1001 Bishop Street, Suite 400

Honolulu, Hawaii 96813

A/E Contract Number N62742-17-D-0004

Architectural: Austin Brockenbrough & Associates Civil: HDR Engineering, Inc.

Corrosion Protection: Coffman Engineers, Inc.

Cost Estimating: WT Partnership Australia Pty Ltd Electrical: Austin Brockenbrough & Associates Environmental: HDR Engineering, Inc.

Fire Protection: Coffman Engineers, Inc.

Fuels System: Enterprise Engineering Inc.

Geotechnical: Douglas Partners Pty Ltd Mechanical: Austin Brockenbrough & Associates Structural: Austin Brockenbrough & Associates Surveying: Gardner Group Pty Ltd Topographic: Bennett and Bennett Pty Ltd

Submitted By: Date: 09 November 2020 Francis T. Hino, Vice President

APPROVED BY:

Specifications:

For Commander, NAVFAC:

Date:

THIS DOCUMENT IS THE SUBJECT OF

BUILDING APPROVAL NUMBER

REF # 201029-19543-BA-Filter Bld REF # 201029-19543-BA-Gantry Bld

REF # 201029-19543-BA-Kiosk Substation REF # 201029-19543-BA-Pump Vault 1 REF # 201029-19543-BA-Pump Vault 2

DATED: 29/10/2020

GARDNER GROUP PTY LTD

FY20 MCON Project PAF180200 APR - Jet Fuel Storage Tanks 1606003 Royal Australia Air Force (RAAF) Base Tindal, Australia

THIS PAGE INTENTIONALLY LEFT BLANK

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 15 LIST OF DRAWINGS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 14 00 WORK RESTRICTIONS

01 20 00.00 20 PRICE AND PAYMENT PROCEDURES

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 31 23.13 20 ELECTRONIC CONSTRUCTION AND FACILITY SUPPORT CONTRACT

MANAGEMENT SYSTEM

01 32 17.00 20 COST-LOADED NETWORK ANALYSIS SCHEDULES (NAS)

01 33 00 SUBMITTAL PROCEDURES

01 33 29 SUSTAINABILITY REPORTING

01 35 13.01 SPECIAL PROJECT PROCEDURES FOR ESTATE PROJECT LIFECYCLE

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 42 15 METRIC MEASUREMENTS

01 45 00.00 20 QUALITY CONTROL

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 58 00 PROJECT IDENTIFICATION

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 78 24.00 20 FACILITY ELECTRONIC OPERATION AND MAINTENANCE SUPPORT

INFORMATION (eOMSI)

01 91 00.15 BUILDING COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION AND DECONSTRUCTION

DIVISION 03 - CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

03 45 00 PRECAST ARCHITECTURAL CONCRETE

DIVISION 05 - METALS

05 12 00 STRUCTURAL STEEL

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 00 METAL STAIRS

05 51 33 METAL LADDERS

05 52 00 METAL RAILINGS

05 59 10 ROLLING COVER FOR AVIATION REFUELING VAULTS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 11 13 BITUMINOUS DAMPPROOFING

07 12 00 BUILT-UP BITUMINOUS WATERPROOFING

07 21 13 BOARD AND BLOCK INSULATION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

PROJECT TABLE OF CONTENTS Page 1

07 41 63 FABRICATED ROOF PANEL ASSEMBLIES

07 42 63 FABRICATED WALL PANEL ASSEMBLIES

07 54 19 POLYVINYL-CHLORIDE ROOFING

07 60 00 FLASHING AND SHEET METAL

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 31 00 ACCESS DOORS AND PANELS

08 34 02 BULLET-RESISTANT COMPONENTS

08 51 23 STEEL WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL WALL AND DOOR LOUVERS

DIVISION 09 - FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 67 23.15 FUEL RESISTIVE RESINOUS FLOORING, 3-COAT SYSTEM

09 69 13 RIGID GRID ACCESS FLOORING

09 90 00 PAINTS AND COATINGS

09 97 13.17 THREE COAT EPOXY INTERIOR COATING OF WELDED STEEL

PETROLEUM FUEL TANKS

09 97 13.27 EXTERIOR COATING OF STEEL STRUCTURES

DIVISION 10 - SPECIALTIES

10 14 00.20 INTERIOR SIGNAGE

10 28 13 TOILET ACCESSORIES

DIVISION 13 - SPECIAL CONSTRUCTION

13 34 19 METAL BUILDING SYSTEMS

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 81 00.00 20 UNITARY AIR CONDITIONING EQUIPMENT

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 08 00 APPARATUS INSPECTION AND TESTING

26 11 16 SECONDARY UNIT SUBSTATIONS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 24 13 SWITCHBOARDS

26 32 13.00 20 SINGLE OPERATION GENERATOR SETS

PROJECT TABLE OF CONTENTS Page 2

26 41 00 LIGHTNING PROTECTION SYSTEM

26 42 13.00 20 CATHODIC PROTECTION BY GALVANIC ANODES

26 51 00 INTERIOR LIGHTING

26 56 00 EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 31 63.00 20 ANALOG/ADDRESSABLE INTERIOR FIRE ALARM SYSTEM

DIVISION 31 - EARTHWORK

31 05 20 GEONET

31 11 00 CLEARING AND GRUBBING

31 23 00.00 20 EXCAVATION AND FILL

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

32 11 20 SUBBASES FOR FLEXIBLE AND RIGID PAVING

32 11 23 AGGREGATE BASE COURSES

32 12 13 BITUMINOUS TACK AND PRIME COATS

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 14.13 CONCRETE PAVING FOR AIRFIELDS AND OTHER HEAVY DUTY

PAVEMENTS

32 16 19 CONCRETE KERBS, GUTTERS AND SIDEWALKS

32 17 23 PAVEMENT MARKINGS

32 31 13.53 HIGH-SECURITY FENCES (CHAIN LINK AND ORNAMENTAL) AND GATES

32 92 19 SEEDING

DIVISION 33 - UTILITIES

33 01 50.60 CLEANING OF PETROLEUM STORAGE TANKS

33 08 53 AVIATION FUEL DISTRIBUTION SYSTEM START-UP

33 09 53 AVIATION FUEL PUMP CONTROL AND ANNUNCIATION SYSTEM

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 30 00 SANITARY SEWERAGE

33 40 00 STORM DRAINAGE UTILITIES

33 52 23.15 POL SERVICE PIPING WELDING

33 52 43.11 AVIATION FUEL MECHANICAL EQUIPMENT

33 52 43.12 AVIATION FUEL PANTOGRAPHS

33 52 43.13 AVIATION FUEL PIPING

33 52 43.14 AVIATION FUEL CONTROL VALVES

33 52 43.23 AVIATION FUEL PUMPS

33 52 43.28 FILTER SEPARATOR, AVIATION FUELING SYSTEM

33 56 10 FACTORY-FABRICATED FUEL STORAGE TANKS

33 56 19 FUEL IMPERMEABLE LINER SYSTEM

33 56 21.17 SINGLE WALL ABOVEGROUND FIXED ROOF STEEL POL STORAGE TANK

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 3

PROJECT TABLE OF CONTENTS Page 4

DOCUMENT 00 01 15

LIST OF DRAWINGS

02/11

PART 1 GENERAL

1.1 SUMMARY

This section lists the drawings for the project pursuant to contract clause "DFARS 252.236-7001, Contract Drawings, Maps and Specifications."

1.2 CONTRACT DRAWINGS

Contract drawings are as follows:

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

1 G-001 17254128 TITLE SHEET, VICINITY MAP, AND LOCATION MAP

2 G-002 17254129 INDEX OF DRAWINGS

3 G-003 17254130 INDEX OF DRAWINGS

4 G-004 17254131 LEGEND, ABBREVIATIONS, AND SYMBOLS

5 G-005 17254132 GENERAL NOTES

6 G-006 17254133 BORING LOGS LEGEND

7 G-007 17254134 BORING LOGS 1

8 G-008 17254135 BORING LOGS 2

9 G-009 17254136 BORING LOGS 3

10 G-010 17254137 BORING LOGS 4

11 G-011 17254138 BORING LOGS 5

12 G-012 17254139 BORING LOGS 6

13 G-013 17254140 BORING LOGS 7

14 G-014 17254141 BORING LOGS 8

15 G-015 17254142 BORING LOGS 9

16 G-016 17254143 BORING LOGS 10

17 G-017 17254144 BORING LOGS 11

18 G-018 17254145 BORING LOGS 12

19 G-019 17254146 BORING LOGS 13

20 G-020 17254147 BORING LOGS 14

21 G-021 17254148 BORING LOGS 15

22 G-022 17254149 BORING LOGS 16

23 G-023 17254150 BORING LOGS 17

DOCUMENT 00 01 15 Page 1

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

24 G-024 17254151 BORING LOGS 18

25 G-025 17254152 BORING LOGS 19

26 G-026 17254153 BORING LOGS 20

27 G-027 17254154 BORING LOGS 21

28 G-028 17254155 BORING LOGS 22

29 G-029 17254156 BORING LOGS 23

30 G-030 17254157 BORING LOGS 24

31 G-031 17254158 BORING LOGS 25

32 A-001 17254159 ARCHITECTURAL LEGEND, ABBREVIATIONS, AND

SYMBOLS

33 A-002 17254160 ARCHITECTURAL SITE PLAN

34 A-003 17254161 ARCHITECTURAL SITE PLAN

35 A-111 17254162 FILTER BUILDING PLAN

36 A-112 17254163 FILTER BUILDING ROOF PLAN

37 A-113 17254164 FILTER BUILDING REFLECTED CEILING PLAN

38 A-121 17254165 PUMP VAULT FLOOR PLANS

39 A-122 17254166 PUMP VAULT ROOF PLANS

40 A-131 17254167 GANTRY FLOOR PLAN

41 A-132 17254168 GANTRY ROOF PLAN

42 A-211 17254169 FILTER BUILDING ELEVATIONS

43 A-212 17254170 FILTER BUILDING ELEVATIONS

44 A-221 17254171 PUMP VAULT ELEVATIONS

45 A-231 17254172 GANTRY ELEVATIONS

46 A-311 17254173 FILTER BUILDING SECTIONS

47 A-321 17254174 PUMP VAULT SECTIONS

48 A-331 17254175 GANTRY SECTIONS

49 A-411 17254176 FILTER BUILDING ENLARGED PLAN & INTERIOR

ELEVATIONS

50 A-511 17254177 FILTER BUILDING WALL SECTIONS & DETAILS

51 A-512 17254178 FILTER BUILDING DETAILS

52 A-513 17254179 FILTER BUILDING DETAILS

53 A-521 17254180 PUMP VAULT WALL SECTIONS & DETAILS

54 A-522 17254181 PUMP VAULT DETAILS

DOCUMENT 00 01 15 Page 2

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

55 A-601 17254182 SCHEDULES AND DETAILS

56 A-602 17254183 SCHEDULES AND DETAILS

57 C-001 17254184 OVERALL FACILITIES MAP

58 C-002 17254185 EXISTING CONDITIONS AND SURVEY CONTROL PLAN

59 C-003 17254186 BORING LOCATION PLAN

60 C-101 17254187 DEMOLITION PLAN

61 C-102 17254188 EROSION CONTROL PLAN

62 C-103 17254189 SITE SURFACING PLAN

63 C-201 17254190 OVERALL SITE PLAN

64 C-202 17254191 SITE AND GEOMETRIC PLAN 1

65 C-203 17254192 SITE AND GEOMETRIC PLAN 2

66 C-204 17254193 SITE AND GEOMETRIC PLAN 3

67 C-205 17254194 SITE AND GEOMETRIC PLAN 4

68 C-206 17254195 SITE AND GEOMETRIC PLAN 5

69 C-207 17254196 SITE AND GEOMETRIC PLAN 6

70 C-208 17254197 GANTRY ENLARGEMENT PLAN

71 C-209 17254198 FILTER BUILDING ENLARGEMENT PLAN

72 C-210 17254199 TURNING PATHS - ROAD TRAIN

73 C-211 17254200 TURNING PATHS - AIRCRAFT REFUELER

74 C-220 17254201 CIVIL SITE SETOUT PLAN

75 C-230 17254202 PAVEMENT BID OPTION - OVERALL SITE PLAN

76 C-231 17254203 PAVEMENT BID OPTION - SITE AND GEOMETRIC PLAN

77 C-232 17254204 PAVEMENT BID OPTION - SITE AND GEOMETRIC PLAN

78 C-233 17254205 PAVEMENT BID OPTION - SITE AND GEOMETRIC PLAN

79 C-234 17254206 PAVEMENT BID OPTION - SITE AND GEOMETRIC PLAN

80 C-240 17254207 OVERALL SITE SIGNAGE AND STRIPING PLAN

81 C-301 17254208 OVERALL JOINTING PLAN

82 C-302 17254209 JOINTING PLAN 1

83 C-303 17254210 JOINTING PLAN 2

DOCUMENT 00 01 15 Page 3

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

84 C-304 17254211 JOINTING PLAN 3

85 C-401 17254212 OVERALL GRADING AND DRAINAGE PLAN

86 C-402 17254213 GRADING AND DRAINAGE PLAN 1

87 C-403 17254214 GRADING AND DRAINAGE PLAN 2

88 C-404 17254215 GRADING AND DRAINAGE PLAN 3

89 C-405 17254216 GRADING AND DRAINAGE PLAN 4

90 C-406 17254217 GRADING AND DRAINAGE PLAN 5

91 C-407 17254218 GRADING AND DRAINAGE PLAN 6

92 C-410 17254219 GANTRY ENLARGEMENT PLAN

93 C-411 17254220 FILTER BUILDING ENLARGEMENT PLAN

94 C-420 17254221 SITE SECTIONS

95 C-421 17254222 SITE SECTIONS

96 C-422 17254223 ROADWAY SITE PLAN AND PROFILE PLAN 1

97 C-423 17254224 ROADWAY SITE PLAN AND PROFILE PLAN 2

98 C-424 17254225 ROADWAY SITE PLAN AND PROFILE PLAN 3

99 C-425 17254226 ROADWAY SITE PLAN AND PROFILE PLAN 4

100 C-426 17254227 ROADWAY SITE PLAN AND PROFILE PLAN 5

101 C-430 17254228 STORM DRAINAGE 401 PLAN AND PROFILE

102 C-431 17254229 STORM DRAINAGE 301 PLAN AND PROFILE

103 C-432 17254230 GANTRY DRAINAGE PLAN AND PROFILE

104 C-433 17254231 CONTAINMENT DRAINAGE PLAN AND PROFILE

105 C-434 17254232 ACCESS ROAD CULVERT PLAN AND PROFILE

106 C-440 17254233 OVERALL PAVEMENT SUBSOIL DRAINAGE PLAN

107 C-501 17254234 OVERALL SITE UTILITIES PLAN

108 C-502 17254235 SITE UTILITIES - WATER LINE

109 C-503 17254236 SITE UTILITIES - SEWER LINE

110 C-504 17254237 SITE UTILITIES - FIRE LOOP - STA 0+000 TO

0+110

111 C-505 17254238 SITE UTILITIES - FIRE LOOP - STA 0+110 TO

0+230

DOCUMENT 00 01 15 Page 4

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

112 C-506 17254239 SITE UTILITIES - FIRE LOOP - STA 0+230 TO

0+350

113 C-507 17254240 SITE UTILITIES - FIRE LOOP - STA 0+350 TO

0+400

114 C-508 17254241 SITE UTILITIES - WATER MAIN TO GANTRY

115 C-509 17254242 SITE UTILITIES - GANTRY SHOWER LINE

116 C-510 17254243 OVERALL POL PIPING PLAN

117 C-511 17254244 OVERALL POL PIPING PLAN

118 C-520 17254245 POL PIPING - GANTRY TO DROP TANK

119 C-521 17254246 POL PIPING - GANTRY DRAIN LINE

120 C-522 17254247 POL PIPING - FILTER BUILDING TO TANK T-0400

PUMP VAULT

121 C-523 17254248 POL PIPING - FILTER BUILDING TO TANK T-0300

PUMP VAULT

122 C-524 17254249 POL PIPING - TANK T-0400 PUMP VAULT TO FILTER

BUILDING

123 C-525 17254250 POL PIPING - TANK T-0300 PUMP VAULT TO FILTER

BUILDING

124 C-526 17254251 POL PIPING - HYDRANT LOOP

125 C-527 17254252 POL PIPING - GANTRY TO FILTER BUILDING

126 C-528 17254253 POL PIPING - GANTRY TO PRODUCT RECOVERY TANK

127 C-529 17254254 POL PIPING - TANK T-0400 PUMP VAULT TO

PRODUCT RECOVERY TANK

128 C-530 17254255 POL PIPING - TANK T-0300 PUMP VAULT TO

PRODUCT RECOVERY TANK

129 C-531 17254256 POL PIPING - FILTER BUILDING TO PRODUCT

130 C-532 17254257 POL PIPING - FILTER BUILDING TO TRANSFER PIT

131 C-533 17254258 POL PIPING - FILTER BUILDING TO TRANSFER PIT

132 C-534 17254259 POL PIPING - FILTER BUILDING TO TRANSFER PIT

133 C-535 17254260 POL PIPING - HYDRANT LOOP TO GANTRY

134 C-536 17254261 POL PIPING - DROP TANK TO FILTER BUILDING

135 C-537 17254262 POL PIPING - FILTER BUILDING TO GENERATOR

136 C-538 17254263 POL PIPING - PRODUCT RECOVERY TANK TO FILTER

137 C-539 17254264 POL PIPING - TANK T-0300 TO TANK LEAK

138 C-540 17254265 POL PIPING - TANK T-0400 TO TANK LEAK

DETECTION PIT

DOCUMENT 00 01 15 Page 5

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

139 C-601 17254266 CIVIL DETAILS

140 C-602 17254267 CIVIL DETAILS

141 C-603 17254268 CIVIL DETAILS

142 C-604 17254269 CIVIL DETAILS

143 C-605 17254270 CIVIL DETAILS

144 C-606 17254271 CIVIL DETAILS

145 C-607 17254272 CIVIL DETAILS

146 C-608 17254273 CIVIL DETAILS

147 C-609 17254274 CIVIL DETAILS

148 C-610 17254275 CIVIL DETAILS

149 C-611 17254276 CIVIL DETAILS

150 C-612 17254277 CIVIL DETAILS

151 C-613 17254278 CIVIL DETAILS

152 C-614 17254279 CIVIL DETAILS

153 C-615 17254280 CIVIL DETAILS

154 C-616 17254281 CIVIL DETAILS

155 CP-001 17254282 CATHODIC PROTECTION NOTES

156 CP-101 17254283 CATHODIC PROTECTION SITE PLAN

157 CP-102 17254284 CATHODIC PROTECTION SITE PLAN

158 CP-501 17254285 CATHODIC PROTECTION SECTIONS AND DETAIL

159 CP-502 17254286 CATHODIC PROTECTION JUNCTION BOX DETAILS

160 CP-503 17254287 CATHODIC PROTECTION DETAILS

161 CP-504 17254288 CATHODIC PROTECTION DETAILS

162 CP-505 17254289 CATHODIC PROTECTION DETAILS

163 E-001 17254290 ELECTRICAL ABBREVIATIONS AND NOTES

164 E-002 17254291 ELECTRICAL LEGENDS

165 E-101 17254292 ELECTRICAL SITE PLAN

166 E-102 17254293 RAAF FUEL FARM SITE PLAN

167 E-103 17254294 TELECOMMUNICATIONS SITE PLAN

168 E-401 17254295 FILTER BUILDING LIGHTING PLAN

169 E-402 17254296 FILTER BUILDING POWER & CONTROLS PLAN

170 E-403 17254297 FILTER BUILDING EARTHING PLAN

171 E-404 17254298 FILTER BUILDING LIGHTNING PROTECTION PLAN

172 E-405 17254299 PUMP VAULT LIGHTING & EARTHING PLANS

DOCUMENT 00 01 15 Page 6

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

173 E-406 17254300 PUMP VAULT POWER & CONTROLS PLANS

174 E-407 17254301 GANTRY LIGHTING PLAN

175 E-408 17254302 GANTRY POWER PLAN

176 E-409 17254303 GANTRY CONTROLS PLAN

177 E-410 17254304 GANTRY EARTHING & LIGHTNING PROTECTION PLAN

178 E-411 17254305 KIOSK SUBSTATION PARTIAL PLANS

179 E-412 17254306 UNDERGROUND TANKS POWER & CONTROLS PLAN

180 E-413 17254307 UNDERGROUND TANKS LIGHTING & EARTHING PLANS

181 E-414 17254308 GENERATOR PARTIAL PLAN

182 E-501 17254309 DETAILS

183 E-502 17254310 DETAILS

184 E-503 17254311 DETAILS

185 E-504 17254312 DETAILS

186 E-601 17254313 SINGLE-LINE DIAGRAMS

187 E-602 17254314 SINGLE-LINE DIAGRAMS

188 E-603 17254315 SINGLE-LINE DIAGRAMS

189 E-604 17254316 WIRING DIAGRAMS

190 E-605 17254317 ESD SYSTEM WIRING DIAGRAM

191 E-606 17254318 WIRING DIAGRAMS

192 E-607 17254319 WIRING DIAGRAMS

193 E-608 17254320 USFF EARTHING SYSTEM DIAGRAM

194 E-609 17254321 CABLE, LIGHTING, AND MCC SCHEDULES

195 E-610 17254322 CONTROL CIRCUIT SCHEDULE

196 E-611 17254323 CONTROL CIRCUIT SCHEDULE

197 E-612 17254324 POWER CIRCUIT SCHEDULE

198 E-613 17254325 PUMP CONTROL PANEL ELEVATION

199 E-614 17254326 ANNUNCIATOR PANEL LAYOUT

200 E-615 17254327 TERMINAL BLOCK CONNECTIONS

201 E-616 17254328 TERMINAL BLOCK CONNECTIONS

202 E-617 17254329 TERMINAL BLOCK CONNECTIONS

203 E-618 17254330 TERMINAL BLOCK CONNECTIONS

204 E-701 17254331 INTERIOR LIGHTING DETAILS

205 E-702 17254332 EXTERIOR LIGHTING DETAILS

206 E-703 17254333 UNDERGROUND STRUCTURE DETAILS

207 E-704 17254334 HAZARDOUS AREA CLASSIFICATION PLANS

208 E-705 17254335 HAZARDOUS AREA CLASSIFICATION PLANS

209 E-706 17254336 HAZARDOUS AREA CLASSIFICATION PLANS

DOCUMENT 00 01 15 Page 7

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

210 F-001 17254337 FIRE PROTECTION NOTES, SYMBOLS AND

ABBREVIATIONS

211 F-002 17254338 FILTER BUILDING - ZONE BLOCK PLAN

212 F-003 17254339 FIRE ALARM SYSTEM FIBER OPTIC CABLE AND

CONDUIT SITE PLAN

213 F-101 17254340 FILTER BUILDING - LIFE SAFETY PLAN

214 F-102 17254341 PUMP VAULT - LIFE SAFETY PLAN

215 F-103 17254342 GANTRY - LIFE SAFETY PLAN

216 F-104 17254343 FILTER BUILDING - FIRE PROTECTION PLAN

217 F-105 17254344 PUMP VAULT - FIRE PROTECTION PLAN

218 F-106 17254345 GANTRY - FIRE PROTECTION PLAN

219 F-501 17254346 FIRE PROTECTION DETAILS

220 M-001 17254347 ABBREVIATIONS AND LEGENDS

221 M-002 17254348 SEQUENCE OF OPERATIONS 1

222 M-003 17254349 SEQUENCE OF OPERATIONS 2

223 M-004 17254350 SEQUENCE OF OPERATIONS 3

224 M-005 17254351 SEQUENCE OF OPERATIONS 4

225 M-010 17254352 OVERALL FUEL SYSTEM FLOW DIAGRAM

226 M-011 17254353 BULK STORAGE TANK (T-0300) FLOW DIAGRAM

227 M-012 17254354 BULK STORAGE TANK (T-0400) FLOW DIAGRAM

228 M-013 17254355 FILTER BUILDING RECEIPT PIPING FLOW DIAGRAM

229 M-014 17254356 FILTER BUILDING ISSUE PIPING FLOW DIAGRAM

230 M-015 17254357 QCI/DROP TANK (T-2600) FLOW DIAGRAM

231 M-016 17254358 GANTRY FLOW DIAGRAM

232 M-017 17254359 HYDRANT LOOP CROSSOVER VALVE PIT FLOW DIAGRAM

233 M-018 17254360 TRANSFER PIT FLOW DIAGRAM

234 M-019 17254361 PRODUCT RECOVERY TANK AND WASTE TANK FLOW

DIAGRAM

235 M-020 17254362 GENERATOR FLOW DIAGRAM

236 M-021 17254363 ENLARGED VENTURI, PIT, AND RECEIPT METER FLOW

DIAGRAM

237 M-101 17254364 OVERALL POL PIPING PLAN

238 MS101 17254365 FILTER BUILDING AND GANTRY FACILITY

ARRANGEMENT PLAN

239 M-102 17254366 TANK (T-0300) PUMP VAULT PIPING PLAN

DOCUMENT 00 01 15 Page 8

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

240 M-103 17254367 TANK (T-0400) PUMP VAULT PIPING PLAN

241 M-104 17254368 FILTER BUILDING MAJOR PIPING PLAN

242 M-105 17254369 FILTER BUILDING MINOR PIPING PLAN

243 M-106 17254370 GENERATOR PIPING PLAN

244 M-107 17254371 DROP TANK AND WASTE TANK PIPING PLAN

245 M-108 17254372 DROP TANK AND PRT PIPING PLAN

246 M-109 17254373 WEST GANTRY PIPING PLAN

247 M-110 17254374 EAST GANTRY PIPING PLAN

248 M-111 17254375 HYDRANT LOOP CROSSOVER VALVE PIT

249 M-112 17254376 TRANSFER PIT

250 M-201 17254377 PUMP VAULT PIPING SECTIONS

251 M-202 17254378 PUMP VAULT PIPING ELEVATIONS

252 M-203 17254379 FILTER BUILDING PIPING SECTIONS AND

ELEVATIONS 1

253 M-204 17254380 FILTER BUILDING PIPING SECTIONS AND

ELEVATIONS 2

254 M-205 17254381 PIG LAUNCHER AND RECEIVER PIPING ELEVATIONS

255 M-206 17254382 QCI/DROP TANK PIPING ELEVATIONS

256 M-207 17254383 PRT AND WASTE TANK PIPING ELEVATIONS

257 M-208 17254384 TRUCK OFFLOAD PIPING ELEVATIONS

258 M-209 17254385 TRUCK FILLSTAND AND BOWSER OFFLOAD PIPING

ELEVATIONS

259 M-210 17254386 HYDRANT HOSE TRUCK CHECKOUT STATION PIPING

ELEVATIONS

260 M-501 17254387 MECHANICAL POL DETAILS 1

261 M-502 17254388 MECHANICAL POL DETAILS 2

262 M-503 17254389 PIPE SUPPORT DETAILS 1

263 M-504 17254390 PIPE SUPPORT DETAILS 2

264 M-505 17254391 BULK TANK DETAILS

265 M-506 17254392 FILTER BUILDING DETAILS 1

DOCUMENT 00 01 15 Page 9

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

266 M-507 17254393 FILTER BUILDING DETAILS 2

267 M-508 17254394 HORIZONTAL UST DETAILS

268 M-509 17254395 GANTRY DETAILS

269 M-510 17254396 QCI/DROP TANK (T-2600) DETAIL

270 M-511 17254397 PRODUCT RECOVERY TANK (T-2700) DETAIL

271 M-512 17254398 WASTE TANK (T-2800) DETAIL

272 M-601 17254399 MECHANICAL POL EQUIPMENT SCHEDULES 1

273 M-602 17254400 MECHANICAL POL EQUIPMENT SCHEDULES 2

274 M-603 17254401 VALVE POSITION SUPERVISION SCHEDULE

275 M-604 17254402 TANK LEVEL SETPOINTS

276 MH001 17254403 MECHANICAL ABBREVIATIONS, LEGEND AND NOTES

277 MH401 17254404 FILTER BUILDING HVAC PLAN

278 MH402 17254405 PUMP VAULT HVAC PLANS

279 MH501 17254406 SCHEDULES AND DETAILS

280 P-001 17254407 PLUMBING ABBREVIATIONS, LEGEND AND NOTES

281 P-401 17254408 FILTER BUILDING PLUMBING PLAN

282 S-001 17254409 STRUCTURAL ABBREVIATIONS, LEGEND AND NOTES

283 S-002 17254410 STRUCTURAL ABBREVIATIONS, LEGEND AND NOTES

284 S-101 17254411 BULK TANK SITE PLAN AND SECTION

285 S-401 17254412 BULK TANK FLOOR SLAB REINFORCING PLAN

286 S-402 17254413 BULK TANK RADIAL GUTTER PLAN

287 S-403 17254414 BULK TANK COLUMN LAYOUT PLAN

288 S-404 17254415 BULK TANK ROOF PLANS

289 S-405 17254416 BULK TANK ROOF SLAB REINFORCING PLAN

290 S-406 17254417 PUMP VAULT FLOOR PLANS

291 S-407 17254418 PUMP VAULT ROOF FRAMING PLAN AND SECTIONS

292 S-408 17254419 FILTER BUILDING FOUNDATION PLAN

293 S-409 17254420 FILTER BUILDING PIPE SUPPORT PLAN

294 S-410 17254421 FILTER BUILDING ROOF FRAMING PLAN AND SECTIONS

295 S-411 17254422 FILTER BUILDING ROOF TRUSS PLAN AND SECTION

DOCUMENT 00 01 15 Page 10

Sheet No.

Drawing No.

NAVFAC

Drawing No.

Sheet Title

296 S-412 17254423 GANTRY FOUNDATION PLAN

297 S-413 17254424 GANTRY ROOF FRAMING PLAN

298 S-414 17254425 DROP TANK COVER FOUNDATION PLAN AND DETAILS

299 S-415 17254426 DROP TANK COVER ROOF FRAMING PLAN AND DETAILS

300 S-416 17254427 REMOTE CONTAINMENT BASIN PLAN AND DETAILS

301 S-417 17254428 HYDRANT LOOP CROSSOVER VALVE PIT PLAN AND

DETAILS

302 S-418 17254429 TRANSFER PIT PLAN AND DETAILS

303 S-419 17254430 BERM ACCESS STAIR PLANS AND DETAILS

304 S-501 17254431 BULK TANK DETAILS AND SECTIONS

305 S-502 17254432 BULK TANK DETAILS AND SECTIONS

306 S-503 17254433 BULK TANK DETAILS AND SECTIONS

307 S-504 17254434 BULK TANK DETAILS AND SECTIONS

308 S-505 17254435 PUMP VAULT REINFORCEMENT ELEVATIONS

309 S-506 17254436 FILTER BUILDING REINFORCEMENT ELEVATIONS

310 S-507 17254437 FILTER BUILDING PIPE SUPPORT DETAILS

311 S-508 17254438 FILTER BUILDING PIPE SUPPORT DETAILS

312 S-509 17254439 FILTER BUILDING DETAILS AND SECTIONS

313 S-510 17254440 GANTRY SECTION

314 S-511 17254441 GANTRY DETAILS

315 S-512 17254442 METAL STAIR PLANS AND DETAILS

316 S-513 17254443 METAL STAIR PLANS AND DETAILS

317 S-514 17254444 ROLLING COVER DETAILS

318 S-515 17254445 ROLLING COVER DETAILS

319 S-516 17254446 ROLLING COVER DETAILS

-- End of Document --

DOCUMENT 00 01 15 Page 11

DOCUMENT 00 01 15 Page 12

Royal Australian Air Force (RAAF) Base Tindal, Australia

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 GENERAL REQUIREMENTS

The Contractor acknowledges and agrees that:

a. the Contractor is a party to the contract with the Naval Facilities Engineering Command, Pacific (NAVFAC Pacific) to carry out the Contractor's Activities and Works on the Royal Australian Air Force (RAAF) base;

b. the Contracting Officer is an employee of the Naval Facilities Engineering Command who NAVFAC Pacific has assigned administration and enforcement authority and responsibility for this contract;

c. Australian Requirements are laws, codes, decrees, labor standards, and regulations of the host country, Commonwealth, State and Territory, currently in effect, that the Contractor is required to comply with, including but not limited to the Australian Requirements Schedule attached at the end of this section;

d. the Contractor is responsible for ensuring it complies with all requirements of the contract, including the Division 01 (General Requirements), Australian Requirements, and any other laws, codes, decrees, labor standards, and regulations of the host country, Commonwealth, State and Territory; Federal Acquisition Regulation (FAR) 52.236-7, Permits and Responsibilities; Defense Federal Acquisition Regulation Supplement (DFARS) 252.222-7002, Compliance with Local Labor Laws (Overseas) of the Request For Proposal, Document 00700;

e. if the Contractor identifies any ambiguity, discrepancy or inconsistency between the requirements of the contract, including the requirements of Division 01, Australian Requirements, and any other laws, codes, decrees, labor standards, and regulations of the host country, Commonwealth, State and Territory, the Contractor must immediately submit a Request for Information (RFI) to the Contracting Officer clearly describing the ambiguity, discrepancy and inconsistency and offer a proposed solution;

f. Immediately notify the Contracting Officer if the Commonwealth or any person authorised by the Commonwealth impedes, disrupts, or frustrates the Contractor's performance of the Contract, or otherwise causes potential Contractor delay; and

g. when an Australian standard or requirement is offered as an equivalent to a U.S. standard or requirement, the Contractor must furnish documentation proving equivalency.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes constructing two 4 ML(25,000 BBL ea)

SECTION 01 11 00 Page 1

Cut'N'Cover bulk fuel storage tanks using standard design and construction methods to accommodate USAF mission aircraft training at Royal Australian Air Force Base (RAAF) Tindal. Project also includes constructing an aircraft liquid fuel truck fillstand, fuel stand unloading, pumphouses, and filter building. Local materials and construction techniques must be used where cost effective. All utilities, automatic tank gauging systems, site improvements, pavements, communications infrastructure, backup generator and other work necessary to provide complete and usable facilities is included in the project.

Facilities will be designed and constructed in accordance with the DoD Unified Facilities Criteria (UFC) 1-202-01, Host Nation Facilities in Support of Military Operations. This project will comply with DoD Antiterrorism/force protection requirements per UFC 4-010-01. The project will comply with applicable criteria contained in the National Construction Code and Australian Government Department of Defence Manual of Fire Protection Engineering to enable interoperability of facilities with local fire services, and incidental related work.

In addition to the requirements specified in the Contract Documents, all work must also be conducted in accordance with the applicable Australian legislation, Australian codes of practice, applicable AS/NZS standards, Australian Defence policies, and relevant Australian Defence authorization.

1.2.2 Location

The work is located at the Royal Australian Air Force (RAAF) Base Tindal, Northern Territory, Australia, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.5 LOCATION OF UNDERGROUND UTILITIES

Obtain permit to work for excavation prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities. Contact the Contracting Officer to coordinate with RAAF Base Tindal for utility information prior to excavating, and within sufficient time required if work occurs on a Monday or after a Northern Territory public or regional holiday. Verify existing utility locations indicated on

SECTION 01 11 00 Page 2 contract drawings, within area of work.

Identify and mark all other utilities. Scan the construction site with Ground Penetrating Radar (GPR), electromagnetic, or sonic equipment, and mark the surface of the ground or paved surface where existing underground utilities are discovered. Verify the elevations of existing piping, utilities, and any type of underground or encased obstruction not indicated, or specified to be removed, that is indicated or discovered during scanning, in locations to be traversed by piping, ducts, and other work to be conducted or installed. Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.5.1 Notification Prior to Excavation

Notify the Contracting Officer at least 15 calendar days prior to starting excavation work.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 3

Version 1.4 dated September 09, 2020

Australian Requirements Schedule

1. Definitions

For the purposes of this Australian Requirements Schedule:

(a) ACM means asbestos containing material.

(b) Approvals means any licence, permit, consent, approval, determination, certificate, notice or other requirement any authority, body or organisation having any jurisdiction in connection with the Site, the Contractor's Activities or the Works or under any applicable Statutory Requirement, which must be obtained or satisfied to:

(i) carry out the Contractor's Activities or the Works; or

(ii) occupy, use, maintain or operate the completed Works.

(c) Classified Information includes:

(i) any Commonwealth document marked with a national security classification; and

(ii) any information that the Contractor knows or ought to know is subject to, or ought to be treated in accordance with, the provisions of the Defence Security Manual.

(d) Code of Federal Regulations (CFR) means the codification of the general and permanent rules and regulations (administrative law) published in the Federal Register by the executive departments and agencies of the U.S. Government.

(e) Code of Practice means a code of practice approved in accordance with the WHS Legislation.

(f) Commonwealth means the Commonwealth of Australia.

(g) Contamination means the presence in, on or under land, air or water of a substance (whether a solid, liquid, gas, odour, heat, sound, vibration or radiation) at a concentration above the concentration at which the substance is normally present in, on or under land, air or water in the same locality, that presents a risk of Environmental Harm, including harm to human health or any other aspect of the Environment, or could otherwise give rise to a risk of non-compliance with any Statutory Requirement for the protection of the Environment.

(h) Contract means the contract awarded under RFP [#INSERT] between the U.S. Government and the

Contractor to perform the construction of the Works.

(i) Contracting Officer has the meaning given in the Contract.

(j) Contractor has the meaning given in the Contract.

(k) Contractor's Activities means all things or tasks which the Contractor is, or may be, required to do to comply with its obligations under the Contract.

(l) Contractor HOTO Obligation means any task, function, requirement or obligation relating to the

HOTO Process (including commissioning of the Works) required to be performed by the Contractor under this Contract or which a HOTO Requirement allocates, or would reasonably be inferred as allocating, to the Contractor, including those that the HOTO Plan and Checklist expressly allocates to the "Contractor Representative" (as that term is used in the HOTO Plan and Checklist).

(m) Dangerous Goods has the meaning given in the Australian Code for the Transport of Dangerous Goods by Road and Rail, Edition 7.7.

(n) Defence means the Commonwealth Department of Defence.

(o) Defence Environmental Requirements means the Defence Environmental Management System and

Defence Environmental Plan applicable to the Site, the Contractor's Activities or the Works, including any procedures, instructions, requirements and standing orders which have been developed or issued under the Defence Environmental Management System or Defence Environmental Plan.

(p) Defence Environmental Management System means the environmental management system applicable to the Site (if any).

(q) Defence Environmental Plan means the environmental plan applicable to the Site (if any).

(r) Defence Requirements means all policies, plans, manuals, guidelines, instructions (including departmental procurement policy instructions) and other Commonwealth or Defence requirements which are, or may become, applicable to the Site, the Contractor's Activities or the Works. To the extent that any of the requirements would require or suggest the insertion of provisions into the Contract, then those provisions will be incorporated by reference into the Contract.

(s) Defence Security Principles Framework is a reference to that document available at https://www.defence.gov.au/dsvs/dspf.asp, as amended from time to time.

(t) Defense Federal Acquisition Regulation Supplement means the Department of Defense supplement to the Federal Acquisition Regulation (FAR) that contains requirements of U.S. law, DoD-wide policies, delegations of FAR authorities, deviations from FAR requirements, and DoD policies/procedures.

(u) DEQMS means the Defence Estate Quality Management System website available at www.defence.gov.au/estatemanagement.

(v) eDEOP 101 means the document titled “Defence Explosive Ordnance Publication (DEOP) 101 - Department of Defence Explosives Regulations” as amended from time to time.

(w) Effective Date means the date shown in Block 31C. AWARD DATE of the Standard Form (SF)

1442, SOLICITATION, OFFER, AND AWARD.

(x) EM 385-1-1 means the latest version of the U.S. Army Corps of Engineers manual in effect on the date the solicitation was issued (refer to Block 3. DATE ISSUED on the SF1442) and prescribing the safety and health requirements for construction contract work.

(y) Environment includes:

(i) ecosystems and their constituent parts, including people and communities;

(ii) natural and physical resources;

(iii) the qualities and characteristics of locations, places and areas; and

(iv) the social, economic, aesthetic and cultural aspects of a thing mentioned in paragraphs (i), (ii) or (iii).

(z) Environmental Clearance Certificate means the Environmental Clearance Certificate issued by the Commonwealth relating to the Contractor's Activities or the Works and any conditions incorporated in that certificate.

(aa) Environmental Harm means any actual or threatened adverse impact on, or damage to, the

Environment.

(bb) Environmental Incident means any Environmental Harm or Contamination arising out of or in connection with the Contractor's Activities or the Works.

(cc) Environmental Requirements includes the:

(i) Environmental Clearance Certificate; and

(ii) Defence Environmental Requirements.

(dd) EO CCC Plan has the meaning given in clause 5.3.

(ee) Federal Acquisition Regulation means the primary document of the United States Government Federal Acquisition Regulations System for the codification and publication of uniform policies and procedures for acquisition.

(ff) GHS means the Globally Harmonised System of Classification and Labelling of Chemicals published by the United Nations, (Rev.8) (2019), as modified by the relevant WHS Legislation.

https://www.unece.org/trans/danger/publi/ghs/ghs_rev08/08files_e.html

(gg) GHS Material means material suspected of containing or likely to contain a substance defined or listed in the GHS.

(hh) GST the tax payable on taxable supplies under the GST Legislation.

(ii) GST Legislation means A New Tax System (Goods and Services Tax) Act 1999 (Cth) and any related Act imposing such tax or legislation that is enacted to validate, recapture or recoup such tax.

(jj) Hazardous Chemical has the meaning given in subregulation 5(1) of the Work Health and Safety

Regulations 2011 (Cth) and includes:

(i) prohibited carcinogen, as defined in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth);

(ii) restricted carcinogen, as defined in subregulation 5(1) of the Work Health and Safety

Regulations 2011 (Cth);

(iii) hazardous chemicals the use of which is restricted under regulation 382 of the Work Health and Safety Regulations 2011 (Cth), including polychlorinated biphenyls;

(iv) Schedule 11 Hazardous Chemicals;

(v) hazardous chemicals listed in Table 14.1 of Schedule 14 of the Work Health and Safety

Regulations 2011(Cth);

(vi) Schedule 15 Chemicals; and

(vii) lead as defined in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth).

(kk) Hazardous Substances means Ozone Depleting Substances, Synthetic Greenhouse Gases, Hazardous

Chemicals or Dangerous Goods.

(ll) HOTO Plan and Checklist means the worksheets contained within the excel workbook titled "HOTO Plan & Checklist" available at https://defence.gov.au/estatemanagement/lifecycle/PlanHandoverTakeover/Default.asp, as updated, superseded or replaced from time to time.

HOTO Process means the process for handover and takeover of the Works to the Contracting Officer and the Commonwealth to enable the occupation, use, operation and maintenance of the Works by the Commonwealth and other users including the:

(i) commissioning of the Works (including the inspection and testing process);

(ii) handover of the Works; and

(iii) occupation, use, operation and maintenance of the Works by the Commonwealth and other users, in accordance with the HOTO Requirements.

HOTO Requirements means the requirements published on DEQMS in respect of the commissioning, handover and takeover of projects on the Defence Estate, including:

(i) the documents set out at https://defence.gov.au/estatemanagement/lifecycle/PlanHandoverTakeover/Default.asp, and all applicable requirements referred to therein; and

(ii) any other requirement published on DEQMS expressed as applying to the commissioning, handover and takeover of projects on the Defence Estate, each as updated, superseded or replaced from time to time.

(mm) NATA means National Association of Testing Authorities Australia.

(nn) MFPE means the Defence Manual of Fire Protection Engineering, as that document is amended from time to time.

(oo) National Construction Code means the National Construction Code that applies in the Northern

Territory, as amended from time to time, produced and maintained by the Australian Building Codes Board on behalf of the Commonwealth government and each Australian State and Territory government.

(pp) Ozone Depleting Substance means any substance identified as having ozone depleting potential in the

Ozone Protection and Synthetic Greenhouse Gas Management Act 1989 (Cth) or any regulations made under that Act.

(qq) Other Contractor means any other contractor, consultant, artist, tradesperson or other person engaged to do work at or in the vicinity of the Site other than the Contractor and its subcontractors.

(rr) PFAS means per- and poly-fluoroalkyl substances.

(ss) Plant, Equipment and Work means those things used, or work undertaken, by the Contractor to construct the Works but which will not form part of the Works.

(tt) Project Documents includes:

(i) Design documentation (shop drawings), Project Plans;

(ii) Approvals;

(iii) any other data, documents, drawings, records, information, and material produced or provided

(or required to be provided) to the Contracting Officer, under or in connection with the Contract, the Contractor's Activities or the Works by, for or on behalf of the Contractor (including by subcontractors); and

(iv) all material at any time derived (under or in connection with the Contract, the Contractor's

Activities or the Works) from, or based on, the material described in subparagraphs (i) and (iii).

(uu) Project Lifecycle and HOTO Plan means the plan prepared by the Contractor in accordance with, and for the purposes of, the HOTO Requirements and finalised under clause 4.2, which must:

(i) be prepared in accordance with the HOTO Plan and Checklist;

(ii) meet all applicable HOTO Requirements and Statutory Requirements; and

(iii) include any other matters required by:

A. the Contract; or B. the Contracting Officer or the Commonwealth.

(vv) Project Plans (also referred to in the Contract as Outline Project Plans) means the Environmental Management Plan, Project Lifecycle and HOTO Plan, Site Management Plan, Work Health and Safety Management Plan and (where required under clause 5.3) the EO CCC Plan.

(ww) Request for Information is a written request for information submitted by the Contractor to the

Contracting Officer. NAVFAC form is available from the Contracting Officer.

(xx) Schedule 11 Hazardous Chemical has the meaning given in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth).

(yy) Schedule 15 Chemical has the meaning given in subregulation 5(1) of the Work Health and Safety

Regulations 2011 (Cth).

(zz) Site means the site or sites for the Works as set out in the Contract.

(aaa) Smart Infrastructure Handbook means the Defence Smart Infrastructure Handbook: Planning, Design and Construction available on DEQMS, as amended from time to time.

(bbb) Statutory Requirements means:

(i) any law applicable to the Contractor's Activities or the Works (including Acts, ordinances, regulations, by-laws and other subordinate legislation) including those of the Commonwealth and the Northern Territory;

(ii) Approvals (including any condition or requirement under an Approval);

(iii) Defence Requirements; and

(iv) Environment Requirements.

(ccc) Synthetic Greenhouse Gas means any gas identified as a Synthetic Greenhouse Gas in the Ozone

Protection and Synthetic Greenhouse Gas Management Act 1989 (Cth) or in any regulations made under that Act.

(ddd) U.S. Government means the federal government of the United States.

(eee) WHS Legislation means:

(i) Work Health and Safety (National Uniform Legislation) Act 2011 (NT) and Work Health and Safety (National Uniform Legislation) Regulations 2011 (NT);

(ii) Work Health and Safety Act 2011 (Cth) and Work Health and Safety Regulations 2011

(Cth); and

(iii) any other legislation and Codes of Practice in the Northern Territory addressing work health and safety.

(fff) Work Health and Safety Plan is

(i) included as part of the Accident Prevention Plan submitted in accordance with Section 01 35 26 Government Safety Requirements and refers to Australian safety requirements in addition to those in the Contract; and

(ii) prepared by the Contractor and finalised under paragraph 5.2 of this Australian Requirements

Schedule which must set out in adequate detail the procedures the Contractor will implement to manage the Contractor's Activities and the Works from a work health and safety perspective to ensure compliance with all Statutory Requirements (including the WHS Legislation).

(ggg) Works means the physical work, which the Contractor must (to the extent required by the Contract), design, construct, commission, complete and hand over in accordance with the Contract.

2. Statutory Requirements

Pursuant to Document 00700, Contract Clauses, Division 01 Specification Section 01 11 00 Paragraph 1.1, FAR 52.236-7, and DFARS 252.225-7042, the Contractor must:

(a) comply with all applicable Statutory Requirements; without limiting paragraph (a):

(b) apply for and obtain all Approvals;

(c) give all notices and pay all fees and other amounts which it is required to pay in respect of the carrying out of its Contract obligations; and

(d) promptly give the Contracting Officer copies of all documents (including Approvals and other notices) that any authority, body, or organisation having jurisdiction over the Site, the Contractor's Activities or the Works issues to the Contractor.

3. Environmental Requirements

The Contractor must:

(a) ensure that in carrying out the Contractor's Activities:

(i) it complies with Statutory Requirements for the protection of the Environment;

(ii) it does not cause or contribute to any Environmental Incident;

(iii) without limiting subparagraph (ii), it does not cause or contribute to Contamination of the Site or any other land, air or water or cause or contribute to any Contamination emanating from the Site;

(iv) it immediately notifies the Contracting Officer of:

A. any non-compliance with the requirements of this paragraph 3;

B. any breach of a Statutory Requirement for the protection of the Environment;

C. any Environmental Incident; or

D. the receipt of any notice, order or communication received from an authority for the protection of the Environment; and

(v) its subcontractors comply with the requirements in this paragraph 3; and

(b) clean up and restore the Environment, including any Contamination or Environmental Harm, arising out of or in connection with, the Contractor's Activities or the Works, whether or not it has complied with all Statutory Requirements and other requirements of the Contract for the protection of the Environment.

4. Project Plans

4.1 Contents of Project Plans

Each Project Plan must set out in adequate detail the following:

(a) the procedure for preparing (including tailoring) and finalising the Project Plans under Paragraph 4.2;

(b) the procedure for regularly reviewing, updating and amending the Project Plan under Paragraph 4.2;

(c) the procedure for ensuring subcontractor compliance with the Project Plans;

(d) the procedure for regularly auditing or other monitoring of Contractor and subcontractor compliance with the Project Plan; and

4.2 Preparation of Project Plans

4.2.1 The Contractor:

(a) must carry out the Contractor's Activities in accordance with, and otherwise implement, the Project Plans; and

(b) for the purposes of paragraph (a), must:

(i) prepare Project Plans in accordance with the requirements of the Contract and this Australian

Requirements Schedule and submit them to the Contracting Officer for review in accordance with the Contract;

(ii) submit Project Plan information included in or supplement to the relevant required submittals identified in the Contract Division 01 specifications;

(iii) not commence any of the Contractor's Activities to which any Project Plan applies until Contracting Officer Approval is obtained and all other preconstruction requirements per Contract are satisfied;

(iv) if any Project Plan is rejected, submit an amended Project Plan to the Contracting Officer whereupon subparagraphs (i) to (iv) will reapply;

(v) after each Project Plan has been approved:

A. regularly review, update and amend each Project Plan and otherwise at least on each anniversary of the Effective Date;

B. update or amend a Project Plan on request of the Contracting Officer; and

C. continue to correct any defects in or omissions from a Project Plan (whether identified by the Contracting Officer or the Contractor), and submit an updated or amended Project Plan to the Contracting Officer, after which:

D. the Contractor must continue to comply with the requirements of the then current Project Plan until the process in this paragraph (b) has been completed in respect of the updated or amended Project Plan; and

E. subparagraphs (i) to (iv) will apply (to the extent applicable); and

(c) The Contractor will not be relieved from compliance with any of its obligations under this contract

(including this Australian Requirements Schedule) or otherwise at law or in equity, as a result of:

(i) the implementation of, and compliance with, the requirements of any Project Plan;

(ii) any direction by the Contracting Officer to update, amend, modify or otherwise implement and comply with a Project Plan or the Contractor's compliance or non-compliance with a Project Plan; and

(iii) any failure by the Contracting Officer , to detect any defect in or omission from a Project Plan.

5. Safety Requirements

5.1 Work Health and Safety

(a) Without limiting the Contractor’s obligation under the Contract to comply with EM 385-1-1, Division 01 Specification Section 01 35 26 Governmental Safety Requirements, 29 CFR 1910 Occupational Safety and Health Standards, the Contractor shall:

(i) ensure that in carrying out the Contractor's Activities:

A. it complies with all Statutory Requirements and other requirements of the

Contract in respect of work health and safety; and

B. it complies with its duty under the WHS Legislation to consult, cooperate and coordinate activities with all other persons who have a work health and safety duty in relation to the same matter;

(ii) Where more stringent safety and occupational health standards are set forth in these Australian requirements and regulations and it satisfies the U.S. safety requirements, the Australian standards shall apply.

(b) without limiting the Contractor's obligations under the Contract or otherwise at law or in equity, notify the

Contracting Officer:

(i) in respect of notifiable incidents within the meaning of the WHS Legislation, immediately (and in any event within 12 hours of such notifiable incident occurring);

(ii) in respect of work health and safety incidents or accidents (which are not notifiable incidents) where the nature of the incident or accident indicates a potential systemic failure to identify hazards and manage risks to health and safety, so far as is reasonably practicable, within 24 hours of the incident or accident occurring; and

(iii) in respect of all other work health and safety matters arising out of or in connection with the

Contractor's Activities and the Works, including the occurrence of any other incident or accident (not required to be reported in accordance with subparagraphs (i) or (ii)), by a monthly report;

(c) for the purposes of paragraph (b), in respect of any notifiable incident:

(i) immediately provide the Contracting Officer and Commonwealth with a copy of the notice required to be provided to the relevant Commonwealth or Northern Territory regulator;

(ii) promptly provide the Contracting Officer and Commonwealth with a copy of all witness statements and the…