CDRL A005 NOTIFICATION OF AIRCRAFT DELAY H-53 v1.pdf
PDF 191 KB Posted
- Attached to
- H-53E Aircraft Maintenance and Repair Services
- Solicitation number
- N6264920R0003
About this file
This document contains a Contract Data Requirements List (CDRL) and related Request for Proposals (RFP) for aircraft maintenance and repair services. The CDRL outlines a notification form requirement for contractors to submit within five days of any anticipated delay to the Contract Delivery Date for an H-53E aircraft. The form must include the aircraft identification, current and proposed delivery dates, reason for delay, and approval signatures. The associated RFP is from the Department of the Navy Naval Supply Systems Command seeking proposals for planned and unplanned depot-level maintenance, repair, and overhaul of CH/MH-53E aircraft supporting the United States Marine Corps and Navy in the Western Pacific region. The work will be performed by Fleet Readiness Center Western Pacific under the Naval Air Systems Command's Integrated Maintenance Program and In-Service Repair requirements.
View the file
Other files
Show 40 more
Latest 50 of 56 listed here. See the rest on GovTribe.
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
DD FORM 1423-1, FEB 2001 PREVIOUS EDITION MAY BE USED. Page 1 of 1 Pages Reset
18. ESTIMATED
TOTAL PRICE
CONTRACT DATA REQUIREMENTS LIST
(1 Data Item)
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services and Communications Directorate (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT
A
C. CATEGORY: X
TDP TM OTHER
D. SYSTEM/ITEM
H-53E PMID AIRCRAFT
E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO.
A005
2. TITLE OF DATA ITEM
NOTIFICATION OF AIRCRAFT DELAY H-53E
3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE
PWS
6. REQUIRING OFFICE
FRCWP Production
7. DD 250 REQ
NO
9. DIST STATEMENT
REQUIRED
None
10. FREQUENCY
AS REQUIRED
12. DATE OF FIRST SUBMISSION
AS REQUIRED
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
8. APP CODE
NA
11. AS OF DATE
AS REQUIRED
13. DATE OF SUBSEQUENT
SUBMISSION
AS REQUIRED Draft
Final
Reg Repro
16. REMARKS
(1) Description: Form that notifies the Government when a delay has been recognized and the aircraft Contract Delivery Date (CDD) will not be met. See attached form.
(2) Purpose: This form serves as notification that there is an expected delay in the Contract Delivery Date (CDD) and the reasons for the delay. This written notification shall contain sufficient information to verify the Contractor or Government delay without extensive investigation efforts
(3) Format: Notification of Aircraft Delay shall be Microsoft Office form similar to the attached example. Form shall include as a minimum:
(a) Aircraft BUNO and T/M/S
(b) Current CDD and Proposed CDD
(c) Reason for change and remarks
(d) Contractor Representative Requesting and date
(e) Remarks and approval sections for FRCWP Program Manager, Comptroller (if requires additional funding), DCMA, and Contracting Specialist.
(4) Frequency: As required. Shall submit within five (5) work days of anticipated or actual delay.
shall be emailed to FRCWP at: usn.atsugi.frcwp.mbx.h53-contract@mail.mil.
Subject line of email shall include CDRL Number and Title
(5) Acceptance: The Government shall have five working days for review and acceptance/rejection of each submission. No response will indicate acceptance.
FRCWP Prod 1 FRCWP Supp 1 FRCWP Bus Ops 1
15. TOTAL 0 4 0
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
17. PRICE GROUP
DCMA 1
| PREVIOUS EDITION MAY BE USED. |
| Pages |
File details come from the government source that posted it. Updated .