6973GH-26-R-00082.pdf

SOLICITATION, OFFER AND AWARD

3. SOLICITATION TYPE1. CONTRACT NO. 2. SOLICITATION NUMBER

6. ISSUED BY CODE 7. ADDRESS OFFER TO (If other than Item 6)

5. REQUISITION/PURCHASE NUMBER

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder"

NEGOTIATED BID (RFP)

SEALED BID (IFB)

4. DATE ISSUED

PAGE OF PAGES

1 93

C. E-MAIL ADDRESS

EXT.NUMBERAREA CODE

B. TELEPHONE (NO COLLECT CALLS)A. NAME

9. FOR

INFORMATION

CALL

CAUTION: LATE Submissions, Modifications and Withdrawals. All offers are subject to all terms and conditions contained in this solicitation.

(Date)(Hour) local timeuntildepository located in copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 7, or if hand carried, in the

SOLICITATION

8. Sealed offers in original and

PART IV - REPRESENTATIONS AND INSTRUCTIONS

OTHER STATEMENTS OF OFFERORS

EVALUATION FACTORS FOR AWARD

INSTR., CONDS., AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND

LIST OF ATTACHMENTS

CONTRACT CLAUSES

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACH.

I

J

K

L

M SPECIAL CONTRACT REQUIREMENTS

CONTRACT ADMINISTRATION DATA

DELIVERIES OR PERFORMANCE

INSPECTION AND ACCEPTANCE

PACKAGING AND MARKING

DESCRIPTION/SPECS./WORK STATEMENT

SUPPLIES OR SERVICES AND PRICE/COST

SOLICITATION/CONTRACT FORM

PART II - CONTRACT CLAUSESPART I - THE SCHEDULE

H

G

F

E

D

C

B

A

SEC. DESCRIPTION PAGE(S) (X) DESCRIPTION SEC. (X)

10. TABLE OF CONTENTS

17. OFFER DATE16. SIGNATURE

SUCH ADDRESS IN SCHEDULE.

IS DIFFERENT FROM ABOVE - ENTER

14C. CHECK IF REMITTANCE ADDRESS

EXT.NUMBERAREA CODE

14B. TELEPHONE NUMBER

(Type or print)AND

ADDRESS

OF

OFFEROR

CODE FACILITY

15. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER14A. NAME

DATEAMENDMENT NO.DATEAMENDMENT NO.

and related documents numbered and dated):

amendments to the SOLICITATION for offerors

(The offeror acknowledges receipt of

13. ACKNOWLEDGEMENT OF AMENDMENTS

CALENDAR DAYS (%)30 CALENDAR DAYS (%)20 CALENDAR DAYS (%)10 CALENDAR DAYS (%)12. DISCOUNT FOR PROMPT PAYMENT the designated point(s), within the time specified in the schedule.

by the offeror) from the date for receipt of offers specified above , to furnish any or all items upon which prices are offered at the price set opposite each item , delivered at

11. In compliance with the above, the undersigned agrees, if this offer is accepted within ______________ calendar days (60 calendar days unless a different period is inserted

NOTE: Item 11 does not apply if the solicitation includes Minimum Bid Acceptance Period .

OFFER (Must be fully completed by offeror)

IMPORTANT - Award will be made on this Form, or by other authorized official written notice.

27. AWARD DATE

(Signature of Contracting Officer)

26. CONTRACT AUTHORITY

24. PAYMENT WILL BE MADE BY

25. NAME OF CONTRACTING OFFICER (Type or print)

CODE 23. ADMINISTERED BY (If other than Item 6)

ITEM

(4 copies unless otherwise specified)

22. SUBMIT INVOICES TO ADDRESS SHOWN IN21. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

20. ACCOUNTING AND APPROPRIATION19. AMOUNT18. ACCEPTED AS TO ITEMS NUMBERED

AWARD (To be completed by CONTRACT AUTHORITY)

CODE

04/14/2026 X

AAQ730-AFN

AAQ-730 FAC. & AVIATION SAFETY ACQ

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

OKLAHOMA CITY OK 73125

1600 CT 05/15/2026

Cynthia L. Cooper 405 Cynthia.Cooper@faa.gov

954-2601

X

X

X

X

X

X

X

X

X

X

X

X

PAGE(S)

Cynthia L. Cooper

6973GH-26-R-00082

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 93

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

6973GH-26-R-00082

THIS PROCUREMENT IS FULL AND OPEN COMPETITION

The Magnitude of Construction is $18,000,000.00 to $25,000,000.00

The Line Item listed on the continuation Page is for Government use only. Please reference

Section B Pricing of this instrument for the contract line items and additional information.

00001 Provide all labor and materials in support of construction services for a mechanical and electrical systems upgrade of Headquarters

Building, at the Mike Monroney Aeronautical

Center (MMAC) in accordance with the attached specifications and drawings.

Section B - Supplies or Services/Prices Section B - Schedule

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

C.1 Description The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project, in accordance with the specifications and drawings, and the other terms, conditions, and provisions as set forth herein. All work performed and any materials and equipment used will be subject to approval by the Contracting Officer Representative (COR) and Contracting Officer (CO). This shall include but not be limited to testing, inspection, scheduling, reporting, and submittals.

C.2 Bid vs. Offer References to the terms "bid", "bidder", et. throughout the specification are intended to mean "offer", "offeror", etc.

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

3.10.4-11 INSPECTION - DISMANTLING, DEMOLITION, OR REMOVAL OF IMPROVEMENTS

(APR 1996)

Section F - Deliveries or Performance Clause List

F.1 Working Hours Work shall be conducted between 6:00 a.m. and 6:00 p.m. on normal government workdays. No Work, with the exception of the demolition work as described below, shall occur at night, or on Saturday’s, Sunday’s or designated government holidays unless approved by the Contracting Officer seven (7) days in advance.

All demolition including the removal of the existing concrete slab, sub-soil removal below existing concrete slab, demolition and removal of interior GWB and CMU partitions, windows, floor, wall and ceiling finishes, HVAC equipment and ductwork,plumbing and waste lines and vents, electrical demolition and removal, and any or all other items related to demolition, shall be between the hours of 6:00 P.M and 6:00 A.M Monday thru Friday. Work on the demolition may also be accomplished on weekends and approved government holidays. Work during these times (weekend and government holidays), must be pre-approved and scheduled in advance. Provide a minimum of seven (7) days prior notice to AMP-400, Project Manager, Mike Monroney Aeronautical Center, 405-954-4574 to coordinate scheduling of any work to be done outside of the occupants normal working hours

F.2 Utility Outages and Shutdown Utility outages and shutdown shall be coordinated with the Contracting Officer and Project Manager. Outages affecting FAA operations are required to be accomplished at night, on weekends, or designated government holidays. Prior to any outage or shutdown, twenty-one (21) working days notification must be made to coordinate scheduling of any work to be performed during any hours.

F.3 Contractor Use of Premises

(a) General: Limit use of site and premises to allow:

(1) Owner Occupancy

(2) Work by others

(b) Access to Site: Limited to area required for construction.

F.4 Contractor's Construction Schedule and Material Submittals The contractor shall prepare and submit the construction work schedule to the Contracting Officer (CO) for approval within fifteen (15) days of the date established for "Commencement of Work" in accordance with Clause 3.2.2.3-56 which is incorporated by reference.

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

Section G - Contract Administration Data Clause List

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within 14 calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

AC1227 RELEASE FORM (JAN 1997)

The contractor will be required to execute Contractor's Release Form DOT

F 4220.4 (2-71) prior to final payment under the contract. (Note: A copy of

Form DOT F 4220.4 (2-71) is attached hereto for information purposes.)

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

H.1 FAA Compliance with Executive Orders

FAA shall comply with all Presidential directives. If any clause, provision, term, or condition in this SIR or contract is inconsistent with any Executive Order or Presidential Memoranda issued on or after January 20, 2025, or implementing guidance thereof, FAA will take action it deems appropriate and as permitted by law to correct any such inconsistency to include finding a provision or clause invalid. Applicable Executive Orders include, but are not limited to:

- Executive Order 14148 of January 20, 2025, Initial Recissions of Harmful Executive Orders and Actions.

- Executive Order 14151 of January 20, 2025, Ending Radical and Wasteful Government DEI Programs and Preferencing.

- Executive Order 14154 of January 20, 2025, Unleashing American Energy.

- Executive Order 14168 of January 20, 2025, Defending Women From Gender Ideology Extremism and Restoring Biological Truth to the Federal Government

- Executive Order 14173 of January 21, 2025, Ending Illegal Discrimination and Restoring Merit-Based Opportunity.

H.2 TIME EXTENSION

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

H.3 ACCIDENT AND FIRE REPORTING

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment;

or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The Contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.4 CONSTRUCTION SAFETY PROGRAM

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities.

Chapter 33 Construction Safety (Section J, Attachment 4) establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

H.5 NOTIFICATION REUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS DISTURBED

If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

H.6 EXERCISE OF OPTIONAL CONTRACT LINE ITEMS (CLINS)

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

3.8.2-17 KEY PERSONNEL AND FACILITIES (JUL 2019)

(a) The personnel and/or facilities as specified below are considered essential to the work being performed hereunder and may, with the consent of the contracting parties, be changed from time to time during the course of the contract.

(b) Prior to removing, replacing, or diverting any of the specified personnel and/or facilities, the Contractor must notify in writing, and receive consent from, the Contracting Officer reasonably in advance of the action and must submit justification (including proposed substitutions) in sufficient detail to permit evaluation of the impact on this contract.

(c) No diversion will be made by the Contractor without the written consent of the Contracting Officer.

(d) The key personnel and/or facilities under this contract are:

Project Manager Superintendent

(List key personnel and/or facilities)

(End of clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC1231 NOTIFICATION REQUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS

REMOVED/DISTURBED (JAN 1997)

(a) Prior to any planned and/or scheduled disturbance of friable asbestos material, mainly CAFCO ceilings, the contractor shall present a written plan to the Contracting Officer. The plan shall include, but not be limited to, location, type facility, size of area to be disturbed or removed, method of containment to be used, disposal procedures, clean-up procedures, number of employees involved, protective clothing/equipment to be used, the date and time removal/disturbance is planned and any other information requested by the Contracting Officer. The contractor shall not proceed with any removal or disturbance of friable asbestos material without written approval from the Contracting Officer.

(b) If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4556 PERSONNEL AND SUPERVISION (JUL 2015)

The contractor shall designate sufficient supervisory personnel to meet task outcomes. Contract supervisors will provide day-to-day supervision of contract personnel including, but not limited to, work monitoring, payroll records, leave, etc. At no time will FAA personnel assume any responsibility for the supervision of contractor personnel.

Government assistance will be available to provide technical and policy guidance through the assigned Contracting Officer’s Representative (COR).

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

H.1 PERMITS AND RESPONSIBILITIES

The Contractor shall secure and pay for all permits, licenses, special inspections, etc., required in the execution of the work, whether of a permanent or temporary nature.

H.2 TIME EXTENSION

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

H.3 ACCIDENT AND FIRE REPORTING

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment;

or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The Contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.4 CONSTRUCTION SAFETY PROGRAM

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities.

Chapter 33 Construction Safety (Section J, Attachment 4) establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

H.5 FAA COMPLIANCE WITH EXECUTIVE ORDERS

FAA shall comply with all Presidential directives. If any clause, provision, term, or condition in this SIR or contract is inconsistent with any Executive Order or Presidential Memoranda issued on or after January 20, 2025, or implementing guidance thereof, FAA will take action it deems appropriate and as permitted by law to correct any such inconsistency to include finding a provision or clause invalid. Applicable Executive Orders include, but are not limited to:

- Executive Order 14148 of January 20, 2025, Initial Recissions of Harmful Executive Orders and Actions.

- Executive Order 14151 of January 20, 2025, Ending Radical and Wasteful Government DEI Programs and Preferencing.

- Executive Order 14154 of January 20, 2025, Unleashing American Energy.

- Executive Order 14168 of January 20, 2025, Defending Women From Gender Ideology Extremism and Restoring Biological Truth to the Federal Government

- Executive Order 14173 of January 21, 2025, Ending Illegal Discrimination and Restoring Merit-Based Opportunity.

H.6 EXERCISE OF OPTIONAL CONTRACT LINE ITEMS (CLINS)

The Government may exercise none, some or all Option items at the prices established in Section B, CLINs 0002- 0005. Exercise of the option CLINs must be made in writing by the Contracting Officer within 30 days of contract award.

H.7 SUBCONTRACTOR SUBSTITUTION

a) If a subcontractor’s experience was submitted in partial satisfaction of the requirement in Section L, Factor 1, Experience, that subcontractor is considered essential to the work being performed hereunder. Any change in the subcontractor or the effort the subcontractor will perform must be reported in sufficient detail to permit evaluation of the impact on this contract directly to and approved by the CO.

b) No removing, replacing, or diversion shall be made by the Contractor without the written consent of the

Contracting Officer. Replacing, substituting, or removing the proposed subcontractor prior to receiving CO consent may be means for terminating the contract by default.

c) This provision is applicable to the following subcontractor: (offer to insert name of subcontractor, if any, used to partially satisfy Experience requirement)

H.8 MAINTENANCE/DEFECT SECURITY

In accordance with Oklahoma Statute§61-113(B)(3), within 60 days of contract award, the successful contractor shall provide a bond or irrevocable letter of credit in a sum equal to the contract price to protect the Oklahoma City Airport Trust and City of Oklahoma City as public agencies to be protected against defective workmanship and materials for a period of one (1) year after acceptance of the project.

H.9 CITY OF OKLAHOMA CITY/OKLAHOMA CITY AIRPORT TRUST

a. In relation to 3.4.1-1 PROPOSAL GUARANTEE (JAN 2017), 3.4.1-4 PERFORMANCE BOND REQUIREMENTS (JAN 2017), and 3.4.1-5 PAYMENT BOND REQUIREMENTS (JAN 2018), is revised to read as follows:

“We, the Principal and Surety(ies) are firmly bound to the United States of America (hereinafter called the Government) as well as City of Oklahoma City and the Oklahoma City Airport Trust. . . "

b. In relation to AC3212 LIABILITY INSURANCE (JAN 1997), paragraph (3) (b) is revised to read as follows:

(b) The policy shall name ‘The United States of America, acting by and through the Federal Aviation Administration’ as an additional insured with respect to operations performed under this contract. The policy shall further name the City of Oklahoma City and the Oklahoma City Airport Trust as an additional insured with respect to operations performed under this contract.

c. In relation to AC3211 SAVE HARMLESS AND INDEMNITY AGREEMENT (JAN 1997); the first sentence is revised to read "The contractor shall save and keep harmless and indemnify the Government as well as Oklahoma City and the Oklahoma City Airport Trust. . . "

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.1.8-1 CANCELLATION, RESCISSION AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (APR 2024)

3.1.8-2 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (APR 2024)

3.2.2.3-33 ORDER OF PRECEDENCE (APR 2024)

3.2.2.3-42 DIFFERING SITE CONDITIONS (APR 2024)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 2024)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2024)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2024)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2024)

3.2.2.3-48 OTHER CONTRACTS (JUL 2024)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (JUL 2024)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (JUL 2024)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2024)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2024)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2024)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2024)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2024)

3.2.2.3-58 LAYOUT OF WORK (JUL 2024)

3.2.2.3-62 PRECONSTRUCTION CONFERENCE (JUL 2024)

3.2.2.3-64 DISMANTLING AND DEMOLISHING OF PROPERTY (JUL 2024)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2024)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2024)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2024)

3.2.5-4 CONTINGENT FEES (OCT 2024)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2024)

3.2.5-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE FAA (OCT 2024)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.2.5-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (OCT 2024)

3.2.5-14 DISPLAY OF HOTLINE POSTER(S) (OCT 2024)

3.3.1-9 INTEREST (APR 2023)

3.3.1-15 ASSIGNMENT OF CLAIMS (JUL 2018)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2021)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (OCT 2024)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-7 NOTICE TO PROCEED (OCT 2019)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2020)

3.4.2-6 RESERVED (APR 2025)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (APR 2025)

3.5-1 AUTHORIZATION AND CONSENT (APR 2023)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT

(JAN 2009)

3.5-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS (JAN 2009)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (JUL 2023)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME

COMPENSATION (OCT 2018)

3.6.2-2 CONVICT LABOR (APR 2025)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (APR 2022)

3.6.2-13 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (APR 2022)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (APR 2025)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2025)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2024)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (APR 2025)

3.6.2-46 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (APR 2025)

3.6.2-47 RESERVED (APR 2025)

3.6.2-49 REPORTING REQUIREMENT FOR U.S.-FLAG CARRIERS REGARDING TRAINING TO

PREVENT HUMAN TRAFFICKING (APR 2025)

3.6.3-10 REFRIGERATION EQUIPMENT AND AIR CONDITIONERS (OCT 2024)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (OCT 2024)

3.6.3-17 EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (OCT 2024)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2024)

3.6.3-25 AEROSOLS (OCT 2024)

3.6.3-26 FOAMS (OCT 2024)

3.6.4-5 FAA BUY AMERICAN PREFERENCE - STEEL AND MANUFACTURED GOODS (APR

2022)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.5-1 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN OWNED ECONOMIC

ENTERPRISES (JAN 2023)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.8.9-2 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JUL 2023)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 2023)

3.10.1-20 WARRANTY-CONSTRUCTION (JUL 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-28 CHANGES REQUIRED BY AMS (JAN 2024)

3.10.2-6 SUBCONTRACTS FOR COMMERCIAL ITEMS AND COMMERCIAL COMPONENTS

(APR 2025)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV

1997)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT

1996)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (APR 2025)

3.2.2.3-41 PERFORMING WORK (APR 2024)

The Contractor must perform, using its own organization, work equivalent to at least 15 percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if the Contractor requests a reduction and the CO determines that it would be to the FAA's advantage to do so.

(End of clause)

3.2.2.3-44 PHYSICAL DATA (JUL 2024)

Data and information the FAA provides or refers to below is for the Contractor's information. The FAA is not responsible for any interpretation or conclusions drawn from the data or information from the Contractor. Further, the FAA does not warrant construction methodology which may be included in these documents.

(a) The descriptions of physical conditions on the drawings and in the specifications are the result of site investigations by AMP / AE Design Firm.

(b) Other relevant information N/A.

(End of clause)

3.2.2.3-50 PROPERTY PROTECTION (JUL 2024)

(a) The Contractor must construct and maintain any temporary fences, gates and other facilities needed to preserve crops, control livestock, and protect property. Before cutting a fence, the Contractor must take necessary precautions to prevent livestock from straying. The Contractor must prevent loss of tension in or damage to adjacent portions of the fence. The Contractor must immediately replace all fencing and gates cut, removed, damaged, or destroyed with new materials to the original standard. Undamaged gates may be reused.

(b) The Contractor must comply with the property owner's requests to leave gates open or closed.

(c) The Contractor must use all necessary precautions to avoid destroying surveying markers such as section corners, witness trees, property corners, mining claim markers, bench markers, triangulation stations, and the like. If the Contractor must destroy any marker, the Contractor must first notify the agency responsible for the marker, as well as the Contracting Officer's (CO) representative, and replace the markers.

(d) The Contractor must use care to prevent unnecessary damage to property in or near the work area caused by the Contractor's work. Unnecessary damage is that which the Contractor can avoid through efficient and careful performance of the work, considering the Contractor's land rights. If the Contractor damages any property, the Contractor must at once notify the owner or custodian and make or arrange to make prompt and full restitution.

(e) Maps and specifications the FAA provides may not give the location of all water supply, drainage, irrigation, and other underground facilities. Before entering a tract of land for contract purposes, the Contractor must determine from the property owner (or other reasonably available source) the location of any irrigation system, domestic water system, source of water, and drainage system existing on the property, whether serving that property or other property. The Contractor must avoid damaging or obstructing these facilities or polluting water supplies.

(f) The Contractor must hold the FAA harmless from any and all suits, actions, and claims for damages, including environmental impairment, to property arising from any of the Contractor's acts or omissions, the Contractor's subcontractors, or any of the Contractor's employees or subcontractor employees, in any way related to the work or operations under this contract.

(g) The Contractor must indemnify and hold harmless the property owners or parties lawfully in possession against all claims or liabilities asserted by third parties, including all…