Amend__3 _Package.pdf

(x)

P14PS00906

x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

PDS

Denver CO 80225-0287 P.O. Box 25287 12795 W. Alameda Pkwy DOI, NPS, DSC Contracting Services

PDS

Denver CO 80225-0287 P.O. Box 25287 12795 W. Alameda Pkwy NPS, DSC Contracting Services Div

JEFF-18120206/09/2014000003

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

06/03/2014

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

JEFF-181202 - South Park Grounds, Jefferson National Expansion Memorial, Clayton County, St. Louis, MO

The purpose of this amendment #3 is to make changes to the Request for Proposal, provide a list of attendees for the Site Visit/Pre-Proposal Conference held on Thursday, June 12 at

9:00 at the Hilton St Louis at the Ball Park, provide a copy of the slide presentation, and to answer questions received as of June 17, 2014. See following Page(s)

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

David E. Thomas

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

a. Part A of RFP and Volume I and Volume II of the Proposal Submission Package, replace the SF 1442, Solicitation, Offer, and Award with the attached Amendment #1 SF1442 which changes:

• Block 11 FROM:

“The Contractor shall begin performance 30 calendar days …. “

• Block 11 TO:

“The Contractor shall begin performance 15 calendar days …. “

• Block 13 FROM:

a. Sealed offers in original and 3 copies ….”

• Block 13 TO:

a. Sealed offers in original and 4 copies ….”

b. Section J of the RFP is changed to add supplemental documents. Replace Section J with the revised Section J which is attached.

c. Section L of the RFP, Page 119, Sub-Factor D – Schedule and Project Management, is changed

• FROM:

The Offeror shall prepare and include both a hardcopy and native format electronic file of the preliminary construction schedule for the proposed project using MS Project software. The schedule shall be a color Gantt chart which clearly defines the critical path (see Specification Section 013216). Include a written narrative with the schedule describing the Offeror’s development of the schedule, including how it defines activities, cost loading, critical path, float, resource loading, etc. The narrative shall also discuss management of site security requirements and coordination of Park operation activities in conjunction with the overall construction schedule. The schedule shall demonstrate understanding of the construction complexity, subcontractor coordination, visitor access needs, NPS operations and access requirements, construction impact mitigation measures, and the Special Construction Requirements included in the specifications, and shall consider the following elements, which are of equal importance:

• TO:

The Offeror shall prepare and include both a hardcopy and native format electronic file of the preliminary construction schedule for the proposed project using MS Project, Primavera P6, or Meridian Prolog software – per Specification 01 32 16 2.1 F.1. The schedule shall be a color Gantt chart which clearly defines the critical path (see Specification Section 013216). Include a written narrative with the schedule describing the Offeror’s development of the schedule, including how it defines activities, cost loading, critical path, float, resource loading, etc. The narrative shall also discuss management of site security requirements and coordination of Park operation activities in conjunction with the overall construction schedule. The schedule shall demonstrate understanding of the construction complexity, subcontractor coordination, visitor access needs, NPS operations and access requirements, construction impact mitigation measures, and the Special Construction Requirements included in the specifications, and shall consider the following elements, which are of equal importance:

d. Section L of the RFP, Page 121, Volume II – Business and Price Proposal, 4., changed

• FROM:

Section B, Contract Price Schedule: Enter the proposed dollar amount for each line item in the price schedule, including any optional items, if applicable. Also provide a schedule of values showing the price breakdown by major work components. A schedule of values format is provided in the Proposal Submission Package.

• TO:

Section B, Contract Price Schedule: Enter the proposed dollar amount for each line item in the price schedule, including any optional items, if applicable.

e. RFP, Volume 2 of the Proposal Submission Package, add the attached excel spreadsheet titled Subcontracted Supplies and/or Services.

f. See Attached Spreadsheet for Questions and Answers as of June 17, 2014.

g. All other terms and conditions remain unchanged.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

P14PS00906

2. TYPE OF SOLICITATION

SEALED BID (IFB)

x NEGOTIATED (RFP)

3. DATE ISSUED

06/03/2014

PAGE OF PAGES

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

JEFF-181202

7. ISSUED BY CODE PDS 8. ADDRESS OFFER TO

NPS, DSC Contracting Services Div 12795 W. Alameda Pkwy P.O. Box 25287 Denver CO 80225-0287

9. FOR

INFORMATION

CALL:

a. NAME

JOY EWALT

b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

303-969-2304

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Jefferson National Expansion Memorial - JEFF-181202

City Arch River 2015, Redesign Arch Ground Encompassing Historic Allees, Sidewalks and Irrigation System

Project Title: South Park Grounds

County, State: Missouri - St. Louis County

Estimated Value: $17,000,000 - $22,000,000

Site Visit: A Pre-Proposal Conference is scheduled for:

Thursday, June 12 at 9:00 AM prevailing Central Time.

Hilton St. Louis at the Ballpark (1 South Broadway)

Gateway Ballroom (2nd floor) (see RFP Clauses, Section L, 52.236-27, Site Visit (Construction) Alternate I (FEB 1995)

11. The Contractor shall begin performance 15 calendar days and complete it within 645 calendar days after receiving award, x notice to proceed. The performance period is x mandatory negotiable. (See .)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

x YES NO 12b. CALENDAR DAYS

a. Sealed offers in original and 4 copies to perform the work required are due at the place specified in Item 8 by 1600 (hour) local time

07/08/2014 (date). If this is a sealed bid solicitation, offers will be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due .

b. An offer guarantee x is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected .

NSN 7540-01-155-3212 STANDARD FORM 1442 (Rev. 4-85) Prescribed by GSA FAR(48 CFR) 53.236-1(d)

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

Continued...

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY CODE PDS 27. PAYMENT WILL BE MADE BY

DOI, NPS, DSC Contracting Services 12795 W. Alameda Pkwy P.O. Box 25287 Denver CO 80225-0287

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT

(Contractor is required to sign this document and return 3 copies to issuing office.)

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations,

29. AWARD

(Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

David E. Thomas 30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 4-85) BACK

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED

P14PS00906

PAGE OF

3 141

NAME OF OFFEROR OR CONTRACTOR

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

00010

JEFF-181202 - South Park Grounds, Jefferson National Expansion Memorial, Clayton County, St.

Louis, MO FOB: Destination

South Grounds

LS

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Solicitation Document No.

Document Title

JEFF-181202 – South Park Grounds

a. three (3) calendar years along with a statement from their insurance company showing their current Experience Modification Rate (EMR).

b. Sub-Factor D – Schedule and Project Management:

The proposed project management plan and schedule will be evaluated to determine the Offeror’s ability to provide effective project management and coordination for this project, including understanding of and ability to anticipate and address significant project constraints, hurdles, and challenges. The overall approach for developing, monitoring, and controlling project schedules and coordination of subcontractors and monitoring of work forces will also be evaluated.

The Offeror shall prepare and include both a hardcopy and native format electronic file of the preliminary construction schedule for the proposed project using MS Project, Primavera P6, or Meridian Prolog software – per Specification 01 32 16 2.1 F.1. The schedule shall be a color Gantt chart which clearly defines the critical path (see Specification Section 013216). Include a written narrative with the schedule describing the Offeror’s development of the schedule, including how it defines activities, cost loading, critical path, float, resource loading, etc. The narrative shall also discuss management of site security requirements and coordination of Park operation activities in conjunction with the overall construction schedule. The schedule shall demonstrate understanding of the construction complexity, subcontractor coordination, visitor access needs, NPS operations and access requirements, construction impact mitigation measures, and the Special Construction Requirements included in the specifications, and shall consider the following elements, which are of equal importance:

Element 1 – Demonstrates how offeror will maintain schedule, cost, and quality control. Describes the coordination of efforts between the prime and subcontractors and indicates the allocation of work quantity between the general contractor and subcontractors.

Element 2 - Quality of the proposed schedule shows logical ties and clearly identifies the critical path for the project. The schedule matches the proposed written approach presented in Subfactor 1 above.

Demonstrates logical thought to approaches on how work will be completed.

Element 3 - Describe your firm’s internal communication and coordination protocols between staff at all levels of the organization who will be working on this project. Describe communication and coordination protocols between your firm and the other members of the proposed project team, including subcontractors, vendors, and NPS representatives.

Element 4 - Provides description of how prime/subcontractor work is allocated and coordinated, controlled, inspected, and accepted. Include the coordination and handling of submittals, shop drawings, and major deliveries to the site.

c. Sub-Factor E - Qualifications of Key Personnel and Subcontractors:

In keeping with the goals of this project and the involved partners as described earlier in Section C of this RFP, the proposal should address the qualifications, prior experience, capabilities, roles and responsibilities of the proposed key personnel for the Offeror and for key subcontractors. The proposal should also identify the proposed project team, including proposed key subcontractors’ teams and describe how the Offeror’s project team operates within the Offeror’s corporate structure and management. In addition, the proposal should describe how the proposed project team will enhance and ensure a well-coordinated and successful outcome for this project.

Element 1 – Resumes detailing the qualifications, prior work experience and capability of the proposed project team, proposed key personnel, and proposed key subcontractors will be evaluated to

FACTOR 2 - PAST PERFORMANCE:

In response to past performance, offerors shall provide a copy of the form entitled “Past Performance Questionnaire” for all relevant construction projects.

Offerors shall complete Sections I and II of each questionnaire to provide applicable information for each project. Upon completion, send the questionnaire to the individuals you have referenced in Section II of the questionnaire. See the attachment itself for detailed information.

NOTE: Offeror must not review the Past Performance Questionnaire prior to submission of its offer. The questionnaires must be submitted by the client/evaluator reference directly to the Contract Specialist (joy_ewalt@nps.gov) prior to the closing date of the solicitation, or they will not be considered.

Offerors should disclose any instances in which its past performance on a particular contract may be considered by others to be less than fully satisfactory by attaching a narrative to the applicable Past Performance Questionnaire. The offeror should relate pertinent facts and circumstances and describe any remedial action taken or to be taken to correct the deficiency. Failure to disclose such instances may result in a determination that the offeror has been less than candid with the Government, which could result in an unfavorable assessment of the offeror’s past performance record. The Government reserves the right to limit the number of references it ultimately contacts and to contact references or use sources other than those provided by the offeror to obtain information related to past performance. Other sources include, but are not limited to, the Past Performance Information Retrieval System (PPIRS), and other Federal agencies. Limited exchanges between the Government and an offeror may occur to clarify the relevance of an offeror’s past performance information and adverse past performance information to which the offeror has not previously had an opportunity to respond.

VOLUME II - BUSINESS AND PRICE PROPOSAL: Volume II shall be submitted in an original and one copy and shall include the following:

1. Standard Form 1442, Solicitation, Offer, and Award, (Construction, Alteration, or Repair):

Complete blocks 14 through 20C only. An official having the authority to contractually bind the offeror's company must sign the SF 1442 in accordance with the procedures prescribed in FAR 4.102. (Please include DINS number in block 14 along with name and address.)

2. Acknowledgement of Amendments: In accordance with Section L, FAR 52.215-1, Instructions to Offerors-Competitive Acquisition, acknowledge all solicitation amendments using one of the methods set forth in Block 11 of Standard Form 30, the amendment.

3. Standard Form 24, Bid Bond: Submit a bid bond duly executed between the offeror and the bonding company.

4. Section B, Contract Price Schedule: Enter the proposed dollar amount for each line item in the price schedule, including any optional items, if applicable. Also provide a schedule of values showing the price breakdown by major work components. A schedule of values format is provided in the Proposal Submission Package.

5. Section K, Representations, Certifications and Other Statements of Offerors: Complete all required representations and certifications if they are not available at www.SAM.gov. NOTE: Current, active registration at www.SAM.gov is a requirement of this contract; the Government highly recommends that offerors register before submitting an offer.

http://www.sam.gov/ http://www.sam.gov/

SECTION J – LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

1. Drawing No. 366/115912, 283 sheets

2. Project Specifications

3. Davis Bacon Wage Rate, General Decision Number: MO140001 MO140001 05/09/2014 MO1

4. Archeological Monitoring and Data Recovery at the Jefferson National Expansion Memorial (JEFF), MWAC, 04/09/2014

5. NPS Installation of Hydraulic Bollard Barricade System, Record Drawings, 02/19/2008

6. Electrical Lighting Plans, Record Drawings, 07/14/2000

7. Temporary Traffic Control Zone Accessibility Requirements, 04/17/2014

8. 32 91 13 “Planting Soil Blending” 06/02/2014 (describes the manufacture of Planting Soil Mixes to be provided to the contractor)

9. Proposal Submission Package Volume I

Volume II

10. Subsurface Exploration: City Arch River 2015, Jefferson National Expansion Memorial, St. Louis Missouri, 26 April 2013, has been prepared by Geotechnology, Inc., St. Louis Missouri.

a. Addendum No. 1 Revised, Supplemental Design Recommendations, City Arch River 2015, Jefferson National Expansion Memorial, St. Louis, Missouri, 03 February 2014.

b. Addendum No. 2 Supplemental Borings and Lateral Load Analysis, Elevated Walkways, City Arch River 2015, Jefferson National Expansion Memorial, St. Louis, Missouri, 13 December 2013.

c. Addendum No. 3 Supplemental Subsurface Exploration, Proposed Visitor Center Addition, Jefferson National Expansion Memorial, St. Louis, Missouri, 20 February 2014.

11. Air Knife Exploration: City Arch River 2015, Jefferson National Expansion Memorial, St. Louis Missouri, 15 November 2013, has been prepared by Geotechnology, Inc., St. Louis Missouri.

12. Phase 1 Environmental Site Assessment, 11 February 2011, has been prepared by Geotechnology Inc., St.

Louis Missouri.

13. Geoarcheological Investigation for CAR2015 Project, 21 November 2012, has been prepared by Louis

Berger Group Inc.

14. Geotechnical Desk Study, 16 February 2011, has been prepared by Geotechnology Inc., St. Louis, Missouri.

15. Engineering Analysis of a Modified DS-50 Barrier, 6 June, 2013, has been prepared by ABS Consulting, St.

Louis, Missouri.

16. Utility Locating Services, CAR 2015, Jefferson National Expansion Memorial, St. Louis, Missouri, 03

February, 2014 has been prepared by Geotechnology, Inc. St. Louis Missouri.

17. Supplemental Utility Locating Services at North Service Center, CAR 2015, Jefferson National Expansion Memorial, St. Louis, Missouri, 19 March, 2014 has been prepared by Geotechnology, Inc. St. Louis Missouri.

Experience READ CAREFULLY: The purpose of this form is for the offeror to list projects performed that are similar to the work described in this solicitation.

Provide information on a minimum of 3 and no more than 7 relevant projects completed within the previous 5 years. Provide a brief written description of the scope of each project with accompanying color photographs, identify initial and final contract amounts, indicate offeror’s role in the project (prime or sub) and percent of work accomplished by offeror, and list key subcontractors (if prime). Indicate Key Personnel for each project and their role on the project if they are being proposed as Key Personnel for this contract.

It is especially important that the offeror disclose instances in which their past performance may be considered by others to be less than fully satisfactory. The offeror should tell their side of the story and describe remedial corrective action that has been taken or will be taken to correct the deficiency. Failure to do so may result in a determination that an offeror has been less than candid with the Government, which could result in an unfavorable assessment of the offeror’s past performance record.

NAME OF CONTRACTOR/OFFEROR:

# PROJECT

NAME:

Project Location:

Name of Owner:

Address of Owner:

Telephone Number:

Project Value:

Dates of Construction:

DESCRIPTION OF THE PROJECT AND SCOPE OF OFFEROR’S WORK

PERFORMANCE REMARKS

Solicitation No. Package No. PARK PMIS Experience Page 1 of 2

DESCRIPTION OF THE PROJECT AND SCOPE OF OFFEROR’S WORK (continuation)

PERFORMANCE REMARKS (continuation)

Solicitation No. Package No. PARK PMIS Experience Page 2 of 2

INSERT OFFEROR'S

COMPANY NAME:

LEVEL OF COMMITMENT TO USE SMALL BUSINESS CONCERNS

SUBCONTRACTOR NAME

Socio- Economic

Status

Description of Supplies/Service Subcontracted

Total Estimated

Subcontract Value

SB

Estimated

Subcontract Value

SDB

Estimated

Subcontract Value

HZSB

Estimated

Subcontract Value

SDVO

Estimated

Subcontract Value

WOSB

Estimated

Subcontract Value

Explain and provide supporting documentation regarding the level of commitments to use SB concerns (for example, what types of committments, if any, are in place for this specific acquisition as a prime and/or written contract, verbal, enforceable, non-enforceable, joint venturing, mentor-protege, etc.

ABC Company 550.00$ 500.00$ 50.00$ XYZ Company -$

2.00$ 2.00$ 2.00$ 2.00$ 2.00$ 2.00$

200.00$ 200.00$ 3.00$ 3.00$

3.00$ 3.00$

Total Subcontracted Value 762.00$ 2.00$ 503.00$ 202.00$ 53.00$ 2.00$ Total Contract Value $10,000,000.00 $10,000,000.00 $10,000,000.00 $10,000,000.00 $10,000,000.00 $10,000,000.00 Subcontracted Value Percent 0.0076% 0.0000% 0.0050% 0.0020% 0.0005% 0.0000%

Mark the appropriate socio-economic category of the subcontractor Small Business (SB) concern.

SB = Small Business, SDB = Small Disadvantaged SB, HZSB = HubZone SB, SDVO = Service-Disabled Veteran Owned SB, WOSB = Woman Owned SB

SUBCONTRACTED SUPPLIES AND/OR SERVICES

NOTE 1: List the type of supplies and/or services to be subcontracted, estimated dollars, and the corresponding socio-economic status of the businesses

NOTE 2: If supplies or services are projected to be subcontracted to small, small disadvantaged, women-owned, service disabled veteran owned, hubzone, or veteran owned small businesses, but large businesses are subsequently substituted, the contracting officer shall be provided with timely written notification.