Solicitation - W912DS26RA015.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section 00 00 00 - Procurement and Contracting Requirements

WVA Electrical Switching Station

W912DS26RA015

Identifier Document Name

Document Description

Reference Identifier

Date Line Item

Page Numbers

Document Type

Provided Under Separate Cover

0001 Evaluation Factors

Evaluation Factors Evaluation Factors

Apr

Attachment No

Section 00 10 00 - Solicitation, Contract Line Item Number (CLIN) Schedule

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price

Amount

0001 All work associated with the construction of the Electrical Switch Station in accordance with the plans and specification. This CLIN includes the space, racks, pathways and cabling ONLY for CCTV and IDS. A complete card access control (CAC) system is part of this CLIN. This CLIN does not include CLINs 0002 - 0004.

Pricing Arrangement: Firm Fixed Price

1 Job

0002 All work associated with furnish and install 4

- 2MW generators as per the plans and specifications.

Product Service Code: Y1EZ North American Industry Classification System (NAICS): 236220 Pricing Arrangement: Firm Fixed Price

1 Job

0003 PRE-PRICED CLIN $100,000.00 (One Hundred Thousand Dollars) Turnover of electronic and printed O/M manuals. The contractor is to turn over all O/M manuals as directed by the COR at the conclusion of construction. (Pre priced CLIN).

Product Service Code: Y1EZ North American Industry Classification System (NAICS): 236220 Pricing Arrangement: Firm Fixed Price

1 Job

0004 PRE-PRICED CLIN $100,000.00 (One Hundred Thousand Dollars) Turnover of electronic and printed as built drawings. The contractor is to turn over all as builts as

1 Job directed by the specifications and COR at the conclusion of construction. (Pre priced

CLIN)

Pricing Arrangement: Firm Fixed Price

Section 00 20 00 - Instructions for Procurements

TOTAL BID (CLIN 0001 THRU 0004) $___________________________

NOTES TO BIDDERS

(1) CLIN 0003 and 0004 are pre-priced and should not change.

(2) Please refer to the Scope of Work section 01 11 00 for a description of the CLINs and reference to drawings and specifications.

(3) Offeror must submit a price for every CLIN. Failure to do so may result in Offer being unacceptable.

(4) Offers are to be valid for 120 calendar days.

(5) Period of performance (PoP - total contract duration) for the base bid scope is 1081 calendar days from NTP (Notice to Proceed).

*** END OF NARRATIVE ***

Section 00 21 00 - Instructions

CPARS- The Federal Acquisition Regulation (FAR) requires that Past Performance Information (PPI)be collected on DoD contracts. The Contractor Performance Assessment Reporting System (CPARS) is a web enabled application the supports the completion, distribution and retrieval of all contract performance evaluations. Contractor Representative are responsible for reviewing and commenting on evaluations submitted on the Contractor Performance Assessment Reporting System (CPARS) website at. https://www.cpars.gov/index.htm

BONDS- The Standard Form (SF24, SF25, and SF25A) for these bonds have been revised as of October2023, when including your proposal/offer, contractors/sureties shall use the revised versions. No other version will be valid and thus may render your proposal/offer nonresponsive.

EVERIFY- "The Contractor must pre-screen Candidates using the E-Verify Program (http://www.

uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-Verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award." *When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

The government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive proposals. Offerors are responsible for ensuring that Proposals are submitted so as to reach the designated recipient and designated location. Offerors are responsible for allowing sufficient time for the proposals to be received in accordance with the instructions provided.

*** END OF NARRATIVE ***

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.204-7 System for Award Management- Registration. (Deviation)

2026-02

52.214-34 Submission of Offers in the English Language.

1991-04

52.214-35 Submission of Offers in U.S. 1991-04

Currency.

52.215-1 Instructions to Offerors- Competitive Acquisition.

(Deviation)

2026-02

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. (Deviation)

2026-02

52.225-12 Notice of Buy American Requirement-Construction Materials Under Trade Agreements.

2014-05

DFARS Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements.

2023-11

252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors.

2023-01

252.215-7016 Notification to Offerors- Postaward Debriefings.

2025-10

252.233-7001 Choice of Law (Overseas). 1997-06

FAR Provisions Incorporated by Full Text

Number Title Effective Alternate Variation

Date Deviation Effective Date

52.216-1 Type of Contract. (Deviation) 2026-02

Type of Contract (Feb 2026) (Deviation)

The Government contemplates award of a contract resulting from this Firm Fixed Price solicitation.

(End of provision)

52.228-1 Bid Guarantee. 1996-09

Bid Guarantee (Sept 1996)

Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening (a) of bids, may be cause for rejection of the bid.

The bidder shall furnish a bid guarantee in the form of a firm commitment, bid bond (b) e.g., supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

To unsuccessful bidders as soon as practicable after the opening of bids; and(1)

To the successful bidder upon execution of contractual documents and bonds (including any (2) necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

The amount of the bid guarantee shall be percent of the bid price or , (c) 20% $3 Million whichever is less.

If the successful bidder, upon acceptance of its bid by the Government within the period (d) specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

In the event the contract is terminated for default, the bidder is liable for any cost of (e) acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of clause)

52.252-1 Solicitation Provisions Incorporated by Reference.

1998-02

Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov

(End of provision)

52.252-3 Alterations in Solicitation. 1984-04

Alterations in Solicitation (Apr 1984)

Portions of this solicitation are altered as follows:

None

(End of clause)

52.252-5 Authorized Deviations in Provisions.

2020-11

Authorized Deviations in Provisions (Nov 2020)

The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) (a) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

The use in this solicitation of any (48 CFR Chapter 2) provision with an authorized deviation (b) is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

DFARS Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective

252.215-7008 Only One Offer. 2022-12

ONLY ONE OFFER (DEC 2022)

(a) Cost or pricing data requirements. After initial submission of offers, if the Contracting Officer notifies the Offeror that only one offer was received, the Offeror agrees to-

(1) Submit any additional cost or pricing data that is required in order to determine whether the price is fair and reasonable (10 U.S.C. 3705) or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 3702 and FAR 15.403-3); and

(2) Except as provided in paragraph (b) of this provision, if the acquisition exceeds the certified cost or pricing data threshold and an exception to the requirement for certified cost or pricing data at FAR 15.403-1(b)(2) through (5) does not apply, certify all cost or pricing data in accordance with paragraph (c) of DFARS provision 252.215-7010, Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data, of this solicitation.

(b) Canadian Commercial Corporation. If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required. If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with DFARS 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following:

(1) Profit rate or fee (as applicable).

(2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1).

(3) Data other than certified cost or pricing data necessary to permit a determination by the U.

S. Contracting Officer that the proposed price is fair and reasonable ____[U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification].

(4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror.

(c) Subcontracts. Unless the Offeror is the Canadian Commercial Corporation, the Offeror shall insert the substance of this provision, including this paragraph (c), in all subcontracts exceeding the simplified acquisition threshold defined in FAR part 2.

Section 00 21 16 - Instructions to Proposers

See attached evaluation factors.

*** END OF NARRATIVE ***

Section 00 22 16 - Supplementary Instructions to Proposers

ELECTRONIC PROPOSALS

(a) Definition. Electronic proposal, as used in this provision, means a proposal, revision or modification of a proposal, or withdrawal of a proposal that is transmitted to and received by the Government via electronic commerce (see FAR Subpart 4.5 -- Electronic Commerce in Contracting).

(b) Offerors may submit electronic proposals as responses to this solicitation. Electronic proposals are subject to the same rules as paper proposals.

(c) The format for electronic proposals in this solicitation is: PDF documents sent via email, ONLY to the Contract Specialist and Contracting Officer, as listed below:

Orlando Nieves: Email Address: Orlando.Nieves@usace.army.mil

Matthew Lubiak: Email Address: Matthew.e.Lubiak@usace.army.mil

(d) If any portion of an electronic proposal received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document -- (1) The Contracting Officer immediately shall notify the offeror and permit the offeror to resubmit the proposal; (2) The method and time for resubmission shall be prescribed by the Contracting Officer after consultation with the offeror; and (3) The resubmission shall be considered as if it were received at the date and time of the original unreadable submission for the purpose of determining timeliness, provided the offeror complies with the time and format requirements for resubmission prescribed by the Contracting Officer.

(e) The Government reserves the right to make award solely on the electronic proposal. However, if requested to do so by the Contracting Officer, the apparently successful offeror promptly shall submit the complete original signed proposal.

*** END OF NARRATIVE ***

Section 00 45 00 - Representations and Certifications

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements- Representation.

2017-01

52.229-12 Tax on Certain Foreign Procurements.

2021-02

DFARS Provisions Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.203-7005 Representation Relating to Compensation of Former DoD Officials.

2022-09

252.204-7008 Compliance with Safeguarding Covered Defense Information Controls.

2016-10

252.225-7055 Representation Regarding Business Operations with the Maduro Regime.

2022-05

252.225-7057 Preaward Disclosure of Employment of Individuals Who Work in the People's Republic of

2022-08

China.

252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region- Representation.

2023-06

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.209-7 Information Regarding Responsibility Matters.

(Deviation)

2026-02

Information Regarding Responsibility Matters (Feb 2026) (Deviation)

(a) Definitions. As used in this provision-

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for

Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

DFARS Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services-Representation.

2021-05

PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE TELECOMMUNICATIONS

EQUIPMENT OR SERVICES-REPRESENTATION (MAY 2021)

The Offeror is not required to complete the representation in this provision if the Offeror has represented in the provision at 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation, that it "does not provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument."

(a) Definitions. "Covered defense telecommunications equipment or services," "covered mission," "critical technology," and "substantial or essential component," as used in this provision, have the meanings given in the 252.204-7018 clause, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services, of this solicitation.

(b) Prohibition. Section 1656 of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits agencies from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) at https://www.sam.gov for entities that are excluded when providing any equipment, system, or service to carry out covered missions that uses covered defense telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless a waiver is granted.

(d) Representation. If in its annual representations and certifications in SAM the Offeror has represented in paragraph (c) of the provision at 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation, that it "does" provide covered defense telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument, then the Offeror shall complete the following additional representation:

The Offeror represents that it [ ] will [ ] will not provide covered defense telecommunications equipment or services as a part of its offered products or services to DoD in the performance of any award resulting from this solicitation.

(e) Disclosures. If the Offeror has represented in paragraph (d) of this provision that it "will provide covered defense telecommunications equipment or services," the Offeror shall provide the following information as part of the offer:

(1) A description of all covered defense telecommunications equipment and services offered (include brand or manufacturer; product, such as model number, original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable).

(2) An explanation of the proposed use of covered defense telecommunications equipment and services and any factors relevant to determining if such use would be permissible under the prohibition referenced in paragraph (b) of this provision.

(3) For services, the entity providing the covered defense telecommunications services (include entity name, unique entity identifier, and Commercial and Government Entity (CAGE) code, if known).

(4) For equipment, the entity that produced or provided the covered defense telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known).

Section 00 70 00 - Conditions of the Contract

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.219-9 Small Business Subcontracting Plan. (Deviation) (Alternate II)

2026-02 Alternate

II

2026-02

52.222-3 Convict Labor. (Deviation) 2026-02

52.222-7 Withholding of Funds. (Deviation) 2026-02

52.240-90 Security Prohibitions and Exclusions Representations and Certifications. (Deviation)

2026-02

52.240-91 Security Prohibitions and Exclusions. (Deviation)

DFARS Clauses Incorporated by Reference

Date

Alternate Deviation

Variation Effective

252.226-7003 Drug-Free Work Force. 2024-08

Section 00 72 00 - General Conditions

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.203-3 Gratuities. 1984-04

52.203-5 Covenant Against Contingent Fees.

2014-05

52.203-6 Restrictions on Subcontractor Sales to the Government.

2020-06

52.203-7 Anti-Kickback Procedures. 2020-06

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity.

2014-05

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity.

2014-05

52.203-12 Limitation on Payments to Influence Certain Federal Transactions.

2020-06

52.203-13 Contractor Code of Business Ethics and Conduct.

2021-11

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-9 Personal Identity Verification of Contractor Personnel.

2011-01

52.204-10 Reporting Executive 2026-02

Compensation and First-Tier Subcontract Awards. (Deviation)

52.204-13 System for Award Management- Maintenance. (Deviation)

2026-02

52.204-19 Incorporation by Reference of Representations and Certifications.

2014-12

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (Deviation)

2026-02

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters.

(Deviation)

2026-02

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations.

(Deviation)

2026-02

52.210-1 Market Research. (Deviation) 2026-02

52.211-13 Time Extensions. 2000-09

52.212-4 Terms and Conditions- Commercial Products and Commercial Services. (Deviation 2026-O0038)

2026-02

52.215-2 Audit and Records-Negotiation.

(Deviation)

2026-02

52.217-2 Cancellation Under Multi-year Contracts.

1997-10

52.219-8 Utilization of Small Business Concerns. (Deviation)

2026-02

52.219-9 Small Business Subcontracting Plan. (Deviation)

2026-02

52.219-16 Liquidated Damages- Subcontracting Plan. (Deviation)

2026-02

52.219-33 Nonmanufacturer Rule.

(Deviation)

2026-02

52.222-1 Notice to the Government of Labor Disputes. (Deviation)

2026-02

52.222-4 Contract Work Hours and Safety Standards-Overtime Compensation. (Deviation)

2026-02

52.222-6 Construction Wage Rate Requirements. (Deviation)

2026-02

52.222-8 Payrolls and Basic Records.

(Deviation)

2026-02

52.222-9 Apprentices and Trainees.

(Deviation)

2026-02

52.222-10 Compliance with Copeland Act Requirements. (Deviation)

2026-02

52.222-11 Subcontracts (Labor Standards).

(Deviation)

2026-02

52.222-12 Contract Termination-Debarment. 2014-05

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations.

2014-05

52.222-14 Disputes Concerning Labor Standards. (Deviation)

2026-02

52.222-35 Equal Opportunity for Veterans.

(Deviation)

2026-02

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (Deviation)

2026-02

52.222-50 Combating Trafficking in Persons. (Deviation)

2026-02

52.222-54 Employment Eligibility Verification. (Deviation)

2026-02

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. (Deviation)

2026-02

52.222-62 Paid Sick Leave Under Executive Order 13706. (Deviation)

2026-02

52.223-5 Pollution Prevention and Right-to- Know Information.

2024-05

52.223-23 Sustainable Products. (Deviation) 2026-02

52.226-7 Drug-Free Workplace. 2024-05

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.

2024-05

52.228-2 Additional Bond Security. 1997-10

52.228-5 Insurance-Work on a Government Installation.

1997-01

52.228-15 Performance and Payment 2020-06

Bonds-Construction.

52.229-3 Federal, State, and Local Taxes. 2013-02

52.232-17 Interest. 2014-05

52.232-23 Assignment of Claims. 2014-05

52.232-27 Prompt Payment for Construction Contracts.

2017-01

52.232-33 Payment by Electronic Funds Transfer-System for Award Management.

2018-10

52.232-39 Unenforceability of Unauthorized Obligations.

2013-06

52.232-40 Providing Accelerated Payments to Small Business Subcontractors.

2023-03

52.233-1 Disputes. (Deviation) 2026-02

52.233-3 Protest after Award. (Deviation) 2026-02

52.233-4 Applicable Law for Breach of Contract Claim. (Deviation)

2026-02

52.236-2 Differing Site Conditions.

(Deviation)

2026-02

52.236-3 Site Investigation and Conditions Affecting the Work. (Deviation)

2026-02

52.236-5 Material and Workmanship.

(Deviation)

2026-02

52.236-6 Superintendence by the Contractor. (Deviation)

2026-02

52.236-7 Permits and Responsibilities.

2026-02

52.236-8 Other Contracts. (Deviation) 2026-02

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (Deviation)

2026-02

52.236-10 Operations and Storage Areas.

(Deviation)

2026-02

52.236-12 Cleaning Up. (Deviation) 2026-02

52.236-13 Accident Prevention. (Deviation) 2026-02

52.236-15 Schedules for Construction Contracts. (Deviation)

2026-02

52.236-21 Specifications and Drawings for Construction. (Deviation)

2026-02

52.242-13 Bankruptcy. 1995-07

52.242-14 Suspension of Work. 1984-04

52.243-4 Changes. (Deviation) 2026-02

52.243-5 Changes and Changed Conditions. (Deviation)

2026-02

52.244-6 Subcontracts for Commercial Products and Commercial Services. (Deviation)

2026-02

52.246-12 Inspection of Construction. 1996-08

52.246-13 Inspection-Dismantling, Demolition, or Removal of Improvements.

1996-08

52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form).

1984-04

52.249-2 Termination for Convenience of the Government (Fixed-Price).

2012-04

52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements).

2012-04

52.249-10 Default (Fixed-Price Construction).

1984-04

DFARS Clauses Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.204-7003 Control of Government Personnel Work Product.

1992-04

252.204-7004 Antiterrorism Awareness Training for Contractors.

2023-01

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

2023-01

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.219-7003 Small Business Subcontracting 2019-12

Plan (DoD Contracts).

252.222-7002 Compliance with Local Labor Laws (Overseas).

1997-06

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

2023-06

252.236-7000 Modification Proposals--Price Breakdown.

1991-12

252.236-7007 Additive or Deductive Items. 1991-12

252.247-7023 Transportation of Supplies by Sea.

2024-10

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.211-12 Liquidated Damages- Construction.

2000-09

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of:

This amount is the "first tier" demurrage based upon costs incurred First Tier: $2,858.00/day.

in administration of the contract past the completion date. This amount does not include any liquidated damages for each day of delay that would accrue to the using service from exclusion of beneficial occupancy.

Second Tier: $714.00/day. The "second tier" demurrage shall be assessed at the rate calculated below in the event the contractor fails to complete documented punchlist items after the date of beneficial occupancy.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.219-28 Postaward Small Business Program Rerepresentation.

Postaward Small Business Program Rerepresentation (Feb 2026) (Deviation)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options.

However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was a small business concern, a small disadvantaged business concern, or a joint venture that was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document /support--table-size-standards.

(d) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition-

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation(s) required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award

Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting officer in writing within the timeframes specified in paragraph (b) of this clause, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under ____NAICS Code assigned to ____contract number.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (g)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1001.

(3) Women-owned small business (WOSB) joint venture eligible under the WOSB Program. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(4) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __ .]

(5) Service-disabled veteran-owned small business (SDVOSB) joint venture eligible under the SDVOSB Program. The Contractor represents that it [ ] is, [ ] is not an SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402.

[____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(6) HUBZone joint venture eligible under the HUBZone Program.[ Complete only if the offeror is a HUBZone small business concern. ] The offeror represents, as part of its offer, that It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: .] Each HUBZone small business concern participating in the HUBZone joint venture must be certified as a HUBZone concern. [____Contractor to sign and date and insert authorized signer's name and title.]

(End of clause)

52.225-11 Buy American-Construction Materials under Trade Agreements. (Deviation)

2026-02

Buy American-Construction Materials under Trade Agreements (Feb 2026) (Deviation)

(a) . As used in this clause-Definitions

Caribbean Basin country construction material means a construction material that-

(1) Is wholly the growth, product, or manufacture of a Caribbean Basin country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

Commercially available off-the-shelf (COTS) item-

(1) Means any item of supply (including construction material) that is-

(i) A commercial product (as defined in paragraph (1) of the definition of "commercial product" at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies.

However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means-

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Designated country means any of the following countries:

(1) A World Trade Organization Government Procurement Agreement (WTO GPA) country (Armenia, Aruba, Australia, Austria, Belgium, Bulgaria, Canada, Croatia, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland, Israel, Italy, Japan, Korea (Republic of), Latvia, Liechtenstein, Lithuania, Luxembourg, Malta, Moldova, Montenegro, Netherlands, New Zealand, North Macedonia, Norway, Poland, Portugal, Romania, Singapore, Slovak Republic, Slovenia, Spain, Sweden, Switzerland, Taiwan, Ukraine, or United Kingdom);

(2) A Free Trade Agreement (FTA) country (Australia, Bahrain, Chile, Colombia, Costa Rica, Dominican Republic, El Salvador, Guatemala, Honduras, Korea (Republic of), Mexico, Morocco, Nicaragua, Oman, Panama, Peru, or Singapore);

(3) A least developed country (Afghanistan, Angola, Bangladesh, Benin, Bhutan, Burkina Faso, Burundi, Cambodia, Central African Republic, Chad, Comoros, Democratic Republic of Congo, Djibouti, Equatorial Guinea, Eritrea, Ethiopia, Gambia, Guinea, Guinea-Bissau, Haiti, Kiribati, Laos, Lesotho, Liberia, Madagascar, Malawi, Mali, Mauritania, Mozambique, Nepal, Niger, Rwanda, Samoa, Sao Tome and Principe, Senegal, Sierra Leone, Solomon Islands, Somalia, South Sudan, Tanzania, Timor-Leste, Togo, Tuvalu, Uganda, Vanuatu, Yemen, or Zambia); or

(4) A Caribbean Basin country (Antigua and Barbuda, Aruba, Bahamas, Barbados, Belize, Bonaire, British Virgin Islands, Curacao, Dominica, Grenada, Guyana, Haiti, Jamaica, Montserrat, Saba, St. Kitts and Nevis, St. Lucia, St. Vincent and the Grenadines, Sint Eustatius, Sint Maarten, or Trinidad and Tobago).

Designated country construction material means a construction material that is a WTO GPA country construction material, an FTA country construction material, a least developed country construction material, or a Caribbean Basin country construction material.

Domestic construction material means-

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if-

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States.

Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Free Trade Agreement country construction material means a construction material that-

(1) Is wholly the growth, product, or manufacture of a Free Trade Agreement (FTA) country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a FTA country into a new and different construction material distinct from the materials from which it was transformed.

Least developed country construction material means a construction material that-

(1) Is wholly the growth, product, or manufacture of a least developed country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the materials from which it was transformed.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that…