S02 Final Specifications 523A5-10-316 Laundry Building 45.pdf

Upgrade VISN 1 Laundry, Building 45 at the

VA Boston Healthcare System

Brockton VA Medical Center Brockton, MA

Specifications (CD)

Volume 1 - Architectural & Structural Sections August 21, 2024

Project Number: 523A5-10-316

TMM 2224

2224 VA Brockton, Bldg. 45, Laundry Upgrade 8-21-24

523A5-10-16

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 05-20

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 11-21

01 32 16 Project Schedule (cost loaded)

01 33 23 Shop Drawings, Product Data, and Samples 11-23

01 35 26 Safety Requirements for Major Projects 12-23

01 42 19 Reference Standards 11-20

01 45 00 Quality Control 02-21

01 45 29 Testing Laboratory Services 11-18

01 45 35 Special Inspections 06-21

01 57 19 Temporary Environmental Controls 01-21

01 74 19 Construction Waste Management 04-22

01 81 13 Sustainable Construction Requirements 10-17

01 91 00 General Commissioning Requirements 04-22

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

02 83 33.13 Lead-Based Paint Removal and Disposal 01-21

DIVISION 03 – CONCRETE

03 30 00 Cast-in-Place Concrete 01-21

DIVISION 04 – MASONRY

04 01 00 Maintenance of Masonry 01-21

04 05 13 Masonry Mortaring 10-17

04 05 16 Masonry Grouting 01-21

04 20 00 Unit Masonry 08-17

DIVISION 05 – METALS

05 12 00 Structural Steel Framing

05 31 00 Steel Decking 01-21

05 50 00 Metal Fabrications 08-18

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17

06 16 63 Cementitious Sheathing 01-21

00 01 10-2

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 13 Thermal Insulation 01-21

07 21 23 Loose-Fill Insulation 01-21

07 27 26 Fluid-Applied Membrane Air Barrier, Vapor Permeable 01-21

07 27 27 Fluid-Applied Membrane Air Barrier, Vapor Retarding 01-21

07 51 00 Built-Up Bituminous Roofing 12-21

07 84 00 Firestopping 01-21

07 92 00 Joint Sealants 04-22

07 95 13 Expansion Joint Cover Assemblies 01-21

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 01-21

08 31 13 Access Doors and Frames 04-22

08 51 23 Steel Windows 01-21

08 71 00 Door Hardware 01-24

08 80 00 Glazing 01-21

08 90 00 Louvers and Vents 01-21

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 01-21

09 06 00 Schedule for Finishes 01-21

09 22 16 Non-Structural Metal Framing 06-18

09 24 00 Portland Cement Plastering 01-21

09 29 00 Gypsum Board 04-20

09 51 00 Acoustical Ceilings 12-18

09 65 13 Resilient Base and Accessories 01-21

09 67 23.60 Resinous Urethane and Epoxy Mortar Flooring (RES-6A and

RES 6B)

01-21

09 91 00 Painting 01-21

DIVISION 10 – SPECIALTIES

10 14 00 Signage 01-21

10 26 00 Wall and Door Protection 01-21

10 44 13 Fire Extinguisher Cabinets 08-18

DIVISION 12 – FURNISHINGS

DIVISION 14– CONVEYING EQUIPEMENT

DIVISION 21- FIRE SUPPRESSION

21 13 13 Wet-Pipe Sprinkler Systems 06-15

00 01 10-3

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 01-23

22 05 12 General Motor Requirements for Plumbing Equipment 09-20

22 05 19 Meters and Gages for Plumbing Piping 09-20

22 05 23 General-Duty Valves for Plumbing Piping 09-20

22 07 11 Plumbing Insulation 09-19

22 08 00 Commissioning of Plumbing Systems 11-16

22 11 00 Facility Water Distribution 05-21

22 11 23 Domestic Water Pumps 09-15

22 13 00 Facility Sanitary and Vent Piping 09-20

22 14 00 Facility Storm Drainage 09-15

22 15 00 General Service Compressed-Air Systems 09-20

22 35 00 Domestic Water Heat Exchangers 09-20

22 40 00 Plumbing Fixtures 12-22

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 03-23

23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment

03-23

23 05 41 Noise and Vibration Control for HVAC Piping and

Equipment

03-23

23 05 93 Testing, Adjusting, and Balancing for HVAC 03-23

23 07 11 HVAC and Boiler Plant Insulation 02-20

23 08 00 Commissioning of HVAC Systems 03-23

23 09 23 Direct-Digital Control System for HVAC 03-23

23 11 23 Facility Natural-Gas Piping 04-20

23 21 11 Boiler Plant Piping Systems 12-23 23 21 13 Hydronic Piping 03-23 23 21 23 Hydronic Pumps 03-23 23 22 13 Steam and Condensate Heating Piping 08-23 23 22 23 Steam Condensate Pumps 04-20 23 23 00 Refrigerant Piping 03-23

23 25 00 HVAC Water Treatment 03-23

23 31 00 HVAC Ducts and Casings 03-23

23 34 00 HVAC Fans 03-23

23 37 00 Air Outlets and Inlets 03-23

23 73 00 Indoor Central-Station Air-Handling Units 03-23

23 81 43 Air-Source Unitary Heat Pumps 03-23

23 82 16 Air Coils 03-23

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 11-22

26 05 13 Medium-Voltage Cables 11-22

26 05 19 Low-Voltage Electrical Power Conductors and Cables 11-22

26 05 26 Grounding and Bonding for Electrical Systems 11-22

26 05 33 Raceway and Boxes for Electrical Systems 11-22

26 05 41 Underground Electrical Construction 11-22

00 01 10-4

26 05 73 Overcurrent Protective Device Coordination Study 11-22

26 08 00 Commissioning of Electrical Systems 11-22

26 12 19 Pad-Mounted, Liquid-Filled, Medium-Voltage Transformers 11-22

26 22 00 Low-Voltage Transformers 11-22

26 23 13 Generator Paralleling Controls 11-22

26 24 13 Distribution Switchboards 11-22

26 24 16 Panelboards 11-22

26 27 26 Wiring Devices 11-22

26 29 11 Motor Controllers 11-22

26 29 21 Enclosed Switches and Circuit Breakers 11-22

26 32 13 Engine Generators 11-22

26 36 23 Automatic Transfer Switches 11-22

26 43 13 Surge Protective Devices 11-22

26 51 00 Interior Lighting 11-22

26 56 00 Exterior Lighting 11-22

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19

27 05 26 Grounding and Bonding for Communications Systems 06-15

27 05 33 Raceways and Boxes for Communications Systems 10-18

27 08 00 Commissioning of Communications Systems 11-16

27 10 00 Control, Communication and Signal Wiring 06-15

27 11 00 Telecommunications Room Fittings 06-15

27 15 00 Communications Structured Cabling 01-16

27 31 00 Voice Communications Switching and Routing Equipment 06-15

27 31 31 Voice Communications Switching and Routing Equipment -

Extension

06-15

27 51 23 Intercommunications and Program Systems 06-15

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18

28 05 13 Conductors and Cables for Electronic Safety and

Security

10-18

28 05 26 Grounding and Bonding for Electronic Safety and

Security

09-11

28 05 28.33 Conduits and Backboxes for Electronic Safety and

Security

09-11

28 08 00 Commissioning of Electronic Safety and Security Systems 11-16

28 13 00 Physical Access Control System 10-11

28 16 00 Intrusion Detection System 10-11

28 23 00 Video Surveillance 09-11

28 31 00 Fire Detection and Alarm 10-11

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GENERAL

GI001 COVER SHEET

GI002 GENERAL NOTES, DETAIL, ABBREVIATIONS & LEGENDS

GI003 SHEET INDEX

ARCHITECTURAL

LS001 LIFE SAFETY CODE SEARCH

LS002 ARCHITECTURAL SITE UTILITY PLAN

LS101 ARCHITECTURAL LIFE SAFETY PLAN - BASEMENT

LS102 ARCHITECTURAL LIFE SAFETY PLAN - FIRST FLOOR

AD100 ARCHITECTURAL DEMOLITION PLAN - BASEMENT

AD101 ARCHITECTURAL DEMOLITION PLAN - FIRST FLOOR

AD111 ARCHITECTURAL DEMOLITION REFLECTED

CEILING PLAN - BASEMENT

AD112 ARCHITECTURAL DEMOLITION REFLECTED

CEILING PLAN - FIRST FLOOR

AE100 ARCHITECTURAL AREA PLANS

AE101-A ARCHITECTURAL FLOOR PLAN - BASEMENT

AE101-B ARCHITECTURAL FLOOR PLAN - FIRST FLOOR

AE111-A ARCHITECTURAL REFLECTED CEILING PLAN - BASEMENT

AE111-B ARCHITECTURAL REFLECTED CEILING

PLAN - FIRST FLOOR

AE121 ARCHITECTURAL ROOF PLAN

AE201 ARCHITECTURAL EXTERIOR ELEVATIONS

AE301 ARCHITECTURAL BUILDING SECTIONS

AE351 ARCHITECTURAL WALL SECTIONS

AE401 ARCHITECTURAL ENLARGED FLOOR PLANS & DETAILS

AE402 ENLARGED STAIR PLANS, SECTIONS & STAIR DETAILS

AE451 ARCHITECTURAL INTERIOR ELEVATIONS

00 01 15 - 2

AE501 ARCHITECTURAL PARTITION TYPES AND DETAILS

AE502 ARCHITECTURAL FRAMING DETAILS

AE601 WINDOW, DOOR AND FRAME TYPES, SCHEDULES

AND DETAILS

AE701-A ARCHITECTURAL FINISH PLAN – BASEMENT

AE701-B ARCHITECTURAL FINISH PLAN - FIRST FLOOR

AE800 EQUIPMENT SCHEDULE

AE900 ARCHITECTURAL SIGNAGE - SCHEDULE & TYPES

AE901-A ARCHITECTURAL SIGNAGE PLAN - BASEMENT

AE901-B ARCHITECTURAL SIGNAGE PLAN - FIRST FLOOR

LAUNDRY EQUIPMENT

LE101 EQUIPMENT PLAN – BASEMENT

LE102 EQUIPMENT PLAN – FIRST FLOOR

LE0001 LAUNDRY EQUIPMENT M2-0001

LE0050 LAUNDRY EQUIPMENT M2-0050

LE0401 LAUNDRY EQUIPMENT M2-0401

LE0402 LAUNDRY EQUIPMENT M2-0402

LE2100 LAUNDRY EQUIPMENT M2-2100

LE2200 LAUNDRY EQUIPMENT M2-2200

LE2300 LAUNDRY EQUIPMENT M2-2300

LE2301 LAUNDRY EQUIPMENT M2-2301

LE2310 LAUNDRY EQUIPMENT M2-2310

LE3100 LAUNDRY EQUIPMENT M2-3100

LE3200 LAUNDRY EQUIPMENT M2-3200

LE3300 LAUNDRY EQUIPMENT M2-3300

LE3301 LAUNDRY EQUIPMENT M2-3301

LE3310 LAUNDRY EQUIPMENT M2-3310

LE3001 LAUNDRY EQUIPMENT BASEMENT PLAN

LE3002 LAUNDRY EQUIPMENT BASEMENT PLAN

LE3003 LAUNDRY EQUIPMENT BASEMENT PLAN

LE3004 LAUNDRY EQUIPMENT BASEMENT PLAN

LE3005 LAUNDRY EQUIPMENT BASEMENT PLAN

LE3006 LAUNDRY EQUIPMENT BASEMENT PLAN

LE3007 LAUNDRY EQUIPMENT BASEMENT PLAN

00 01 15 - 3

STRUCTURAL

S001 STRUCTURAL NOTES

S002 STRUCTURAL NOTES

S101 FOUNDATION PLAN

S102 FLOOR FRAMING PLAN

S103 ROOF FRAMING PLAN

S201 FRAMING ELEVATIONS AND DETAILS

S301 CONCRETE DETAILS

S302 CONCRETE DETAILS

S501 STEEL DETAILS

PLUMBING

P-001 PLUMBING LEGEND

PD100 PLUMBING DEMOLITION PLAN - FOUNDATION

PD101 PLUMBING DEMOLITION PLAN - BASEMENT

PF101 PLUMBING PLAN - FOUNDATION

PL101 PLUMBING PLAN - BASEMENT

PL102 PLUMBING PLAN - FIRST FLOOR

P-501 PLUMBING DETAILS

P-601 PLUMBING SCHEDULES

P-701 PLUMBING NATRUAL GAS RISER

P-702 PLUMBING COMPRESSED AIR RISER

P-703 WATER PIPING RISER

P-704 SANITARY PIPING RISER

MECHANICAL

M-001 MECHANICAL LEGEND

MD101 MECHANICAL DEMOLITION PLAN - FIRST FLOOR

MD102 MECHANICAL DEMOLITION PLAN - ROOF

MH101 MECHANICAL HVAC PLAN - BASEMENT

MH102 MECHANICAL HVAC PLAN - FIRST FLOOR

MH103 MECHANICAL HVAC PLAN - ROOF

MP101 MECHANICAL PIPING PLAN - BASEMENT

MP102 MECHANICAL PIPING PLAN - FIRST FLOOR

M-501 MECHANICAL DETAILS

00 01 15 - 4

M-502 MECHANICAL DETAILS

M-503 MECHANICAL DETAILS

M-601 MECHANICAL SCHEDULES

M-602 MECHANICAL SCHEDULES

M-603 MECHANICAL SCHEDULES

M-701 MECHANICAL FLOW DIAGRAMS

M-702 MECHANICAL FLOW DIAGRAMS

M-800 MECHANICAL CONTROLS

M-801 MECHANICAL CONTROLS

M-802 MECHANICAL CONTROLS

ELECTRICAL

E-001 ELECTRICAL LEGEND, NOTES AND ABBREVIATIONS

ED101 ELECTRICAL DEMOLITION PLAN - BASEMENT

EL101A ELECTRICAL LIGHTING PLAN - BASEMENT

EL101B ELECTRICAL LIGHTING PLAN - FIRST FLOOR

EP101A ELECTRICAL POWER PLAN - BASEMENT

EP101B ELECTRICAL POWER PLAN - FIRST FLOOR

EP101C ELECTRICAL POWER PLAN - ROOF

EP102A ELECTRICAL LAUNDRY EQUIP POWER PLAN - BASEMENT

EP102B ELECTRICAL LAUNDRY EQUIP POWER

PLAN - FIRST FLOOR

EP401 ELECTRICAL ENLARGED POWER PLANS

EP501 ELECTRICAL DETAILS

EP601 ELECTRICAL EQUIPMENT CONNECTION SCHEDULE

EP602 ELECTRICAL LAUNDRY EQUIPMENT CONNECTION

SCHEDULE

EP603 ELECTRICAL LAUNDRY EQUIPMENT (SEAMLESS

MECHANICAL SUPPORT) CONNECTION SCHEDULE

EP604 ELECTRICAL PANEL SCHEDULES

EP605 ELECTRICAL PANEL SCHEDULES AND RISER DIAGRAM

EP701 ELECTRICAL EXISTING ONE-LINE DIAGRAM

TELECOM

T-001 TELECOM LEGEND, NOTES AND ABBREVIATIONS

TT101A BASEMENT PLAN – TELECOM

00 01 15 - 5

TT101B FIRST FLOOR – TELECOM

TT401 ENLARGED TELECOM PLAN AND DETAILS

FIRE PROTECTION

FA001 FIRE ALARM LEGEND

FA101 BASEMENT FLOOR FIRE ALARM PLAN

FA102 FIRST FLOOR FIRE ALARM PLAN

FX001 FIRE SUPPRESSION LEGEND

FX101 BASEMENT FLOOR FIRE SUPPRESSION PLAN

FX102 FIRST FLOOR FIRE SUPPRESSION PLAN

FX501 FIRE SUPPRESSION LEGEND REFERENCE PLAN

FX502 BASEMENT FLOOR FIRE SUPPRESSION REFERENCE PLAN

FX503 FIRST FLOOR FIRE SUPPRESSION REFERENCE PLAN

- - - E N D - - -

11-01-21

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

GENERAL

1.1 SAFETY REQUIREMENTS

A. Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for VA Brockton, Bldg. 45, Laundry

Upgrade as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the

Contracting Officer’s Representative (COR).

C. Offices of Toland Mizell Monar, as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. NOT USED

E. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: BASE BID: Work includes general construction, alterations, walks, grading, necessary removal of existing structures and construction and certain other items.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

01 00 00 -2

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all subcontractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without an appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer. Patients and staff are not to be photographed at any time.

4. VA reserves the right to close or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

C. Guards:

1. The Construction Site, including all phases, should be secured at all times.

2. The General Contractor shall provide unarmed guards at each fenced entrance at all times when gates are kept open to prevent any VA ptient or employee walking in without safety measrues. This person should not be the General Contractor, Quality Control Officer, or

Safety Officer, but should be a guard with no other responsibilities when the gate is left open.

01 00 00 -3

D. Key Control:

1. The General Contractor shall provide two sets of duplicate keys and lock combinations to the Contracting officers representative (COR) for the purpose of security inspections of every area of project including toolboxes and parked machines and take any emergency action.

2. The Contractor shall provide access to VA Engineers at all times.

The Contractor shall keep a VA provided lock at each gate along with their own to ensure the site is secured at all times. If the VA provided lock or key is lost, Contractor shall reimburse the VA for the cost of a new lock or key up to $150.00.

3. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See Section 08 71

00, DOOR HARDWARE and coordinate.

E. Document Control:

1. Before starting any work, the General Contractor/Subcontractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of

“sensitive information”.

2. The General Contractor is responsible for the safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to complete the project.

3. NOT USED

4. NOT USED

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in a specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

Security, access and maintenance of all project drawings, both scanned and electronic, shall be performed and tracked through the EDMS system.

01 00 00 -4

“Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

F. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited// number of permits shall be issued for General

Contractor and its employees for parking in designated areas only.

Contractor to coordinate with VA Facility Manager.

3. No vehicle shall be parked, left standing or left idling outside the existing fenced area.

4. The Contractor’s personnel are only allowed to park in the

Contractor’s lot east of Pilgrim Ave. opposite the Golf Course. All other equipment, parking, and storage shall be within the fenced construction area.

1.6 OPERATIONS AND STORAGE AREAS (FAR 52.236-10)

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the

Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the

Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting

Officer, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by

01 00 00 -5 the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The

Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as determined by the COR.

E. Workers are subject to rules of Medical Center applicable to their conduct.

F. Execute work in such a manner as to interfere as little as possible with work being done by others. Keep roads clear of construction materials, debris, and standing construction equipment and vehicles at all times.

G. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others.

1. Do not store materials and equipment in other than assigned areas.

2. NOT USED

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

H. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR . All such actions shall be coordinated with the COR or Utility Company involved:

1. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor. //

I. Phasing and Scheduling:

1. The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur.

01 00 00 -6

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

2. To ensure such executions, Contractor shall furnish the COR with a schedule of approximate dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such dates to ensure accomplishment of this work in successive phases mutually agreeable to Medical Center Director, COR and Contractor.

J. Building (s) No. (s) 45 will be vacated by Government beginning immediately after date of receipt of Notice to Proceed and turned over to Contractor.

K. Building(s) No.(s) 45 will NOT be occupied during performance of work

1. NOT USED

2. Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical Centers operations will not be hindered.

3. Immediate areas of alterations not mentioned in preceding

Subparagraph 1 will be temporarily vacated while alterations are performed.

L. Construction Fence: Before construction operations begin, Contractor shall provide a chain link construction fence, 2.1m (seven feet) minimum height, around the construction area indicated on the drawings.

Provide gates as required for access with necessary hardware, including hasps and padlocks. Fasten fence fabric to terminal posts with tension bands and to line posts and top and bottom rails with tie wires spaced at maximum 375mm (15 inches). Bottom of fences shall extend to 25mm

(one inch) above grade. Remove the fence when directed by COR. Existing

01 00 00 -7 fencing may be incorporated as part of this perimeter fence as long as the existing fence is not altered and is left in good condition at the conclusion of the project.

M. When a building and/or construction site is turned over to Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

1. The Contractor shall maintain a minimum temperature of 4 degrees C

(40 degrees F) at all times, except as otherwise specified.

2. The Contractor shall make arrangements for pre-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractor's employee or watchman.

N. Utilities Services: Maintain existing utility services for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR . Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR

COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON WORK RESULTS FOR

ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. The contractor shall submit a request to interrupt any such services to the COR, in writing, 7 days in advance of the proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least

01 00 00 -8 inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and should be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

O. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, shall be removed back to their source. Those which are indicated to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

P. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking clear of construction materials, debris and standing construction equipment and vehicles. Wherever excavation for new utility lines cross existing roads, at least one lane must be open to traffic at all times with approval.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

Q. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF ROADWAYS.

01 00 00 -9

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR of building in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by both, to the Contracting Officer. This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur, and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by Contractor with new items in accordance with specifications which will be furnished by Government.

Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR

52.243-4).

C. Re-Survey: Thirty days before the expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and will form basis for determining extent of repair work required of

Contractor to restore damage caused by Contractor's workers in executing work of this contract.

01 00 00 -10

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage to portions of existing structures and grounds where work is to be done, materials handled, and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items in location directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

4. PCB Transformers and Capacitors : The Contractor shall be responsible for disposal of any Polychlorinated Biphenyl (PCB) transformers and capacitors . The transformers and capacitors shall be taken out of service and handled in accordance with the procedures of the Environmental Protection Agency (EPA) and the

Department of Transportation (DOT) as outlined in Code of Federal

01 00 00 -11

Regulation (CFR), Titled 40 and 49 respectively. The EPA's Toxic

Substance Control Act (TSCA) Compliance Program Policy Nos. 6-PCB-6 and 6-PCB-7 also apply. Upon removal of PCB transformers and capacitors for disposal, the "originator" copy of the Uniform

Hazardous Waste Manifest (EPA Form 8700-22), along with the Uniform

Hazardous Waste Manifest Continuation Sheet (EPA Form 8700-22A) shall be returned to the Contracting Officer who will annotate the contract file and transmit the Manifest to the Medical Center's

Chief.

a) Copies of the following listed CFR titles may be obtained from the Government Printing Office:

40 CFR 261........Identification and Listing of Hazardous Waste

40 CFR 262........Standards Applicable to Generators of Hazardous

Waste

40 CFR 263........Standards Applicable to Transporters of

Hazardous Waste

40 CFR 761........PCB Manufacturing, Processing, Distribution in

Commerce, and use Prohibitions

49 CFR 172........Hazardous Material tables and Hazardous

Material Communications Regulations

49 CFR 173........Shippers - General Requirements for Shipments and Packaging

49 CRR 173........Subpart A General

49 CFR 173........Subpart B Preparation of Hazardous Material for

Transportation

49 CFR 173........Subpart J Other Regulated Material; Definitions and Preparation

TSCA..............Compliance Program Policy Nos. 6-PCB-6 and 6-

PCB-7

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (FAR 52.236-9)

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed, and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs

01 00 00 -12 or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workers, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting Officer.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the

Contractor fails or refuses to repair the damage promptly, the

Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils and the environment. Refer to Articles, "Alterations", "Restoration", and

"Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

D. Refer to FAR clause 52.236-7, "Permits and Responsibilities," which is included in General Conditions. A National Pollutant Discharge

Elimination System (NPDES) permit is required for this project. The

Contractor is considered an "operator" under the permit and has extensive responsibility for compliance with permit requirements. VA will make the permit application available at the (appropriate medical center) office. The apparent low bidder, contractor and affected subcontractors shall furnish all information and certifications that are required to comply with the permit process and permit requirements.

Many of the permit requirements will be satisfied by completing construction as shown and specified. Some requirements involve the

Contractor's method of operations and operations planning and the

Contractor is responsible for employing best management practices. The affected activities often include, but are not limited to the following:

1. Designating areas for equipment maintenance and repair.

2. Providing waste receptacles at convenient locations and provide regular collection of wastes.

01 00 00 -13

3. Locating equipment wash down areas on site and provide appropriate control of wash-waters.

4. Providing protected storage areas for chemicals, paints, solvents, fertilizers, and other potentially toxic materials; and

5. Providing adequately maintained sanitary facilities.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the

COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4) and "DIFFERING SITE CONDITIONS" (FAR 52.236-2).

1.11 NOT USED

1. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by

(FAR 52.236-4)

1.12 NOT USED

01 00 00 -14

1.13 NOT USED

1.14 AS-BUILT DRAWINGS

A. The contractor shall maintain two full-sized sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.15 WARRANTY MANAGEMENT

A. Warranty Management Plan: Develop a warranty management plan which contains information relevant to FAR 52.246-21 Warranty of Construction in at least 30 days before the planned pre-warranty conference, submit four sets of the warranty management plan. Include within the warranty management plan all required actions and documents to assure that the

Government receives all warranties to which it is entitled. The plan must be in narrative form and contain sufficient detail to render it suitable for use by future maintenance and repair personnel, whether tradesman, or of engineering background, not necessarily familiar with this contract. The term “status” as indicated below must include due date and whether item has been submitted or was approved. Warranty information made available during the construction phase must be submitted to the Contracting Officer for approval prior to each monthly invoice for payment. Assemble approved information in a binder and turn over to the Government upon acceptance of the work. The construction warranty period will begin on the date of the project acceptance and continue for the product warranty period. A joint 4 month and 9-month warranty inspection will be conducted, measured from time of acceptance, by the Contactor and the Contracting Officer. Include in the warranty management plan, but not limited to, the following:

1. Roles and responsibilities of all personnel associated with the warranty process, including points of contact and telephone numbers

01 00 00 -15 within the company of the Contractor, subcontractors, manufacturers or suppliers involved.

2. Furnish with each warranty the name, address and telephone number of each of the guarantor’s representatives nearest project location.

3. Listing and status of delivery of all Certificates of Warranty for extended warranty items, to include roofs, HVAC balancing, pumps, motors, transformers and for all commissioned systems such as fire protection and alarm systems, sprinkler systems and lightning protection systems, etc.

4. A list for each warranted equipment item, feature of construction or system indicating:

a. Name of item.

b. Model and serial numbers.

c. Location where installed.

d. Name and phone numbers of manufacturers and suppliers.

e. Name and phone numbers of manufacturers or suppliers.

f. Names, addresses and phone numbers of sources of spare parts.

g. Warranties and terms of warranty. Include one-year overall warranty of construction, including the starting date of warranty of construction. Items which have extended warranties must be indicated with separate warranty expiration dates.

h. Starting point and duration of warranty period.

i. Summary of maintenance procedures required to continue the warranty in force.

j. Cross-reference to specific pertinent Operation and Maintenance manuals.

k. Organizations, names and phone numbers of people to call for warranty service.

l. Typical response time and repair time expected for various warranted equipment.

5. The plans for attendance at the 4 and 9-month post construction warranty inspections conducted by the government.

6. Procedure and status of tagging of all equipment covered by extended warranties.

7. Copies of instructions to be posted near selected pieces of equipment where operation is critical for warranty and/or safety reasons.

01 00 00 -16

B. Performance & Payment Bonds: The Performance & Payment Bonds must remain effective throughout the construction period. In the event the Contractor fails to commence and diligently pursue any construction warranty work required, the Contracting Officer will have the work performed by others, and after completion of the work, will charge the remaining construction warranty funds of expenses incurred by the Government while performing the work, including, but not limited to administrative expenses.

1. In the event sufficient funds are not available to cover the construction warranty work performed by the Government at the contractor’s expense, the Contracting Officer will have the right to recoup expenses from the bonding company.

2. Following oral or written notification of required construction warranty repair work, the Contractor shall respond in a timely manner. Written verification will follow oral instructions. Failure to respond will be cause for the

Contracting Officer to proceed against the Contractor.

C. Pre-Warranty Conference: Prior to contract completion, and at a time designated by the Contracting Officer, the Contractor shall meet with the

Contracting Officer to develop a mutual understanding with respect to the requirements of this section. Communication procedures for Contractor notification of construction warranty defects, priorities with respect to the type of defect, reasonable time required for Contractor response, and other details deemed necessary by the Contracting Officer for the execution of the construction warranty will be established/ reviewed at this meeting. In connection with these requirements and at the time of the

Contractor’s quality control completion inspection, furnish the name, telephone number and address of a licensed and bonded company which is authorized to initiate and pursue construction warranty work action on behalf of the Contractor. This point of contract will be located within the local service area of the warranted construction, be continuously available and be responsive to Government inquiry on warranty work action and status. This requirement does not relieve the Contractor of any of its responsibilities in conjunction with other portions of this provision.

D. Contractor’s Response to Construction Warranty Service Requirements:

01 00 00 -17

E. Following oral or written notification by the Contracting Officer, the

Contractor shall respond to construction warranty service requirements in accordance with the “Construction Warranty Service Priority List” and the three categories of priorities listed below. Submit a report on any warranty item that has been repaired during the warranty period. Include within the report the cause of the problem, date reported, corrective action taken, and when the repair was completed. If the Contractor does not perform the construction warranty within the timeframe specified, the

Government will perform the work and back charge the construction warranty payment item established.

1. First Priority, Code 1. Perform onsite inspection to evaluate situation, and determine course of action within 4 hours, initiate work within 6 hours and work continuously to completion or relief.

2. Second Priority, Code 2. Perform onsite inspection to evaluate situation, and determine course of action within 8 hours, initiate work within 24 hours and work continuously to completion or relief.

3. Third Priority Code, 3. All other work to be initiated within 3 workdays and work continuously to completion or relief.

4. The “Construction Warranty Service Priority List” is as follows:

a) Code 1-Life Safety Systems

Fire suppression systems.

Fire alarm system(s).

b) Code 1-Air Conditioning Systems

Air conditioning leak in part of the building, if causing damage.

Air conditioning system not cooling properly.

c) Code 1 Doors

Overhead doors not operational, causing a security, fire or safety problem.

1) Interior, exterior personnel doors or hardware, not functioning properly, causing security, fire or safety problems.

d) Code 3-Doors

Overhead doors not operational.

Interior/exterior personnel doors or hardware not functioning properly.

e) Code 1-Electrical

01 00 00 -18

Power failure (entire area or any building operational after

1600 hours).

Security lights.

Smoke detectors.

f) Code 2-Electrical

Power failure (no power to a room or part of building).

Receptacle and lights not operational (in a room or part of building).

g) Code 3-Electrical

Exterior lights not operational.

h) Code 1-Gas

Leaks and pipeline breaks.

i) Code 1-Heat

Power failure affecting heat.

j) Code 1-Plumbing

Hot water heater failure.

2) Leaking water supply pipes

k) Code 2-Plumbing

Flush valves not operating properly

Fixture drain, supply line or any water pipe leaking.

Toilet leaking at base.

l) Code 3- Plumbing

Leaky faucets.

m) Code 3-Interior

Floors damaged.

Paint chipping or peeling.

Casework damaged.

n) Code 1-Roof Leaks

Damage to property is occurring.

o) Code 2-Water (Exterior)

No water to facility.

p) Code 2-Water (Hot)

No hot water in portion of building listed.

q) Code 3

All work not listed above.

F. Warranty Tags: At the time of installation, tag each warranted item with a durable, oil and water-resistant tag approved by the

Contracting Officer. Attach each tag with a copper wire and spray with

01 00 00 -19 a silicone waterproof coating. Also submit two record copies of the warranty tags showing the layout and design. The date of acceptance and the QC signature must remain blank until the project is accepted for beneficial occupancy. Show the following information on the tag.

Warranty Tags

Type of product/material

Model number

Serial number

Contract number

Warranty period from/to

Inspector’s signature

Construction Contractor

Address

Telephone number

Warranty Contact

Address

Telephone number

Warranty response time priority code

1.16 USE OF ROADWAYS

A. For hauling, use only established public roads and roads on Medical

Center property and, when authorized by the COR, such temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed, and restoration performed by the Contractor at Contractor's expense. When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.17 NOT USED

1.18 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical equipment to provide heat, ventilation, plumbing, light and power will be permitted subject compliance with the following provisions:

1. Permission to use each unit or system must be given by COR in writing. If the equipment is not installed and maintained in

01 00 00 -20 accordance with the written agreement and following provisions, the

COR will withdraw permission for use of the equipment.

2. Electrical installations used by the equipment shall be completed in accordance with the drawings and specifications to prevent damage to the equipment and the electrical systems, i.e. transformers, relays, circuit breakers, fuses, conductors, motor controllers and their overload elements shall be properly sized, coordinated and adjusted.

Installation of temporary electrical equipment or devices shall be in accordance with NFPA 70, National Electrical Code, (2014

Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be correct and it shall be determined that motors are not overloaded. The electrical equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuum cleaning and wiping clean interior and exterior surfaces.

3. Units shall be properly lubricated, balanced, and aligned.

Vibrations must be eliminated.

4. Automatic temperature…