Amendment 0014.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to provide responses to Pre-Proposal Inquiries, provide an updated Price Proposal Form, and provide Hard Copy Proposal Delivery Instructions.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 14

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 15-Apr-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008519R9252

X 9B. DATED (SEE ITEM 11)

09-Oct-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

15-Apr-2020

CODE

NAVFAC MID ATLANTIC

ACQUISITION CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

N40085 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008519R9252

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0014

MAILED HARD COPY PROPOSAL DELIVERY

The Non-Price Phase II and Price HARD COPY proposals shall be delivered by MAIL ONLY on the dates and times listed below, respectively, unless those dates are changed via Solicitation Amendment. Amendment 0012 includes the requirements for the hard copy proposals.

Proposals shall be labeled

“PRICE PROPOSAL OR NON-PRICE PHASE II PROPOSAL FOR RFP N4008519R9252,

ATTN: John Bishop; DO NOT OPEN IN MAIL ROOM”.

Hand delivered proposals will not be accepted.

Express Mail to:

Naval Facilities Engineering Command, Mid-Atlantic 9324 Virginia Avenue Building Z-140, Room 216 Norfolk, Virginia 23511 Attn: John Bishop, ACQ22

Hard Copy Proposal Due Dates:

Non-Price Phase II Hard Copy Proposal Due Date:

Wednesday, 29 April 2020, 1200 local time

Price Hard Copy Proposal Due Date:

Wednesday, 13 May 2020, 1200 local time

PRICE PROPOSAL FORM

This amendment provides an updated price proposal form. This form replaces all previous versions in their entirety.

PRE-PROPOSAL INQUIRIES

This amendment provides responses to PPIs number 34, 35, 46, 50, 55, 83, 88, 89, 127, 128, 132, 138, 153, 165, 169, 172, 175-177, 179, 180, 184, 189, 190, 194, 201-204, 220, 221, 239, 255, 257-259, 272, 273, 276, 280, 281, 291, 293-301

As of the publication of this Amendment, the Government has responded to all PPIs received to date. Offerors are advised to notify the contract specialist immediately if a previously submitted a PPI has not been answered.

AMENDMENT 014 - DESIGN BUILD RFP

A. PART 1 CONTRACT DOCUMENTS - FACTOR 5

1. FAVORABLE RATINGS - SCHEDULE:

a. See Amendment 0006, "A schedule that phase’s individual building completion dates within the package so the Government can take beneficial occupancy earlier than the 1,826 days overall completion date may be considered more favorably."

b. Factor 5, (4) Schedule "The awardee’s proposed project duration from award for each Project will be incorporated into the contract. Upon award, each project will have a separate completion date."

B. PART 2 GENERAL REQUIREMENTS

1. 01 57 19.01 20 - SUPPLEMENTAL TEMPORARY ENVIRONMENTAL CONTROLS

Additional Surplus Soils requirements are provided in MCBCAMLEJ Surplus Soil MILCON Spec Revision, Dated 6 April 2020; refer to Addendum H.5.

2. 01 31 23.13 20 ELECTRONIC CONSTRUCTION AND FACILITY SUPPORT

CONTRACT MANAGEMENT SYSTEM

PART 1 GENERAL

1.1 CONTRACT ADMINISTRATION

Add to the end of the paragraph, “In the event that ECMS is unavailable, and at the request of the Government, the Contractor may propose alternate Construction Management Software for use on this project. The proposed software solution must meet or exceed the requirements set forth within this specification. The use of alternate Construction Management software must be approved by the Government.”

C. PART 3 PROJECT PROGRAM - GENERAL (ALL MILCONS)

1. CHAPTER 6 ENGINEERING SYSTEMS REQUIREMENTS (ESR)

a. ESR B20 EXTERIOR ENCLOSURE – GENERAL

The goal of this RFP is to provide the contractor opportunity to offer cost effective solutions for all buildings while satisfying the requirements established by the D/B RFP. This includes but not limited to:

i. B201001 Exterior Closure system to match the exterior/architectural style as described in the BEAP (including brick masonry veneer, water table, Aluminum Standing Seam Metal Roof, etc...).

ii. B201002 Exterior Wall Back-Up Construction System including concrete/masonry wall systems (metal studs not permitted)

iii. B201003 Continuous insulation, vapor retarder, water-resistive barrier, and air barrier with envelope performance testing that comply with specified requirements.

b. ESR D30, GENERAL SYSTEM REQUIREMENTS

i. Remove: “The new facilities shall not use rooftop heating, ventilation, and air conditioning (HVAC) equipment. All major HVAC equipment shall be located in mechanical rooms. Consider attic and above-ceiling placement of AHU equipment only when absolutely necessary. Stairs are required for any above-ceiling or attic located air-handling equipment (excluding VAV terminals). Attic space may be used for mechanical equipment if there is a 6-foot-wide stairway with double doors for maintenance purposes.

Equipment with cooling coils placed above ceilings shall have secondary drain pans with approved gravity drainage piping.”

Replace with: “New facilities shall not use rooftop heating, ventilation, and air conditioning (HVAC) equipment. All major HVAC equipment must be located in mechanical rooms; major HVAC equipment must not be located above ceiling or in attic spaces.

Equipment with cooling coils placed above ceilings shall have secondary drain pans with approved gravity drainage piping.”

c. ESR D40 FIRE PROTECTION

i. Standard for Commissioning of Fire Protection and Life Safety Systems –

ii. ESR D40 FMCP Requirements – Technical Training

• Provide training at each building for the Electronics Mechanics and

Firefighters (Firefighters are “A” Platoon and “B” Platoon), so they have the opportunity to see the layout of each building and to locate all of the devices installed.

• Firefighters are required to develop a pre-fire plan for each building.

• Required Instruction Time: Provide 8 hours min. of instruction for each building after final acceptance of the system. The instruction shall be given during regular working hours on such dates and times as selected by the Contracting Officer. The instruction will be divided into two or more days. The training shall allow for rescheduling for unforeseen maintenance and/or fire department response.

• Provide seven laptops min. for this package.

• Need fire alarm company to install the operating system and software package that are associated with the installed fire alarm system to include the data sheets for the fire alarm control panel circuit cards and devices installed, and installation, programming, operation, and maintenance manuals on each laptop.

d. ESR G202003 PAVED SURFACES

Provide a 24’ x 36’ Portland cement concrete Pad at each building; location to be determined during CDW. Refer to Locker Concrete Pad sketch in Addendum.

e. ESR G205005 PLANTINGS

TOTAL LANDSCAPE AREA is defined as: The total disturbed area within the limits of the site that is not determined to be or designated as impervious; (i.e. buildings /structures, impervious parking lots, impervious walkways & plazas, etc.); Install per the

RFP.

f. ESR G4010 ELECTRICAL DISTRIBUTION Fault current calculation to be determined by AE2. The input (X/R Ratio and substation impedances) was provided in Addendum 13.

g. ESR G4030 SITE COMMUNICATION AND SECURITY In respond to PPIs, the following excerpts are provided out of the final RFP:

1) INSTALL 200 PR OSP COPPER FM ALL FACILITIES TO SITE MH, DISTANCE

TBD. INSTALL 24 FOC FM ALL FACILITIES TO SITE MH.

2) P1522/1529 Should be 24 SM FOC AND 100 PAIR OSP COPPER TO ALL FACILITIES; HQ/s AND OPS SUPPORT FACILITY BLDG.

h. ESR G403003 CABLES AND WIRING

1) The PPI comment says 'ALL' but not all MILCON G43003 are the same. Also there’s distances for all the cables with the exception of a couple, and that was TBD or ROM from the DMARC manhole to the new facilities on the site plans.

2) There’s a requirement for at least one conduit in all cases to have Fiber Mess Innerduct, please allow for this.

3) Comply with D/B RFP for requirements for cables and wiring and requirements changed in the Amendments.

2. PART 3.1 P1199

No changes

3. PART 3.2 P1300

a. CHAPTER 6, E20 FURNISHINGS - SYSTEM DESCRIPTION Change the FF&E estimate to the following amount of $7,138,982. This estimate does NOT include the Contractor’s Handling and Administration Rate (HAR).

b. ESR G4030 SITE COMMUNICATION AND SECURITY In respond to PPIs, the following excerpts are provided out of the final RFP:

1) INSTALL 200 PR OSP COPPER FM ALL FACILITIES TO SITE MH,

DISTANCE TBD. INSTALL 24 FOC FM ALL FACILITIES TO SITE MH.

2) 1300’ ductbank is in regards to P1300 Armory; which is not collocated with the HQ bldg. P1300-DIRECT BURIED CONDUIT/HANDHOLE SYSTEM IS

ACCEPTABLE FOR THE ARMORY ONLY; HQ DUCTS SHALL BE

CONCRETE ENCASED. HANDHOLES SHALL MEET BASE

SPECIFICATIONS 33 82 00; 4’X4’ CONCRETE WITH TIER 22 RATED LID.

3) IN REGARDS TO P1300, DUCTBANK IN SUPPORT OF THE NEW ARMORY

ONLY, MAY BE DIRECT BURIED DUCTBANK/HANDHOLE SYSTEM FROM

NEW SITE TO EXISTING MANHOLE 588. HANDHOLES SHALL MEET BASE

SPECIFICATIONS 33 82 00; 4’X4’ CONCRETE WITH TIER 22 RATED LID.

4. PART 3.3 - P1509

a. CHAPTER 6, E20 FURNISHINGS

1) PPI Response: Assume that the pad mounted switch has available switchway to connect to at 6th Marines Regimental HQ

2) System Description: Change the FF&E estimate to the following amount of $2,397,397. This estimate does NOT include the Contractor’s Handling and Administration Rate (HAR).

3) ESR E201003 - Auditorium Seating: AE2 DOR to develop design of the 10th Regimental HQ Large and Medium Classrooms that may incorporate fixed auditorium seating as determined based on in-depth interviews and design developed during CDW with User.

4) Price Proposal Form - updated Price Proposal Form, added Planned Modifications

(FF&E, ESS, A/V) for the P1509 6th MARDIV REG HQ as CLINS 0088, 0089, and

5. PART 3.4 - P1520

Change the FF&E estimate to the following amount of $1,872,817. This estimate does

6. PART 3.5 - P1522

Change the FF&E estimate to the following amount of $3,461,142. This estimate does

b. CHAPTER 1 PROJECT DESCRIPTION The sentence in the third paragraph describing the MEU’s square footages should read “The P1522 Headquarters Replacement includes two facilities: 22nd MEU Battalion Headquarters (CC61072) consisting of a 21,473 SF and 24th MEU Battalion Headquarters (CC61072) consisting of 21,473 SF.” This Programmed Space as stated in Chapter 4.0 Building Requirements matches the 21,473 GSF for both 22nd MEU HQ and 24th MEU HQ.

c. CHAPTER 6 – ESR G1020 SITE DEMOLITION & RELOCATIONS

As noted existing inactive steam lines and vaults are in front of the building; they will not be serving any surrounding buildings. Contractor has option to remove entire system or a segment of system which is in conflict with new utilities.

d. CHAPTER 6 – ESR G4010 ELECTRICAL DISTRIBUTION

Both P1522 and P1529 state to connect to the existing primary power distribution along L Street at one of the power poles for overhead connection. These projects are on the same site, provide (1) 4-way pad mounted switch and connection to the L Street OH line.

Provide line item cost so that whichever project is constructed first will provide the switch and OH line connection.

7. PART 3.6 - P1524

Change the FF&E estimate to the following amount of $1,401,268. This estimate does

b. OUTSIDE INFRASTRUCTURE - The following changes address Bid Option 27 as updated in Price Proposal Form and replaces previous requirements. In addition to Part 6 Attachments, refer to the following attachments:

1) Location Maps: Refer to Attachment H.2 - P1522 and P1529 Comm Map from

Building 1 to site; and Attachments H.3 - TO Trailer #2 (BAS) Communications on Reasoner.

2) Attachment H.4 - P1524 NEW trailer location telecom notes to HDR dated 30 Mar

2020. Contractor to be advised of telecom lines servicing TRLR SITE FSRM 19- 0073 from manhole to site from under roadway as noted on drawing.

c. Chapter 6 – ESR G403001 TELECOMMUNICATIONS SYSTEMS (OPTION 27):

Remove G4030 SITE COMMUNICATION AND SECURITY including G403001

TELECOMMUNICATIONS SYSTEMS, G403002 CABLE TV SYSTEMS (CATV),

G403003 CABLES AND WIRING, G403004 DUCTBANKS, and MANHOLES AND HANDHOLES in its entirety and replace with the following sections:

G4030 SITE COMMUNICATION AND SECURITY

Provide a site communication system including, but not necessarily limited to Voice and Data Telecommunications Systems including all conduit and wiring, underground structures, termination equipment, poles and structures, and grounding systems as required for a complete and usable system.

G403001 TELECOMMUNICATIONS SYSTEMS

Provide Telecommunications Systems design in accordance with Part 5 Prescriptive Specification Section 32 82 00 Telecommunication Outside Plant (OSP) and BICSI TDMM.

This specification is edited to provide specific Marine Corps Base Camp Lejeune Requirements. All work should be in accordance with most current versions of the Telecommunications Support Division G-6.

KTR (CONTRACTOR) SHALL CONTACT BASE TELEPHONE POC (STEVE DAIGLE

AT 910-451-9439) MINIMUM 30 DAYS PRIOR TO DEMOLITION, PROTECT AND

PRESERVE, AND TO SCHEDULE THE REMOVAL OF EXISTING

TELECOMMUNICATIONS COMPONENTS IF DEEMED VALUABLE.

The DMARC connection point for the site telecommunications Fiber and Copper systems must be underground to an existing Manhole system for the P1524 project Headquarters.

Then extended to the new project facility underground in a system of manholes and duct bank underground in direct buried in conduit to the new telecommunications equipment room.

The contractor shall coil 60 feet of OSP cable in the manhole/demarcation point. All OSP cables shall be tested by the contractor. The G6 will perform splicing of the newly installed cables to the existing active OSP cables. The connection point to the Base OSP infrastructure must be provided as follows:

• 1199 and 1524 Telecommunications Service Base Bid that include the Outside Infrastructure scope of work which extends down HH Smith Blvd. as referenced in RFP in Part 6 - Attachments Chapter B5, and the scope of work as shown below in G403003 and G403004.

• Bid Option #27 (refer to Price Proposal Form) is an extension of system to a manhole that serves project name REPLACE II MEF, 2ND MLG, AND 2ND

MARDIV HQTRS which are buildings in project #1800 and #1801; refer to Part 6 – Attachments, Chapter B5.

• The Outside Plant scope of work requires the contractor to ensure system is fully functional prior to site demolition. The scope is shown below in section G403003 and G403004 as replacement to work being demolished. Refer to Part 6 - Chapter B.5, P1514 and Chapters B1.1 and B1.2 for attachments that references scope and associated GIS maps.

G403002 CABLE TV SYSTEMS (CATV)

Cable TV service will be provided by a local service provider. Provide underground empty 4 inch conduit with pull string from telecommunication room where CATV horizontal drops are terminated to project site boundary. Service provider will provide cable. Coordinate details and locations with service provider.

G403003 CABLES AND WIRING

Cables and wiring for site telecommunications are required as stated in their respective categories.

NOTE: PRIOR TO DEMOLTION AND AFTER CONTRACTOR HAS INSTALLED

INFRASTRUCTURE THE GOV’T SHALL INSTALL AND TERMINATE NEW

FIBER FROM HHFC404 TO FC520 AND FC525.

Base Bid P1524 requires the following:

• Provide 500’ of 100-Pair 24-AWG Copper Cable Outside Plant rated from new Headquarters facility to new Manhole on the corner of HM Smith Blvd. and Reasoner St.

• Provide 500’ of 24 Strand Single Mode Fiber Optic Cable Outside Plant rated from new Headquarters facility to new Manhole on the corner of HM Smith Blvd.

and Reasoner St.

Bid Option #27 (refer to Price Proposal Form) requires the following:

• Provide 2100 pair 24AWG OSP copper cabling from vault of FC307 to NEW manhole at Intersection of HM Smith Blvd and Access road near FC332.

• Provide all required splices of 2100 pair OSP copper cable from FC307 to NEW manhole located at Intersection of HM Smith Blvd and Access road near FC332.

• Provide splice of 2100 pair OSP copper cable to 1500 pair copper cable at NEW manhole located at Intersection of HM Smith Blvd and Access road near FC332.

• Provide 1500 pair 24AWG OSP copper cabling from NEW manhole at Intersection of HM Smith Blvd and Access road near FC332 to NEW Manhole (#-002) at Intersection of HM Smith Blvd and Conner St.

• Provide splice of 1500 pair OSP copper cable to 900 pair 24AWG OSP copper cabling at NEW manhole at Intersection of HM Smith Blvd and Conner St.

• Provide 900 pair 24AWG OSP copper cabling from NEW manhole at Intersection of HM Smith Blvd and Conner St. to NEW manhole at Intersection of HM Smith Blvd and Reasoner St.

• Provide 288 strand SM OSP Fiber optic cable from vault of FC307 to NEW manhole at Intersection of HM Smith Blvd and Access road near FC332.

• Provide splice of 288 SM OSP FOC 144 SM OSP FOC at NEW manhole located at Intersection of HM Smith Blvd and Access road near FC332.

• Provide 144 strand SM OSP Fiber optic cable from NEW manhole at Intersection of HM Smith Blvd and Access road near FC332 to NEW manhole at Intersection of HM Smith Blvd and Conner St.

• Provide splice of 144 SM OSP FOC 96 SM OSP FOC at NEW manhole at

Intersection of HM Smith Blvd and Conner St.

• Provide 96 strand SM OSP Fiber optic cable from NEW manhole at Intersection of HM Smith Blvd and Conner St. to NEW manhole at Intersection of HM Smith Blvd and Reasoner St.

• Provide splice of 96 SM OSP at NEW manhole at Intersection of HM Smith Blvd and Reasoner St.

NOTE: All copper pairs not carried through splice points shall be clear capped with 710 modules.

• Scope inside Main Switch Room FC307 as follows:

o Contractor shall install (21) 100 pair protectors, with tip cables, on main frame in telecommunications switch room. Contractor shall coordinate with base telephone for protector placement in switch room.

o Contractor shall perform vault splice of 2100 pair OSP copper cable to protector tip cables.

o Contractor shall perform vault splice of 288 SM OSP FOC to 288 strand MIC fiber to enter switch room. Contractor shall terminate 288 SM OSP FOC in rack mounted distribution cabinets within switch room of FC307.

NOTE: Contractor shall coordinate with base telephone for placement of fiber distribution cabinets within switch room.

Bid Option 27 also requires the following:

• 24 strand SM OSP Fiber optic cable from NEW manhole at Intersection of HM Smith Blvd and Reasoner St. to NEW manhole at Intersection of Gonzalez Loop and Reasoner St. Contractor shall leave 60’ slack coil in manhole.

• Contractor shall perform splice of 24 SM OSP FOC at NEW manhole at Intersection of HM Smith Blvd and Reasoner St.

• 300 pair 24AWG OSP copper cabling from NEW manhole at Intersection of HM

Smith Blvd and Reasoner St. to NEW manhole at Intersection of Gonzalez Loop and Reasoner St. Contractor shall leave 30’ slack coil in manhole.

• Contractor shall perform splice of 900 pair OSP copper cable to 300 pair 24AWG

OSP copper cabling at NEW manhole at Intersection of HM Smith Blvd and Reasoner St.

NOTE: Contractor shall coordinate with the Base Telecommunications Group regarding Fiber and Copper cable identification and fiber strand and copper pair allocations.

G403004 DUCTBANKS, MANHOLES AND HANDHOLES

Provide a system of concrete encased duct-banks, manholes, and hand-holes for site telecommunications.

P1524 Base Bid to provide for the following:

NOTE: PRIOR TO DEMOLTION THE CONTRACTOR SHALL INSTALLED

OUTSIDE PLANT INFRASTRUCTURE SHOWN BELOW BULLETS.

• INSTALL NEW HANDHOLE NEAR REASONER ST AND LOGISTICS

LANE.

• INSTALL NEW HANDHOLE NEAR RP520.

• INSTALL (2) 1 1/4” HDPE DUCT FROM HHFC404 TO NEW HANDHOLE

NEAR REASONER ST AND LOGISTICS LANE.

• INSTALL (2) 1 1/4” HDPE DUCT FROM NEW HANDHOLE NEAR

REASONER ST AND LOGISTICS LANE AND NEW HANDHOLE NEAR

RP520.INSTALL

• (1) 1 ¼” HDPE DUCT FROM NEW HANDHOLE NEAR RP-520 TO RP-520.

• INSTALL (1) 1 ¼” HDPE DUCT FROM NEW HANDHOLE NEAR RP-520 TO

RP-525.

Provide 500’ of 3-way 4” conduit system concrete encased duct-bank from the new HQ facility to the new Manhole on the corner of HM Smith Blvd. and Reasoner St.

Bid Option 27 (Price Proposal Form) requires the following:

Provide 6 way 4” concrete encased duct bank/manhole system from intersection of HM Smith Blvd. and Reasoner St. to FC307

• Provide new Manhole at Intersection of HM Smith Blvd and Access road near

FC332.

• Provide new Manhole at Intersection of HM Smith Blvd and Conner St.

• Provide new Manhole at Intersection of HM Smith Blvd and Reasoner St.

• Provide 6 way 4” concrete encased duct bank/manhole system from FC307 to the intersection of HM Smith and Reasoner St. to FC307.

• Provide 6 way 4” concrete encased duct bank/manhole system from Gonzalez to

New Manhole at HM Smith Blvd.

• Provide new Manhole at Intersection of Gonzalez Loop and Reasoner St.

**Additional manholes shall be installed as required per Base Specifications 33 82 00.

Provide underground electrically detectable film warning tape with two-line messaging in permanent one inch bold letters continuously for the entire length for underground duct banks. Provide Innerduct in one of the three ducts. Provide the point of building entry hidden below ground. Seal all incoming communications ducts to resist liquid and gas infiltration at all maintenance holes and building entrance point locations.

d. CHAPTER 6, ESR D503001 – Response to PPI inquiry regarding Wi-Fi Site Survey:

Wireless access point telecommunications outlets shall be placed to cover all admin spaces within the facility to support wireless communications using the 5Ghz frequency band.

• When hot mapping, the 5GHz band on the equipment shall be used.

8. PART 3.7 - P1525

CHAPTER 6, E20 FURNISHINGS - SYSTEM DESCRIPTION

Change the FF&E estimate to the following amount of $521,339. This estimate does

9. PART 3.8 – P1529

Change the FF&E estimate to the following amount of $2,425,589. This estimate does NOT include the Contractor’s Handling and Administration Rate (HAR).

b. CHAPTER D30, ESR D30 SYSTEM DESCRIPTION As noted in Addendum 13, 1529 and 1522 are identical plans and have the same requirements. Requirements have been updated in Amendment 13 to match. System Description for P1522 to include:

“Provide a variable air volume (VAV) system with shut-off terminal units and hot water heating coils. The VAV AHU will feature a chilled water cooling coil and a hot water preheating coil. Ventilation air will be provided via the VAV AHU(s). Provide a total enthalpy fixed plate heat exchanger energy recovery section in the VAV AHU.

Chilled water will be generated by an air-cooled chiller, and hot water will be generated by condensing gas boiler[s]. Size the AHU coils, chillers, and boilers for full capacity, in the event of a heat recovery system failure.

The primary air from the VAV AHU will be ducted to the terminal units by medium-pressure galvanized metal ductwork. Supply air from the terminal unit to the zone and return air from the zone to the AHU will be ducted by low-pressure galvanized metal ductwork.

Ensure that energy reduction requirements as prescribed in UFC 1-200-02, High Performance and Sustainable Building Requirements are met.”

c. CHAPTER 6 – ESR G4010 ELECTRICAL DISTRIBUTION Both P1522 and P1529 state to connect to the existing primary power distribution along L Street at one of the power poles for overhead connection. These projects are on the same site, provide (1) 4-way pad mounted switch and connection to the L Street OH line. Provide line item cost so that whichever project is constructed first will provide the switch and OH line connection.

D. PART 4 PERFORMANCE TECHNICAL SPECIFICATIONS

1. Section 27 10 00 Building Telecommunication Cabling System: In response to PPIs:

a. Is there a need to provide an outlet box for every electrical receptacle when the total room occupancy is (1) for rooms over 100 square feet? For rooms with 1 occupant, can it be proposed as a min total of (2) outlet boxes with (4) CAT6 cables? - Install per 27 10 00; 80 sq/ft or smaller, (2) quad work area outlets. 80-100 sq/ft, (3).

Greater than 100 sq/ft is considered “open office space”, @every power receptacle.

b. Please confirm the statement “Provide CATV/Display double gang box with (1) coax cable and (2) CAT6 cables per location” - Install Per 27 10 00, ALL TV Locations shall receive (2) CAT6 and (1) COAX.

c. Does the statement “Provide (6) outlet boxes on wall with (4) CAT6 cables" supersede statement of “Provide (1) outlet box with (4) CAT6 cables every 6’ along the walls.” - Per 27 10 00 or comply with most stringent requirements; unless this is in reference to a space which may have greater requirements than the spec…e.g.

computer lab.

d. Please confirm the term "user" represents the total number of occupants, resulting in

(2) CAT6 cables per occupant? - Quantity of telecom outlets/CAT6 cables is not determined by quantity of “users”. Buildings telecom is populated per 27 10 00.

E. PART 6 ATTACHMENTS

1. Attachment B.2, P1520 Site Drawing: Refer to CLIN 0004, Base Bid (Item 0004B) that includes the abatement and complete demolition of Buildings 118 & 118A. Buildings will be vacant and can be demolished once NTP is issued or the abatement and demolition of other P-1509F facilities Refer to CLIN 0045 (OPTION 13) for abatement and demolition of Buildings 219, 219A, 223, and 221.

2. Attachment K.1 Historical geotechnical data and reports to be provided; refer to attachment.

F. ATTACHMENT H

1. F Price Proposal Form: See attached updated form

2. P1522 and P1529 Comm Map from Building 1

3. TO Trailer #2 (BAS) Communications on Reasoner

4. SPECIFICATION SECTION 01 57 19.01 20 SUPPLEMENTAL TEMPORARY

ENVIRONMENTAL CONTROLS, MCBCAMLEJ Surplus Soil MILCON Spec Revision, 6 April 2020

5. Locker Concrete Pad Drawing

6. Historical Geotechnical Reports

---END OF AMENDMENT---

(End of Summary of Changes)

SOLICITATION NO. N40085‐19‐R‐9252

PROJECT TITLE/LOCATION: HFRM PACKAGE 2

PREAWARD INQUIRY FORM (TEMPLATE)

Page Section Para.

34 3/12/2020

Part 2 01 31 19.05 20

01 31 19.05 20 1.3 PAK meetings, please confirm whether a single PAK will be held for the entire package of 8 projects, or if a PAK will be required for each individual project.

One PAK meeting is required to kickoff the entire package. 14

35 3/12/2020

Part 2 01 31 19.05 20

01 31 19.05 20 1.3.6 Partnering meetings, please confirm whether a single partnering meeting should be assumed for the entire package of 8 projects, or if partnering will be required for each individual project.

Multiple MILCONs can utilize the same partnering meeting.

If the project team determines additional partnering is required for separate MILCONs due to specialized program requirements then that is encouraged.

46 3/12/2020

Part 6 Attachment B.2, P1520

Site drawing for P1520 shows existing building B118 conflicting with the footprint of the new HQ. Please confirm if there is a phasing requirement to demolishing B219, B221, B223, or if the buildings are currently vacant and can be demolished at any time.

Refer to CLIN 0004: Base Bid (Item 0004B) includes the abatement and complete demolition of Buildings 118 & 118A. Buildings will be vacant and can be demolished once NTP is issued or the abatement and demolition of other P‐ 1509F facilities Refer to CLIN 0045 (OPTION 13) for abatement and demolition of Buildings 219, 219A, 223, and 221.

50 3/12/2020

Part 2 01 33 10.05 20, 2.2.5

Please advise on the maximum number of design submittals the government is able to review concurrently. Please note that there may be multiple design submittals within each project (i.e. P number) and overlapping submittals due to concurrent project design phases.

The maximum number of design submittals that the government is able to review concurrently will be determined by the contractro's schedule and is directly related to the sequencing of the CDW schedule. The RFP dictates when the first CDW shall occur, and when subsequent are allowed.

55 3/12/2020

Part 3.6, Chapter 6, ESR

B201001

All Projects

Projects P‐1522, P‐1524, P‐1525 and P‐1529 include language in the 5th paragraph of B201001 Exterior Closure that allows alternatives to brick masonry veneer, provided any such alternative meets the RFP and BEAP standards. Projects P‐1199, P‐1300, P‐1509, and P‐1520 do not contain the same paragraph that allows alternatives. Please confirm that the option to use alternatives to the listed enclosure systems will also be acceptable for P‐1199, P‐1300, P1509 and P‐1520.

The goal of this RFP is to provide the contractor opportunity to provide a cost effective solution for all buildings while satisfying the requirements established by the D/B RFP. This includes but not limited to:

B201001 Exterior Closure system to match the exterior/architectural style as described in the BEAP (including brick masonry veneer, water table, Aluminum Standing Seam Metal Roof, etc...).

B201002 Exterior Wall Back‐Up Construction System including concrete/masonry wall systems (metal studs not permitted) B201003 Continuous insulation, vapor retarder, water‐resistive barrier, and air barrier with envelope performance testing that comply with specified requirements.

REFERENCE

Question No. QUESTION GOVERNMENT RESPONSEDate Received

Posted on Amend

July 2011

PREAWARD INQUIRY FORM (TEMPLATE)

Page Section Para.

Question No. QUESTION GOVERNMENT RESPONSEDate Received

Amend 83 3/16/2020

PART 3.2

CHAPTER

6 ‐ ESR

B20 ‐

B201003

B201003 INSULATION & VAPOR RETARDER states to “Provide continuous insulation, vapor retarder, water‐ resistive barrier, and air barrier as required to meet OR EXCEED requirements of project's energy savings requirements as indicated by applicable American Society of Heating, Refrigerating, and Air‐Conditioning Engineers (ASHRAE) 90.1 calculations called for in Unified Facilities Criteria (UFC) 1‐200‐02, High Performance and Sustainable Building Requirements, and meeting minimum building envelope insulation requirements of UFC 3‐101‐01, Architecture." Including this reference and all other “or exceed” instances in the RFP, Please confirm that the technical evaluation criteria does not include “exceeding RFP requirements” as betterments, strengths or additional considerations to offers who provide design features that are in excess of the RFP as a basis of award.

Specifically regarding Part 3.2, Chapter 3 – ESR B20 Exterior Enclosure language:

See page 4 of Amendment 0013 for revised language. “Contractor is required to meet minimum building envelope insulation requirements of UFC 3‐101‐01, Architecture. Exceeding RFP requirements will not be considered as a betterment, strength or additional considerations by offers."

Regarding other instances: In accordance with the April 2016 Department of Defense Source Selection Procedures, a Strength is defined as “an aspect of an offeror's proposal that has merit or exceeds specified performance or capability requirements in a way that will be advantageous to the Government during contract performance.” The Government may identify Strengths for aspects of the Offeror’s proposal that have merit or exceed specified performance or capability requirements in a way that will be advantageous to the Government during contract performance. Factor 4, Basis of Evaluation states “The Government will evaluate the Offeror's technical solution to determine adherence to or enhancing of the technical requirements of the RFP.” In accordance with the April 2016 Department of Defense Source Selection Procedures, a Strength is defined as “an aspect of an offeror's proposal that has merit or exceeds specified performance or capability requirements in a way that will be advantageous to the Government during contract performance.” The Government will evaluate the Offeror’s Factor 4 proposal to determine adherence to or enhancing of the technical requirements of the RFP and may identify Strengths for aspects of the Offeror’s Factor 4 proposal that have merit or exceed specified performance or capability requirements in a way that will be advantageous to the Government during contract performance.”

88 3/18/2020 RFP, Page 13 of 59, Para (1) Solicitation Submittal Requirements ‐ Originally had the Non‐Price portion of the Submittal to be 1 Original and 8 copies and a CD.

Amendment 4 changed this to 9 copies. This is a lot of information. Is the requirement still 1 Original and 9 Copies and a CD?

See Amendment 0012 and Amendment 0013. 14

89 3/18/2020 RFP, Page 13 of 59, Para (1) Solicitation Submittal Requirements ‐ If a CD is required (1 Original and 9 Copies and 1 CD) and since the Original governs, then please allow the CD (Electronic Copy) to be turned in within 48 Hours of the Proposal Due Date and Time. This way the CD can have the accurate pricing information.

Otherwise the 50 page bid proposal form, Subcontracting plan, and the other items to be filled in will not be able to reflect the accurate numbers because of the last minute nature of these bid completions.

See Amendment 0012 and Amendment 0013. 14

PREAWARD INQUIRY FORM (TEMPLATE)

Page Section Para.

Question No. QUESTION GOVERNMENT RESPONSEDate Received

Amend 127 3/20/2020

Part 2 01 45 00.05 20

According to 1.3 QC PROGRAM REQUIREMENTS, "No construction work or testing may be performed unless the QC Manager is on the work site." Please define what is required by "on the work site". Is one QC Manager required for the entire package, one per project (P#) for a potential total of eight, one per bounded site per Figure 1 ‐ Site Vicinity Map in Part 3 for a potential total of twelve.

The Contractor is required to provide a QC program that ensures enough management is within the package to oversee construction work or testing taking place at each project(P#) number site. The Contractor shall determine the structure of management personnel within their entire package, at a minimum Provide one Quality Control Manager(QCM) for the contract with a minimum of

(15) years experience as a QCM on projects of similar size, scope and complexity.

Provide one Assistance Quality Control Manager(QCM) for each project(P#) with a minimum of (5) years experience as a QCM on projects of similar size, scope and complexity.

128 3/20/2020

Part 2 01 30 00.05 20

According to 1.5 SUPERVISION, "Provide at least one (1) qualified Project Manager and one (1) on‐site Project Superintendent per construction site." Please define what is required by "per construction work site". Is one PM and Superintendent required for the entire package, one per project (P#) for a potential total of eight each, one per bounded site per Figure 1 ‐ Site Vicinity Map in Part 3 for a potential total of twelve each. Please also consider if a single Project Manager could manager more than one construction site, and clarify what this minimum requirement is.

The Contractor is required to provide a management system comprised of Project Managers and Site Superintendents that ensures enough management is within the package to oversee project and site management at project(P#) number site.

The Contractor shall determine the structure of management personnel within their entire package, at a minimum Provide one Project Manager for the contract with a minimum of (15) years experience as a Project Manager on projects of similar size, scope and complexity. Provide one Assistance Project Manager for each project(P#) with a minimum of (5) years experience as a Project Manager or Project Engineer on projects of similar size, scope and complexity. Provide one Project Superintendent for the contract with a minimum of (15) years experience as a Project Superintendent on projects of similar size, scope and complexity.

Provide one Assistance Project Superintendent for each project(P#) with a minimum of (5) years experience as a Project Superintendent on projects of similar size, scope and complexity.

132 3/20/2020

2818 ESR D4040

The expeditionary ops building includes a covered area, and D4040 only speaks to wet pipe sprinklers. If the canopy is to be used for storage, NFPA 13 would require it to be sprinklered. If so, a dry pipe system would be required, similar to what is indicated for the P1300 project for a covered weapons cleaning area. Please advise whether sprinkler protection is required for this canopy.

Correct, Canopy design may require a dry pipe automatic sprinkler system when attached to the building. Design must comply with UFC, NFPA, and other Building Codes. Outdoor Covered area is intended as a multi‐purpose space for breaks between meetings or small social gathering area.

PREAWARD INQUIRY FORM (TEMPLATE)

Page Section Para.

Question No. QUESTION GOVERNMENT RESPONSEDate Received

Amend 138 3/20/2020

954 ESR D40

The ESR D40 for each project references "commissioning" and states to comply with NFPA and NAVFAC criteria.

NFPA 3 is the "Standard for Commissioning of Fire Protection and Life Safety Systems". While testing of systems is performed, we have not seen NAVFAC typically perform commissioning per NFPA 3 requirements.

Additionally, the 01 91 00.15 22 specification section applicable to each project does not list fire protection systems as requiring "commissioning". Please confirm that NFPA 3 level commissioning of the fire protection systems on these projects is not required.

Compliance with NFPA 3 is not required. A Fire Protection Quality Control Specialist must have the credentials and perform the tasks defined in Specification Section 01 45 00.00 20 (Design and Construction Quality Control). Systems must comply with respective NFPA Codes (i.e., fire sprinkler systems per NFPA 13, fire alarm systems per NFPA 72, fire pumps per NFPA 20, Life Safety Systems per NFPA 101, etc.).

153 3/20/2020

2365 D503001 P1524, Part 3.6

In paragraph 2, statement to use WI‐FI site survey software to provide heat maps verifying coverage. Is there a specific frequency band to test to? 2.4Ghz, 5Ghz, others?

Wireless access point telecommunications outlets shall be placed to cover all admin spaces within the facility to support wireless communications using the 5Ghz frequency band.

When hot mapping, the 5GHz band on the equipment shall be used.

165 3/20/2020

2424 G4010 P1524

What is the fault current of the medium voltage system so we can ensure the withstand rating of medium voltage equipment meets base requirements? Assumption of infinite fault current on medium voltage system is not feasible.

Fault current calculation to be determined by AE2. The input (X/R Ratio and substation impedances).

169 3/20/2020

2187‐ 2188, 2875‐

G4010 P1522/1529

Both P1522 and P1529 state to connect to the existing primary power distribution along L Street at one of the power poles for overhead connection. Each project states to provide a 4‐way MV Pad‐mounted Switch. Please confirm if a 4‐way switch is to be provided for each project, or only once?

These projects are on the same site, provide (1) 4‐way pad mounted switch and connection to the L Street OH line. Provide line item cost so that whichever project is constructed first will provide the switch and OH line connection.

172 3/24/2020

Part 3.5 ‐ Chapter

6.0 ESR

D30;

Part 3.8 ‐ Chapter

6.0 ESR

D30

System Description

The P1522 HQ buildings look to be identical to the P1529 HQ building. However, when comparing the System Description of Chapter 6.0 ESR D30, the second through fourth paragraphs look to have been omitted from B1529. Please confirm that the Engineering System Requirements D30 at P1529 are the same as P1522.

1522 and 1529 are identical plans and have same requirements. Requirements have been updated in Amendment to match.

175 3/24/2020 5 G403003 2

Please provide a map indicating the location of "Building‐ 1" relative to P1522/P1529.

Refer to Amendment for map of Bldg 1 near the circle 14

PREAWARD INQUIRY FORM (TEMPLATE)

Page Section Para.

Question No. QUESTION GOVERNMENT RESPONSEDate Received

Amend 176 3/24/2020

5 G403003 All

Please clarify quantity and routing of 24 AWG Copper Cable Outside Plant rated and Single Mode Fiber Optic Cable to be extend from existing/new manholes to the Expeditionary OPS Support Facility Building. RFP only addresses HQ Building telecommunication service entrance requirements.

1) The PPI comment says 'ALL' but not all MILCON G43003 are the same. Also there’s distances for all the cables with the exception of a couple, and that was TBD or ROM from the DMARC manhole to the new facilities on the site plans.

2) Refer to D/B RFP for requirements for cables and wiring. P1522/1529 Should be 24 SM FOC AND 100 PAIR OSP COPPER TO ALL FACILITIES; HQ/s AND OPS

SUPPORT FACILITY BLDG

177 3/24/2020

5 G403003 2

This section of the RFP states "provide 1700’ of 288 Strands Single Mode Fiber Optic Cable Outside Plant rated from existing Building‐1 to existing Manhole 584."

Please confirm that the addition of conduit and/or "innerduct" is not required for the 1700' from existing Building‐1 to existing Manhole 584.

Comply with RFP requirements; There’s a requirement for one conduit in all cases to have Fiber Mess Innerduct, please allow for this.

179 3/24/2020

1311 G403004 2

The RFP requires a 1300' telecommunications ductbank from the site (presumably the HQ site) to manhole 588.

The provided GIS information does not show this manhole location. Please provide additional GIS data showing the precise location of manhole 588.

Additional GIS data provided in Amendment 13 14

PREAWARD INQUIRY FORM (TEMPLATE)

Page Section Para.

Question No. QUESTION GOVERNMENT RESPONSEDate Received

Amend 180 3/24/2020

General Please confirm that betterments within the Offeror's proposal are not allowed and will not be evaluated by the Government.

In accordance with the April 2016 Department of Defense Source Selection Procedures, a Strength is defined as “an aspect of an offeror's proposal that has merit or exceeds specified performance or capability requirements in a way that will be advantageous to the Government during contract performance.” The Government may identify Strengths for aspects of the Offeror’s proposal that have merit or exceed specified performance or capability requirements in a way that will be advantageous to the Government during contract performance.

Factor 4, Basis of Evaluation states “The Government will evaluate the Offeror's technical solution to determine adherence to or enhancing of the technical requirements of the RFP.” In accordance with the April 2016 Department of Defense Source Selection Procedures, a Strength is defined as “an aspect of an offeror's proposal that has merit or exceeds specified performance or capability requirements in a way that will be advantageous to the Government during contract performance.” The Government will evaluate the Offeror’s Factor 4 proposal to determine adherence to or enhancing of the technical requirements of the RFP and may identify Strengths for aspects of the Offeror’s Factor 4 proposal that have merit or exceed specified performance or capability requirements in a way that will be advantageous to the Government during contract performance.

184 3/24/2020

10 E201003 2

In RFP P1509 Section E201003 Fixed Seating states to provide auditorium seating. However, the RFP does not indicate where the auditorium seating is to be located.

Please confirm that auditorium seating is not required.

AE2 DOR to develop designof the 10th Regimental HQ Large and Medium Classrooms that may incorporate fixed auditorium seating as determined based on in‐depth interviews and design developed during CDW with User.

189 3/24/2020

F‐30

Attachme nt I ‐ Price Proposal Form

N/A

Attachment I ‐ Price Proposal Form does not include any Planned Modifications (FF&E, ESS, A/V) for the P1509 6th MARDIV REG HQ. Please clarify if Planned Modifications for the 6th MARDIV REG HQ should be included on the Price Proposal Form.

Please see updated Price Proposal Form, they have been added as CLINS 0088, 0089, and 0090

190 3/24/2020

F‐49

Attachme nt I ‐ Price Proposal Form

1.3b

Attachment I ‐ Price Proposal Form General Notes 1.3b states that the Government will evaluate offers for award purposes by adding the price for CLINs 0009 through 0087 to the total price for CLINs 0001 through 0008.

However, the Price Proposal Form does not have a line item for the total price of CLINs 0001 through 0087. Will this total price line item be added to the Price Proposal Form?

No total price line item will be added. 14

PREAWARD INQUIRY FORM (TEMPLATE)

Page Section Para.

Question No. QUESTION GOVERNMENT RESPONSEDate Received

Amend 194 3/24/2020

F‐42

Attachme nt I ‐ Price Proposal Form

CLIN 0068

CLIN 0068 Option 27 on the Price Proposal Form is for P1522 Communication Duct Bank. However, the RFP does not differentiate what Duct Bank is to be included in the Base Bid vs Option 27. Please clarify the scope to be included in CLIN 0068 Option 27 Communication Duct Bank.

Refer to Amendment 14 for description of Base Bid and Bid Option 27 as referenced in Price Proposal Form.

201 3/24/2020

1 E20 4

P1300 Section E20 states the FF&E budget is estimated to be $6,254,940. However, the Price Proposal Form's total estimated budget for P1300 FF&E is $5,542,942. Please confirm the P1300 estimated FF&E budget on the Price Proposal Form is correct.

The correct value is $6,432,385, see updated Price Proposal Form 14

202 3/24/2020

1 E20 4

P1509 Section E20 states the FF&E budget is estimated to be $3,424,933. However, the Price Proposal Form's total estimated budget for P1509 FF&E is $2,422,653. Please confirm the P1509 estimated FF&E budget on the Price Proposal Form is correct.

The correct value is $3,522,093, see updated Price Proposal Form 14

203 3/24/2020

1 E20 4

P1522 Section E20 states the FF&E budget is estimated to be $3,032,537. However, the Price Proposal Form's total estimated budget for P1522 FF&E is $2,687,344. Please confirm the P1522 estimated FF&E budget on the Price Proposal Form is correct.

The correct value is $3,118,566, see updated Price Proposal Form 14

204 3/24/2020

1 E20 4

P1529 Section E20 states the FF&E budget is estimated to be $2,125,133. However, the Price Proposal Form's total estimated budget for P1529 FF&E is $1,883,229. Please confirm the P1529 estimated FF&E budget on the Price Proposal Form is correct.

The correct value is $2,185,420, see updated Price Proposal Form 14

220 3/24/2020

Various Part 3 Chapter 6

ESR B20

B201001

Exterior Closure: The RFP generally describes exterior closure as a cavity type exterior wall system composed of brick masonry veneer and unit masonry backup wall system. Part 3 for P1522, P1524, P1525, P1529, B201001 permits the contractor to consider "alternatives, such as architectural precast with thin brick.” Will the Government please provide a performance specification for the exterior closure allowing multiple wall systems which meet the visual requirements of the BEAP, envelope performance requirements and interior finishes?

No additional performance specs will be provided.

The goal of this RFP is to provide the contractor opportunity to provide a cost effective solution for all buildings while satisfying the requirements established by the D/B RFP. This includes but not limited to:

B201001 Exterior Closure system to match the exterior/architectural style as described in the BEAP (including brick masonry veneer, water table, Aluminum Standing Seam Metal Roof, etc...).

B201002 Exterior Wall Back‐Up Construction System including concrete/masonry wall systems (metal studs not permitted) B201003 Continuous insulation, vapor retarder, water‐resistive barrier, and air…