Attachment E - 618-22-100_MPLS_PT_TripleC-CA-SubmittalLOG.xlsx

XLSX spreadsheet 171 KB Posted

Attached to
618-22-100 Renovate for Expanded Polytrauma Phase 1
Solicitation number
36C26323R0058_1
Issued by

About this file

Written by GovTribe AI ·

This solicitation document is for a construction project to renovate and expand polytrauma care facilities at the Minneapolis VA Health Care System. The project scope includes general construction, electrical, plumbing and other trades as required to complete the work. It is a total set-aside for Service-Disabled Veteran-Owned Small Businesses, with an estimated value between $10-20 million. Offerors must be verified as SDVOSBs in the VetCert system to be considered. The NAICS code is 236220 and small business size standard is $45 million. Pricing must include all applicable taxes.

View the file

Other files

File Type Posted
36C26323R0058 0001.pdf PDF
See Attached document - Attachment 1 Questions and Answers Request 7.12.2023.doc DOC document
See Attached document - Attachment 5 618-22-100 Prebid Sign-in Roster.pdf PDF
See Attached document - Attachment 2 MPLS Expand Polytrauma Program - Pre Bid Walk Through.pdf PDF
See Attached document - Attachment 7 Polytrauma Structural Coordination.pdf PDF
See Attached document - Attachment 6 618-21-700.MPLS.POLYTRAUMA.PG104i.pdf PDF
See Attached document - Attachment 4 Polytrauma Addendum Summary.docx DOCX document
See Attached document - Attachment 3 Site Visit Agenda Poly Trauma Agenda June 26 2023.docx DOCX document
Attachment D.5 - 4_618-22-100_MPLS_PT_IFB_EQUIP_230404.pdf PDF
Attachment C Specifications Polytrauma 1477 pages.pdf PDF
Attachment D.7-6_618-22-100_MPLS_PT_IFB_PLUMB_230404.pdf PDF
Attachment D.9 - 8_618-22-100_MPLS_PT_IFB_MECH_230404.pdf PDF
Attachment A - Final SOW-618-22-100 - REV4 4.18 (6 pages).pdf PDF
Attachment D.11 - 10_618-22-100_MPLS_PT_IFB_ELEC_230404.pdf PDF
Attachment I VAAR 852.219-75 Limitations on Subcontracting Cert of Compliance (2 Pages).pdf PDF
Attachment F - VA6500 Appendix C and Appendix D.pdf PDF
Attachment H Questions Request Form (1 page).doc DOC document
Attachment K Combined Single Source Justifications_Redacted.pdf PDF
Attachment D.1 - 618-22-100_MPLS_PT_IFB_GENERAL_230404.pdf PDF
Attachment D.2 - 2_618-22-100_MPLS_PT_IFB_ARCH_230404.pdf PDF
Attachment J Wage Determination MN20230117 05.19.2023.pdf PDF
Attachment D.3 - 3_618-22-100_MPLS_PT_IFB_INTERIORS_230404.pdf PDF
Attachment D.12 - 11_618-22-100_MPLS_PT_IFB_TELECOM_230404.pdf PDF
Attachment B Price Schedule Breakdown (1 Page).pdf PDF
Attachment F - VA6500 Appendix C 1-2-3a-6a-7a-7d-9 and Appendix D (6 pages).pdf PDF
Attachment D.4 - 4_618-22-100_MPLS_PT_IFB_EQUIP_230404 (2).pdf PDF
Attachment D.1 - 4_618-22-100_MPLS_PT_IFB_EQUIP_230404.pdf PDF
Attachment D.1 - 4_618-22-100_MPLS_PT_IFB_EQUIP_230404 (1).pdf PDF
Attachment D.6 -5_618-22-100_MPLS_PT_IFB_FIRE_230404.pdf PDF
Attachment G - Past Performance Questionnaire (3 Pages).docx DOCX document
36C26323R0058 1.pdf PDF
Attachment F - VA6500 Appendix C 1-2-3a-6a-7a-7d-9 and Appendix D.pdf PDF
Attachment D.10 - 9_618-22-100_MPLS_PT_IFB_MECH_230404.pdf PDF
Attachment D.8 - 7_618-22-100_MPLS_PT_IFB_PLUMB_230404.pdf PDF
Attachment D.4 - 4_618-22-100_MPLS_PT_IFB_EQUIP_230404.pdf PDF
Show all 35

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

VisiSpecs Submittal Register

TRIPLE-C Project Submittal LogInstructionsProject Locationwebsite address
Project Name618-22-100 Renovate for Expanded Polytrama Program
Issued for BiddingTriple C designated staff shall log each submittal into the Project Submittal Log on the day it is received (hardcopy or electronic)
Project NumberTriple C designated staff shall review the submittal, or process the submittal to another reviewer (internal or consultant) on the day the submittal is received, including all information below, and date due back
Status KeyOOpenOnce the submittal is reviewed, a Triple C "submittal review stamp" shall be affixed to a Triple C submittal transmittal, and processed back to the Client or Submitter, as appropriate per contract.Add columns as required for tracking additional and revised submittal. Brief over revision requirements
CClosed
STATUS (pending, open, or closed)DIVISIONSPECIFICATION SECTION NUMBERSPECIFICATION SECTION NAMEPARAGRAPH NUMBERSUBMITTALSUBMITTAL TYPEDETAILCONTRACTOR SUBMITTAL NUMBERDate Received from OwnerDue back to Owner
(2-Days)Approved /

Apprvd w. comments/

Revise & resubmitAdd Columns where neededResubmittal of previous submittal?Resubmittal DateForwarded to Name (consultant, etc.)Forwarded to Firm (consultant, etc.)Date Forwarded (to consult)Date Received BackDate Returned to OwnerCOR APPR.
OPEN/CLOSEDIVISIONSecNumSecNameParNumSubmittalTypeDetaildd/mm/yyreviseRevision #dd/mm/yyRobbieB&Pdd/mm/yydd/mm/yydd/mm/yydd/mm/yy
O0101 32 16.15Project Schedules (Small Projects - Design-Bid-Build)1.5.A.THE COMPLETE PROJECT SCHEDULE SUBMITTAL
Within 45 calendar days after receipt of Notice to Proceed, the Contractor shall submit for the Contracting Officer's review; three blue line copies of the interim schedule on sheets of paper 765 x 1070 mm (30 x 42 inches) and an electronic file in the previously approved CPM schedule program. The submittal shall also include three copies of a computer-produced activity/event ID schedule showing project duration; phase completion dates; and other data, including event cost. Each activity/event on the computer-produced schedule shall contain as a minimum, but not limited to, activity/event ID, activity/event description, duration, budget amount, early start date, early finish date, late start date, late finish date and total float. Work activity/event relationships shall be restricted to finish-to-start or start-to-start without lead or lag constraints. Activity/event date constraints, not required by the contract, will not be accepted unless submitted to and approved by the Contracting Officer. The contractor shall make a separate written detailed request to the Contracting Officer identifying these date constraints and secure the Contracting Officer’s written approval before incorporating them into the network diagram. The Contracting Officer’s separate approval of the Project Schedule shall not excuse the contractor of this requirement. Logic events (non-work) will be permitted where necessary to reflect proper logic among work events, but must have zero duration. The complete working schedule shall reflect the Contractor's approach to scheduling the complete project. The final Project Schedule in its original form shall contain no contract changes or delays which may have been incurred during the final network diagram development period and shall reflect the entire contract duration as defined in the bid documents. These changes/delays shall be entered at the first update after the final Project Schedule has been approved. The Contractor should provide their requests for time and supporting time extension analysis for contract time as a result of contract changes/delays, after this update, and in accordance with Article, ADJUSTMENT OF CONTRACT COMPLETION.
O0101 32 16.15Project Schedules (Small Projects - Design-Bid-Build)1.5.B.THE COMPLETE PROJECT SCHEDULE SUBMITTAL
Within 30 calendar days after receipt of the complete project interim Project Schedule and the complete final Project Schedule, the Contracting Officer or his representative, will do one or both of the following
O0101 32 16.15Project Schedules (Small Projects - Design-Bid-Build)1.5.C.THE COMPLETE PROJECT SCHEDULE SUBMITTAL
The approved baseline schedule and the computer-produced schedule(s) generated there from shall constitute the approved baseline schedule until subsequently revised in accordance with the requirements of this section.
O0101 32 16.15Project Schedules (Small Projects - Design-Bid-Build)1.5.D.THE COMPLETE PROJECT SCHEDULE SUBMITTAL
The Complete Project Schedule shall contain approximately [________] work activities/events.
O0101 33 23Shop Drawings, Product Data, and Samples1.4.A.SUBMITTAL REGISTER
The submittal register will list items of equipment and materials for which submittals are required by the specifications. This list may not be all inclusive and additional submittals may be required by the specifications. The Contractor is not relieved from supplying submittals required by the contract documents but which have been omitted from the submittal register.
O0101 33 23Shop Drawings, Product Data, and Samples1.4.B.SUBMITTAL REGISTER
The submittal register will serve as a scheduling document for submittals and will be used to control submittal actions throughout the contract period.
O0101 33 23Shop Drawings, Product Data, and Samples1.4.C.SUBMITTAL REGISTER
The VA will provide the initial submittal register in electronic format. Thereafter, the Contractor shall track all submittals by maintaining a complete list, including completion of all data columns, including dates on which submittals are received and returned by the VA.
O0101 33 23Shop Drawings, Product Data, and Samples1.4.D.SUBMITTAL REGISTER
The Contractor shall update the submittal register as submittal actions occur and maintain the submittal register at the project site until final acceptance of all work by Contracting Officer.
O0101 33 23Shop Drawings, Product Data, and Samples1.4.E.SUBMITTAL REGISTER
The Contractor shall submit formal monthly updates to the submittal register in electronic format. Each monthly update shall document actual submission and approval dates for each submittal.
O0101 33 23Shop Drawings, Product Data, and Samples1.5.A.SUBMITTAL SCHEDULING
Submittals are to be scheduled, submitted, reviewed, and approved prior to the acquisition of the material or equipment.
O0101 33 23Shop Drawings, Product Data, and Samples1.5.B.SUBMITTAL SCHEDULING
Coordinate scheduling, sequencing, preparing, and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow time for potential resubmittal.
O0101 33 23Shop Drawings, Product Data, and Samples1.5.C.SUBMITTAL SCHEDULING
No delay costs or time extensions will be allowed for time lost in late submittals or resubmittals.
O0101 33 23Shop Drawings, Product Data, and Samples1.5.D.SUBMITTAL SCHEDULING
All submittals are required to be approved prior to the start of the specified work activity.
O0101 33 23Shop Drawings, Product Data, and Samples1.6.A.SUBMITTAL PREPARATION
Each submittal is to be complete and in sufficient detail to allow ready determination of compliance with contract requirements.
O0101 33 23Shop Drawings, Product Data, and Samples1.6.B.SUBMITTAL PREPARATION
Collect required data for each specific material, product, unit of work, or system into a single submittal. Prominently mark choices, options, and portions applicable to the submittal. Partial submittals will not be accepted for expedition of construction effort. Submittal will be returned without review if incomplete.
O0101 33 23Shop Drawings, Product Data, and Samples1.6.C.SUBMITTAL PREPARATION
If available product data is incomplete, provide Contractor-prepared documentation to supplement product data and satisfy submittal requirements.
O0101 33 23Shop Drawings, Product Data, and Samples1.6.D.SUBMITTAL PREPARATION
All irrelevant or unnecessary data shall be removed from the submittal to facilitate accuracy and timely processing. Submittals that contain the excessive amount of irrelevant or unnecessary data will be returned with review.
O0101 33 23Shop Drawings, Product Data, and Samples1.6.E.SUBMITTAL PREPARATION
Provide a transmittal form for each submittal with the following information
O0101 33 23Shop Drawings, Product Data, and Samples16.F.SUBMITTAL PREPARATION
The Contractor is responsible for reviewing and certifying that all submittals are in compliance with contract requirements before submitting for VA review. Proposed deviations from the contract requirements are to be clearly identified. All deviations submitted must include a side by side comparison of item being proposed against item specified. Failure to point out deviations will result in the VA requiring removal and replacement of such work at the Contractor's expense.
O0101 33 23Shop Drawings, Product Data, and Samples1.6.G.SUBMITTAL PREPARATION
Stamp, sign, and date each submittal transmittal form indicating action taken.
O0101 33 23Shop Drawings, Product Data, and Samples1.6.H.SUBMITTAL PREPARATION
Stamp used by the Contractor on the submittal transmittal form to certify that the submittal meets contract requirements is to be similar to the following
O0101 33 23Shop Drawings, Product Data, and Samples1.7.A.SUBMITTAL FORMAT AND TRANSMISSION
Provide submittals in electronic format, with the exception of material samples. Use PDF as the electronic format, unless otherwise specified or directed by the Contracting Officer.
O0101 33 23Shop Drawings, Product Data, and Samples1.7.B.SUBMITTAL FORMAT AND TRANSMISSION
Compile the electronic submittal file as a single, complete document. Name the electronic submittal file specifically according to its contents.
O0101 33 23Shop Drawings, Product Data, and Samples1.7.C.SUBMITTAL FORMAT AND TRANSMISSION
Electronic files must be of sufficient quality that all information is legible. Generate PDF files from original documents so that the text included in the PDF file is both searchable and can be copied. If documents are scanned, Optical Character Resolution (OCR) routines are required.
O0101 33 23Shop Drawings, Product Data, and Samples1.7.D.SUBMITTAL FORMAT AND TRANSMISSION
E-mail electronic submittal documents smaller than 5MB in size to e-mail addresses as directed by the Contracting Officer.
O0101 33 23Shop Drawings, Product Data, and Samples1.7.E.SUBMITTAL FORMAT AND TRANSMISSION
Provide electronic documents over 5MB through an electronic FTP file sharing system. Confirm that the electronic FTP file sharing system can be accessed from the VA computer network. The Contractor is responsible for setting up, providing, and maintaining the electronic FTP file sharing system for the construction contract period of performance.
O0101 33 23Shop Drawings, Product Data, and Samples1.7.F.SUBMITTAL FORMAT AND TRANSMISSION
Provide hard copies of submittals when requested by the Contracting Officer. Up to 3 additional hard copies of any submittal may be requested at the discretion of the Contracting Officer, at no additional cost to the VA.
O0101 33 23Shop Drawings, Product Data, and Samples1.13.A.VA REVIEW OF SUBMITTALS AND RFIS
The VA will review all submittals for compliance with the technical requirements of the contract documents. The Architect-Engineer for this project will assist the VA in reviewing all submittals and determining contractual compliance. Review will be only for conformance with the applicable codes, standards and contract requirements.
O0101 33 23Shop Drawings, Product Data, and Samples1.13.B.VA REVIEW OF SUBMITTALS AND RFIS
Period of review for submittals begins when the VA COR receives submittal from the Contractor.
O0101 33 23Shop Drawings, Product Data, and Samples1.13.C.VA REVIEW OF SUBMITTALS AND RFIS
Period of review for each resubmittal is the same as for initial submittal.
O0101 33 23Shop Drawings, Product Data, and Samples1.13.D.VA REVIEW OF SUBMITTALS AND RFIS
VA review period is 15 working days for submittals.
O0101 33 23Shop Drawings, Product Data, and Samples1.13.E.VA REVIEW OF SUBMITTALS AND RFIS
VA review period is 10 working days for RFIs.
O0101 33 23Shop Drawings, Product Data, and Samples1.13.F.VA REVIEW OF SUBMITTALS AND RFIS
The VA will return submittals to the Contractor with the following notations
O0101 33 23Shop Drawings, Product Data, and Samples1.14.A.APPROVED SUBMITTALS
The VA approval of submittals is not to be construed as a complete check, and indicates only that the general method of construction, materials, detailing, and other information are satisfactory.
O0101 33 23Shop Drawings, Product Data, and Samples1.14.B.APPROVED SUBMITTALS
VA approval of a submittal does not relieve the Contractor of the responsibility for any error which may exist. The Contractor is responsible for fully complying with all contract requirements and the satisfactory construction of all work, including the need to check, confirm, and coordinate the work of all subcontractors for the project. Non-compliant material incorporated in the work will be removed and replaced at the Contractor’s expense.
O0101 33 23Shop Drawings, Product Data, and Samples1.14.C.APPROVED SUBMITTALS
After submittals have been approved, no resubmittal for the purpose of substituting materials or equipment will be considered unless accompanied by an explanation of why a substitution is necessary.
O0101 33 23Shop Drawings, Product Data, and Samples1.14.D.APPROVED SUBMITTALS
Retain a copy of all approved submittals at project site, including approved samples.
O0101 45 00Quality Control1.3.A.SUBMITTALS
Government approval is required for all submittals. CQC inspection reports shall be submitted under this Specification section and follow the Applicable Specification section naming convention.
O0101 45 00Quality Control1.3.A.1SUBMITTALS
Preconstruction Submittals

a. Interim CQC Plan

b. CQC Plan

O0101 45 00Quality Control1.3.A.2SUBMITTALS
Test Reports

a)Verification Statement

O0101 45 00Quality Control1.3.A.3SUBMITTALS
Third-Party Inspection Reports

a. Third-Party Inspection Report shall be submitted to the COR.

b. Inspection reports shall include work inspected or tested was or was not completed in conformance to approved construction documents.

1) Discrepancies shall be brought to the immediate attention of the contractor and COR.

c. Final Third-Party Inspection Report:

1) Prior to the start of Commissioning activities, the Third-Party Inspection contractor shall submit a final Report documenting inspections and tests, and correction of any discrepancies noted in the inspections or tests

O0101 45 00Quality Control3.5.A.SUBMITTALS AND DELIVERABLES:
Submittals have to comply with the requirements in Section 01 33 23 Shop Drawings, Product Data, and Samples. The CQC organization is responsible for certifying that all submittals and deliverables are in compliance with the contract requirements. When Section 01 91 00 General Commissioning Requirements is included in the contract, the submittals required by the section have to be coordinated with the Section 01 33 23 Shop Drawings, Product Data, and Samples to ensure adequate time is allowed for each type of submittal required.
O0101 45 00Quality Control3.5.A.1SUBMITTALS AND DELIVERABLES:
Third-Party Inspection individuals or specified technical companies shall review the

submittals before the contractor submits to the COR.

O 01 01 45 35 Special Inspections 1.4.M SUBMITTALS Submittals: Government approval is required for all submittals. CQC Special Inspection reports shall be submitted under this Specification section and follow the Applicable Specification section or description naming convention. Submit the following:

1. SD-01 Preconstruction Submittals;

2. SIOR Letter of Acceptance;

3. Special Inspections Project Manual;

4. Special Inspections Agency's Written Practices

5. NDT Procedures and Equipment’ Calibration Records;

6. SD-06 Test Reports;

7. Special Inspections

8. Daily Reports;

9. Special Inspections; Biweekly Reports;

10. SD-07 Certificates;

11. Fabrication Plant

12. Steel Truss Plant;

13. Wood Truss Plant;

14. AC472 Accreditation;

15. Steel Joist Institute Membership;

16. Precast Concrete Institute (PCI) Certified Plant;

17. Certificate of Compliance;

18. Special Inspector of Record Qualifications;

19. Special Inspector Qualifications;

20. Qualification Records for NDT technicians;

21. SD-11 Closeout Submittals;

22. Interim Final Report of Special Inspections;

23. Comprehensive Final Report of Special Inspections;

O0101 57 19Temporary Environmental Controls1.4.A.SUBMITTALS
In accordance with Section, 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES, furnish the following:

1. Environmental Protection Plan: After the contract is awarded and prior to the commencement of the work, the Contractor shall meet with the Contracting Officer Representative (COR) to discuss the proposed Environmental Protection Plan and to develop mutual understanding relative to details of environmental protection. Not more than 20 days after the meeting, the Contractor shall prepare and submit to the Contracting Officer ] for approval, a written and/or graphic Environmental Protection Plan including, but not limited to, the following:

a. Name(s) of person(s) within the Contractor's organization who is (are) responsible for ensuring adherence to the Environmental Protection Plan.

b. Name(s) and qualifications of person(s) responsible for manifesting hazardous waste to be removed from the site.

c. Name(s) and qualifications of person(s) responsible for training the Contractor's environmental protection personnel.

d. Description of the Contractor's environmental protection personnel training program.

e. A list of Federal, State, and local laws, regulations, and permits concerning environmental protection, pollution control, noise control and abatement that are applicable to the Contractor's proposed operations and the requirements imposed by those laws, regulations, and permits.

f. Methods for protection of features to be preserved within authorized work areas including trees, shrubs, vines, grasses, ground cover, landscape features, air and water quality, fish and wildlife, soil, historical, and archeological and cultural resources.

g. Procedures to provide the environmental protection that comply with the applicable laws and regulations. Describe the procedures to correct pollution of the environment due to accident, natural causes, or failure to follow the procedures as described in the Environmental Protection Plan.

h. Permits, licenses, and the location of the solid waste disposal area.

i. Drawings showing locations of any proposed temporary excavations or embankments for haul roads, stream crossings, material storage areas, structures, sanitary facilities,] and stockpiles of excess or spoil materials. Include as part of an Erosion Control Plan approved by the District Office of the U.S. Soil Conservation Service and the Department of Veterans Affairs.

j. Environmental Monitoring Plans for the job site including land, water, air, and noise.

k. Work Area Plan showing the proposed activity in each portion of the area and identifying the areas of limited use or nonuse. Plan should include measures for marking the limits of use areas. This plan may be incorporated within the Erosion Control Plan.

l. Inclusion of “best management practices” and methodologies.

O0101 57 19Temporary Environmental Controls1.4.B.SUBMITTALS
Approval of the Contractor's Environmental Protection Plan will not relieve the Contractor of responsibility for adequate and continued control of pollutants and other environmental protection measures.
O0101 74 19Construction Waste Management1.5.A.SUBMITTALS
In accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, and SAMPLES, furnish the following
O0101 74 19Construction Waste Management1.5.B.SUBMITTALS
Prepare and submit to the Resident Engineer a written demolition debris management plan. The plan shall include, but not be limited to, the following information
O0101 74 19Construction Waste Management1.5.C.SUBMITTALS
Designated Manager responsible for instructing personnel, supervising, documenting and administer over meetings relevant to the Waste Management Plan.
O0101 74 19Construction Waste Management1.5.D.SUBMITTALS
Monthly summary of construction and demolition debris diversion and disposal, quantifying all materials generated at the work site and disposed of or diverted from disposal through recycling.
O0101 74 19Construction Waste Management1.5.E.SUBMITTALS
Target waste diversion rate by material and an overall diversion rate.
O0101 74 19Construction Waste Management1.5.F.SUBMITTALS
Final report documenting the results of implementation of the preconstruction waste

management plan.

O0101 81 13Sustainable Construction Requirements1.5.A.SUBMITTALS
All submittals to be provided by contractor to COR.
O0101 81 13Sustainable Construction Requirements1.5.B.SUBMITTALS
Sustainability Action Plan
O0101 81 13Sustainable Construction Requirements1.5.C.SUBMITTALS
Low Pollutant-Emitting Materials Tracking SpreadsheetWithin 30 days after Preconstruction Meeting provide a preliminary Low Pollutant-Emitting Materials Tracking Spreadsheet. The Low Pollutant-Emitting Materials Tracking Spreadsheet must be an electronic file and include all materials on Project in categories described under Low Pollutant-Emitting Materials in 01 81 13.
O0101 81 13Sustainable Construction Requirements1.5.D.SUBMITTALS
Construction Indoor Air Quality (IAQ) Management Plan
O0101 81 13Sustainable Construction Requirements1.5.E.SUBMITTALS
Product Submittals
O0101 81 13Sustainable Construction Requirements1.5.F.SUBMITTALS
Sustainable Construction Progress ReportsConcurrent with each Application for Payment, submit a Sustainable Construction Progress Report to confirm adherence with Sustainability Action Plan.
O0101 81 13Sustainable Construction Requirements1.5.G.SUBMITTALS
Closeout SubmittalsWithin 14 days after Substantial Completion provide the following
O0101 91 00General Commissioning Requirements1.13.A.SUBMITTALS
Preliminary Commissioning Plan SubmittalThe Commissioning Agent has prepared a Preliminary Commissioning Plan based on the final Construction Documents. The Preliminary Commissioning Plan is included as an Appendix to this specification section. The Preliminary Commissioning Plan is provided for information only. It contains preliminary information about the following commissioning activities
O0101 91 00General Commissioning Requirements1.13.B.SUBMITTALS
Final Commissioning Plan SubmittalBased on the Final Construction Documents and the Contractor’s project team, the Commissioning Agent will prepare the Final Commissioning Plan as described in this section. The Commissioning Agent will submit three hard copies and three sets of electronic files of Final Commissioning Plan. The Contractor shall review the Commissioning Plan and provide any comments to the VA. The Commissioning Agent will incorporate review comments into the Final Commissioning Plan as directed by the VA.
O0101 91 00General Commissioning Requirements1.13.C.SUBMITTALS
Systems Functional Performance Test ProcedureThe Commissioning Agent will submit preliminary Systems Functional Performance Test Procedures to the Contractor, and the VA for review and comment. The Contractor shall return review comments to the VA and the Commissioning Agent. The VA will also return review comments to the Commissioning Agent. The Commissioning Agent will incorporate review comments into the Final Systems Functional Test Procedures to be used in Systems Functional Performance Testing.
O0101 91 00General Commissioning Requirements1.13.D.SUBMITTALS
Pre-Functional ChecklistsThe Commissioning Agent will submit Pre-Functional Checklists to be completed by the Contractor.
O0101 91 00General Commissioning Requirements1.13.E.SUBMITTALS
Test and Inspection ReportsThe Commissioning Agent will submit test and inspection reports to the VA with copies to the Contractor and the Architect/Engineer.
O0101 91 00General Commissioning Requirements1.13.F.SUBMITTALS
Corrective Action DocumentsThe Commissioning Agent will submit corrective action documents to the VA Resident Engineer with copies to the Contractor and Architect.
O0101 91 00General Commissioning Requirements1.13.G.SUBMITTALS
Preliminary Commissioning Report SubmittalThe Commissioning Agent will submit three electronic copies of the preliminary commissioning report. One electronic copy, with review comments, will be returned to the Commissioning Agent for preparation of the final submittal.
O0101 91 00General Commissioning Requirements1.13.H.SUBMITTALS
Final Commissioning Report SubmittalThe Commissioning Agent will submit four sets of electronically formatted information of the final commissioning report to the VA. The final submittal will incorporate comments as directed by the VA.
O0101 91 00General Commissioning Requirements1.13.I.SUBMITTALS
Data for Commissioning
O0202 82 11Traditional Asbestos Abatement2.4.A.SUBMITTALS
PRE-START MEETING SUBMITTALS
O0202 82 11Traditional Asbestos Abatement2.4.B.SUBMITTALS
SUBMITTALS DURING ABATEMENT
O0202 82 11Traditional Asbestos Abatement2.4.C.SUBMITTALS
SUBMITTALS AT COMPLETION OF ABATEMENT
O0202 82 13.13Glovebag Asbestos Abatement2.5.A.SUBMITTALS
PRE-start MEETING SUBMITTALS
O0202 82 13.13Glovebag Asbestos Abatement2.5.B.SUBMITTALS
SUBMITTALS DURING ABATEMENT
O0202 82 13.13Glovebag Asbestos Abatement2.5.C.SUBMITTALS
SUBMITTALS AT COMPLETION OF ABATEMENT
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.APRE-START MEETING SUBMITTALSSubmit a detailed work schedule for the entire project reflecting contract documents and the phasing/schedule requirements from the CPM chart.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.BPRE-START MEETING SUBMITTALSSubmit a staff organization chart showing all personnel who will be working on the project and their capacity/function. Provide their qualifications, training, accreditations, and licenses, as appropriate. Provide a copy of the "Certificate of Worker's Acknowledgment" and the "Affidavit of Medical Surveillance and Respiratory Protection" for each person.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.CPRE-START MEETING SUBMITTALSSubmit Asbestos Hazard Abatement Plan developed specifically for this project, incorporating the requirements of the specifications, prepared, signed and dated by the CPIH/CI
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.DPRE-START MEETING SUBMITTALSSubmit the specifics of the materials and equipment to be used for this project with manufacturer names, model numbers, performance characteristics, pictures/diagrams, and number available for the following
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.EPRE-START MEETING SUBMITTALSSubmit the name, location, and phone number of the approved landfill; proof/verification the landfill is approved for ACM disposal; the landfill's requirements for ACM waste; the type of vehicle to be used for transportation; and name, address, and phone number of subcontractor, if used. Proof of asbestos training for transportation personnel shall be provided.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.FPRE-START MEETING SUBMITTALSSubmit required notifications and arrangements made with regulatory agencies having regulatory jurisdiction and the specific contingency/emergency arrangements made with local health, fire, ambulance, hospital authorities and any other notifications/arrangements.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.GPRE-START MEETING SUBMITTALSSubmit the name, location and verification of the laboratory and/or personnel to be used for analysis of air and/or bulk samples. Personal air monitoring must be done in accordance with OSHA 29 CFR 1926.1101(f) and Appendix A. And area or clearance air monitoring in accordance with EPA AHERA protocols.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.HPRE-START MEETING SUBMITTALSSubmit qualifications verificationSubmit the following evidence of qualifications. Make sure that all references are current and verifiable by providing current phone numbers and documentation.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.IPRE-START MEETING SUBMITTALSSubmit information on personnelProvide a resume; address each item completely; copies of certificates, accreditations, and licenses. Submit an affidavit signed by the CPIH/CIH stating that all personnel submitted below have medical records in accordance with OSHA 29 CFR 1926.1101(m) and 29 CFR 1910.20 and that the company has implemented a medical surveillance program and written respiratory protection program, and maintains recordkeeping in accordance with the above regulations. Submit the phone number and doctor/clinic/hospital used for medical evaluations.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.JPRE-START MEETING SUBMITTALSSubmit copies of State license for asbestos abatement; copy of insurance policy, including exclusions with a letter from agent stating in plain language the coverage provided and the fact that asbestos abatement activities are covered by the policy; copy of the AHAP incorporating the requirements of this specification; information on who provides your training, how often; who provides medical surveillance, how often; who performs and how is personal air monitoring of abatement workers conducted; a list of references of independent laboratories/IH's familiar with your air monitoring and Asbestos Hazard Abatement Plans; copies of monitoring results of the five referenced projects listed and analytical method(s) used.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.KPRE-START MEETING SUBMITTALSRented equipment must be decontaminated prior to returning to the rental agency.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.1.LPRE-START MEETING SUBMITTALSSubmit, before the start of work, the manufacturer's technical data for all types of encapsulants, all MSDS, and application instructions.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.2.ASUBMITTALS DURING ABATEMENTThe Competent Person shall maintain and submit a daily log at the regulated area documenting the dates and times of the followingpurpose, attendees and summary of meetings; all personnel entering/exiting the regulated area; document and discuss the resolution of unusual events such as barrier breeching, equipment failures, emergencies, and any cause for stopping work; representative air monitoring and results/TWAs/ELs. Submit this information daily to the VPIH/CIH.
O0202 82 13.19Asbestos Floor Tile and Mastic Abatement2.5.2.BSUBMITTALS DURING ABATEMENTThe CPIH/CIH shall document and maintain the inspection and approval of the regulated area preparation prior to start of work and daily during work.
O0202 83 33.13Lead-Based Paint Removal and Disposal1.6.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0202 83 33.13Lead-Based Paint Removal and Disposal1.6.B.SUBMITTALS
Manufacturer's Literature and Data
O0202 83 33.13Lead-Based Paint Removal and Disposal1.6.C.SUBMITTALS
Test ReportsSubmit testing laboratory reports.
O0202 83 33.13Lead-Based Paint Removal and Disposal1.6.D.SUBMITTALS
CertificatesCertify completed training.
O0202 83 33.13Lead-Based Paint Removal and Disposal1.6.E.SUBMITTALS
QualificationsSubstantiate qualifications comply with specifications.
O0202 83 33.13Lead-Based Paint Removal and Disposal1.6.F.SUBMITTALS
Record Documents
O0303 30 00Cast-in-Place Concrete1.4.A.SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, and SAMPLES.
O0303 30 00Cast-in-Place Concrete1.4.B.SUBMITTALS:
Submittal drawingsReinforcing steel
O0303 30 00Cast-in-Place Concrete1.4.C.SUBMITTALS:
Manufacturer's Literature & Data
O0303 30 00Cast-in-Place Concrete1.4.D.SUBMITTALS:
Sustainable Construction Submittals
O0303 30 00Cast-in-Place Concrete1.4.E.SUBMITTALS:
CertificatesApproval request including qualifications of principals and technicians and evidence of active participation in program of Cement and Concrete Reference Laboratory (CCRL) of National Institute of Standards and Technology // and copy of report of latest CCRL, Inspection of Laboratory. //
O0303 30 00Cast-in-Place Concrete1.4.F.SUBMITTALS:
Test Report for Concrete Mix DesignsTrial mixes including water�cement // fly ash // ratio curves, concrete mix ingredients, and admixtures.
O0303 30 00Cast-in-Place Concrete1.4.G.SUBMITTALS:
Shoring and Reshoring SequenceSubmit for approval a shoring and reshoring sequence for flat slab/flat plate portions, prepared by a registered Professional Engineer. As a minimum, include timing of form stripping, reshoring, number of floors to be re-shored and timing of re-shore removal to serve as an initial outline of procedures subject to modification as construction progresses. Submit revisions to sequence, whether initiated by Resident Engineer (see FORMWORK) or Contractor.
O0303 30 00Cast-in-Place Concrete1.6.H.SUBMITTALS:
Test reports on splitting tensile strength (Fct) of lightweight concrete.
O0404 01 00Maintenance of Masonry1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0404 01 00Maintenance of Masonry1.4.B.SUBMITTALS
Manufacturer's Literature and Data
O0404 01 00Maintenance of Masonry1.4.C.SUBMITTALS
Samples
O0404 01 00Maintenance of Masonry1.4.D.SUBMITTALS
Test reports
O0404 05 13Masonry Mortaring1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0404 05 13Masonry Mortaring1.4.B.SUBMITTALS
Manufacturer's Literature and Data
O0404 05 13Masonry Mortaring1.4.C.SUBMITTALS
Test ReportsCertify each product complies with specifications.
O0404 05 13Masonry Mortaring1.4.D.SUBMITTALS
CertificatesCertify each product complies with specifications.
O0404 05 13Masonry Mortaring1.4.E.SUBMITTALS
QualificationsSubstantiate qualifications comply with specifications.
O0404 05 16Masonry Grouting1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0404 05 16Masonry Grouting1.4.B.SUBMITTALS
Manufacturer's Literature and Data
O0404 05 16Masonry Grouting1.4.C.SUBMITTALS
Sustainable Construction Submittals
O0404 05 16Masonry Grouting1.4.D.SUBMITTALS
Test ReportsCertify each product complies with specifications.
O0404 05 16Masonry Grouting1.4.E.SUBMITTALS
CertificatesCertify each product complies with specifications.
O0404 20 00Unit Masonry1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0404 20 00Unit Masonry1.4.B.SUBMITTALS
Submittal Drawings
O0404 20 00Unit Masonry1.4.C.SUBMITTALS
Manufacturer's Literature and Data
O0404 20 00Unit Masonry1.4.D.SUBMITTALS
Samples
O0404 20 00Unit Masonry1.4.E.SUBMITTALS
Sustainable Construction Submittals
O0404 20 00Unit Masonry1.4.F.SUBMITTALS
Test reportsCertify products comply with specifications.
O0404 20 00Unit Masonry1.4.G.SUBMITTALS
CertificatesCertify products comply with specifications.
O0404 20 00Unit Masonry1.4.H.SUBMITTALS
Delegated Design Drawings and CalculationsSigned and sealed by responsible design professional.
O0404 72 00Cast Stone Masonry1.3.A.SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0404 72 00Cast Stone Masonry1.3.B.SUBMITTALS
Samples
O0404 72 00Cast Stone Masonry1.3.C.SUBMITTALS
Shop Drawings
O0404 72 00Cast Stone Masonry1.3.D.SUBMITTALS
CertificatesTest results indicating that the cast stone meets specification requirements and proof of plant certification.
O0404 72 00Cast Stone Masonry1.3.E.SUBMITTALS
Submit manufacturers test results of cast stone previously made by manufacturer.
O0404 72 00Cast Stone Masonry1.3.F.SUBMITTALS
Laboratory DataDescription of testing laboratories facilities and qualifications of its principals and key personnel.
O0404 72 00Cast Stone Masonry1.3.G.SUBMITTALS
List of jobs furnished by the manufacturer, which were similar in scope and at least three (3) years of age.
O0505 12 00Structural Steel Framing1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0505 12 00Structural Steel Framing1.4.B.SUBMITTALS
Submittal Drawings
O0505 12 00Structural Steel Framing1.4.C.SUBMITTALS
Sustainable Construction Submittals
O0505 12 00Structural Steel Framing1.4.D.SUBMITTALS
Test ReportsCertify products comply with specifications.
O0505 12 00Structural Steel Framing1.4.E.SUBMITTALS
CertificatesCertify each product complies with specifications.
O0505 12 00Structural Steel Framing1.4.F.SUBMITTALS
QualificationsSubstantiate qualifications comply with specifications.
O0505 12 00Structural Steel Framing1.4.G.SUBMITTALS
Delegated Design Drawings and CalculationsSigned and sealed by responsible Architect/Engineer.
O0505 12 00Structural Steel Framing1.4.H.SUBMITTALS
Record SurveysSigned and sealed by responsible surveyor or engineer.
O0505 31 00Steel Decking1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0505 31 00Steel Decking1.4.B.SUBMITTALS
Submittal Drawings
O0505 31 00Steel Decking1.4.C.SUBMITTALS
Manufacturer's Literature and Data
O0505 31 00Steel Decking1.4.D.SUBMITTALS
Sustainable Construction Submittals
O0505 31 00Steel Decking1.4.E.SUBMITTALS
CertificatesCertify each product complies with specifications.
O0505 31 00Steel Decking1.4.F.SUBMITTALS
QualificationsSubstantiate qualifications comply with specifications.
O0505 31 00Steel Decking1.4.G.SUBMITTALS
Insurance CertificationAssist the Government in preparation and submittal of roof installation acceptance certification as may be necessary in connection with fire and extended coverage insurance.
O0505 40 00Cold-Formed Metal Framing1.4.A.SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0505 40 00Cold-Formed Metal Framing1.4.B.SUBMITTALS
Shop DrawingsShop and erection drawings showing steel unit layout, connections to supporting members, and information necessary to complete installation as shown and specified.
O0505 40 00Cold-Formed Metal Framing1.4.C.SUBMITTALS
Manufacturer's Literature and DataShowing steel component sections and specifying structural characteristics.
O0505 40 00Cold-Formed Metal Framing1.4.D.SUBMITTALS
Design of the light gauge for this project shall be provided by the contractor’s structural engineer for the loads shown on the construction documents. Submit signed and sealed calculations performed by a structural engineer with at least 5 years experience in the design of light gauge metal and registered in the state of the project. Calculations shall be submitted with plans elevations and details for review and approval.
O0505 40 00Cold-Formed Metal Framing1.4.E.SUBMITTALS
Sustainable Construction Submittals:

1. Recycled Content: Identify post-consumer and pre-consumer recycled content percentage by weight.

O0505 50 00Metal Fabrications1.3.A.SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0505 50 00Metal Fabrications1.3.B.SUBMITTALS
Manufacturer's Literature and Data
O0505 50 00Metal Fabrications1.3.C.SUBMITTALS
Shop Drawings
O0505 50 00Metal Fabrications1.3.D.SUBMITTALS
Manufacturer's Certificates
O0505 50 00Metal Fabrications1.3.E.SUBMITTALS
Design Calculations for specified live loads including dead loads.
O0505 50 00Metal Fabrications1.3.F.SUBMITTALS
Furnish setting drawings and instructions for installation of anchors to be preset into concrete and masonry work, and for the positioning of items having anchors to be built into concrete or masonry construction.
O0505 51 00Metal Stairs1.3.A.SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0505 51 00Metal Stairs1.3.B.SUBMITTALS
Sustainable Design Submittals, as described below
O0505 51 00Metal Stairs1.3.C.SUBMITTALS
Shop DrawingsShow design, fabrication details, installation, connections, material, and size of members.
O0505 51 00Metal Stairs1.3.D.SUBMITTALS
Fabrication qualifications.
O0505 51 00Metal Stairs1.3.E.SUBMITTALS
Installer qualifications.
O0505 51 00Metal Stairs1.3.F.SUBMITTALS
Calculations.
O0505 51 00Metal Stairs1.3.G.SUBMITTALS
Welding qualifications.
O0606 60 60Plastic Fabrication Resin Panels1.3 BSUBMITTALS
Product Data
O0606 60 60Plastic Fabrication Resin Panels1.3 CSUBMITTALS
Product Test Reports
O0606 60 60Plastic Fabrication Resin Panels1.3 DSUBMITTALS
Building approvals
O0606 60 60Plastic Fabrication Resin Panels1.3 ESUBMITTALS
Shop Drawings
O0606 60 60Plastic Fabrication Resin Panels1.3 FSUBMITTALS
Samples for initial selection
O0606 60 60Plastic Fabrication Resin Panels1.3 GSUBMITTALS
Samples for verifications
O0606 10 00Rough Carpentry1.3.A.SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0606 10 00Rough Carpentry1.3.B.SUBMITTALS
Sustainable Design Submittals, as described below
O0606 10 00Rough Carpentry1.3.C.SUBMITTALS
Shop Drawings showing framing connection details, fasteners, connections and dimensions.
O0606 10 00Rough Carpentry1.3.D.SUBMITTALS
Manufacturer’s Literature and Data
O0606 10 00Rough Carpentry1.3.E.SUBMITTALS
Manufacturer’s certificate for unmarked lumber.
O0606 16 63Cementitious Sheathing1.3.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0606 16 63Cementitious Sheathing1.3.B.SUBMITTALS
Manufacturer's Literature and Data
O0606 16 63Cementitious Sheathing1.3.C.SUBMITTALS
Samples
O0606 20 00Finish Carpentry1.5.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0606 20 00Finish Carpentry1.5.B.SUBMITTALS
Submittal Drawings
O0606 20 00Finish Carpentry1.5.C.SUBMITTALS
Manufacturer's Literature and Data
O0606 20 00Finish Carpentry1.5.D.SUBMITTALS
Samples
O0606 20 00Finish Carpentry1.5.E.SUBMITTALS
Sustainable Construction Submittals
O0606 20 00Finish Carpentry1.5.F.SUBMITTALS
CertificatesCertify // each product complies // products comply // with specifications.
O0606 20 00Finish Carpentry1.5.G.SUBMITTALS
QualificationsSubstantiate qualifications comply with specifications.
O0707 01 50.19Preparation for Re-Roofing1.5.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0707 01 50.19Preparation for Re-Roofing1.5.B.SUBMITTALS
Submittal Drawings
O0707 01 50.19Preparation for Re-Roofing1.5.C.SUBMITTALS
Manufacturer's Literature and Data
O0707 01 50.19Preparation for Re-Roofing1.5.D.SUBMITTALS
PhotographsDocument existing conditions potentially affected by roofing operations before work begins.
O0707 01 50.19Preparation for Re-Roofing1.5.E.SUBMITTALS
Field Inspection Reports
O0707 01 50.19Preparation for Re-Roofing1.5.F.SUBMITTALS
Infrared Roof Moisture Survey Report.
O0707 08 00Facility Exterior Closure Commissioning1.6.A.SUBMITTALS
The commissioning process requires review of selected Submittals that pertain to the systems to be commissioned. The Commissioning Agent will provide a list of submittals that will be reviewed by the Commissioning Agent. This list will be reviewed and approved by the VA prior to forwarding to the Contractor. Refer to Section 01 33 23 SHOP DRAWINGS, PRODUCT DATA, and SAMPLES for further details.
O0707 08 00Facility Exterior Closure Commissioning1.6.B.SUBMITTALS
The commissioning process requires Submittal review simultaneously with engineering review. Specific submittal requirements related to the commissioning process are specified in Section 01 91 00 GENERAL COMMISSIONING REQUIREMENTS.
O0707 13 00Sheet Waterproofing1.3.A.SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0707 13 00Sheet Waterproofing1.3.B.SUBMITTALS
Manufacturer's Literature and Data
O0707 13 00Sheet Waterproofing1.3.C.SUBMITTALS
Certificates
O0707 13 00Sheet Waterproofing1.3.D.SUBMITTALS
Samples
O0707 13 52Modified Bituminous Sheet Waterproofing1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0707 13 52Modified Bituminous Sheet Waterproofing1.4.B.SUBMITTALS
Submittal Drawings
O0707 13 52Modified Bituminous Sheet Waterproofing1.4.C.SUBMITTALS
Manufacturer's Literature and Data
O0707 13 52Modified Bituminous Sheet Waterproofing1.4.D.SUBMITTALS
Samples
O0707 13 52Modified Bituminous Sheet Waterproofing1.4.E.SUBMITTALS
Test reportsCertify products comply with specifications.
O0707 13 52Modified Bituminous Sheet Waterproofing1.4.F.SUBMITTALS
CertificatesCertify products comply with specifications.
O0707 13 52Modified Bituminous Sheet Waterproofing1.4.G.SUBMITTALS
QualificationsSubstantiate qualifications comply with specifications.
O0707 21 13Thermal Insulation1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0707 21 13Thermal Insulation1.4.B.SUBMITTALS
Submittal Drawings
O0707 21 13Thermal Insulation1.4.C.SUBMITTALS
Manufacturer's Literature and Data
O0707 21 13Thermal Insulation1.4.D.SUBMITTALS
Sustainable Construction Submittals
O0707 21 23Loose-Fill Insulation1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0707 21 23Loose-Fill Insulation1.4.B.SUBMITTALS
Manufacturer's Literature and Data
O0707 21 23Loose-Fill Insulation1.4.C.SUBMITTALS
Samples
O0707 21 23Loose-Fill Insulation1.4.D.SUBMITTALS
Sustainable Construction Submittals
O0707 22 00Roof and Deck Insulation1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0707 22 00Roof and Deck Insulation1.4.B.SUBMITTALS
Submittal Drawings
O0707 22 00Roof and Deck Insulation1.4.C.SUBMITTALS
Manufacturer's Literature and Data
O0707 22 00Roof and Deck Insulation1.4.D.SUBMITTALS
Samples
O0707 22 00Roof and Deck Insulation1.4.E.SUBMITTALS
Sustainable Construction Submittals
O0707 22 00Roof and Deck Insulation1.4.F.SUBMITTALS
QualificationsSubstantiate qualifications meet specifications.
O0707 27 26Fluid-Applied Membrane Air Barrier, Vapor Permeable1.4.A.SUBMITTALS
Submittal ProceduresSection 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
O0707 27 26Fluid-Applied Membrane Air Barrier, Vapor Permeable1.4.B.SUBMITTALS
Manufacturer's Literature and Data

This is the start of the file's text. The full file is on GovTribe.

File details come from the government source that posted it. Updated .