Amendment A002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

N/A

PAGE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE NO. 5. PROJECT NO. (If applicable)

A002 09/23/2025 N/A OR NPS CRLA 2018(1),

Cleetwood Trail and Marina

Improvements

6. ISSUED BY CODE N/A 7. ADMINISTERED BY (If other than Item 6) CODE N/A

Department of Transportation Federal Highway Administration 610 East Fifth Street Vancouver WA 98661-3801

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and Zip Code) 9A. AMENDMENT OF SOLICITATION NO.

X

69056723R000010

9B. DATED (SEE ITEM 11)

08/21/2025

10A. MODIFICATION OF CONTRACT/ORDER NO.

N/A

10B. DATED (SEE ITEM 13)

CODE: N/A FACILITY CODE: N/A

N/A

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

| X | The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

(__ ) is extended, ( x ) is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

N/A

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A THIS CHANGE ORDER IS ISSUED PURSUANT TO (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN

ITEM 10A.

N/A

B THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (Such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D OTHER (Specify type of modification and authority)

N/A

E. IMPORTANT: Contractor n/a is not, n/a is required to sign this document and return n/a copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements

See page 2

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15a. NAME AND TITLE OF SIGNER (Type or print) 15a. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

N/A

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY_________________________________________ BY N/A___________________________ N/A (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION NOT USABLE

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

Amendment No. A002, dated 09/20/2025 OR NPS CRLA 2018(1), Solicitation No. 69056723R000010 Cleetwood Trail and Marina Improvements

REVISIONS ARE AS FOLLOWS:

SF 1442, SOLICITATION, OFFER, AND AWARD (Pen & Ink change)

Page A-2, Physical Data. Revises language.

Page A-6, Block 24. Removes language.

SOLICITATION PROVISIONS

Page B-20, Technical Evaluation Factor 1. Revises language.

CONTRACT CLAUSES

Pages C-98 through C-99. Deletes FAR Clauses 52.236-1 Performance of Work by the

Contractor (Apr 1984), 52.236-2 Differing Site Conditions (Apr 1984), and 52.236-3 Site

Investigation and Conditions Affecting the Work (Apr 1984).

Page C-99a. Adds updated FAR Clause 52.236-2 Differing Site Conditions (AUG 2025)

& 52.236-3 Site Investigation and Conditions Affecting the Work (AUG 2025)

Pages C-105 through C-106. Deletes FAR Clause 52.243-4 Changes (June 2007).

Pages C-106a. Adds updated FAR Clause 52.243-4 Changes (Jul 2025)

Pages C-130 through C-131. Adds TAR Clause 1252.232-70 -- Electronic Submission of

Payment Requests (Nov 2022) [(DEVIATION Aug 2025)]

MINIMUM WAGE SCHEDULE

Page D-1 through D-22. Updates General Wage Decision Number OR20250001 effective

09/19/2025

SPECIAL CONTRACT REQUIREMENTS

Page E-3a, Subsection 102.02 and 102.02B. Adds additional language and subsection

Physical Data.

Page E-9, Subsection 104.05. Deletes reference to FAR Clause 52.236-4

Page E-18, Subsection 107.10. Deletes reference to FAR Clause 52.236-4

Page E-34, Subsection 151.01. Deletes reference to FAR Clause 52.236-4

Amendment No. A002, dated 09/20/2025 OR NPS CRLA 2018(1), Solicitation No. 69056723R000010 Cleetwood Trail and Marina Improvements

Page F-92, Subsection 645.01. Deletes reference to FAR Clause 52.236-4

ENCLOSURES

Pages:

A-2

A-6

B-20

C-98 through C-99a

C-106a

C-130 through C-131

D-1 through D-22

E-3a

E-9

E-18

E-34

F-92

A-2 according to Subsection 102.05A. The apparent low bidder will be determined by the lowest bid for the combined total of the Base and Option schedules.

Electronic Plan Sheets. This solicitation includes electronic plan sheets available at https://sam.gov/opp/1719177bca874e61a3e5758ecb999afa/view.

Viewing the Project: This project was pre-advertised in the Notice to Prospective bidders posted on https://sam.gov/opp/1719177bca874e61a3e5758ecb999afa/view dated September 16, 2024.

The project may be advertised during a period when viewing of the project may not be possible due to snow. Therefore, prospective Offerors were encouraged to view the project during fall as conditions permitted.

Site Visit: There will be an organized site visit on September 17, 2025. Participants will meet at

Cleetwood Cove Trail parking lot (coordinates: 42.980350°, -122.083332°) at 09:00am. All technical questions must be submitted to wfl.plans-spec@dot.gov; questions and answers will be publicly posted to this solicitation notice on SAM.gov. No questions will be answered during the site visit. Site visit attendees will be asked to sign-in, and the sign-in sheet will also be publicly posted to SAM.gov.

Physical Data. Physical data applicable to this project is listed in the Special Contract Requirements, Subsection 102.02B Physical Data.

Representations & Certifications. Submit or update Representations and Certifications online at https://www.sam.gov/SAM/ before bid submittal. For more details go to FAR Provision

52.204-8 Annual Representations and Certifications (see page B-2.). If you have previously registered on-line and the NAICS code for this solicitation is different than the code listed in your online file, please note the amended changes on the lines provided in FAR 52.204-8.

Requests for Information. Requests for technical information (Plan and Division 100 – 700

Specification questions only) about this project will only be accepted in writing (see Block 9 on page A-5).

Price Evaluation Factor. This solicitation contains a Price Evaluation Factor. In accordance with 13 CFR subsection 126.613, we will apply a factor of 10% to an apparent low bid submitted by a large business when we also receive a bid from a HUBZone small business;

the 10% factor does not apply to an apparent low bid submitted by a small business.

SF 1442, Solicitation, Offer, and Award. Particular attention should be paid to Standard Form l442, Solicitation, Offer and Award, to assure that Blocks 14, 15, 16, 19, 20A, and 20C are completed correctly. Sign Block 20B according to the instructions in Subsection 102.02.

You must submit a completed ‘Authority to Sign’ document. You must also complete the representations and certifications contained in the Contract Provisions beginning on page B-1. Failure to furnish or complete any of the above may result in your offers being considered nonresponsive and being rejected.

Notice to Offeror Revised by Amendment A001 & A002 Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements https://sam.gov/opp/1719177bca874e61a3e5758ecb999afa/view https://sam.gov/opp/1719177bca874e61a3e5758ecb999afa/view mailto:wfl.plans-spec@dot.gov https://www.sam.gov/SAM/

A-6

Continuation SF 1442

Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements

ADDITIONAL INFORMATION: See Subsections 102.03 and 102.04 of Standard

Specifications for Construction of Roads and Bridges on Federal Highway Projects, FP-

14, U.S. Customary Units.

Block 24 SUBMITTING INVOICES: See Subsection 109.08 of the Standard Specifications for

Construction of Roads and Bridges on Federal Highway Projects FP-14, U.S. Customary

Units.

The Contractor also affirms that it does not operate any diversity, equity, and inclusion

(DEI) initiatives that are inconsistent with the Equal Protection principles of the

Constitution and the non-discrimination requirements of Federal law, as interpreted by the Supreme Court in Students for Fair Admissions v. Harvard, 600 U.S. 181 (2023).

ESTIMATED PRICE RANGE. The price range of the project work is between $25,000,000 and

$35,000,000.

SUBCONTRACTING PLAN. This Request for Proposals requires an offeror who is a LARGE business to submit an acceptable subcontracting plan prior to contract award. A large business is one whose average gross annual receipts over the past 3 years equal $45 million or more. For your information the subcontracting plan form is included beginning on page A-6a. This requirement does not apply to SMALL businesses

Revised by Amendment A002 marino.chea Cross-Out

B-20

Offer Instructions

a. What do we submit? Submit all documents listed in the Offer checklist.

b. What technical document do we submit?

• Documentation demonstrating the elements have been met in accordance with

Technical Evaluation Factor 1.

• Documentation demonstrating the requirement has been met for Technical Evaluation

Factor 2.

• For Projects with no CPARS rating, submit past performance information made available by project owners.

• If no past performance information can be obtained, submit documentation demonstrating why it was not possible to obtain.

c. What are the minimum criteria for our technical rating?

TECHNICAL EVALUATION FACTOR 1 – PROPOSED PRIME CONTRACTOR

RECENT AND RELEVANT EXPERIENCE

Projects submitted for this factor must meet the requirements defined below and the contractor must have been the prime contractor for the project. Proposed subcontractors' experience may be used for Construction and Operational Elements.

Requirements:

Provide a brief narrative demonstrating how each of the following requirements have been met for a minimum of two and no more than seven projects:

• Completed after January 1st, 2019; AND

• Multi-year road construction project in excess of $15 million; AND

• At least 30% of the work performed under the contract shall have been self-performed by the offeror as the prime contractor. The percentage of work performed by the Contractor is computed as the cost of the contract work performed on-site by the Contractor’s employees divided by the total cost of the contract.; AND

• All of the Construction Elements and Operational Elements are collectively represented.

Projects that do not meet each of these minimum requirements will not be considered for Factor 1.

Individual projects do not need to contain all elements in all categories (i.e., Construction and

Operational); however, all elements in each category must be collectively demonstrated in projects that are eligible for consideration.

Construction Elements

Solicitation Provisions Revised by Amendment A002 Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements marino.chea Cross-Out

C-98

(d) If a stop-work order is not canceled and the work covered by the order is terminated for default, the Contracting Officer shall allow, by equitable adjustment or otherwise, reasonable costs resulting from the stop-work order.

(e) The Government’s rights to terminate this contract at any time are not affected by action taken under this clause.

(f) If, as the result of the Contractor’s intentional or negligent misstatement, misrepresentation, or miscertification, a protest related to this contract is sustained, and the Government pays costs, as provided in FAR 33.102(b)(2) or 33.104(h)(1), the Government may require the Contractor to reimburse the

Government the amount of such costs. In addition to any other remedy available, and pursuant to the requirements of Subpart 32.6, the Government may collect this debt by offsetting the amount against any payment due the Contractor under any contract between the Contractor and the Government.

52.233-4 Applicable Law for Breach of Contract Claim (Oct 2004)

United States law will apply to resolve any claim of breach of this contract.

52.236-1 Performance of Work by the Contractor (Apr 1984)

(NOTE: This clause does not apply when award is made to other than the low bidder after applying the price preference for HUBZone small business concerns under FAR clause 52.219-4, in which case the percentage in clause 52.219-14 will control).

The Contractor shall perform on the site, and with its own organization, work equivalent to at least fifty (50) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

52.236-2 Differing Site Conditions (Apr 1984)

(a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the

Contracting Officer of—

(1) Subsurface or latent physical conditions at the site which differ materially from those indicated in this contract; or

(2) Unknown physical conditions at the site, of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in the contract.

(b) The Contracting Officer shall investigate the site conditions promptly after receiving the notice. If the conditions do materially so differ and cause an increase or decrease in the Contractor’s cost of, or the time required for, performing any part of the work under this contract, whether or not changed as a result of the conditions, an equitable adjustment shall be made under this clause and the contract modified in writing accordingly.

(c) No request by the Contractor for an equitable adjustment to the contract under this clause shall be allowed, unless the Contractor has given the written notice required; provided, that the time prescribed in paragraph (a) of this clause for giving written notice may be extended by the Contracting Officer.

(d) No request by the Contractor for an equitable adjustment to the contract for differing site conditions shall be allowed if made after final payment under this contract.

52.236-3 Site Investigation and Conditions Affecting the Work (Apr 1984)

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including but not limited to (1) conditions bearing upon

Contract Clauses Revised by Amendment A002 Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements marino.chea Cross-Out marino.chea Cross-Out

C-99 transportation, disposal, handling, and storage of materials; (2) the availability of labor, water, electric power, and roads; (3) uncertainties of weather, river stages, tides, or similar physical conditions at the site; (4) the conformation and conditions of the ground; and (5) the character of equipment and facilities needed preliminary to and during work performance. The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by the Government, as well as from the drawings and specifications made a part of this contract. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(b) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

52.236-5 Material and Workmanship (Apr 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer’s approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer’s approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor’s expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the

Contracting Officer deems incompetent, careless, or otherwise objectionable.

52.236-6 Superintendence by the Contractor (Apr 1984)

At all times during performance of this contract and until the work is completed and accepted, the

Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

52.236-7 Permits and Responsibilities (Nov 1991)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State, and municipal laws, codes, Contract Clauses Revised by Amendment A002 Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements

C-99a

52.236-2 Differing Site Conditions (AUG 2025)

(a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the Contracting Officer of

(1) Latent physical conditions or subsurface conditions at the site which differ materially from those indicated in this contract; or

(2) Unknown physical conditions at the site, of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the contract.

(b) (1) The Contracting Officer will investigate the site conditions promptly after receiving such a notice.

(2) If the conditions materially so differ and cause an increase or decrease in the Contractor's cost of, or the time required for, performing any part of the work under this contract an equitable adjustment must be made under this clause.

(c) No request for an equitable adjustment to the contract under this clause will be allowed, unless the Contractor has given the written notice required.

(d) No request for an equitable adjustment to the contract for differing site conditions will be allowed if made after final payment under this contract.

52.236-3 Site Investigation and Conditions Affecting the Work (AUG 2025)

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including—

(1) Conditions bearing upon transportation, disposal, handling, and storage of materials

(2) The availability of labor, water, electric power, and roads;

(3) Uncertainties of weather, river stages, tides, or similar physical conditions at the site;

(4) The conformation and conditions of the ground; and

(5) The character of equipment and facilities needed preliminary to and during work performance.

(b) The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by the Government, as well as from the drawings and specifications made a part of this contract. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(c) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

Contract Clauses Revised by Amendment A002 Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements

C-105

(i) Made a reduced or untimely payment to the small business subcontractor; or

(ii) Failed to make a payment, which is now untimely.

(c) Content of notice. The Contractor shall include the reason(s) for making the reduced or untimely payment in any notice required under paragraph (b) of this clause.

52.242-13 Bankruptcy (July 1995)

In the event the contractor enters into proceedings relating to bankruptcy, whether voluntary or involuntary, the contractor agrees to furnish, by certified mail or electronic commerce method authorized by the contract, written notification of the bankruptcy to the contracting officer responsible for administering the contract. This notification shall be furnished within five days of the initiation of the proceedings relating to bankruptcy filing. This notification shall include the date on which the bankruptcy petition was filed, the identity of the court in which the bankruptcy petition was filed, and a listing of government contract numbers and contracting offices for all government contracts against which final payment has not been made. This obligation remains in effect until final payment under this contract.

52.242-14 Suspension of Work (Apr 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or

(2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the

Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the

Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

52.243-4 Changes (June 2007)

(a) The Contracting Officer may, at any time, without notice to the sureties, if any, by written order designated or indicated to be a change order, make changes in the work within the general scope of the contract, including changes—

(1) In the specifications (including drawings and designs);

(2) In the method or manner of performance of the work;

(3) In the Government-furnished property or services; or

(4) Directing acceleration in the performance of the work.

(b) Any other written or oral order (which, as used in this paragraph (b), includes direction, instruction, interpretation, or determination) from the Contracting Officer that causes a change shall be treated as a change order under this clause; Provided, that the Contractor gives the Contracting Officer written notice stating—

Contract Clauses Revised by Amendment A002 Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements

C-106

Project: OR NPS CRLA 2018(1), Cleetwood Trail and Marina Improvements

(1) The date, circumstances, and source of the order; and

(2) That the Contractor regards the order as a change order.

(c) Except as provided in this clause, no order, statement, or conduct of the Contracting Officer shall be treated as a change under this clause or entitle the Contractor to an equitable adjustment.

(d) If any change under this clause causes an increase or decrease in the Contractor’s cost of, or the time required for, the performance of any part of the work under this contract, whether or not changed by any such order, the Contracting Officer shall make an equitable adjustment and modify the contract in writing. However, except for an adjustment based on defective specifications, no adjustment for any change under paragraph (b) of this clause shall be made for any costs incurred more than 20 days before the Contractor gives written notice as required. In the case of defective specifications for which the

Government is responsible, the equitable adjustment shall include any increased cost reasonably incurred by the Contractor in attempting to comply with the defective specifications.

(e) The Contractor must assert its right to an adjustment under this clause within 30 days after

(1) receipt of a written change order under paragraph (a) of this clause or (2) the furnishing of a written notice under paragraph (b) of this clause, by submitting to the Contracting Officer a written statement describing the general nature and amount of the proposal, unless this period is extended by the

Government. The statement of proposal for adjustment may be included in the notice under paragraph (b) of this clause.

(f) No proposal by the Contractor for an equitable adjustment shall be allowed if asserted after final payment under this contract.

52.244-2 Subcontracts (Jun 2020)

(a) Definitions. As used in this clause-

“Approved purchasing system” means a Contractor’s purchasing system that has been reviewed and approved in accordance with part 44 of the Federal Acquisition Regulation (FAR).

“Consent to subcontract” means the Contracting Officer’s written consent for the Contractor to enter into a particular subcontract.

Subcontract means any contract, as defined in FAR subpart 2.1, entered into by a subcontractor to furnish supplies or services for performance of the prime contract or a subcontract. It includes, but is not limited to, purchase orders, and changes and modifications to purchase orders.

(b)When this clause is included in a fixed-price type contract, consent to subcontract is required only on unpriced contract actions (including unpriced modifications or unpriced delivery orders), and only if required in accordance with paragraph (c) or (d) of this clause.

(c)If the Contractor does not have an approved purchasing system, consent to subcontract is required for any subcontract that-

(1)Is of the cost-reimbursement, time-and-materials, or labor-hour type; or

(2)Is fixed-price and exceeds-

(i)For a contract awarded by the Department of Defense, the Coast Guard, or the National Aeronautics and Space Administration, the greater of the simplified acquisition threshold, as defined in FAR 2.101 on the date of subcontract award, or 5 percent of the total estimated cost of the contract; or

(ii)For a contract awarded by a civilian agency other than the Coast Guard and the National Aeronautics and Space Administration, either the simplified acquisition threshold, as defined in FAR 2.101 on the date of subcontract award, or 5 percent of the total estimated cost of the contract.

(d)If the Contractor has an approved purchasing system, the Contractor nevertheless shall obtain the

Contracting Officer’s written consent before placing the following subcontracts:

(e)

C-106a

52.243-4 Changes (Jul 2025)

(a)

(1) At any time, the Contracting Officer may issue a written order, identified as a change order, to make changes in the work within the scope of the contract, including changes—

(i) In the specifications (including drawings and designs);

(ii) In the method or manner of performance of the work;

(iii) In the Government-furnished property or services; or

(iv) Directing acceleration in the performance of the work.

(2) If there are any sureties, the Contracting Officer does not need to notify them of a written order.

(b) Any other written or oral order (which, as used in this paragraph (b), includes direction, instruction, interpretation, or determination) from the Contracting Officer that causes a change shall be treated as a change order under this clause; provided, that the Contractor gives the Contracting Officer written notice stating—

(1) The date, circumstances, and source of the order; and

(2) That the Contractor regards the order as a change order.

(c) Except as provided in this clause, no order, statement, or conduct of the Contracting Officer shall be treated as a change under this clause or entitle the Contractor to an equitable adjustment.

(d) If any change under this clause causes an increase or decrease in the Contractor's cost of, or the time required for, the performance of any part of the work under this contract, whether or not changed by any such order, the Contracting Officer shall make an equitable adjustment and modify the contract in writing.

However, except for an adjustment based on defective specifications, no adjustment for any change under paragraph (b) of this clause shall be made for any costs incurred more than 20 days before the Contractor gives written notice as required. In the case of defective specifications for which the Government is responsible, the equitable adjustment shall include any increased cost reasonably incurred by the Contractor in attempting to comply with the defective specifications.

(e)

(1) The Contractor must assert its right to an adjustment under this clause, by submitting to the Contracting Officer a written statement describing the general nature and amount of proposal within 30 days, unless this period is extended by the Government, after—

(i) Receipt of a written change order under paragraph (a) of this clause; or

(ii) The furnishing of a written notice under paragraph (b) of this clause.

(2) The statement of proposal for adjustment may be included in the notice under paragraph (b) of this clause.

(f) No proposal by the Contractor for an equitable adjustment shall be allowed if asserted after final payment under this contract.

C-130

1252.232-70 -- Electronic Submission of Payment Requests (Nov 2022) [(DEVIATION Aug 2025)]

(a) Definitions. As used in this clause—

(1) Contract financing payment has the meaning given in FAR 32.001.

(2) Payment request means a bill, voucher, invoice, or request for contract financing payment or invoice payment with associated supporting documentation. The payment request must comply with the requirements identified in FAR 32.905(b), “Content of Invoices,” this clause, and the applicable Payment clause included in this contract.

(3) Electronic form means an automated system transmitting information electronically according to the accepted electronic data transmission methods and formats identified in paragraph (c) of this clause.

Facsimile, email, and scanned documents are not acceptable electronic forms for submission of payment requests.

(4) Invoice payment has the meaning given in FAR 32.001.

(b) Electronic payment requests. Except as provided in paragraph (e) of this clause, the contractor shall submit payment requests in electronic form. Purchases paid with a Governmentwide commercial purchase card are considered to be an electronic transaction for purposes of this rule, and therefore no additional electronic invoice submission is required.

(c) Processing system. The Department of Transportation utilizes the DELPHI system for processing invoices. The DELPHI module for submitting invoices is called iSupplier. Access to DELPHI is granted with electronic authentication of credentials (name & valid email address) utilizing the GSA credentialing platform login.gov. Vendors submitting invoices are required to submit invoices via iSupplier (DELPHI) and authenticated via www.login.gov.

(d) Invoice requirements. To receive payment and in accordance with the Prompt Payment Act, all invoices submitted as attachments in iSupplier (DELPHI) shall contain the following:

(1) Invoice number and invoice date.

(2) Period of performance covered by invoice.

(3) Contract number and title.

(4) Task/Delivery Order number and title (if applicable).

(5) Amount billed (by CLIN), current and cumulative.

(6) Total ($) of billing.

(7) Cumulative total billed for all contract work to date.

(8) Name, title, phone number, and mailing address of person to be contacted in the event of a defective invoice.

(9) Travel. If the contract includes allowances for travel, all invoices which include charges pertaining to travel expenses will catalog a breakdown of reimbursable expenses with the appropriate receipts to substantiate the travel expenses.

[(10) The following statement “The Contractor certifies that, by submitting this invoice to the Government, the supplies and/or services billed have been shipped, rendered, or delivered in accordance with instructions issued by the ordering officer; that they are reflected in the quantities and/or period of performance stated on the invoice; and that such supplies and/or services conform to the quantity and quality requirements specified in the applicable contract, order, or blanket purchase agreement.

Furthermore, pursuant to Executive Order 14173, Ending Illegal Discrimination And Restoring Merit-Based Opportunity, the Contractor certifies that it is in compliance with the Equal Protection principles of the Constitution and all applicable Federal anti-discrimination laws, and acknowledges that such compliance is material to the Government’s payment decision under the False Claims Act (31 U.S.C.

§ 3729(b)(4)). The Contractor also affirms that it does not operate any diversity, equity, and inclusion (DEI) initiatives that are inconsistent with the Equal Protection principles of the Constitution and the non-discrimination requirements of Federal law, as interpreted by the Supreme Court in Students for Fair Admissions v. Harvard, 600 U.S. 181 (2023).”]

C-131

(e) Payment system registration. All persons accessing the iSupplier (DELPHI) will be required to have their own unique user ID and password and be credentialed through login.gov.

(1) Electronic authentication. See www.login.gov for instructions.

(2) To create a www.login.gov account, the user will need a valid email address and a working phone number. The user will create a password and then www.login.gov will reply with an email confirming the email address.

(3) iSupplier (DELPHI) registration instructions: New users should navigate to: http://einvoice.esc.gov to establish an account. Users are required to log in to iSupplier (DELPHI) every 45 days to keep it active.

(4) Training on DELPHI. To facilitate use of DELPHI, comprehensive user information is available at http://einvoice.esc.gov.

(5) Account Management. Vendors are responsible to contact their assigned COR when their firm's points of contacts will no longer be submitting invoices, so they can be removed from the system.

(f) Waivers. For contractors/vendors who are unable to utilize DOT's DELPHI system, waivers may be considered by DOT on a case-by-case basis. Vendors should contact their Contracting Officer's Representative (COR) for procedures.

(g) Exceptions and alternate payment procedures. If, based on one of the circumstances set forth in 1232.7002(a) or (b), and the contracting officer directs that payment requests be made by mail, the contractor shall submit payment requests by mail through the United States Postal Service to the designated agency office. If alternate payment procedures are authorized, the Contractor shall include a copy of the Contracting Officer's written authorization with each payment request. If DELPHI is succeeded by later technology, the Contracting Officer will supply the Contractor with the latest applicable electronic invoicing instructions.

(End of clause)

D - 1

General Wage Decision

Notice: On March 14, 2025 Executive Order 14026 was revoked. Contact U.S.

Department of Labor for further guidance.

Revised by Amendment A002

"General Decision Number: OR20250001 09/19/2025

Superseded General Decision Number: OR20240001

State: Oregon

Construction Type: Highway

Counties: Oregon Statewide.

HIGHWAY CONSTRUCTION PROJECTS

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(1).

|If the contract is entered |. Executive Order 14026 |

|into on or after January 30, | generally applies to the |

|2022, or the contract is | contract. |

|renewed or extended (e.g., an |. The contractor must pay |

|option is exercised) on or | all covered workers at |

|after January 30, 2022: | least $17.75 per hour (or |

| | the applicable wage rate |

| | listed on this wage |

| | determination, if it is |

| | higher) for all hours |

| | spent performing on the |

| | contract in 2025. |

|If the contract was awarded on|. Executive Order 13658 |

|or between January 1, 2015 and| generally applies to the |

|January 29, 2022, and the | contract. |

|contract is not renewed or |. The contractor must pay all|

|extended on or after January | covered workers at least |

|30, 2022: | $13.30 per hour (or the |

| | applicable wage rate listed|

| | on this wage determination,|

| | if it is higher) for all |

| | hours spent performing on |

| | that contract in 2025. |

D - 2

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the

Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/03/2025

1 01/10/2025

2 01/31/2025

3 02/28/2025

4 04/11/2025

5 06/27/2025

6 07/11/2025

7 07/25/2025

8 08/22/2025

9 08/29/2025

10 09/19/2025

BROR0001-031 06/01/2025

Rates Fringes

BRICKLAYER.......................$ 49.60 25.15

CARP0503-016 06/01/2025

Carpenters:

CARPENTERS..................$ 53.94 16.81

DIVER STANDBY...............$ 67.58 19.40

DIVERS TENDERS..............$ 60.34 19.40

DIVERS......................$ 103.21 19.40

MANIFOLD AND/OR

DECOMPRESSION CHAMBER

OPERATORS...................$ 65.34 19.40

MILLWRIGHTS.................$ 53.94 16.81

PILEDRIVERS.................$ 55.79 15.81

DEPTH PAY:

50 to 100 feet 2.00 per foot over 50 feet

101 to 150 feet 3.00 per foot over 50 feet

151 to 200 feet 4.00 per foot over 50 feet over 220 feet 5.00 per foot over 50 feet

D - 3

Zone Differential (Add to Zone A rates):

Zone B - $1.25

Zone C - 1.70

Zone D - 2.00

Zone E - 3.00

Zone F - 5.00

Zone G - 10.00

ZONE A - All jobs or projects located within 30 miles of the respective City Hall

ZONE B - More than 30 miles and less than 40 miles from the

ZONE C - More than 40 miles and less than 50 miles from the

ZONE D - More than 50 miles and less than 60 miles from the

ZONE E - More than 60 miles and less than 70 miles from the

ZONE F - More than 70 miles from the respective City Hall.

ZONE G - More than 100 miles from the respective City Hall.

BASEPOINTS CITIES FOR CARPENTERS (EXCLUDING MILLWRIGHTS AND

PILEDRIVERS)

ALBANY ASTORIA BAKER

BEND BROOKINGS BURNS

COOS BAY EUGENE

GOLDENDALE GRANTS PASS HERMISTON

HOOD RIVER KLAMATH FALLS LAGRANDE

LAKEVIEW LONGVIEW MADRAS

MEDFORD NEWPORT

ONTARIO PENDLETON

PORTLAND PORT ORFORD REEDSPORT

ROSEBURG SALEM

THE DALLES TILLAMOOK VANCOUVER

BASEPOINTS FOR MILLWRIGHTS

EUGENE NORTH BEND LONGVIEW

PORTLAND MEDFORD THE DALLES

VANCOUVER

BASEPOINTS FOR PILEDRIVERS

BEND EUGENE LONGVIEW

MEDFORD North Bend PORTLAND

D - 4

* ELEC0048-006 01/01/2025

CLACKAMAS, CLATSOP, COLUMBIA, HOOD RIVER, MULTNOMAH, TILLAMOOK,

WASCO, WASHINGTON, SHERMAN AND YAMHILL (NORTH) COUNTIES

CABLE SPLICER....................$ 69.85 30.44

ELECTRICIAN......................$ 63.50 29.73

HOURLY ZONE PAY:

Hourly Zone Pay shall be paid on jobs located outside of the free zone computed from the city center of the following listed cities:

Portland, The Dalles, Hood River, Tillamook, Seaside and

Astoria

Zone Pay:

Zone 1: 31-50 miles $1.50/hour

Zone 2: 51-70 miles $3.50/hour

Zone 3: 71-90 miles $5.50/hour

Zone 4: Beyond 90 miles $9.00/hour

*These are not miles driven. Zones are based on Delorrne

Street Atlas USA 2006 plus.

ELEC0112-001 06/01/2025

BAKER, GILLIAM, GRANT, MORROW, UMATILLA, UNION, WALLOWA, AND

WHEELER COUNTIES

CABLE SPLICER....................$ 63.00 27.87

ELECTRICIAN......................$ 60.00 27.78

ELEC0280-003 01/01/2025

BENTON, CROOK, DESCHUTES, JEFFERSON, LANE (EAST OF A LINE

RUNNING NORTH AND SOUTH FROM THE NORTHEAST CORNER OF COOS

COUNTY TO THE SOUTHEAST CORNER OF LINCOLN COUNTY), LINN,

MARION, POLK AND YAMHILL (SOUTHERN HALF) COUNTIES

CABLE SPLICER....................$ 60.80 22.24

ELECTRICIAN......................$ 56.46 23.05

D - 5

* ELEC0291-006 12/01/2024

MALHEUR COUNTY

CABLE SPLICER....................$ 46.81 19.86

ELECTRICIAN......................$ 42.55 19.86

* ELEC0659-004 01/01/2025

DOUGLAS (EAST OF A LINE RUNNING NORTH AND SOUTH FROM THE NE

CORNER OF COOS COUNTY TO THE SE CORNER OF LINCOLN COUNTY),

HARNEY, JACKSON, JOSEPHINE, KLAMATH AND LAKE COUNTIES

CABLE SPLICER....................$ 64.58 1.5%+22.34

ELECTRICIAN......................$ 45.58 20.70

ZONE PAY: BASE POINTS ARE FROM THE DOWNTOWN POST OFFICE IN

GRANTS PASS, KLAMATH FALLS, ROSEBURG AND MEDFORD.

ZONE 1: 0-20 MILES $0.00 PER HOUR

ZONE 2: > 20-30 MILES $1.50 PER HOUR

ZONE 3: >30-40 MILES $3.30 PER HOUR

ZONE 4: >40-50 MILES $5.00 PER HOUR

ZONE 5: >50-60 MILES $6.80 PER HOUR

ZONE 6: >60 MILES $9.50 PER HOUR

*THESE ARE NOT MILES DRIVEN. zONES ARE BASED ON DELORNE

STREET ATLAS USA 5.0.

ELEC0932-004 01/01/2024

COOS, CURRY, LINCOLN, DOUGLAS AND LANE COUNTIES (AREA LYING

WEST OF A LINE NORTH AND SOUTH FROM THE N.E. CORNER OF COOS

COUNTY TO THE S.E. CORNER OF LINCOLN COUNTY)

ELECTRICIAN......................$ 50.03 24.00

ENGI0701-005 01/01/2024

ZONE 1:

POWER EQUIPMENT OPERATORS (See Footnote C)

D - 6

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 56.66 16.90

GROUP 1A....................$ 58.82 16.90

GROUP 1B....................$ 60.98 16.90

GROUP 2.....................$ 54.75 16.90

GROUP 3.....................$ 53.60 16.90

GROUP 4.....................$ 50.27 16.90

GROUP 5.....................$ 49.03 16.90

GROUP 6.....................$ 45.81 16.90

Zone Differential (add to Zone 1 rates):

Zone 2 - $3.00

Zone 3 - $6.00

For the following metropolitan counties: MULTNOMAH;

CLACKAMAS; MARION; WASHINGTON; YAMHILL; AND COLUMBIA;

CLARK; AND COWLITZ COUNTY, WASHINGTON WITH MODIFICATIONS AS

INDICATED:

All jobs or projects located in Multnomah, Clackamas and

Marion Counties, West of the western boundary of Mt. Hood

National Forest and West of Mile Post 30 on Interstate 84 and West of Mile Post 30 on State Highway 26 and West of

Mile Post 30 on Highway 22 and all jobs or projects located in Yamhill County, Washington County and Columbia County and all jobs or porjects located in Clark & Cowlitz County, Washington except that portion of Cowlitz County in the Mt.

St. Helens ""Blast Zone"" shall receive Zone I pay for all classifications.

All jobs or projects located in the area outside the identified boundary above, but less than 50 miles from the

Portland City Hall shall receive Zone II pay for all

All jobs or projects located more than 50 miles from the

Portland City Hall, but outside the identified border above, shall receive Zone III pay for all classifications.

For the following cities: ALBANY; BEND; COOS BAY; EUGENE;

GRANTS PASS; KLAMATH FALLS; MEDFORD; ROSEBURG

All jobs or projects located within 30 miles of the respective city hall of the above mentioned cities shall receive Zone I pay for all classifications.

All jobs or projects located more than 30 miles and less than

50 miles from the respective city hall of the above mentioned cities shall receive Zone II pay for all

D - 7

All jobs or projects located more than 50 miles from the respective city hall of the above mentioned cities shall receive Zone III pay for all classifications.

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

Group 1

Concrete Batch Plan and or Wet mix three (3) units or more

Crane, Floating one hundred and fifty (150) ton but less than two hundred and fifty (250) ton.

Crane, two hundred (200) ton through two hundred ninety-nine

(299) ton with two-hundred-foot (200?) boom or less

(including jib, inserts and/or attachments)

Crane, ninety (90) ton through one hundred ninety-nine (199) ton with over two hundred (200?) boom Including jib, inserts and/or attachments)

Crane, Tower Crane with one hundred seventy-five-foot (175?)

tower or less and with less than two-hundred-foot (200?) jib

Crane, Whirley ninety (90) ton and over Helicopter when used in erecting work

Tunnel Boring Machine

Tunnel, Micro Boring Tunnel Machine

Group 1A

Crane, floating two hundred fifty (250) ton and over

Crane, two hundred (200) ton through two hundred ninety-nine

(299) ton, with over two-hundred-foot (200?) boom

(including jib, inserts and/or attachments)

Crane, three hundred (300) ton through three hundred ninety-nine (399) ton

Crane, Tower Crane with over one hundred seventy-five-foot

(175?) tower or over two hundred foot (200?) jib

Crane, tower Crane on rail system or 2nd tower or more in work radius

Group 1B

Crane, three hundred (300) ton through three hundred ninety-nine (399) ton, with over two hundred- foot (200?)

boom (including jib, inserts and/or attachments)

Floating crane, three hundred fifty (350) ton and over

Crane, four hundred (400) ton and over

Group 2

Asphalt Plant (any type)

Asphalt Roto-Mill, pavement profiler eight foot (8?) lateral cut and over

Auto Grader or ?Trimmer?

Blade, Robotic

Bulldozer, Robotic Equipment (any type)

Bulldozer, over one hundred twenty thousand (120,000) lbs.

and above

Canal Trimmer

D - 8

Concrete Batch Plant and/or Wet Mix one (1) and two (2) drum

Concrete Canal Liner Operator

Concrete Diamond Head Profiler

Concrete, Automatic Slip Form Paver

Crane, Boom Truck fifty (50) ton and with over one hundred fifty-foot (150?) boom and over

Crane, Floating (derrick barge) thirty (30) ton but less than one hundred fifty (150) ton

Crane, Cableway twenty-five (25) ton and over

Crane, Floating Clamshell three (3) cu. Yds. And over

Crane, ninety (90) ton through one hundred ninety-nine (199) ton up to and including two hundred- foot (200?) boom

(including jib inserts and/or attachments)

Crane, fifty (50) ton through eighty-nine (89) ton with over one hundred fifty-foot (150?) boom

(including…