Amendment_0003_to_P16PS00660.pdf

(x)

P16PS00660

x x

7 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

PDS

Denver CO 80225-0287 P.O. Box 25287 12795 W. Alameda Pkwy NPS, DSC Contracting Services Div

JEFF 199869B09/12/2016000003

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

08/22/2016

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

JEFF 199869B

Jefferson National Expansion Memorial

JEFF Museum Exhibits

Please refer to Attachment #1 for the purpose of Amendment 0003.

The proposal deadline remains Thursday, October 6, 2016 at 3:00pm Mountain Time (MT) as stated in Amendment 0002. The question deadline remains Tuesday, September 27, 2016 at

3:00pm Mountain Time (MT) as stated in Amendment 0002.

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Jason Longshore

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

JEFF 199869B

Museum Exhibits

P16PS00660 / Amendment 0003 Attachment #1

09/12/2016

The purposes of Amendment 0003 are to:

1) Delete and replace the RFP document in its entirety due to the below listed changes in the clauses and provisions.

2) Delete the following provisions and clauses:

a. Clause 52.211‐10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR

1984)

b. Clause 52.211‐13 TIME EXTENSION (SEPT 2000)

c. Clause 52.215‐10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA

(AUG 2011)

d. Clause 52.215‐11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA –

MODIFICATIONS (AUG 2011)

e. Clause 52.215‐12 SUBCONTRACTOR CERTIFED COST OR PRICING DATA (OCT 2010)

f. Clause 52.215‐13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA – MODIFICATIONS

(OCT 2010)

g. Clause 52.215‐15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

h. Clause 52.215‐18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS

(PRB) OTHER THAN PENSIONS (JUL 2005)

i. Clause 52.215‐19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

j. Clause 52.219‐4 NOTICE OF PRICE EVALUATION FOR HUBZONE SMALL BUSINESS CONCERNS

(OCT 2014)

k. Clause 52.219‐9 SMALL BUSINESS SUBCONTRACTING PLAN (OCT 2015) ALTERNATE II (OCT

2001) from the RFP document.

l. Clause 52.219‐16 LIQUIDATED DAMAGES ‐ SUBCONTRACTING PLAN (JAN 1999) from the RFP document.

m. Provision 52.222‐23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE

EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

n. Clause 52.222‐27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION

(APR 2015)

o. Clause 52.225‐11 BUY AMERICAN‐CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS

(FEB 2016)

p. Provision 52.225‐12 NOTICE OF BUY AMERICAN REQUIRMENT – CONSTRUCTION MATERIALS

UNDER TRADE AGREEMENTS (MAY 2014)

q. Clause 52.227‐4 PATENT INDEMNITY – CONSTRUCTION CONTRACTS (DEC 2007)

r. Clause 52.228‐12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (MAY 2014)

s. Clause 52.228‐14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

t. Clause 52.232‐5 PAYMENTS UNDER FIXED‐PRICE CONSTRUCTION CONTRACTS (MAY 2014)

u. Clause 52.232‐27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (MAY 2014)

v. Clause 52.236‐1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

P16PS00660 / Amendment 0003

w. Clause 52.236‐2 DIFFERING SITE CONDITIONS (APR 1984)

x. Clause 52.236‐3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

y. Clause 52.236‐4 PHYSICAL DATA (APR 1984)

z. Clause 52.236‐5 MATERIAL AND WORKMANSHIP (APR 1984)

aa. Clause 52.236‐6 SUPERINTENDANCE BY THE CONTRACTOR (APR 1984)

bb. Clause 52.236‐7 PERMITS AND RESPONSIBILITIES (NOV 1991)

cc. Clause 52.236‐8 OTHER CONTRACTS (APR 1984)

dd. Clause 52.236‐9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS (APR 1984)

ee. Clause 52.236‐10 OPERATIONS AND STORAGE AREAS (APR 1984)

ff. Clause 52.236‐11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

gg. Clause 52.236‐12 CLEANING UP (APR 1984)

hh. Clause 52.236‐13 ACCIDENT PREVENTION ALT I (NOV 1991)

ii. Clause 52.236‐14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

jj. Clause 52.236‐15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

kk. Clause 52.236‐17 LAYOUT OF WORK (APR 1984)

ll. Clause 52.236‐21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

mm. Clause 52.236‐26 PRECONSTRUCTION CONFERENCE (FEB 1995)

nn. Provision 52.236‐27 SITE VISIT (CONSTRUCTION) (FEB 1995)

oo. Clause 52.242‐14 SUSPENSION OF WORK (APR 1984)

pp. Clause 52.243‐4 CHANGES (JUN 2007)

qq. Clause 52.246‐12 INSPECTION OF CONSTRUCTION (AUG 1996)

rr. Clause 52.246‐21 WARRANTY OF CONSTRUCTION (MAR 1994)

ss. Clause 52.248‐3 VALUE ENGINEERING – CONSTRUCTION (OCT 2015)

tt. Clause 52.249‐2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED‐PRICE) ‐

ALTERNATIE I (APR 2012 ‐ SEPT 1996)

uu. Clause 52.249‐10 DEFAULT (FIXED‐PRICE CONSTRUCTION) (APR 1984)

vv. Section G.3 DIAPR 2010‐14 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM

(JUL 2010)

ww. Section G.4 DIAPR 2011‐4 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS

INTERNET PAYMENT PLATFORM (APR 2013)

xx. Section H.1 OPTION FOR ADDITIONAL SERVICES ‐ SEPARATELY PRICED LINE ITEMS

P16PS00660 / Amendment 0003

3) Add the following provisions and clauses:

a. Clause 52.217‐7 OPTION FOR INCREASED QUANTITY – SEPARATELY PRICED LINE ITEM (MAR

1989)

b. Provision 52.222‐24 PREAWARD ON‐SITE EQUAL OPPORTUNITY COMPLIANCE EVALUATION

(FEB 1999)

c. Clause 52.227‐3 PATENT INDEMNITY (APR 1984)

d. Clause 52.232‐1 PAYMENTS (APR 1984).

e. Clause 52.232‐25 PROMPT PAYMENT (JUL 2013).

f. Provision 52.237‐1 SITE VISIT (APR 1984)

g. Clause 52.237‐2 PROTECTION OF GOVERNMENT BUILDINGS , EQUIPMENT, AND

VEGETATION (APR 1984)

h. Clause 52.242‐17 GOVERNMENT DELAY OF WORK (APR 1984).

i. Clause 52.243‐1 CHANGES – FIXED PRICE (AUG 1987) ALTERNATE II (APR 1984)

j. Clause 52.246‐2 INSPECTION OF SUPPLIES (FIXED –PRICE) (AUG 1996)

k. Clause 52.248‐1 VALUE ENGINEERING (OCT 2010)

l. Clause 52.249‐2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED‐PRICE)

(APR 2012)

m. Clause 52.249‐8 DEFAULT (FIXED‐PRICE SUPPLY AND SERVICE) (APR 1984)

n. DOI‐AAAP‐0028 (JUN 2015) ELECTRONIC INVOICING AND PAYMENT REQUIRMENTS

INTERNET PAYMENT PLATFORM (APR 2013).

o. DOI‐AAAP‐0050 (FEB 2015) CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM

(DEC 2015).

4) Item No. 9 SUBCONTRACTING PLAN from Section L. Volume II ‐ BUSINESS AND PRICE PROPOSAL in the RFP document. A subcontracting plan is not a requirement.

5) Delete and replace Volume II Submission Package in its entirety. The Subcontracting Plan form has been removed from the solicitation requirements.

6) Incorporate Attachment O ‐ JEFF MWE Contract #1 Building Construction Drawings and

Specifications (for reference only). Please note the included documents do not comprise a current and complete set of Contract #1 (JEFF Visitor Center) Drawings and Specifications and should not be assumed to be such. These documents are provided for reference only and are not to be used for pricing purposes.

7) Provide contractor questions and government response.

The proposal deadline remains Thursday, October 6, 2016 at 3:00pm Mountain Time (MT) as stated in

Amendment 0002. The question deadline remains Tuesday, September 27, 2016 at 3:00pm Mountain

Time (MT) as stated in Amendment 0002.