36C24619B0039-001.docx

36C24619B0039

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE

DOCUMENTS (

Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C24619B0039 X 08-16-2019

TBD

TBD

652-319 Department of Veterans Affairs Network Contracting Office 6 1201 Broad Rock Blvd Richmond VA 23249 Department of Veterans Affairs Network Contracting Office 6 1201 Broad Rock Blvd Richmond VA 23249

MARK S. HARVILLE

804.675.5841 Project Title: Construct New Clinical Lab #652-319. H.H. McGuire VAMC, Richmond, Virginia.

Project Description: The Department of Veterans Affairs is seeking the services of a qualified Service Disabled Veteran Owned Small Business construction firm to provide all labor, material, transportation, equipment and qualified supervision required to perform construction services required to complet the above-referenced project.

Project site is located at the Hunter Holmes McGuire VA Medical Center, 1201 Broad Rock Blvd., Richmond, VA 23249.

All work shall be performed in accordance with the construction drawings and specifications.

Please refer to the Scope of Work, Specifications and Drawings for additional information on the project requirements.

X 52.211-10 X (0 ) zero 2:30 pm 09-13-2019 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

See Bid Items List on Page 3 for further details.

Department of Veterans Affairs Network Contracting Office 6 1201 Broad Rock Blvd Richmond VA 23249 Department of Veterans Affairs Financial Services Center P.O. Box 149971 Austin TX 78714-9971

Table of Contents

CONSTRUCT NEW CLINICAL LAB

VAMC RICHMOND

PROJECT NO. 652-319

SOLICITATION NO. 36C24619B0039

LIST OF BID ITEMS : Bidders shall affix price the each of the following bid item(s) . Failure to do so shall be grounds for rejection of the bid as non-responsive. Award shall be made to that responsible bidder whose bid, conforming to the invitation for bids, will be the most advantageous to the Government, considering only price and price-related factors included in the invitation.

1. Bid Item #1 (Base Bid): The base bid shall include all work shown in the drawings and specifications inclusive of all work shown as deductive bid work. Work includes general construction, structural systems, earthwork, alterations, plumbing, mechanical and electrical work, fire protection, data and utility systems, asbestos abatement, necessary removal of existing structures and construction and certain other items. The existing hospital must remain in operation throughout construction. CHANGE FROM DRAWINGS: the roof anchors & railing, 7 of the 13 PAC’s, and white PVC construction fence have all been deleted. Construction area will still require a chain link fence. Completion Time: 680 days

BID Item 1 (Base Bid) $___________________________________

2. Bid Item #2 (Deduct Alternate 1): Contractor shall perform all work as described in Bid Item 1 except the following: Delete the generator, site work and any related installation; Delete guard rail installed on roof. Completion Time: 660 days

BID Item 2 (Deduct Alternate 1) $__________________________

3. Bid Item #3 (Deduct Alternate 2): Contractor shall perform all work as described in Bid Item 2 except the following: Delete moveable partition system between the corridor C3F-2 and chemistry lab 3F-106F; Delete window shades; Delete operable partition between the breakroom 3F-112 and the conference room 3F-113; Delete the metal sun shade; Delete signage; Delete PAC system per AI601 door schedule; Delete security cameras model ADC610-M1110; Delete final flooring and provide sealed concrete only within the lab. Completion Time: 650 days

BID Item 3 (Deduct Alternate 2) $__________________________

4. Bid Item #4 (Deduct Alternate 3): Contractor shall perform all work as described in Bid Item 3 except: Delete the space savers from the clean supply 3F-131 and archive 3F-124 rooms. Completion Time: 640 days

BID Item 4 (Deduct Alternate 3) $__________________________

5. Bid Item #5 (Deduct Alternate 4): Contractor shall perform all work as described in Bid Item 4 except: Delete all the interior partitions and finishes for rooms 3F-101, 3F-103, 3F-105, 3F-105A, 3F-107, 3F-112 and 3F-113. Completion Time: 610 days

BID Item 5 (Deduct Alternate 4) $__________________________

6. Bid Item #6 (Deduct Alternate 5): Contractor shall perform all work as described in Bid Item 5: Delete all the interior partitions and finishes for rooms C3F-3, 3F-114, 3F-115, 3F-116, 3F-117, 3F-118, 3F-119, 3F-120, 3F-121, 3F-122 and 3F-123. Completion Time: 580 days

BID Item 6 (Deduct Alternate 5) $__________________________

7. Bid Item #7 (Deduct Alternate 6): Contractor shall perform all work as described in Bid Item 6 except the following: Delete all the interior partitions and finishes for the corridor C3F-2 and rooms 3F-108, 3F-109, 3F-110 and 3F-111 but keep plumbing rough-ins. Completion Time: 550 days.

BID Item 7 (Deduct Alternate 6) $__________________________

8. Bid Item #8 (Deduct Alternate 7): Contractor shall perform all work as described in Bid Item 7 except: Delete the installation of the pneumatic tube system. Completion Time: 545 days

BID Item 8 (Deduct Alternate 7) $__________________________

9. 9. Bid Item #9 (Deduct Alternate 8): Contractor shall perform all work as described in Bid Item 8 except the following: Delete Lab refrigerator; Delete relocation of autoclave; Delete new roof storm drainage overflow piping and instead provide perimeter roof scupper drainage; Delete removal of second floor storm drainage piping and abandon instead.

Completion Time: 530 days

BID Item 9 (Deduct Alternate 8) $__________________________

10. Bid Item #10 (Deduct Alternate 9): Contractor shall perform all work as described in Bid Item 9 except the following: Delete penthouse, change both AHU 57 & 58 from interior to exterior type units; Delete all Tie-in finishes between existing building and new lab area, but new doors and opening stay as still required. Completion Time: 510 days

BID Item 10 (Deduct Alternate 9) $__________________________

11. Bid Item #11 (Deduct Alternate 10): Contractor shall perform all work as described in Bid Item 10 except: Delete the chiller unit, but installation of the new hydronic piping still required. Completion Time: 500 days

BID Item 11 (Deduct Alternate 10) $__________________________

CONSTRUCT NEW CLINICAL LAB

VAMC RICHMOND

PROJECT NO. 652-319

SOLICITATION NO. 36C24619B0039

SCOPE OF WORK

The Department of Veterans' Affairs is seeking the services of a qualified Service Disabled Veteran Owned Small Business construction company to provide all labor, material, transportation, equipment and qualified supervision required for the “Construct New Clinical Lab for Surgical Expansion” project #652-319 located at the H.H. McGuire VA Medical Center, 1201 East Broad Rock Boulevard, Richmond, Virginia, 23249.

In general, the project is a partial renovation and an addition to the existing medical center building of approximately 18,050 square feet. The work shall be performed in strict accordance with construction drawings and specifications prepared by AES Group, Inc., and completed within 680 calendar days from receipt of the Notice to Proceed. This includes final Inspection and cleanup.

The NAICS code for this project is 236220 with a small business size standard of $36.5 million. The estimated construction cost is between $5,000,000 and $10,000,000. This procurement is 100% set-aside for Service-Disabled, Veteran-Owned Small Business (SDVOSB). Offers are solicited only from SDVOSB concerns and offers received from concerns that are not from SDVOSB concerns shall not be considered.

Page 1 of Page 1 of

INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE AND BONDS

(a) If the bid/offer exceeds $150,000, a bid guarantee is required in an amount not less than twenty (20) percent of the bid/offer price or $3M, whichever is less.

(b) Bidders are reminded that an acceptable Bid Guarantee MUST be received with the bid/offer before the bid opening. Failure to furnish a properly executed bid guarantee in the proper form and amount, with original signature(s) and embossed with the surety corporate seal, by the time set for opening of bids/offers, will require rejection of the bid/offer in all cases except those listed in Federal Acquisition Regulation (FAR) 28.101-4, and may be cause for rejection even then.

For guidance, Bidders/Offerors are referred to FAR provision 52.228-1, BID GUARANTEE (SEP 1996) in the solicitation, FAR Part 28.101 Bid Guarantees, and FAR Part 28.2 Sureties and Other Security for Bonds. Corporate sureties offered for bonds must appear on the list contained in the Department of Treasury Circular 570, “Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and Acceptable Reinsuring Companies, ” See http://www.fms.treas.gov/c570/c570.html

(c) If the contract will exceed $30,000 but will not exceed $150,000, the bidder/offeror to whom award is made will be required to furnish a Payment Bond, Standard Form 25A, or alternative payment protection.

(d) If the contract will exceed $150,000, the bidder/offeror to whom award is made shall be required to furnish a Payment Bond, Standard Form 25A, and a Performance Bond, Standard Form 25. Copies of the Standard Forms 25A and 25 may be obtained upon application to the Issuing Office.

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

SUBMISSION OF BIDS

The bidder shall submit the following in response to this Invitation for Bids:

1. A completed and signed Standard Form 1442.

1. A completed copy of the Representations and Certifications (See FAR 52.204-8 Annual Representations and Certifications (MAR 2012)).

1. A fully executed bid bond.

1. Documentation of their safety record.

1. All forms and/or certifications as directed in the solicitation, including the specifications.

SAFETY AND ENVIRONMENTAL RECORD: In order to be eligible for consideration and award, the contractor shall have no more than three serious, or one repeat, or one willful OSHA or EPA violation(s) in the past 3 years and have an Experience Modification Rate (EMR) of equal to or less than 1.0.

All Bidders/Offerors shall submit the following information pertaining to their past Safety and Environmental record with their bid.

1. A self-certification on company letterhead that the bidder has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years. Bidders shall submit copies of their OSHA logs (OSHA Form 300A) for the past three years with their bid. If the firm has been in business for less than three years, they shall submit copies of their OSHA logs for the period of time they have been in business.

1. Information regarding their current Experience Modification Rate (EMR) equal to or less than 1.0. This information shall be obtained from the bidder’s/offeror’s insurance company and be furnished on the insurance carrier’s letterhead.

Self-insured contractors or other contractors that cannot provide their EMR rating on insurance letterhead must obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self-insured contractors or other contractors that cannot provide EMR rating on insurance letterhead from the states or territories of CA, DE, MI, NJ, ND, OH, PA, WA, WY, and PR shall obtain their EMR rating from their state run worker’s compensation insurance rating bureau.

DESCRIPTION OF WORK: See SCOPE OF WORK and BID ITEM LIST

COST RANGE: $ 5,000,000.00 - $10,000,000.00

NAICS: The NAICS Code for this procurement is 236220, Commercial and Institutional Construction, with a maximum small business size standard of $36.5 million.

COMPLETION TIME: 680 calendar days from receipt of the Notice to Proceed. This includes final Inspection and cleanup.

SDVOSB SET-ASIDE: Effective June 20, 2007, Public Law 109-461, the Veterans Benefits, Health Care, and Information Technology Act of 2006 allow procurements to be set-aside for SDVOSBs and VOSBs. This procurement is 100% set-aside for Service-Disabled, Veteran-Owned Small Business (SDVOSB). Bids are solicited only from SDVOSB concerns and bids received from concerns that are not SDVOSB concerns shall be rejected. In order to be considered, the firm must be registered on the U.S. Department of Veteran Affairs VIP website (https://www.vip.vetbiz.va.gov/) as a SDVOSB at the time of submission of their bid. No award will be made to a bidder that is not registered.

SECURITY REQUIREMENTS: VA Handbook 5400.3 requirements for Certification and Accreditation of the contractor’s computer system (if used) do not apply to this acquisition. If the contractor opts to use a computer or computer system for processing of contract documents, the requirements of FIPS 140-2 for encryption of contract documents must be met.

PLANS/DRAWINGS/SPECIFICATIONS: Drawings and specifications are attached in electronic format to this solicitation. Offerors are responsible for downloading and printing their own bid sets. The VA will not provide hard copies of the drawings and specifications to any offeror. Contractors are responsible for ensuring that any construction document package used for bidding or construction is complete and up-to-date.

METRIC PRODUCTS: Products manufactured to metric dimensions will be considered on an equal basis with those manufactured using inch-pound units, providing they fall within the tolerances specified using conversion tables and contained in the latest revision of Federal Standard No. 376, and all other requirements of this document are met.

If a product is manufactured to metric dimensions and those dimensions exceed the tolerances specified in inch-pound units, a request should be made to the Contracting Officer, in writing, to determine if the product is acceptable. The Contracting Officer, in concert with the Contracting Officer’s Representative (COR), will accept or reject the product.

CONTRACTOR RESPONSIBILITY: Contractor shall be required to complete all contract work and schedule a final inspection within the specified contract performance period. Should the Contractor fail to complete the contract work (including scheduling of the final inspection), and it is determined by the Government to be a Contractor-caused delay, the Contractor shall be in default status. If the Government determines it to be in the best interest of the Government to allow the Contractor to continue to perform contract work, the Contractor shall provide equitable consideration to the Government for additional time granted for completion of contract work. Such agreement shall not be deemed a waiver of the Government’s right to terminate this contract in the event the Contractor fails to complete the contract work (including scheduling of the final inspection) on or before the completion date.

TRAINING: Effective July 1 2005, all employees of the general contractor and subcontractors shall have the 10-hour OSHA certified construction safety course and/or other relevant competency training, as determined by the COTR with input from the ICRA (Infection Control Risk Assessment) team. The General Contractor’s competent person shall have completed the 30-hour OSHA certified construction safety course. Documentation of training shall be submitted to the Contracting Officer for review and approval prior to any work being performed. No ID badge will be issued to an employee who does not provide this documentation. There shall be no exceptions to this requirement.

TUBERCULOSIS (TB) TESTING: It is the responsibility of the contractor to provide TB training annually and a PPD test annually for any employee(s) providing services at Hunter Holmes McGuire VAMC, Richmond, Virginia. The Government reserves the right to review the contractor’s records.

PRE-BID CONFERENCE: A pre-bid conference has been scheduled for August 26, 2019, at 2:00 p.m. in the main medical center (Bldg. 500), 2nd Floor, Room 2K-115; Hunter Holmes McGuire VA Medical Center, Richmond, VA. This pre-bid conference will be the only opportunity for potential bidders to visit the site. All potential bidders, subcontractors, and suppliers are strongly encouraged to attend this pre-bid conference.

NOTE: ALL QUESTIONS OR REQUESTS FOR INFORMATION (RFI’S) REGARDING THIS SOLICITATION MUST BE SUBMITTED VIA E-MAIL TO THE CONTRACTING OFFICER: (mark.harville@va.gov); NO TELEPHONE QUESTIONS WILL BE RESPONDED TO. ALSO, DO NOT CONTACT THE ARCHITECT-ENGINEER OR VA RICHMOND ENGINEERING DIRECTLY. DEADLINE FOR RECEIPT OF BIDDER QUESTIONS IS 4:00 PM (EST), August 30, 2019. RESPONSES TO RFI’S RECEIVED BY THE DEADLINE WILL BE ISSUED AS PART OF AMENDMENTS TO THE ORIGINAL SOLICITATION.

KEYS: All keys provided the Contractor for use during the project shall be returned to the Contracting Officer's Representative (COR) at completion of the work or upon request. No keys shall be reproduced by the Contractor. There shall be a charge of $10.00 for each key that is lost or not returned to the COR. Payment shall be made to the Hunter Holmes McGuire VA Medical Center, Richmond, Virginia upon receipt of a Bill of Collection.

PREPARATION OF BIDS/OFFERS/PROPOSALS: Bidders are responsible for any and all costs incurred for the preparation and submission of bids or proposals.

PRIVACY AND CONFIDENTIALITY: Contractors to the Department of Veteran Affairs may be unintentionally exposed to sensitive information. Information may be overheard, seen on documents or electronic devices, or observed that could potentially violate the privacy and confidentiality of our veterans, employees, volunteers, and their families. Regulations such as, but not limited to the Health Insurance Portability and Accountability Act of 1996 (HIPAA), Freedom of Information Act (FOIA) and Privacy Act of 1974 have been enacted to protect sensitive information from being improperly disclosed. Information should not be divulged or released to anyone unless specifically authorized by this contract or its’ attached documents in accordance with the contracted services. Failure to comply with applicable statutes and regulation can result in the termination of this contract and civil and criminal penalties, including fines and imprisonment. All suspected or actual breeches of privacy and confidentiality should be reported immediately to the Contracting Officer, Contracting Officer’s Representative (COR) or the Facility Privacy Officer.

The C&A requirements do not apply and a Security Accreditation Package is not required. If the contractor opts to use a computer or computer system for processing contract documents, the requirements of FIPS 140-2 for encryption of contract documents must be met.

VETS 100: Title 38, USC Section 4212(d) and Public Law 105-339, requires that federal contractors report, at least annually, the number and category of veterans who are within their workforce. Submission of the VETS 100 reporting information can be done electronically at: http://vets100.cudenver.edu. Award cannot be made unless the awardee has filed their VETS 100 report; therefore, all bidders/offerors are encouraged to file every year.

SYSTEM FOR AWARD MANAGEMENT (SAM): Federal Acquisition Regulations require that federal contractors register in the System for Award Management (SAM) database at http://www.sam.gov and enter all mandatory information into the system. Award cannot be made until the contractor has registered. Bidders are encouraged to ensure that they are registered in SAM prior to submitting their bid

1.1 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price, Requirements contract resulting from this solicitation.

(End of Provision)

1.2 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014) (a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

1.3 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

RICHMOND, VIRGINIA

(End of Provision)

1.4 52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of Provision)

1.5 52.233-2 SERVICE OF PROTEST (SEP 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

MARK S. HARVILLE

Hand-Carried Address:

Department of Veterans Affairs Contracting Office Network Contracting Office 6 1201 Broad Rock Blvd Richmond VA 23249

Mailing Address:

Department of Veterans Affairs Contracting Office Network Contracting Office 6 1201 Broad Rock Blvd Richmond VA 23249

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

1.6 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for—

8/26/2019 AT 3:00PM LOCAL TIME

(c) Participants will meet at—

ROOM 2K-113, 2ND FLOOR, VAMC RICHMOND

(End of Provision)

1.7 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

(End of Provision)

1.8 VAAR 852.211-72 TECHNICAL INDUSTRY STANDARDS (NOV 2018)

(a) The Contractor shall conform to the standards established by: UNDERWRITERS LABORATORIES NFPA LIFE SAFETY CODE 101 as to in accordance with construction industry standards.

(b) The Contractor shall submit proof of conformance to the standard. This proof may be a label or seal affixed to the equipment or supplies, warranting that the item(s) have been tested in accordance with the standards and meet the contract requirement. Proof may also be furnished by the organization listed above certifying that the item(s) furnished have been tested in accordance with and conform to the specified standards.

(c) Offerors may obtain the standards cited in this provision by submitting a request, including the solicitation number, title and number of the publication to: UNDERWRITERS LABORATORIES

(d) The offeror shall contact the Contracting Officer if response is not received within two weeks of the request.

1.9 VAAR 852.228-72 ASSISTING SERVICE-DISABLED VETERAN-OWNED AND VETERAN-OWNED SMALL BUSINESSES IN OBTAINING BONDS (DEC 2009) Prime contractors are encouraged to assist service-disabled veteran-owned and veteran-owned small business potential subcontractors in obtaining bonding, when required. Mentor firms are encouraged to assist protégé firms under VA's Mentor-Protégé Program in obtaining acceptable bid, payment, and performance bonds, when required, as a prime contractor under a solicitation or contract and in obtaining any required bonds under subcontracts.

(End of Clause)

1.10 VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE RESOLUTION (OCT 2018)

(a) Any protest filed by an interested party shall—

(1) Include the name, address, fax number, email and telephone number of the protester;

(2) Identify the solicitation and/or contract number;

(3) Include an original signed by the protester or the protester’s representative and at least one copy;

(4) Set forth a detailed statement of the legal and factual grounds of the protest, including a description of resulting prejudice to the protester, and provide copies of relevant documents;

(5) Specifically request a ruling of the individual upon whom the protest is served;

(6) State the form of relief requested; and

(7) Provide all information establishing the timeliness of the protest.

(b) Failure to comply with the above may result in dismissal of the protest without further consideration.

(c) Bidders/offerors and Contracting Officers are encouraged to use alternative dispute resolution (ADR) procedures to resolve protests at any stage in the protest process. If ADR is used, the Department of Veterans Affairs will not furnish any documentation in an ADR proceeding beyond what is allowed by the Federal Acquisition Regulation.

(End of Provision)

1.11 VAAR 852.233-71 ALTERNATE PROTEST PROCEDURE (OCT 2018)

(a) As an alternative to filing a protest with the Contracting Officer, an interested party may file a protest by mail or electronically with: Executive Director, Office of Acquisition and Logistics, Risk Management and Compliance Service (003A2C), Department of Veterans Affairs, 810 Vermont Avenue NW, Washington, DC 20420 or Email: EDProtests@va.gov.

(b) The protest will not be considered if the interested party has a protest on the same or similar issue(s) pending with the Contracting Officer.

(End of Provision) PLEASE NOTE: The correct mailing information for filing alternate protests is as follows:

Or for solicitations issued by the Office of Construction and Facilities Management:

REPRESENTATIONS AND CERTIFICATIONS

3.1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[X](i) 52.204-17, Ownership or Control of Offeror.

[X](ii) 52.204-20, Predecessor of Offeror.

[](iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[](iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[](v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Certification.

[](vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

[](vii) 52.227-6, Royalty Information.

[](A) Basic.

[](B) Alternate I.

[](viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

3.2 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision— "Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission…