W912WJ21B0017.pdf

CODE

(Hour)

PAGE(S)

until 01:00 PM local time 18 Aug 2021

A X B X C

D

EX

X G F 34 - 39

40 - 41 X H 42 heather.skorik@usace.army.mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA FAR (48 CFR) 53.214(c)

1 42

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

W912WJ 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

HEATHER SKORIK 978-318-8040

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

2 - 5

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT

PACKAGING AND MARKING

6 J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 9 - 12 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIONS AND INSTRUCTIONS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

13 - 33

PART II - CONTRACT CLAUSES

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.5. DATE ISSUED

16 Jul 2021

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

W912WJ21B0017

Section B - Supplies or Services and Prices

BID SCHEDULE

BIDDING SCHEDULE

Refer to Section 01 22 00 MEASUREMENT AND PAYMENT Item Estimated Unit Estimated No. Description Quantity Unit Price Amount

BASE BID ITEMS

0001 Site Preparation and Restoration 1 Job Job $ 0002 Excavate Outfall 08 (OF-08) 1 Job Job $ 0003 Service Contract Reporting Formerly known as Contractor Manpower Reporting Application 1 Job Job $________

TOTAL ESTIMATED AMOUNT BASE BID $

Optional Item

0004 Off-Site Disposal (RCRA D Disposal Facility)

0004AA First 5,000 Tons 5,000 Ton $ $

0004AB Over 5,000 Tons 16,000 Ton $ $

TOTAL ESTIMATED AMOUNT, OPTIONAL BID ITEMS $

TOTAL ESTIMATED AMOUNT, OPTIONAL AND BASE ITEMS $

Note 1: Contractors identify a point of contact e-mail for all correspondence related to this bid: @ .

Note 2: Item Number 0004 is an Optional Line item that may, at the option of the Government, be exercised within 240 days after contract is awarded.

If awarded, 90 days will be added to the contract.

Note 3: Item Number 0004 above is subdivided into two estimated quantities and shall be separately priced. The Government will evaluate these items on the basis of the total price of their sub-items. (AFARS 5152.211-9001 Variations in Estimated Quantities -- Subline Items).

BID OPENING

VIRTUAL BID OPENING SOLICITATION INSTRUCTIONS

Due to COVID-19 health concerns, bids submitted in response to this solicitation will be submitted electronically. The bid opening will be conducted via a telephone conference call that is open to the public.

Electronic Bid Submission

WHAT - Bids shall be submitted electronically, as described. The bid shall not contain classified data. The use of hyperlinks in bids is prohibited.

NOTE: The only authorized transmission method for bids in response to this solicitation is electronically via SAFE online submission. NO OTHER TRANSMISSION METHODS (EMAIL, FACSIMILE, REGULAR

MAIL, HAND CARRIED, ETC.) WILL BE ACCEPTED.

WHEN - Bids must be submitted not later than one (1) hour before the time designated for bid opening.

Bids submitted after the bid submission time will be considered late bids.

THE BID SUBMISSION TIME IS 1:00 PM Eastern Time.

Bids must be received by the Government by the date/time specified in the solicitation.

HOW - Bidders shall electronically send their bids using the following link:

https://safe.apps.mil/

WHO - The SAFE site will require contacts for bid submission to be provided. All requests for information and the bid submission must be sent to BOTH of the below contacts to ensure timely receipt of bids.

Please use the following contact information to submit bids:

Contract Specialist Heather Skorik at Heather.Skorik@usace.army.mil

Contracting Officer Erin Bradley at Erin.E.Bradley@usace.army.mil

BIDDERS MUST REQUEST AN UPLOAD LINK: Bidders must e-mail the Contract Specialist and Contracting Officer no later than five (5) working days prior to the bid opening date to receive a request link which will allow for file uploads via the SAFE site. Bidders that fail to request a link at least five (5) working days before bid opening date may not be able to receive a request link in time to upload their bids.

SUBMISSION FORMAT: Submission shall be in Adobe PDF format. You are limited to five (5) maximum files per upload (total size cannot exceed 2GB). If you have a large number of files, recommend that you combine or ZIP your files before uploading to the SAFE site. Bidders may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

BID GUARANTEE: This solicitation requires submission of a bid guarantee in accordance with FAR 52.228-1. Electronic bid submissions must include a scanned copy of the original bid guarantee. The original bid guarantee with “wet” signature and raised seal (if applicable) must be mailed or delivered to the below and received by the bid opening time and date:

Bid Opening Official – Contracting Division U.S. Army Corps of Engineers 696 Virginia Road Concord, MA 01742

Minor discrepancies in receipt of the original bid guarantee due to COVID-19 related impacts may be waived solely at the discretion of the Contracting Officer. For example, there are guards who are stationed at the 696 Virginia Road location who can take receipt of guarantees. If no guard is available to sign for packages at the time of delivery and a package is not delivered, the Contracting Officer may allow for delayed delivery of the original bid guarantee. A scanned copy of the original bid guarantee must be included in the electronic bid submission for the bid to be considered responsive.

FILE DESCRIPTION: Include a “File Description” for each file you upload. The “File Description” will be included in the e-mail notice to each of the recipients you choose to have access your file(s). NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.

INSTRUCTIONS TO FOLLOW ON THE SAFE WEBSITE:

1. Once at the SAFE website, select the “Drop-off” icon. This allows users without a Common Access Card (CAC, an ID issued to certain Government users), or users whose computer is not configured to read a CAC the option to access the SAFE site as a guest.

2. After selecting the “Click Here” link, you will be prompted to add your personal information, file information, recipient (Government points of contact) information and e-mail settings.

3. When completing your file information, you will be required to enter the email addresses for all recipients. For this solicitation, the recipients are the Contract Specialist and the Contracting Officer, listed above. Although the email address of the Government employee who initiated the request link will be automatically entered, this address may not be correct. The Bidder must enter and add the e-mail addresses for both the Contracting Officer and Specialist listed above to the Recipient List. The Bidder can enter an additional e-mail address if desired. After entering the e-mail address, click the ADD button to add the e-mail to the “Recipients List” for your response. When your bid is submitted, a notification will be sent to the selected recipients.

NOTE: Do NOT send the SAFE site packages to group e-mail accounts.

Even if you successfully upload your bid to the SAFE site, notification will not be sent to the Government recipients until you verify your e-mail address. Entering an incorrect e-mail may result in the rejection of your submission for lateness. A Bidder can confirm proper submission by the ‘Drop-Off Completed” screen which generates based on proper file submission.

NOTE: It has been reported that documents are more quickly uploaded into the SAFE website when using a Firefox web browser. The Government cannot verify that this is true and offers no guarantee that Bidders will have more success utilizing any particular browser.

TIMELINES OF BIDS:

For the purposes of establishing whether a bid submission is considered timely, the Government considers the date and time the submission is completely uploaded into the SAFE website. For bids larger than the 2GB capacity of the SAFE website and require multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the SAFE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases.

The Government will not be responsible for bids delivered to any location or to anyone other than those designated to receive bids. Bidders are responsible for ensuring that bids are submitted so as to reach the designated recipient. Bidders are responsible for allowing sufficient time for the bid to be received in accordance with the instructions provided.

Bid Opening

Bids will be opened one hour after the time for bid submission noted above. This one hour delay is necessary to allow for technical delays. The Bid Opening Official or Contract Specialist may open electronic documents before the bid opening to prepare for the bid opening, but will not record or communicate bid prices with any other individual until the bid opening. No Government officials will open electronic documents until the independent government estimate is finalized and received by the Bid Opening Official.

THE BID OPENING TIME IS 2:00 PM Eastern Time.

The bid opening will be conducted via public conference call. Bidders and members of the public may use the below information to access the conference call:

Call In Info: 1-844-800-2712 or 669-234-1177

Access Code: 199 273 2405

During the bid opening, the Bid Opening Official will read the bid totals in the order received electronically.

The Bid Opening Official will then read the total amount of the independent government estimate and announce the apparent low bidder. If requested, the Bid Opening Official may read the line item prices of the apparent low bidder. The Contract Specialist will record the bid opening results, which will be posted to www.SAM.gov as quickly as practicable following the bid opening.

In accordance with FAR 14.402-1(c), interested persons may examine the bids after the bid opening.

Interested persons may contact the Contract Specialist identified above following the bid opening to request an electronic copy of the bid(s). Please be considerate of limited Government resources and request bid copies only as necessary.

To preserve conference line stability, bidders are asked to limit the number of individual calls to the conference line to the minimum needed for participation. The bid opening will proceed as scheduled even if individual bidders or members of the public are not able to access the telephone line at the bid opening time. Any interested party may access the results of the bid opening on www.SAM.gov shortly after the bid opening.

Section C - Descriptions and Specifications

INFORMATION FOR BIDDERS

The period of performance is 375 calendar days from contract award.

The following are attached and considered part of the contract documents:

Drawings, titled “Outfall 008 Remediation Stratford Army Engine Plant Stratford, Connecticut” dated 6/11/2021 Specifications, titled “Environmental Remediation of Outfall 008 Stratford Army Engine Plant Stratford, Connecticut” dated June 2021

Section E - Inspection and Acceptance

CLAUSES INCORPORATED BY FULL TEXT

52.246-4 INSPECTION OF SERVICES--FIXED-PRICE (AUG 1996)

(a) Definitions. "Services," as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires.

(c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by reperformance, the Government may (1) require the Contractor to take necessary action to ensure that future performance conforms to contract requirements and (2) reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may (1) by contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Government that is directly related to the performance of such service or (2) terminate the contract for default.

(End of clause)

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984

Section H - Special Contract Requirements

AT OPSEC

4. Suspicious Activity Reporting Training: The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

15. Pre-screen candidates using E-Verify Program: The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/everify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award." *When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative.

This Form will be provided to the Contracting Officer and shall become part of the official contract file.

VETERAN'S INFO

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222‐38, FAR Clause 52.222‐35, FAR Clause 52.222‐37, DFARS 222.13 and Department of Labor regulations, U.S.

Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set‐ aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veterans Affairs–VOW to Hire Heros Act http://benefits.va.gov/vow/ Army Wounded Warrior Program – http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation–Hiring Our Heros http://www.hiringourheroes.org/ Guide to Hiring Veterans – Reference Material http://www.whitehouse.gov/sites/default/files/docs/white_house_business_council_- _guide_to_hiring_veterans_0.pdf

CONTRACTOR PERFORMANCE

CONTRACTOR PERFORMANCE EVALUATIONS (CPARS)

In accordance with the provisions of Subpart 36.201 (Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction Contractor's performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement.

For service contracts awarded at or above $1,000,000.00, the USACE will evaluate contractor's performance annually and at completion and prepare a performance report using the Contractor

Performance Assessment Reporting System (CPARS), which is now a web based system. After an evaluation (interim or final) is written up by the USACE, the Contractor will have the ability to access, review and comment on the evaluation for a period of 60 days.

Accessing and using CPARS typically requires specific software, called PKI certification, which is installed on the user's computer. However, although users are encouraged to use PKI certificates whenever possible, a waiver has been approved to allow industry users to access the system without a PKI certificate. Contractors wishing to log on without a PKI certificate should select the "Contractor (pending PKI)" logon option. The certification is a Department of Defense item and was implemented to provide security in electronic transactions.

The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.navy.mil/ . If the Contractor wishes to participate in the performance evaluation process, access to CPARS and PKI certification is the sole responsibility of the Contractor.

CONTRACTOR MANPOWER REPORTING

REPORTING OF CONTRACTOR MANPOWER DATA ELEMENTS

(a) Scope. The following sets forth contractual requirements for reporting of contractor labor work year equivalents (also called Contractor Man-year Equivalents (CMEs)) in support of the Army, pursuant to 10 U.S.C.

129a, 10 U.S.C. 2461(g), Section 343 of P.L. 106-65, and 32 CFR 668. Reporting shall be accomplished electronically by direct contractor submission to the System for Award Management site, SAM.gov. Information on the background, purposes, and significance of this reporting requirement, and the 32 CFR 668 Final Rule as published in the Federal Register, can be found at this Web Site. The Army’s objective is to collect as much significant CME data as possible to allow accurate reporting to Congress and for effective Army planning. The reporting data elements should not be viewed as an “all or nothing” requirement. Even partial reporting, e.g., direct labor hours, appropriation data, place of performance, Army customer, etc., will be helpful.

(b) Applicability. This reporting requirement applies to certain services covered by Federal Supply Class or Service codes for “Research and Development,” and “Other Services and Construction” which are over $3M.

Report submissions shall not contain classified information. (Also see “Exemptions” at (d) below.)

(c) Requirements. The contractor is required to report the following contractor manpower information, associated with performance of this contract action in support of Army requirements, for all covered contracts, using SAM.gov. (Other information requirements associated with the manpower data collection (contract and task or delivery order numbers; appropriation data and amounts; total estimated value of contract; federal supply class or service code; major Army organizational element receiving or reviewing work; beginning and ending data for reporting period; place of performance; name, address, and point of contact for contractor; etc.) are specified and explained at the web site).

(1) Labor Hours. Composite direct labor hours, and the value of those indirect labor hours plus compensation related costs for direct labor hours ordinarily included in the indirect pools1.

(2) Rates. Alternatively, contractors may report two distinct, relevant (annualized) composite or average indirect labor rates in lieu of raw indirect labor hours and the value of those indirect hours. Such rates shall be annualized average estimates for the reporting contractor and need not be developed for each reporting period.

Either method chosen should be consistently reported.

1 Compensation costs are defined in the reporting instructions at the Army Web Site.

(d) Exemption(s). If the contractor is unable to comply with these reporting requirements without creating a whole new cost allocation system or system of records (such as a payroll accounting system), or due to similar insurmountable practical or economic reasons, the contractor may claim an exemption to at least a portion of the reporting requirement by certifying in writing to the contracting officer the clear underlying reason(s) for exemption from the specified report data element(s), and further certifying that they do not otherwise have to provide the exempted information, in any form, to the United States Government. The “self-exemption” will apply to all contract actions involving the contractor and will be reviewed and approved by the Deputy Assistant Secretary of the Army (Procurement), in coordination with the Deputy Assistant Secretary of the Army (Force Management and Resources), whose decision is final in this matter.

(e) Uses and Safeguarding of Information. The information submitted will be treated as contractor proprietary when associated with a contractor name of contract number.

(f) Subcontract Data. The contractor shall ensure that all reportable subcontract data is timely reported to the data collection web site (citing this contract/order number). At the discretion of the prime contractor, this reporting may be done directly by subcontractors to the data collection site; or by the prime contractor after consolidating and rationalizing all significant data from their subcontractors.

(g) Report schedule. The contractor is required to report the required information to the web site annually.

The reporting period will be from the beginning of the period of performance until 30 September of each government fiscal year, not to exceed 12 months and must be reported by 31 October of each calendar year.

(h) Reporting Flexibility. Contractors are encouraged to communicate with the Help Desk identified at the data collection web site to resolve reporting difficulties. Changes to facilitate reporting may be authorized by the contracting officer or the Help Desk (under HQDA policy direction and oversight).

WEATHER DELAYS

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSE entitled “DEFAULT (FIXED-PRICE SUPPLY AND SERVICE).” In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied.

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The UNUSUALLY severe weather must actually cause a delay to the completion of the project.

The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor’s progress schedule must reflect these anticipated adverse weather delays in all-weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS

BASED ON 5-DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEPT OCT NOV DEC

9 8 6 3 2 2 2 2 2 4 6 8

c. Upon contract award and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s scheduled work day. The number of actual adverse weather delay days shall include days impacted by weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled “DEFAULT (FIXED PRICE SUPPLY AND SERVICE).”

Section I - Contract Clauses

INSURANCE REQUIRED

52.236-4004 INSURANCE REQUIRED

In accordance with CONTRACT CLAUSE titled “INSURANCE – WORK ON A GOVERNMENT INSTALLATION” the Contractor shall procure and maintain during the entire period of his performance under this contract the following kinds and minimum amounts of insurance:

TYPE AMOUNT

Workmen’s Compensation and Employers’ Not less than $100,000 Liability Insurance The Contractor shall comply with all applicable Workmen’s Compensation Statutes and shall furnish evidence of Employers’ Liability Insurance.

General Liability Insurance Minimum limits of Bodily injury liability insurance on the $500,000 per accident comprehensive form of policy.

Automobile Liability Insurance Minimum limits of damage liability insurance on the $200,000 per person and comprehensive form of policy and shall $500,000 per accident cover the operation of all automobiles $20,000 per accident used in performance of the contract. For property damage

SPECIFICATIONS AND DRAWINGS

(a) The Contractor shall, within fivedays after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

SCHEDULES FOR CONTRACTS

(a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be promptly submitted to the Contracting Officer, who shall promptly make a determination in writing. Any adjustment by the Contractor without such a determination shall be at its own risk and expense. The Contracting Officer shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided.

(b) Wherever in the specifications or upon the drawings the words "directed," "required," "ordered," "designated," "prescribed," or words of like import are used, it shall be understood that the "direction," "requirement," "order," "designation," or "prescription," of the Contracting Officer is intended and similarly the words "approved," "acceptable," "satisfactory," or words of like import shall mean "approved by," or "acceptable to," or "satisfactory to" the Contracting Officer, unless otherwise expressly stated.

(c) Where "as shown," "as indicated," "as detailed," or words of similar import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word "provided" as used herein shall be understood to mean "provide complete in place," that is "furnished and installed."

(d) Shop drawings means drawings, submitted to the Government by the Contractor, subcontractor, or any lower tier subcontractor pursuant to a contract, showing in detail (1) the proposed fabrication and assembly of structural elements, and (2) the installation (i.e., fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials furnished by the contractor to explain in detail specific portions of the work required by the contract. The Government may duplicate, use, and disclose in any manner and for any purpose shop drawings delivered under this contract.

(e) If this contract requires shop drawings, the Contractor shall coordinate all such drawings, and review them for accuracy, completeness, and compliance with contract requirements and shall indicate its approval thereon as evidence of such coordination and review. Shop drawings submitted to the Contracting Officer without evidence of the Contractor’s approval may be returned for resubmission. The Contracting Officer will indicate an approval or disapproval of the shop drawings and if not approved as submitted shall indicate the Government’s reasons therefor.

Any work done before such approval shall be at the Contractor’s risk. Approval by the Contracting Officer shall not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from responsibility for complying with the requirements of this contract, except with respect to variations described and approved in accordance with (f) of this clause.

(f) If shop drawings show variations from the contract requirements, the Contractor shall describe such variations in writing, separate from the drawings, at the time of submission. If the Contracting Officer approves any such variation, the Contracting Officer shall issue an appropriate contract modification, except that, if the variation is minor or does not involve a change in price or in time of performance, a modification need not be issued.

(g) The Contractor shall submit to the Contracting Officer for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. Three sets (unless otherwise indicated) of all shop drawings, will be retained by the Contracting Officer and one set will be returned to the Contractor.

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-13 Contractor Code of Business Ethics and Conduct JUN 2020 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

JUN 2020

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

JUN 2020

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding JUN 2020 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

JUN 2020

52.214-28 Subcontractor Certified Cost Or Pricing Data--Modifications- -Sealed Bidding

JUN 2020

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.219-8 Utilization of Small Business Concerns OCT 2018 52.222-3 Convict Labor JUN 2003 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-41 Service Contract Labor Standards AUG 2018 52.222-44 Fair Labor Standards And Service Contract Labor Standards-

Price Adjustment

MAY 2014

52.222-50 Combating Trafficking in Persons OCT 2020 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 NOV 2020 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-14 Rights in Data--General MAY 2014 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-1 Payments APR 1984 52.232-8 Discounts For Prompt Payment FEB 2002 52.232-11 Extras APR 1984 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-25 Prompt Payment JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation

APR 1984

52.242-13 Bankruptcy JUL 1995 52.243-1 Alt I Changes--Fixed Price (Aug 1987) - Alternate I APR 1984 52.244-5 Competition In Subcontracting DEC 1996 52.244-6 Subcontracts for Commercial Items NOV 2020 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-8 Default (Fixed-Price Supply & Service) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General AUG 2019 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2021

252.204-7020 NIST SP 800-171 DoD Assessment Requirements NOV 2020 252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.225-7048 Export-Controlled Items JUN 2013 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JAN 2021 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $1,835.00 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default--Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default--Fixed-Price Supply and Service clause in this contract.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within the period of peformance. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.219-14 LIMITATIONS ON SUBCONTRACTING (MAR 2020)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Applicability. This clause applies only to--

(1) Contracts that have been set aside for small business concerns or 8(a) participants;

(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants;

(3) Orders set aside for small business concerns or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F); and

(4) Orders issued directly to small business concerns or 8(a) participants under multiple-award contracts as described in 19.504(c)(1)(ii).

(c) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of the contract in the case of a contract for--

(1) Services (except construction). At least 50 percent of the cost of contract performance incurred for personnel shall be expended for employees of the concern.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies). The concern shall perform work for at least 50 percent of the cost of manufacturing the supplies, not including the cost of materials.

(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.

(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees.

(d) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraph (b)(1) and (2) of this clause--

[Contracting Officer check as appropriate.]

X By the end of the base term of the contract and then by the end of each subsequent option period; or

___ By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (b)(3) and (4) of this clause, by the end of the performance period for the order.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (NOV 2020)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of…