AMENDMENT 0009 SPEC DOCUMENT FOR VOL 4 OF 7 (PKG 5).pdf

Super Hornet, Pkg 5, Organizational Level Maint Hangar, Kuwait 480569

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK -- REVISED BY AMENDMENT NO. 0009

01 14 00 WORK RESTRICTIONS

01 15 00.12 10 SUPPLEMENTARY REQUIREMENTS -- REVISED BY AMENDMENT NO.

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 17.12 10 COST-LOADED NETWORK ANALYSIS SCHEDULES (NAS)

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS -- REPLACED BY AMENDMENT

NO. 0009

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 42 15 METRIC MEASUREMENTS

01 45 00.00 10 QUALITY CONTROL -- REVISED BY AMENDMENT NO. 0009

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS -- REVISED

BY AMENDMENT NO. 0009

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 58 00 PROJECT IDENTIFICATION

01 78 00 CLOSEOUT SUBMITTALS -- DELETED BY AMENDMENT NO. 0009

01 78 00.49 CLOSEOUT SUBMITTALS -- ADDED BY AMENDMENT NO. 0009

01 78 23 OPERATION AND MAINTENANCE DATA

01 91 00.15 10 TOTAL BUILDING COMMISSIONING REVISED BY AMENDMENT NO. 0004

DIVISION 03 - CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

03 44 00 REINFORCED AUTOCLAVE AERATED CONCRETE PANELS

03 52 00 LIGHTWEIGHT CONCRETE ROOF INSULATION

DIVISION 04 - MASONRY

04 20 00 UNIT MASONRY

DIVISION 05 - METALS

05 12 00 STRUCTURAL STEEL

05 21 00 STEEL JOIST FRAMING

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 00 METAL STAIRS

05 51 33 METAL LADDERS

05 52 00 METAL RAILINGS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 41 16.00 10 PLASTIC-LAMINATE-CLAD ARCHITECTURAL CABINETS

06 61 16 SOLID SURFACING FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 05 23 PRESSURE TESTING AN AIR BARRIER SYSTEM FOR AIR TIGHTNESS

07 21 13 BOARD AND BLOCK INSULATION

07 27 10.00 10 BUILDING AIR BARRIER SYSTEM

07 27 19.01 SELF-ADHERING AIR BARRIERS

PROJECT TABLE OF CONTENTS Page 1

W912ER21R0025 AMENDMENT 0009

07 27 26 FLUID-APPLIED MEMBRANE AIR BARRIERS

07 41 63 FABRICATED ROOF PANEL ASSEMBLIES

07 42 63 FABRICATED WALL PANEL ASSEMBLIES

07 52 00 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 55 00 PROTECTED MEMBRANE ROOFING

07 60 00 FLASHING AND SHEET METAL

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 11 16 ALUMINUM DOORS AND FRAMES

08 31 00 ACCESS DOORS AND PANELS

08 33 13 COILING COUNTER DOORS

08 34 02 BULLET-RESISTANT COMPONENTS (FOR GUARDHOUSE)

08 34 16.10 STEEL SLIDING HANGAR DOORS

08 34 16.11 STEEL SLIDING CORROSION CONTROL HANGAR PLENUM DOORS

08 34 19 INDUSTRIAL STEEL SLIDING DOORS

08 34 59 VAULT DOORS AND DAY GATES

08 41 13 ALUMINUM-FRAMED ENTRANCES AND STOREFRONTS

08 51 13 ALUMINUM WINDOWS-- REVISED BY AMENDMENT NO. 0003

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL WALL LOUVERS

DIVISION 09 - FINISHES

09 22 00 SUPPORTS FOR PLASTER

09 24 23 INTERIOR CEMENT STUCCO

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 62 38 STATIC-CONTROL FLOORING

09 65 00 RESILIENT FLOORING

09 66 16 TERRAZZO FLOOR TILE

09 67 23.14 CHEMICAL RESISTANT RESINOUS FLOORING

09 67 23.16 FUEL RESISTIVE RESINOUS FLOORING, 5-COAT SYSTEM

09 84 20 ACOUSTICAL WALL PANELS

09 90 00 PAINTS AND COATINGS

DIVISION 10 - SPECIALTIES

10 14 00.10 EXTERIOR SIGNAGE

10 14 00.20 INTERIOR SIGNAGE

10 22 39 FOLDING PANEL PARTITIONS

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

10 51 13 METAL LOCKERS

10 56 13 STEEL SHELVING

10 81 13 BIRD CONTROL DEVICES

DIVISION 11 - EQUIPMENT

11 72 13 MEDICAL EQUIPMENT, MISCELLANEOUS

DIVISION 12 - FURNISHINGS

12 24 13 ROLLER WINDOW SHADES

PROJECT TABLE OF CONTENTS Page 2

12 36 00 COUNTERTOPS

12 48 13 ENTRANCE FLOOR MATS AND FRAMES

12 50 00.13 10 FURNITURE AND FURNITURE INSTALLATION

DIVISION 13 - SPECIAL CONSTRUCTION

13 26 00 CORROSION CONTROL HANGAR COMPONENTS AND ACCESSORIES

13 34 16 METAL CANOPY SYSTEM

13 34 17 PEDESTRIAN CANOPY SYSTEM

13 34 19 METAL BUILDING SYSTEMS

13 48 00 SEISMIC BRACING FOR MISCELLANEOUS EQUIPMENT

DIVISION 21 - FIRE SUPPRESSION

21 13 13.00 11 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

21 13 24.00 10 AQUEOUS FILM-FORMING FOAM (AFFF) FIRE PROTECTION SYSTEM

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 07 19 PLUMBING PIPING INSULATION

22 15 14 GENERAL SERVICE COMPRESSED-AIR SYSTEMS, LOW PRESSURE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 05 48.19 SEISMIC BRACING FOR HVAC

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC REVISED BY AMENDMENT

NO. 0003

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 23 00 REFRIGERANT PIPING

23 30 00 HVAC AIR DISTRIBUTION

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT -- REVISED BY

AMENDMENT NO. 0003

23 81 29 VARIABLE REFRIGERANT FLOW HVAC SYSTEMS

DIVISION 25 - INTEGRATED AUTOMATION

25 05 11.01 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

25 05 11.02 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS: FIRE

AND LIFE SAFETY SYSTEMS

DIVISION 26 - ELECTRICAL

26 05 19.10 10 INSULATED WIRE AND CABLE REVISED BY AMENDMENT NO. 0008

26 05 26.00 40 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS

26 05 48.00 10 SEISMIC PROTECTION FOR ELECTRICAL EQUIPMENT

26 20 00 INTERIOR DISTRIBUTION SYSTEM REVISED BY AMENDMENT NO. 0008

26 24 13 SWITCHBOARDS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 35 43 400/60-HERTZ (HZ) SOLID STATE FREQUENCY CONVERTER

26 41 00 LIGHTNING PROTECTION SYSTEM

26 51 00 INTERIOR LIGHTING

26 52 00.00 40 EMERGENCY LIGHTING -- ADDED BY AMENDMENT NO. 0003

26 53 00.00 40 EXIT SIGNS -- ADDED BY AMENDMENT NO. 0003

26 56 00 EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

PROJECT TABLE OF CONTENTS Page 3

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 10 05 ELECTRONIC SECURITY SYSTEMS (ESS)--REVISED BY AMENDMENT

NO. 0003

28 31 64.00 11 FIRE DETECTION AND ALARM SYSTEM, ADDRESSABLE -- REVISED

BY AMENDMENT NO. 0003

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

32 11 23 AGGREGATE BASE COURSES FOR ROADS AND AIRFIELDS

32 12 13 BITUMINOUS TACK AND PRIME COATS

32 12 15.13 ASPHALT PAVING FOR AIRFIELDS

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 14.13 CONCRETE PAVING FOR AIRFIELDS AND OTHER HEAVY DUTY

PAVEMENTS

32 17 23 PAVEMENT MARKINGS

32 31 13 CHAIN LINK FENCES AND GATES

DIVISION 33 - UTILITIES

33 01 50 HIGH LEVEL AND LEAK DETECTION SYSTEM ADDED BY AMENDMENT

NO. 0008

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 30 00 SANITARY SEWERAGE

33 40 00 STORM DRAINAGE UTILITIES

33 72 02 UNDERGROUND COMMUNICATION SYSTEM -- ADDED BY AMENDMENT

NO. 0003

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)-- ADDED BY

AMENDMENT NO. 0003

DIVISION 34 - TRANSPORTATION

34 71 13.19 CRASH RATED ACTIVE VEHICLE BARRIERS AND CONTROLS REVISED

BY AMENDMENT NO. 0003

34 73 16 AIRFIELD GROUNDING

DIVISION 41 - MATERIAL PROCESSING AND HANDLING EQUIPMENT

41 22 13.15 BRIDGE CRANES, OVERHEAD ELECTRIC, UNDER RUNNING

41 22 23.19 MONORAIL HOISTS

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK -- REVISED BY AMENDMENT NO. 0009

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

1.1.1.1 Package 1A - Base Infrastructure

1.1.1.2 Package 5 - Organizational Level Maintenance Hangar

1.1.1.3 Package 1B - Base Infrastructure Improvements - Electrical and Telecommunications

1.1.2 Location

1.2 OCCUPANCY OF PREMISES

1.3 LOCATION OF UNDERGROUND UTILITIES

1.3.1 Notification Prior to Excavation

1.4 BACKGROUND INFORMATION

1.5 SCOPE BREAKDOWN FOR THE WORK OF THIS CONTRACT

1.5.1 Base Bid CLINs

1.5.2 Optional CLINs

1.6 DIVISION ONE SPECIFICATIONS

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK --

REVISED BY AMENDMENT NO. 0009

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Utility Outage Requests

Utility Connection Requests

Borrow Permits

Excavation Permits

Welding Permits

Burning Permits

Salvage Plan; G; M/R

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes site grading and utility infrastructure improvements, pump house, power check pad, compass calibration pad, aircraft taxiways, related site improvements, and incidental related work. The work of this contract includes construction of facilities and improvements identified in three (3) design packages for improvements at Ahmed Al Jaber Air Base, Kuwait. These three (3) design packages are initially described below.

These packages are described in more detail later within this specification section.

1.1.1.1 Package 1A - Base Infrastructure

The work includes site grading and utility infrastructure improvements to support multiple facility projects, pump house, power check pad, compass calibration pad, aircraft taxiways, related site improvements, and incidental related work.

1.1.1.2 Package 5 - Organizational Level Maintenance Hangar

The work includes construction of a new Organizational Level Maintenance Hangar, Organizational Level Corrosion Control Hangar, vehicle parking sunshades, guard house, related site improvements, and incidental related

SECTION 01 11 00 Page 2 work.

1.1.1.3 Package 1B - Base Infrastructure Improvements - Electrical and Telecommunications

The work includes electrical and telecommunications infrastructure improvements to support multiple facility projects throughout Al Jaber Air Base.

1.1.2 Location

The work is located at the Ahmed Al Jaber Air Base, Kuwait, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.2 OCCUPANCY OF PREMISES

Adjacent buildings will be occupied during performance of work under this Contract.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.3 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities.

Verify existing utility locations indicated on contract drawings, within area of work.

1.3.1 Notification Prior to Excavation

Notify the Contracting Officer and Al Jaber Air Base Military Engineering Projects (MEP) Manager via official letter at least 72 hours prior to starting excavation work.

1.4 BACKGROUND INFORMATION

The work of this construction contract is associated with the fielding of new F/A-18E/F Super Hornet aircraft at Al Jaber Air Base, Kuwait through the Foreign Military Sales (FMS) program. These new aircraft require construction of new facilities and improvements to existing facilities within the base.

These new facilities and facility improvements have been designed as a series of Packages that could be implemented individually or in groups.

All of the Packages associated with fielding new F/A-18E/F Super Hornet aircraft are as follows. This construction contract requires completion of construction for some (but not all) of these Packages.

Package 1A - Base Infrastructure (part of this Contract) Package 1B - Base Electrical and Telecommunications Infrastructure (part of this Contract) Package 2 - Quick Reaction Area (QRA) and Combat Aircraft Loading Area

(CALA)

Package 3 - General Purpose Warehouse Package 4 - Parking Apron and Aircraft Parking Shelters Package 5 - Organizational Level Maintenance Hangar (with Corrosion Control Hangar) (part of this Contract)

SECTION 01 11 00 Page 3

Package 6 - Aircrew Training Facility Package 7 - Intermediate Level Engine Shop Package 8 - Intermediate Level Airframes Shop Package 9 - Squadron Operations Facility

1.5 SCOPE BREAKDOWN FOR THE WORK OF THIS CONTRACT

The work of this construction contract includes the following three Packages. Package 1A for base infrastructure to support new facilities in all Packages including demolition, initial grading, stormwater control, utility infrastructure (domestic water, sanitary sewer, and fire water), and incidental related work. Package 1A also includes installation of the power check pad, compass calibration pad, taxiways, and associated incidental related work. Package 5 to construct the Organizational Level Maintenance Hangar, the Corrosion Control Hangar, various parking sunshades and parking areas, Guard House, and associated incidental related work. Finally, Package 1B for electrical and telecommunications infrastructure improvements to support multiple facility projects throughout Al Jaber Air Base, including switching station improvements, electrical substations, electrical ductwork and cabling, telecommunications ductwork and telecommunications cabling.

All work of this construction contract is to be broken down into the following categories, also referred to as Construction Contract Line Items (CLINs). These CLINs are not intended to describe the work exclusively or limit the work for this Contract. The Contractor is responsible to ensure that the total cost of all CLINs is sufficient to perform the entire work. Instead, these CLINs are merely intended to guide the Contractor in how the Government intends for the Contractor to itemize costs for the work. CLINs are identified as being part of the Base Bid (mandatory) or as Bid Options. The Government shall have sole option to determine whether Bid Options are implemented.

1.5.1 Base Bid CLINs

0001 - Mobilization and Demobilization. Mobilization and Demobilization in accordance with the Contract Documents.

0002 - Sitework and Utility Infra. Fac. A. Construct Sitework and Utility Infrastructure, identified as Facility A in Package 1A, in accordance with the Contract Documents. This work includes but may not be limited to demolition of existing facilities, rough grading, stormwater improvements, and all utility infrastructure (domestic water, sanitary sewer, and fire water) identified as Facility A in Package 1A.

0003 - Pump House, Water Storage Tanks. Construct Pump House and Water Storage Tanks in accordance with the Contract Documents. This work is identified as Facility P in Package 1A.

0004 - Org. Level Corrosion Control Hangar. Construct Organizational Level Corrosion Control Hangar in accordance with the Contract Documents.

This work is further identified as Facility D in Package 5.

0005 - Org. Level Maintenance Hangar. Construct Organizational Level Maintenance Hangar in accordance with the Contract Documents. This work is further identified as Facility J in Package 5.

0006 - Guard House. Construct Guard House in accordance with the Contract Documents. This work is identified as part of Facility N in Package 5.

SECTION 01 11 00 Page 4

The work of this CLIN does not include Vehicle Parking Sunshades and Equipment Shelters, which is included in a different CLIN.

0007 - Sitework and Utility Infra. Fac D, J, N. Construct Associated Sitework and Utility Infrastructure to support Package 5 Facilities D, J, and N in accordance with the Contract Documents. This work includes, but is not limited to, utility tie-ins, fine grading, site concrete, asphalt pavement, and other incidental site improvements associated with Facilities D (Organizational Level Corrosion Control Hangar), J (Organizational Level Maintenance Hangar), and N (Guard House, Parking Area, etc).

0008 - Electrical Switching Station. Construct Electrical Switching Station in accordance with the Contract Documents. This work is identified as part of Facility R in Package 1B. This work includes, but may not be limited to, grading, concrete and/or asphalt pavements, and construction of the new Switching Station and electrical gear. This work does not include site electrical medium voltage ductbank or cabling, which is included in a different CLIN.

0009 - Electrical Substation #1. Construct Electrical Substation #1 in accordance with the Contract Documents. This work is identified as Facility S in Package 1B. This work includes, but may not be limited to, grading, concrete and/or asphalt pavements, and construction of the new Electrical Substation #1 and electrical gear. This work does not include site electrical medium or low voltage ductbank or cabling, which is included in a different CLIN.

0010 - Electrical Substation #2. Construct Electrical Substation #2 in accordance with the Contract Documents. This work is identified as Facility T in Package 1B. This work includes, but may not be limited to, grading, concrete and/or asphalt pavements, and construction of the new Electrical Substation #2 and electrical gear. This work does not include site electrical medium or low voltage ductbank or cabling, which is included in a different CLIN.

0011 - MV Ductbank & Cabling to Substa #1 & #2. Construct Site Electrical Medium Voltage Ductbank and Cabling from the Electrical Switching Station (Facility R in Package 1B) to Electrical Substation #1 (Facility S in Package 1B) and Electrical Substation #2 (Facility T in Package 1B) in accordance with the Contract Documents. This Site Electrical Medium Voltage Ductbank and Cabling is identified as part of Facility R in Package 1B. This work includes any associated excavation, backfill and compaction, utility or pavement crossings, pavement replacement, and any other incidental related work.

0012 - LV Ductbank & Cabling From Substa #1 & #2. Construct Site Electrical Low Voltage Ductbank and Cabling from Electrical Substation #1 (Facility S in Package 1B) and Electrical Substation #2 (Facility T in Package 1B) to all new or existing facilities serviced by either substation, in accordance with the Contract Documents. This Site Electrical Low Voltage Ductbank and Cabling is identified as part of Facility R in Package 1B. This work includes excavation, backfill, compaction, utility or pavement crossings, pavement replacement, and incidental related work.

0013 - LV Ductbank & Cabling to Warehouse. Construct Site Electrical Low Voltage Ductbank and Cabling from Existing Substation S/S N5 to new facility Package 3 General Purpose Warehouse in accordance with the

SECTION 01 11 00 Page 5

Contract Documents. This work includes tie-in to existing S/S N5 and termination at Package 3 General Purpose Warehouse. This Contract does not include construction of Package 3 General Purpose Warehouse (by others). This work includes any associated excavation, backfill and compaction, utility or pavement crossings, pavement replacement, and any other incidental related work.

0014 - Telecom Infra at Existing Vault. Construct Telecommunications Infrastructure at Existing Communications Vault in accordance with the Contract Documents. This work is identified as part of Facility R Electrical Switching Station in Package 1B. This work includes, but may not be limited to, all equipment, cabling, and terminations within the existing Communications Vault, Handhole HH-01, and all site telecommunications ductbank and cabling from the Communications Vault to

HH-01.

0015 - Telecom Ductbank and Cabling. Construct Site Telecommunications Ductbank and Cabling identified as part of Facility R in Package 1B in accordance with the Contract Documents. The scope of this CLIN includes all site telecommunications ductbank and cabling as shown, EXCEPT for any telecommunications ductbank and cabling from handhole HH-07 to Package 6 Aircrew Training Facility (HH-08, HH-09, and new infrastructure within the existing Aircrew Training Facility Building). Work includes excavation, backfill, compaction, utility or pavement crossings, pavement replacement, and incidental related work.

1.5.2 Optional CLINs

0016 - Power Check and Compass Calibration Pads. Construct Power Check Pad and Compass Calibration Pad complete in accordance with the Contract Documents. The work includes, but is not limited to, any sitework and utilities specifically associated with these facilities. This work is identified as Facilities B and C in Package 1A.

0017 - Parking Sunshades & Equipment Shelters. Construct Vehicle Parking Sunshades and Equipment Shelters in accordance with the Contract Documents. This work is identified as part of Facility N in Package 5.

The work of this CLIN does not include the Guard House, which is included a different CLIN.

0018 - Electrical Substation #3. Construct Electrical Substation #3 in accordance with the Contract Documents. This work is identified as Facility V in Package 1B. This work includes, but may not be limited to, grading, concrete and/or asphalt pavements, and construction of the new Electrical Substation #3 and electrical gear. This work does not include site electrical medium or low voltage ductbank or cabling, which is included in a different CLIN.

0019 - MV Ductbank & Cabling to Substa #3. Construct Site Electrical Medium Voltage Ductbank and Cabling from the Electrical Switching Station (Facility R in Package 1B) to Electrical Substation #3 (Facility V in Package 1B) in accordance with the Contract Documents. This Site Electrical Medium Voltage Ductbank and Cabling is identified as part of Facility R in Package 1B. This work includes any associated excavation, backfill and compaction, utility or pavement crossings, pavement replacement, and any other incidental related work.

0020 - LV Ductbank & Cabling From Substa #3. Construct Site Electrical Low Voltage Ductbank and Cabling from Electrical Substation #3 (Facility V

SECTION 01 11 00 Page 6 in Package 1B) to all new or existing facilities serviced by this substation, in accordance with the Contract Documents. This Site Electrical Low Voltage Ductbank and Cabling is identified as part of Facility R in Package 1B. This work includes any associated excavation, backfill and compaction, utility or pavement crossings, pavement replacement, and any other incidental related work.

0021 - LV Ductbank & Cabling to CALA. Construct Site Electrical Low Voltage Ductbank and Cabling from Existing UDS1 to new facility Package 2 Combat Aircraft Loading Area (CALA) in accordance with the Contract Documents. This work includes tie-in to existing UDS1 and termination at Package 2 CALA. This Contract does not include construction of Package 2 CALA (by others). This work includes any associated excavation, backfill and compaction, utility or pavement crossings, pavement replacement, and any other incidental related work.

0022 - Telecom Ductbank & Cabling to Training Fac. Construct Site Telecom Ductbank and Cabling to Package 6 Aircrew Training Facility in accordance with the Contract Documents. This work is part of Facility R in Package 1B. This CLIN includes telecom ductbank and cabling from handhole HH-07 to Package 6 Aircrew Training Facility (HH-08, HH-09, and new infrastructure within the existing Training Facility). This work includes excavation, backfill, compaction, utility or pavement crossings, pavement replacement, infrastructure within the existing facility, and incidental work.

0023 - Enhanced Turnover Assistance. Provide Enhanced Turnover Assistance for all work completed in this Contract as described in Specification Section 01 15 00.12 10, Paragraph 1.11, in accordance with the Contract Documents.

1.6 DIVISION ONE SPECIFICATIONS

The three (3) Packages that comprise this construction contract each include a stand-alone technical specification package that applies specifically to that Package. Each technical specification package includes corresponding Division 01 General Requirements specifications.

However, despite the inclusion of three (3) sets of Division 01 specifications, the Government requires the Contractor to perform the work as if there were only one set of Division 01 specifications provided. The Government does not require the Contractor to provide Division 01 functions in triplicate. Despite this expectation, the Government cannot simply delete duplicated Division 01 specifications from two of the three sets of technical specifications since the technical specifications reference the Division 01 specifications in areas.

The Government intends for the three sets of Division 01 specifications provided (with each of the three sets of technical specifications) to be identical. However, in the event of any conflict, if it should arise, the Division 01 specifications issued for Package 1A shall be considered primary and shall govern.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 11 00 Page 7

-- End of Section --

SECTION 01 11 00 Page 8

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 15 00.12 10

SUPPLEMENTARY REQUIREMENTS -- REVISED BY AMENDMENT NO. 0009

PART 1 GENERAL

1.1 SUBMITTALS

1.2 MEETING MINUTES

1.3 FOREIGN OBJECTS DAMAGE CONTROL

1.4 NOTICES

1.4.1 Notice Of Construction

1.4.2 Issuance of NOTAMS

1.5 UNSCHEDULED WORK STOPPAGES

1.6 DIGGING PERMITS

1.6.1 Requirements for Digging Permits

1.6.2 Requests for Digging Permits

1.6.3 Preparation of Requests for Digging Permits

1.6.4 Existing Underground Utilities

1.6.5 Use of Underground Utility Detecting Device

1.6.6 Hand Excavation

1.7 HAUL ROUTES - SPECIAL REQUIREMENTS

1.8 RESPONSIBILITY FOR PHYSICAL SECURITY

1.9 CERTIFICATES OF COMPLIANCE

1.10 ACCIDENT PREVENTION

1.10.1 Ground Fault Circuit Interrupter (GFCI) Requirement - Overseas

Construction

1.10.2 Temporary Power - Electrical Distribution Boxes

1.10.3 Reinforcement Caps

1.11 ENHANCED TURNOVER ASSISTANCE

1.12 LOCALLY AVAILABLE SERVICE FOR EQUIPMENT

1.13 CONTRACTOR'S MOBILIZATION AREA

1.14 CONTRACTOR'S OFF BASE MOBILIZATION AREA

1.14.1 Facilities Within the Mobilization Site

1.14.2 Special Requirements

1.15 PHYSICAL CONDITIONS

1.16 STANDARDIZATION

1.17 ON-BASE PHOTOGRAPHY PROHIBITION

1.18 PUBLIC RELEASE OF INFORMATION

1.18.1 Prohibition

1.18.2 Subcontract and Purchase Orders

1.19 UNEXPLODED ORDNANCE

1.19.1 UXO Safety Support During Construction

1.20 CUSTOM EXEMPT CONTRACT

1.21 COMPLIANCE WITH HOST COUNTRY RULES AND CUSTOMS

1.21.1 Contractor's Responsibilities

1.22 RADIO TRANSMITTER RESTRICTIONS

1.23 BASE HOT WORK PERMITS

1.23.1 Requirement for Hot Work Permits

1.23.2 Requests for Hot Work Permits

1.23.3 Preparatory Inspections and Inspection of Equipment

SECTION 01 15 00.12 10 Page 1

-- End of Section Table of Contents --

SECTION 01 15 00.12 10 Page 2

SECTION 01 15 00.12 10

SUPPLEMENTARY REQUIREMENTS -- REVISED BY AMENDMENT NO. 0009

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Foreign Objects Damage (FOD) Control Plan; G M/R

Requests for Digging Permits; G M/R

Proposed Means of Providing Project Security; G M/R

SD-07 Certificates

Certificates Of Compliance

SD-11 Closeout Submittals

O&M Performance Period Reports and Records; G M/R

1.2 MEETING MINUTES

The Contractor shall be responsible for the preparation of minutes of all meetings specified in the contract documents. Unless otherwise specified, these minutes shall be prepared within two (2) working days after meeting and signed by both the Contractor and Contracting Officer. Contractor shall provide signed copies to all attendees.

1.3 FOREIGN OBJECTS DAMAGE CONTROL

The Contractor shall prepare and submit to the Contracting Officer, for approval, his plan to control Foreign Objects Damage (FOD) at its mobilization site, construction site and during work on or near aircraft runways and/or taxiways. The plan shall be specific and shall describe in detail measures to be implemented to prevent deposit of foreign objects on runways and/or taxiways during construction. The Foreign Objects Damage (FOD) Control Plan shall be submitted fifteen (15) calendar days prior to the start of any work on or near aircraft runways or taxiways. No work will be allowed near any runways or taxiways without approval of the FOD control plan by the Contracting Officer.

SECTION 01 15 00.12 10 Page 3

1.4 NOTICES

1.4.1 Notice Of Construction

A Notice Of Proposed Construction Or Alteration must be submitted to Airfield Operations at least 30 days prior to the start of construction.

This notification must be submitted as directed by the Contracting Officer, but the Contractor must provide all information and prepare appropriate documentation for submission.

1.4.2 Issuance of NOTAMS

Only Airfield Operations can close, open, or restrict the use of any part of an airfield facility. Any conditions that would prevent, restrict, or present a hazard to arriving or departing aircraft requires public notification. Public notification is accomplished by the Notice to Airmen (NOTAM) system. NOTAMS are submitted to the managing aviation authority by the KAF. It is the responsibility of the Contractor to coordinate with the Contracting Officer for the issuance of NOTAMS during construction. The Contractor shall provide the necessary information at least 72 hours before occurrence of the event that requires the NOTAM.

1.5 UNSCHEDULED WORK STOPPAGES

The Contractor shall anticipate unscheduled removal from the work site an average of 10 hours per month per installation. If the total quantity of delays varies above or below the stated quantity, an equitable adjustment under Contract Clause 52.243-4 CHANGES shall be made upon written demand of either party. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date if, in the judgment of the Contracting Officer, a delay is justified.

1.6 DIGGING PERMITS

1.6.1 Requirements for Digging Permits

Prior to the start of any work activity which requires excavation within the current base, the Contractor shall obtain a digging permit.

1.6.2 Requests for Digging Permits

Requests for Digging Permits shall be submitted through the Contracting Officer to the Base a minimum of seven (7) days prior to the start of the work activity covered by the permit. The request for a Digging Permit shall include a narrative description of the work to be performed and a detailed map of the area of the excavation clearly marking the location of all known utilities or other obstructions. If the work activity covered by the Digging Permit request also requires a utility outage, a separate request for the outage shall be submitted.

1.6.3 Preparation of Requests for Digging Permits

Prior to submitting a request for a Digging Permit, the Contractor shall carefully review the area to be excavated to determine the location of existing utilities and other obstructions. The Contractor will review available drawings and will conduct a visual inspection of the site. The Contractor will utilize underground utility detecting devices such as metal and cable detectors to determine the location of existing utilities. All

SECTION 01 15 00.12 10 Page 4 utility lines found shall be clearly flagged or marked and the location of the utility shall be shown on the drawing to be submitted with the request for Digging Permit.

1.6.4 Existing Underground Utilities

Existing utilities may be present in the construction area which may not be shown, or are inaccurately shown, on the base as-built drawings and the contract drawings. The Contractor shall exercise utmost care in researching locations of existing utilities and reducing damage to existing utilities.

Any utilities damaged by the Contractor shall be promptly repaired by the Contractor. The Contracting Officer will review and approve any proposed repairs. Any damage to existing utilities will be immediately reported to the Contracting Officer and the Al Jaber Air Base Military Engineering Projects (MEP) Manager.

1.6.5 Use of Underground Utility Detecting Device

Prior to any excavation, a metal and/or cable detecting device shall be used along the route of the excavation. All underground utilities discovered by this method will be flagged a minimum distance of one-half (1/2) meter on each side of the location.

1.6.6 Hand Excavation

Hand excavation methods and special supervisory care shall be used between any flagged markers, in areas of known or suspected hazards, and in areas known or suspected to have multiple and/or concentrated utility lines or connections.

1.7 HAUL ROUTES - SPECIAL REQUIREMENTS

The Contractor shall be responsible for coordinating with the Host Government use of any existing roads as haul routes. Construction, and routing of new haul roads, and/or upgrading of existing roads for the Contractor's use, is the sole responsibility of the Contractor. It shall be the Contractor's responsibility to obtain such local authorizations, permits and licenses necessary to establish his mobilization camp, quarry operations, batching operations and haul routes.

1.8 RESPONSIBILITY FOR PHYSICAL SECURITY

Prior to mobilization, the Contractor shall submit his proposed means of providing project security to prevent unauthorized access to equipment, facilities, materials and documents, and to safeguard them against sabotage, damage, and theft. The Contractor shall be responsible for physical security of all materials, supplies, and equipment of every description, including property which may be Government-furnished or owned, for all areas occupied jointly by the Contractor and the Government, as well as for all work performed.

1.9 CERTIFICATES OF COMPLIANCE

Any certificates required for demonstrating proof of compliance of materials with specification requirements shall be executed in accordance with Section 01 33 00 SUBMITTAL PROCEDURES. Each certificate shall be signed by an official authorized to certify in behalf of the manufacturing company involved and shall contain the name and address of the Contractor, the project name and location, description and the quantity of the items

SECTION 01 15 00.12 10 Page 5 involved, and date or dates of shipment or delivery to which the certificates apply. Copies of laboratory test reports submitted with certificates shall contain the name and address of the testing laboratory and the date or dates of the tests to which the report applies.

Certification shall not be construed as relieving the Contractor from furnishing satisfactory material.

1.10 ACCIDENT PREVENTION

The Contractor shall comply with all applicable Host Country laws and with such additional measures as the Contracting Officer may find necessary in accordance with CONTRACT CLAUSE 52.236-13 entitled ACCIDENT PREVENTION (NOV 1991). Applicable provisions of the Corps of Engineers manual entitled Safety and Health Requirements Manual EM 385-1-1, will be applied to all work under this contract. The referenced manual may be obtained from the Contracting Officer's Representative at the jobsite or from the Middle East District at Winchester, Virginia.

1.10.1 Ground Fault Circuit Interrupter (GFCI) Requirement - Overseas Construction

The Corps of Engineers Health and Safety Manual, EM 385-1-1, section 11.C.05.a. states: "The GFCI device shall be calibrated to trip within the threshold values of 5 ma +/- 1 ma as specified in Underwriters Laboratory (UL) Standard 943." A variance from USACE has been granted allowing 10 ma, in lieu of 5 ma, for overseas activities that use 220 Volts(V)/50 hertz(hz) electrical power.

1.10.2 Temporary Power - Electrical Distribution Boxes

EM 385-1-1 section 11.A.01.a. states "All electrical wiring and equipment shall be a type listed by a nationally recognized testing laboratory for the specific application for which it is to be used." This includes temporary electrical distribution boxes. Locally manufactured electrical boxes will not be allowed. Only manufactured electrical distribution boxes that meet the European CE requirements, with 10 ma CE type GFCIs installed shall be allowed.

Contractors shall:

a. Make no modifications that might void any CE or manufacturer certification.

b. Test the installed systems to demonstrate that they operate properly and provide the 10 ma earth leakage protection.

c. Ensure GFCIs will have an integral push-to-test function. The testing shall be performed on a regular basis.

d. Check that proper grounding is checked regularly and flexible cords, connectors, and sockets inspected before each use.

1.10.3 Reinforcement Caps

All rebar and other protruding reinforcing steel, onto and into which employees could fall, shall be guarded to eliminate the hazard of

SECTION 01 15 00.12 10 Page 6 impalement. The guarding shall meet Code of Regulations, Title 8, Section

344.90 California Impalement Protection. Each protective cover shall be marked with the following information:

(1) Model Number or Trademark.

(2) California Approval Number as issued pursuant to Sections 1712 and 1505 of the above listed Code .

(3) Size(s) designation.

1.11 ENHANCED TURNOVER ASSISTANCE

The Contractor shall provide Enhanced Turnover Assistance for a period of 365 calendar days from the date of Substantial Completion. The purpose of Enhanced Turnover Assistance is to ensure performance of all preventative maintenance and repair during the warranty period in order to preserve all warranties through the warranty period. Enhanced Turnover Assistance shall include the following:

a. Provision of all maintenance materials or consumables required to perform any manufacturer-recommended routine preventative maintenance or repair for any equipment or systems provided or constructed as part of this Contract.

b. Performance of all manufacturer-recommended routine preventative maintenance or repair for any equipment or systems provided or constructed as part of this Contract.

c. Performance and acceptable documentation of all manufacturer-recommended preventive maintenance inspections for any equipment or systems provided or constructed as part of this Contract.

d. All materials provided or work performed as part of Enhanced Turnover Assistance shall be conducted within time and operational usage requirements established by relevant manufacturers. In order to ensure compliance with this provision, the Contractor must develop a Preventative Maintenance Schedule and provide updates to the Contracting Officer no less than monthly during the Enhanced Turnover Assistance period.

e. All materials or consumables provided as part of Enhanced Turnover Assistance must comply with all relevant manufacturer recommendations or guidelines for the preventative maintenance task being performed.

f. All work provided as part of Enhanced Turnover Assistance must be performed and supervised by proficient technicians with qualifications that comply with all relevant manufacturer recommendations or guidelines for the preventative maintenance task being performed.

1.12 LOCALLY AVAILABLE SERVICE FOR EQUIPMENT

All equipment furnished under this contract, regardless of country of manufacture or purchase, must have in-country service availability. In the event that the Contractor proposed to provide equipment for which in-country service is not available, the Contractor must provide written justification for the Contracting Officer's approval. This justification shall be submitted for each product or material for which a waiver is

SECTION 01 15 00.12 10 Page 7 sought concurrently with the submittal required by the Technical Provisions. Submission of group or "blanket" waivers is unacceptable.

1.13 CONTRACTOR'S MOBILIZATION AREA

The Contractor will be permitted to use an area as directed by the Contracting Officer within the contract limits for operation of his construction equipment and plants, shops, warehouses, and offices. The Contractor shall not be authorized to have living accommodations for his work force on the site. The Contractor is responsible for obtaining any required additional mobilization area above that designated. On completion of the contract, all facilities shall be removed from the mobilization area by the Contractor and shall be disposed of in accordance with applicable Host Government Laws and Regulations. The site shall be cleared of construction debris and other materials and the area restored to its final grade. See Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES for additional requirements.

1.14 CONTRACTOR'S OFF BASE MOBILIZATION AREA

The Contractor shall provide, furnish, operate and maintain facilities for his batching operations (e.g. concrete, asphalt, etc.) major shops and living facilities for his workers in an area off base. The specific area must be located such that no new contractor facilities are within the "Inhabited Building Clear Zone" (approximately 1355 meters, radius) surrounding ammunition/explosives storage and/or handling areas. The Contractor must submit his desired site location to the Contracting Officer for approval. All utilities will be the responsibility of the Contractor and shall be provided at no cost to the Government. On completion of the contract, all facilities shall be removed by the Contractor and shall be disposed of in the manner directed by the Contracting Officer. The site shall be cleared of construction debris and other materials and the area restored to its original condition. See Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES for additional requirements.

1.14.1 Facilities Within the Mobilization Site

All facilities within the Contractor's mobilization site shall be of substantial construction suitable for the local weather conditions.

Housing, messing and sanitary facilities shall meet the requirements of Corps of Engineers Safety and Health Requirements Manual EM 385-1-1. The Contractor shall provide all utilities required to make the site self-sufficient.

1.14.2 Special Requirements

The Contractor shall be responsible for coordinating with the Host Government use of any existing roads as haul routes. Construction, and routing of new haul roads, and/or upgrading of existing roads for the Contractor's use, is the sole responsibility of the Contractor. It shall be the Contractor's responsibility to obtain such local authorizations, permits and licenses necessary to establish his mobilization camp, quarry operations, batching operations and haul routes.

1.15 PHYSICAL CONDITIONS

The indications of physical conditions on the drawings and in the specifications are the result of site investigations.

SECTION 01 15 00.12 10 Page 8

1.16 STANDARDIZATION

Where two or more items of the same type or class of equipment furnished in this project are required, the units shall be products of the same manufacturer and shall be interchangeable when of the same size, capacity, performance characteristics, and rating. The only exception to this requirement is where the items are interchangeable due to conformance with industry standards (valves, fittings, etc.), they need not be by the same manufacturer. This requirement applies to all manufactured items in the project which normally require repair or replacement during the life of the equipment.

1.17 ON-BASE PHOTOGRAPHY PROHIBITION

The Contractor shall not engage in any form of photography without prior written approval from the Contracting Officer.

1.18 PUBLIC RELEASE OF INFORMATION

1.18.1 Prohibition

There shall be no public release of information or photographs concerning any aspect of the materials or services relating to this bid, contract, purchase order, or other documents resulting therefrom without the prior written approval of the Contracting Officer.

1.18.2 Subcontract and Purchase Orders

The Contractor agrees to insert the substance of this clause in all purchase orders and subcontract agreements issued under this contract.

1.19 UNEXPLODED ORDNANCE

1.19.1 UXO Safety Support During Construction

Portions of Ahmed Al Jaber Air Base have been cleared by Explosive Ordnance Disposal (EOD) teams. However, unexploded ordnance (UXO) may be discovered and/or uncovered within or around the construction work areas. It is the responsibility of the Contractor to be aware of the risk of encountering UXO and to take all actions necessary to assure a safe work area to perform the requirements of this contract. If at any time during contract performance, the Contractor becomes aware of or encounters UXO or potential UXO, the Contractor shall immediately stop work at the site of the encounter, move to a safe location, notify the contracting Officer, and mitigate any delays to scheduled or unscheduled contract work. The Contractor shall not perform nor incur any costs for the removal or disposal of UXO. The Contractor assumes the risk of any and all personal injury, property damage or other liability, arising out of and resulting from any Contractor action hereunder.

1.20 RESIDUAL CONSTRUCTION MATERIAL

All Contractor purchased materials and equipment intended for incorporation into the completed facilities and which are later determined excess to the actual construction requirements, will become the property of the Government. The residual materials and equipment shall be tagged (giving the area where like type material and equipment were installed), and stored in an orderly manner in a designated area as directed and approved by the Contracting Officer.

SECTION 01 15 00.12 10 Page 9

1.20 CUSTOM EXEMPT CONTRACT

The Contractor shall furnish to the Contracting Officer, just prior to completion of this contract, a consolidated inventory of all excess supplies, materials and equipment imported duty free for use under this contract. The Contractor shall either pay required duties on the excesses, re-export the excesses, or the excesses shall become the property of the Government.

1.21 COMPLIANCE WITH HOST COUNTRY RULES AND CUSTOMS

The laws of Host Country may prohibit access to certain areas of the country which are under military control. The Contractor shall furnish the Contracting Officer the names of personnel, type, and amounts of equipment, dates and length of time required at the site, and the purpose of entering the host country. It is understood that areas to which rights of entry are provided by the Host Government are to be used only for work carried out under the contract and no destruction or damages shall be caused, except through normal usage, without concurrence of the Host Government.

1.21.1 Contractor's Responsibilities

The following items are the sole responsibility of the Contractor to investigate, estimate as to cost, and assume the risk, as normally encountered by Contractors. The Contractor shall be responsible for determining the effect of the following on his own cost of performance of the contract and for including sufficient amount in the contract price:

a. Official language and type of accounts required to satisfy the officials of the Local Government.

b. Entry and exit visas, residence permits, and residence laws applicable to aliens. This includes any special requirements of the Host Government, including those required by local Labor Offices, which the Contractor may have to fulfill before an application for a regular block of visas will be accepted.

c. Passports, health and immunization certificates, and quarantine clearance.

d. Compliance with local labor and insurance laws, including payment of employer's share of contribution, collecting balance from employee and paying into insurance funds.

e. Strikes, demonstrations and work stoppage.

f. Collection through withholding and payment to local Government, of any Host Country income tax on employees subject to tax.

g. Arranging to perform work in the Host Country, to import personnel, to employ non-indigenous labor, to receive payments and to remove such funds from the country.

h. Operating under local laws, practices, customs and controls, and with local unions, in connection with hiring and firing, mandatory wage scales, vacation pay, severance pay, overtime, holiday pay, 7th day of rest, legal notice or pay in lieu thereof for dismissal of employees, slowdown and curtailed schedules during religious

SECTION 01 15 00.12 10 Page 10 holidays and ratio of local labor employed in comparison to others.

i. Possibility of claims in local bureaus, litigation in local courts, or attachment of local bank accounts.

j. Compliance with workmen's compensation laws and contributions into funds. Provisions of necessary medical service for Contractor employees.

k. Special license required by the local Government for setting up and operating any manufacturing plant in the Host Country, e.g.

concrete batching, precast concrete, concrete blocks, etc.

l. Sales within the host country of Contractor-owned materials, and equipment.

m. Special licenses for physicians, mechanics, tradesmen, drivers, etc.

n. Identification and/or registration with local police of imported personnel.

o. Stamp tax on documents, payments and payrolls.

p. Base passes for permanent staff, day laborers, motor vehicles, etc.

q. Compliance with all customs and import rules, regulations and restrictions, including, but not limited to, local purchase requirements.

1.22 RADIO TRANSMITTER RESTRICTIONS

To preclude accidental actuation of sensitive electronic equipment, the Contractor shall not use radio transmitting equipment without prior approval of the Contracting Officer.

1.23 BASE HOT WORK PERMITS

1.23.1 Requirement for Hot Work Permits

Prior to the start of a work activity including hot work (welding, burning, etc.) or the operating of other flame producing devices, the Contractor shall obtain a Hot Work Permit.

1.23.2 Requests for Hot Work Permits

Requests for Hot Work Permits shall be submitted through the Contracting Officer to the Base Fire Department a minimum of 7 days prior to the start of the work activity covered by the permit. The request for a Hot Work Permit shall include a narrative description of the work to be accomplished, a list of equipment to be used, and a description of special safety precautions that the Contractor will put in place during the work to assure compliance with EM 385-1-1 and…