W91151-16-B-0021.pdf

0010822254

Performance and Payment Bonds are required (see section 00700, FAR Clause 52.228-15).

As required by FAR 36.204, the estimated magnitude of this project is more than $10,000,000.

The NAICS for this acquisition is 238210, Electrical Contractors and Other Wiring Installation Contractors (SB size standard $15.0 million).

The aw ardee of this contract w ill be required to provide a dedicated Superintendent through completion of the project (see section 00700, FAR Clause 52.236-6).

Project Manager, Quality Control and Superintendent Positions are considered key positions. These positions SHALL not be subcontracted below the prime contractor.

This is a competitive 8(a) solicitation restricted to SBA Certif ied 8(a) companies w ithin SBA Region VI only.

X

ROY R CANTRELL (254)287-3057

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

27-Jul-2016

(RFP)

(IFB)

CALL:

Open End Electric Requirements Contract FY16

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______ calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________02 Sep 2016 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All of fers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

MISSION AND INSTALLATION CONTRACTING CMD

MISSION CONTRACTING OFFICE (MCO)

BUILDING 1001, ROOM W103

1001 761ST TANK BATTALION AVE

FORT HOOD TX 76544-5025

W91151

PAGE OF PAGES

1 OF

CODE W91151

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

DIRECTORATE OF PUBLIC WORKS

ENGINEERING DIVISION (CONTRACTING SECTION)

BLDG 4610, ENGINEER DRIVE

FORT HOOD TX 76544-5055

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

AD001636P

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W91151-16-B-0021 50

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W91151-16-B-0021

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job OEE Requirements Contract FY16

FFP

Open End Requirements Contract FY16 FOB: Destination

PURCHASE REQUEST NUMBER: 0010822254

NET AMT

0002 Job Bonds OEE

FFP

Base Year OEE Payment and Performance Bonds

1001 Job OPTION Option Year 1 OEE

FFP

Option Year 1 OEE

1002 Job OPTION Bonds OEE Option Year 1

FFP

Payment and Performance Bonds OEE Option Year 1.

2001 Job OPTION Option Year 2 OEE

FFP

Option Year 2 OEE.

2002 Job OPTION Bonds OEE Option Year 2

FFP

Payment and Performance Bonds OEE Option Year 2.

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Exhibit A Tech Exhibit A - ATT A -

Bid Schedule

1 03-JUN-2016

Exhibit B1 Tech Exhibit B1 - Division 1 Specifications

102 03-JUN-2016

Exhibit B2 Tech Exhibit B2 - ATT B

- Specifications

317 03-JUN-2016

Exhibit B3 Tech Exhibit B3 - Electric Meters

10 03-JUN-2016

Exhibit C Tech Exhibit C - ATT C - Section 16510e Interior Light Fixtu

71 01-FEB-2016

Exhibit D Tech Exhibit D - ATT D - Section 16520e Exterior Light Fixtu

27 01-FEB-2016

Exhibit E Tech Exhibit E - ATT E - Justification for WTech Node Plus

1 01-FEB-2016

Exhibit F Tech Exhibit F - ATT F - FM 10-67-1 Concepts Petrolium Ops

571 01-FEB-2016

Exhibit G Tech Exhibit G - ATT G - DA Pam 385-64 Safety Ammunition &

346 10-OCT-2013

Exhibit H Tech Exhibit H - ATT H - AR 190-11 MP Physical Security Arms

87 05-SEP-2013

Exhibit J Tech Exhibit J - ATT J - Trench & Grounding Details

1 05-MAY-2003

Exhibit K Tech Exhibit K - ATT K - Handhole Details

1 01-FEB-2016

Exhibit L Tech Exhibit L - ATT L - In-line Electrical Primary Riser De

1 02-JUL-2001

Exhibit M Tech Exhibit M - ATT M

- In-line Electrical Primary Riser 90

1 10-FEB-1999

Exhibit N Tech Exhibit N - ATT N - Solar LIghting Fixture Assembly

3 01-FEB-2016

Exhibit P Tech Exhibit P - ATT P - Static Ground Detail

1 01-FEB-2016

Exhibit Q Tech Exhibit Q -ATT Q - Transformer Concrete Pad Detail

1 05-MAY-2003

Exhibit R Tech Exhibit R - ATT R - FH Reg 420-9 Energy Conservation

41 24-OCT-2007

Exhibit S Tech Exhibit S - ATT S - LED Fixture Detail

1 03-FEB-2016

Exhibit T Tech Exhibit T - ATT T - Electrical GIS SOP

25 01-FEB-2016

Exhibit U Tech Exhibit U - ATT U - Special Provisions

1 07-DEC-2012

SYNOPSIS

PROJECT SYNOPSIS

Create New Electrical Requirements Contract

Project No. AD001636P

DESCRIPTION OF WORK:

The work shall be located at various locations on Fort Hood, TX. The exact location will be shown by the Contracting Officer. Building(s) will and will not be occupied during performance of work under this Contract. The Contractor shall provide all plant, supervision, labor, materials, equipment, supplies and transportation necessary to complete this scope of work. Except as provided elsewhere in this contract, all work shall comply with applicable State, local and Federal laws and regulations, industry and construction codes and standards, manufacturer’s specifications and recommendations, and all contract special provisions, terms and conditions.

The purpose of this contract will be used to provide miscellaneous electrical services to all areas of the Fort Hood Military Reservation at Fort Hood, Texas, encompassing the tasks identified in the bid schedule (Tech Exhibit - A), and includes the installation of new or replacement of existing vacuum circuit breakers, single and three phase primary overhead and underground electrical distribution lines, wood and steel poles, down guys, overhead guys, anchors, cross arms, insulators, new and rebuilt pole and pad mounted transformers, fused cutouts, lightning arrestors, steel reinforced concrete transformer pads, gang operated air switches, primary and secondary electrical metering, single and three phase overhead and underground secondary, roadway lighting, high mast lighting, flood lighting, ball field lighting, solar lighting fixtures, pole-mounted obstruction light fixtures, steel reinforced concrete base foundations for steel poles, lighting controllers, continuity testing of ammo bunkers, ammunition holding areas and railheads, static ground testing for fuel tankers, static ground installations for fuel tankers, lightning aerial rods, painting of static grounding points, service risers, service laterals, wiring gutters, panel boards, circuit breakers, fused safety switches, switch racks, dry type transformers, conduits, trenching, primary and secondary conductors and cables, extra heavy duty power cords, receptacles, outlets, hand holes, core drilling, tele-power poles, interior and exterior light fixtures, emergency back-up fixtures and lamp supply units, exit signs and light switches.

As-built drawings in CAD format are required at the conclusion of each project (task order), as identified in the contract's special provisions and specifications. Additionally, Tech Exhibit - T shall be completed at the conclusion of each project (task order) for all electrical points of interest identified on Tech Exhibit - T that is applicable to each project (task order).

The following Tech Exhibits and Attachments are included as part of the Solicitation.

Tech Exhibit A - Att A - Bid Schedule Tech Exhibit B1 - Att B1 - Division 1 Specifications Tech Exhibit B2 - Att B - Specifications Tech Exhibit B3 - Electric Meter Specifications Tech Exhibit C - Att C - Section 16510e Interior Light Fixtures Schedule Tech Exhibit D - Att D - Section 16520e Exterior Light Fixture Schedule Tech Exhibit E - Att E - Justification for Purchase of WTech Exhibit Node Plus (WNC) Power Meter & i.LON 600 Lon Works/IP Server Tech Exhibit F - Att F - FM 10-67-1 Concepts and Equipment of Petroleum Operations Tech Exhibit G - Att G - Department of the Army Pamphlet 385-64 Safety Ammunition and Explosives

Safety Standards Tech Exhibit H - Att H - Army Regulation 190-11 Military Police Physical Security of Arms, Ammunition, and Explosives Tech Exhibit J - Att J - Trench and Grounding Details Tech Exhibit K - Att K - Handhole Detail Tech Exhibit L - Att L - In-Line Electrical Primary Riser Detail Tech Exhibit M - Att M - In-Line Electrical Primary Riser at 90 Degrees to Line Detail Tech Exhibit N - Att N - Solar Lighting Fixture Assembly Tech Exhibit P - Att P - Static Ground Details Tech Exhibit Q - Att Q - Transformer Concrete Pad Detail Tech Exhibit R - Att R - Energy Conservation Program Tech Exhibit S - Att S - LED Fixture Detail Tech Exhibit T - Att T - Electrical GIS SOP Tech Exhibit U - Att U - Special Provisions

Solicitation documents, including Tech Exhibit and Attachments, specifications, and miscellaneous data, will be furnished to the contractor in Adobe PDF format on the Federal Business Opportunities website ( https://www.fbo.gov/ ). After award, one set of Adobe PDF contract drawings and PDF specifications will be furnished to the Contractor on CD. Reference publications will not be furnished. Contractor shall immediately check furnished drawings and notify the Government of any discrepancies.

A project construction sign will not be required for this project unless specified otherwise. Contractor shall keep all permits and other documents required to be on the job site in a 3-ring binder or posed on a bulletin board within the construction area.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government 1001 N/A N/A N/A Government 1002 N/A N/A N/A Government 2001 N/A N/A N/A Government 2002 N/A N/A N/A Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 POP 12-JUL-2016 TO

11-JUL-2017

N/A DIRECTORATE OF PUBLIC WORKS

DPW CONSTRUCTION COR

4612 ENGINEER DRIVE

FORT HOOD TX 76544

W45NQ9

0002 POP 12-JUL-2016 TO

11-JUL-2017

N/A (SAME AS PREVIOUS LOCATION)

1001 POP 12-JUL-2017 TO

11-JUL-2018

N/A (SAME AS PREVIOUS LOCATION)

1002 POP 12-JUL-2017 TO

11-JUL-2018

N/A (SAME AS PREVIOUS LOCATION)

2001 POP 12-JUL-2018 TO

12-JUL-2019

N/A (SAME AS PREVIOUS LOCATION)

2002 POP 12-JUL-2018 TO

12-JUL-2019

N/A (SAME AS PREVIOUS LOCATION)

Section 00100 - Bidding Schedule/Instructions to Bidders

SPECIAL NOTICE

SPECIAL NOTICE

Any bids received in response to this solicitation SHALL carry a 120 day acceptance period before prices need to be verified, extended or re-negotiated.

Public Bid Openings and Mailing Address:

Directorate of Public Works ATTN: Engineering Division (CONTRACTING SECTION) Building 4612 Engineer Drive Fort Hood, Texas 76522

Bid Opening will be conducted in QA Conference Room, Building 4610 Engineer Drive, Fort Hood, Texas.

1. Pre-requisites for Specialty Trade licensure and certification:

The contractor shall provide documentation to support that it possesses the qualifications to, or can acquire assets to, demonstrate journeyman (or master license) qualifications in the following trades: The Contractor shall provide written verification of being in the normal business of air conditioning construction as a prime contractor for a minimum of 5 years performing HVAC work, utilizing the NAICS 238220, Plumbing, Heating and Air-Conditioning Contractors. In responding to this solicitation for bids, the bidder shall provide copies of certifications/training identified above and below as a part of the bid. Current Texas Refrigeration Certification is required. Failure to provide this documentation will render the bid non-responsive and no further consideration will be given to that bidder for award of this contract. No substitution of the individual possessing the required pre-qualifications will be authorized without the written approval of the Contracting Officer, and no time will be allowed for the contractor to acquire the required training/certification after the contract is awarded.

2. Work Experience:

The prime contractor shall demonstrate that it possesses general construction contract management by providing at least three examples of relevant work experience in an awarded contract similar to the requirements stated in this solicitation. Documentation shall be submitted with the bid and include the contract number, the date of contract award, the customer's name and contact information, the awarded dollar value, a description of all work elements included in the contract, the number and type of specialty trades needed to complete the contract, and the period of time allocated for completion of the work.

Federal work experience is preferred; however, the Government will accept work experience from both State and institutional and commercial contracts as well. No residential work experience will be considered appropriate for this purpose. Failure to provide this documentation will render the bid non-responsive and no further consideration will be given to that bidder for award of this contract.

SUBCONTRACTOR LIST

Offerors shall submit a list of proposed subcontractors as an attachment to their bid. If offeror does not intend on utilizing subcontractors (self-perform), offeror shall state so in their bid. Failure to provide this listing or statement will render the quote nonresponsive and eliminate the offer from further consideration for award.

(End of special requirements)

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management JUL 2013 52.214-3 Amendments To Invitations For Bids DEC 1989 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids MAR 1997 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

252.204-7008 Compliance With Safeguarding Covered Defense Information Controls

DEC 2015

252.215-7008 Only One Offer OCT 2013

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price Requirements contract resulting from this solicitation.

(End of provision)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Mission and Installation Contracting Command Office - Fort Hood Installation Support Division, Construction Team ATTN: Kay D. Brown, Contracting Officer 1001 761st Tank Battalion Ave, Room W103 Fort Hood, Texas 76544-5045

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for--

8 Aug 2016, 1:00 pm

(c) Participants will meet at--

DPW - Fort Hood Building 4610, Engineer Drive, QA Conference Room Fort Hood, Texas 76544

From the Main Gate Entrance, proceed to the Santa Fe Avenue Overpass. At the second light, turn left onto Santa Fe Avenue. Continue along Santa Fe Avenue to Engineer Drive. Turn left at Engineer Drive and park in the DPW West Parking lot.

Enter Building 4610 at the West double doors, turn left to the waiting area. Attendees will be escorted in to the QA Conference room.

(d) Participants are asked to notify the Government of their intent to attend this site visit and pre-bid conference by sending an email to the Contract Specialist at the following email address. Information needed in the notification is: company name, address, POC name and email address or telephone number, and the number of attendees in the group.

(e) Fort Hood is a closed access installation. All visitors must obtain a visitors’ pass at the Main Gate

Visitors’ Center before being allowed on post. Consequently, participants should allow at least one or two hours prior to the site visit for obtaining this pass.

f. All questions resulting from the site visit must be submitted electronically to the email below prior to 4:00 PM CDT on 15 Aug 2016 to be considered:

roy.r.cantrell2.civ@mail.mil

(f). Remarks and explanations made by the government representative during the course of the site visit, whether orally or in writing, shall not change or qualify any of the terms or conditions of the solicitation.

This same qualification applies to the written answers provided to the questions. The solicitation can only be changed by a formal written amendment issued by Mission and Installation Contracting Command – Fort Hood.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

None.

Section 00600 - Representations & Certifications

52.204-16 Commercial and Government Entity Code Reporting JUL 2015 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.203-7996 (Dev) Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements - Representation (Deviation 2016-O0003)

OCT 2015

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (APR 2016)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238210.

(2) The small business size standard is $15,000,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vi) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.209-11, Representation by Corporations Regarding elinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(viii) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(ix) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(x) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xi) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvi) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xvii) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xviii) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xix) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xx) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxi) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxii) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00700 - Contract Clauses

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2015

52.204-13 System for Award Management Maintenance JUL 2013 52.204-18 Commercial and Government Entity Code Maintenance JUL 2015 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.214-3 Amendments To Invitations For Bids DEC 1989 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids MAR 1997 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.219-8 Utilization of Small Business Concerns OCT 2014 52.219-14 Limitations On Subcontracting NOV 2011 52.219-18 Alt I Notification of Competition Limited to Eligible 8(A)

Concerns (Jun 2003) - Alternate I

APR 2005

52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity APR 2015

52.222-27 Affirmative Action Compliance Requirements for Construction

APR 2015

52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-27 Prompt Payment for Construction Contracts MAY 2014 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7997 (Dev) Prohibition on Contracting with Entities that Require Certain

Internal Confidentiality Agreements (Deviation 2016-O0003)

OCT 2015

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting.

DEC 2015

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7001 Hazard Warning Labels DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities FEB 2013 252.225-7048 Export-Controlled Items JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012

52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of and shall not be binding until so approved.

(End of clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the date of completion identified in each task order (Since this is a requirements contracts, no specific completion date can be given herin for completion of work. Such completion dates will be identified in each individual task order). The time stated for completion shall include final cleanup of the premises.

See Note: Government period of performance is calculated based upon the table of performance periods not inclusive of supply or logistical considerations. Contractor shall provide documentary evidence for variation from Government proposed timelines. Where Contractor supply chain or equipment availability differs from actual construction period, Contractor shall provide documentary evidence to support variance from Government proposed performance period including firm commitment date for installation. Failure to conform to firm commitment date for installation shall be considered Contractor delay.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the task order, the Contractor shall pay liquidated damages to the Government in the amount of $575.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.219-18 NOTIFICATION OF COMPETITION LIMITED TO ELIGIBLE 8(A) CONCERNS (JUN 2003)--

ALTERNATE I (APR 2005)

(a) Offers are solicited only from small business concerns expressly certified by the Small Business Administration (SBA) for participation in the SBA's 8(a) Program and which meet the following criteria at the time of submission of offer--

(1) The Offeror is in conformance with the 8(a) support limitation set forth in its approved business plan; and

(2) The Offeror is in conformance with the Business Activity Targets set forth in its approved business plan or any remedial action directed by the SBA.

(3) The offeror's approved business plan is on the file and serviced by .

(b) By submission of its offer, the Offeror certifies that it meets all of the criteria set forth in paragraph (a) of this clause.

(c) Any award resulting from this solicitation will be made to the Small Business Administration, which will subcontract performance to the successful 8(a) offeror selected through the evaluation criteria set forth in this solicitation.

(d)(1) Agreement. A small business concern submitting an offer in its own name shall furnish, in performing the contract, only end items manufactured or produced by small business concerns in the United States or its outlying areas. If this procurement is processed under simplified acquisition procedures and the total amount of this contract does not exceed $25,000, a small business concern may furnish the product of any domestic firm. This paragraph does not apply to construction or service contracts.

(2) The insert name of SBA's contractor will notify the Mission Installation Contracting Command - Fort Hood Contracting Officer in writing immediately upon entering an agreement (either oral or written) to transfer all or part of its stock or other ownership interest to any other party.

(3) The offeror's approved business plan is on the file and serviced by the Dallas/Fort Worth SBA District Office or an SBA District Office within SBA Region VI.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its…