W56HZV-20-R-0025 0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. Contract ID Code Page Of

2. Amendment/Modification No.

3. Effective Date

4. Requisition/Purchase Req No.

5. Project No. (If applicable)

6. Issued By Code 7. Administered By (If other than Item 6) Code

8. Name And Address Of Contractor (No., Street, City, County, State and Zip Code)

9A. Amendment Of Solicitation No.

9B. Dated (See Item 11)

10A. Modification Of Contract/Order No.

10B. Dated (See Item 13) Code Facility Code

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing items 8 and 15, and returning ____________ copies of the amendments: (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. Accounting And Appropriation Data (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATIONS OF CONTRACTS/ORDERS

It Modifies The Contract/Order No. As Described In Item 14.

A. This Change Order is Issued Pursuant To: The Changes Set Forth In Item 14 Are Made In

The Contract/Order No. In Item 10A.

B. The Above Numbered Contract/Order Is Modified To Reflect The Administrative Changes (such as changes in paying office, appropriation data, etc.) Set

Forth In Item 14, Pursuant To The Authority of FAR 43.103(b).

C. This Supplemental Agreement Is Entered Into Pursuant To Authority Of:

D. Other (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______________ copies to the Issuing Office.

14. Description Of Amendment/Modification (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. Name And Title Of Signer (Type or print)

16A. Name And Title Of Contracting Officer (Type or print)

15B. Contractor/Offeror 15C. Date Signed 16B. United States Of America 16C. Date Signed

By (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITIONS UNUSABLE

30-105-02 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

SEE SCHEDULE

X

Firm Fixed Price

0003 2021APR26

W56HZV

ACC-DTA

6501 E. 11 MILE RD.

DETROIT ARSENAL, MI 48397-5000

TYLER WONSOWICZ

EMAIL: TYLER.J.WONSOWICZ.CIV@MAIL.MIL

W56HZV-20-R-0025

2021MAR01

X

X

/SIGNED/

2 signed

SEE SECOND PAGE FOR DESCRIPTION

1 3

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: TYLER WONSOWICZ

Buyer Office Symbol/Telephone Number: CCTA-HTB-C/(586)282-4010

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

The purpose of Amendment 0003 to W56HZV-20-R-0025 is to make the following changes:

- Revised Attachment 0001 - STS Crane Specification:

- Removed CONFORMITE EUORPEENE (CE) reference in Section 1.2.3

- Revised Section 1.3.4

- Incorporated FAR 52.211-11, Liquidated Damages

- Revised Attachment 0013 Site Visit Information to reflect the new date of the Virtual Q&A Conference (06 MAY 2021)

All other terms and conditions except those addressed in Amendment 0003 remain in full force and effect.

*** END OF NARRATIVE A0004 ***

2 3

W56HZV-20-R-0025

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION F - DELIVERIES OR PERFORMANCE

Status Regulatory Cite Title Date Status Regulatory Cite Title Date _______ _______________ ______________________________________________________________________ ____________ _______ _______________ ______________________________________________________________________ ____________

F-1 CHANGED 52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT SEP/2000

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of:

- $1,900.00 per calendar day for 0-90 days of delay.

- $2,675.00 per calendar day for 91-180 days of delay.

- $3,450.00 per calendar day for 181+ days of delay.

(b) If the Government terminates this contract in whole or in part under the Default -- Fixed-Price Supply and Service clause, the

Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default -- Fixed-Price Supply and Service clause in this contract.

(End of Clause)

3 3

W56HZV-20-R-0025