537-15-160 Project Manual Vol1.pdf

The Emergency Department Renovation Jesse Brown VAMC, Chicago IL 60612

VA Contract No.: 36C25218D0191 Delivery Order: 36C25219N0275

Project # 573-15-160

For the Department of Veterans Affairs

Great Lakes Acquisition Center (NCO 12) Captain James A. Lovell, FHCC

3001 Green Bay Rd., Bldg. 1, Rm 329 North Chicago, IL 60064-3048

Project Manual Volume 1

DIVISIONS 00-14

100% Construction Documents 5/30/2020

GUIDON-CMTA JV,.

lstoy Luke - IL Stamp

PROJECT CONTACTS:

OWNER:

Jesse Brown VA Medical Center Engineering Svc 820 S. Damen Ave Chicago IL 60612

ISSUE DATE: May 30, 2020

Jesse Brown VAMC VA: 537-15-160 Emergency Department Renovations Chicago, IL 60612

10-01-17 100% Construction Documents

May 30, 2020

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 00 Table of Contents 10-17 00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 12-18 01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 04-13 01 33 23 Shop Drawings, Product Data, and Samples 05-17 01 35 26 Safety Requirements 02-17 01 35 33 Infection Control Requirements 06-19 01 35 33.01 Construction Safety Procedures Appendix A 01 35 33.02 Construction Safety Procedures Appendix B 01 35 33.03 Construction Safety Procedures Appendix C 01 35 33.04 Construction Safety Procedures Appendix D 01 35 33.05 Construction Safety Procedures Appendix E 01 35 33.06 Construction Safety Procedures Appendix F 01 42 19 Reference Standards 05-16 01 45 00 Quality Control 03-19 01 45 29 Testing Laboratory Services 11-18 01 45 35 Special Inspections 03-19 01 57 19 Temporary Environmental Controls 01-11 01 58 16 Temporary Interior Signage 07-15 01 74 19 Construction Waste Management 09-13 01 81 13 Sustainable Construction Requirements 10-17

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

DIVISION 03 – CONCRETE NOT USED

DIVISION 04 – MASONRY NOT USED

04 20 00 Unit Masonry 08-17 04 72 00 Cast Stone Masonry 06-14

DIVISION 05 – METALS

05 12 00 Structural Steel Framing 11-18 05 43 00 Slotted Channel Framing

Chicago, IL 60612

10-01-17 100% Construction Documents

May 30, 2020

00 01 10-2

05 50 00 Metal Fabrications 08-18

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 13 Thermal Insulation 10-17 07 53 23 Ethylene-Propylene-Diene-Monomer 07 60 00 Flashing and Sheet Flashing 07 81 00 Applied Fireproofing 10-17 07 84 00 Firestopping 02-16 07 92 00 Joint Sealants 10-17 07 95 13 Expansion Joint Assemblies 02-16

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16 08 14 00 Interior Wood Doors 02-16 08 17 10 Integrated Door Assemblies 02-16 08 31 13 Access Doors and Frames 02-16 08 33 00 Coiling Doors and Grilles 09-18 08 42 43 Intensive Care Units/Critical Care Unit(ICU/CCU)

Entrances 08 71 00 Door Hardware 05-19 08 71 13 Automatic Door Operators 02-16 08 80 00 Glazing 10-15 08 90 00 Louvers and Vents 05-15

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 02-15 09 22 16 Non-Structural Metal Framing 06-18 09 29 00 Gypsum Board 06-18 09 30 13 Ceramic/Porcelain Tiling 09-15 09 51 00 Acoustical Ceilings 12-18 09 65 13 Resilient Base and Accessories 02-16 09 65 16 Resilient Sheet Flooring 05-18 09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES

10 21 23 Cubicle Curtain Tracks 05-15 10 25 13 Patient Bed Service Walls 01-20 10 26 00 Wall and Door Protection 10-15 10 28 00 Toilet, Bath, and Laundry Accessories 02-16 10 44 13 Fire Extinguisher Cabinets 08-18

DIVISION 11 – EQUIPMENT NOT USED

Chicago, IL 60612

10-01-17 100% Construction Documents

May 30, 2020

00 01 10-3

DIVISION 12 – FURNISHINGS

12 32 00 Manufactured Wood Casework 09-15 12 36 00 Countertops 12-18

DIVISION 13 - SPECIAL CONSTRUCTION NOT USED

DIVISION 14– CONVEYING EQUIPEMENT NOT USED

DIVISION 21- FIRE SUPPRESSION

21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16 22 07 11 Plumbing Insulation 09-15 22 11 00 Facility Water Distribution 09-15 22 13 00 Facility Sanitary and Vent Piping 09-15 22 40 00 Plumbing Fixtures 09-15 22 62 00 Vacuum Systems for Laboratory and Healthcare Facilities 09-15 22 63 00 Gas Systems for Laboratory and Healthcare Facilities 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

08-17 23 05 11 Common Work Results for HVAC 08-17 23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment 08-17

23 05 41 Noise and Vibration Control for HVAC Piping and Equipment

02-15

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-15 23 07 11 HVAC and Boiler Plant Insulation 02-15 23 09 23 Direct-Digital Control System for HVAC 09-11 23 21 13 Hydronic Piping 08-17 23 31 00 HVAC Ducts and Casings 03-13 23 34 00 HVAC Fans 02-15 23 36 00 Air Terminal Units 02-15 23 37 00 Air Outlets and Inlets 02-15 23 40 00 HVAC Air Cleaning Devices 02-12 23 82 16 Air Coils 04-11

DIVISION 25 – INTEGRATED AUTOMATION NOT USED

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16

Chicago, IL 60612

10-01-17 100% Construction Documents

May 30, 2020

00 01 10-4

26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17 26 05 26 Grounding and Bonding for Electrical Systems 01-17 26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 09 23 Lighting Controls 01-18 26 27 26 Wiring Devices 01-18 26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19 27 05 26 Grounding and Bonding for Communications Systems 06-15 27 05 33 Raceways and Boxes for Communications Systems 10-18 27 10 00 Control, Communication and Signal Wiring 06-15 27 15 00 Communications Structured Cabling 01-16 27 52 23 Nurse Call and Code Blue Systems 10-18

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18 28 05 13 Conductors and Cables for Electronic Safety and

Security 10-18

28 05 26 Grounding and Bonding for Electronic Safety and Security

09-11

28 05 28.33 Conduits and Backboxes for Electronic Safety and Security

09-11

28 31 00 Fire Detection and Alarm 10-11

DIVISION 31 – EARTHWORK NOT USED

DIVISION 32 – EXTERIOR IMPROVEMENTS NOT USED

DIVISION 33 – UTILITIES NOT USED

DIVISION 34 – TRANSPORTATION NOT USED

DIVISION 48 – Electrical Power Generation NOT USED

Chicago, IL 60612

10-01-17

100% Construction Documents

May 30, 2020

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GI000 COVER SHEET

GI101 LIFE SAFETY PLAN

GC100 INFECTION CONTROL/PHASING PLAN

GC101 FIRST FLOOR - PHASE 1 AND 2

GC102 FIRST FLOOR - PHASE 3 AND 4

GC103 FIRST FLOOR - PHASE 5 AND 6

AE001 ARCHITECTURAL SYMBOLS AND ABBREVIATIONS

AE002 WALL TYPES

AE003 FIRST FLOOR - ALTERNATIVES

AD100 FIRST FLOOR EXISTING PLAN

AD101 FIRST FLOOR OVERALL DEMOLITION PLAN

AE101 FIRST FLOOR OVERALL ARCHITECTURAL PLAN

AE102 FIRST FLOOR ARCHITECTURAL PLAN - A

AE103 FIRST FLOOR ARCHITECTURAL PLAN – B

AE201 SECOND FLOOR PLAN AND BUILDING SECTION

AE202 ROOF PLAN

AC111 FIRST FLOOR OVERALL REFLECTED CEILING PLAN

AC112 FIRST FLOOR REFLECTED CEILING PLAN - A

AC113 FIRST FLOOR REFLECTED CEILING PLAN – B

AC201 SECOND FLOOR REFLECTED CEILING PLAN

AE501 BUILDING DETAILS

AE502 BUILDING DETAILS

AE601 DOOR SCHEDULE AND DETAILS

AI101 FIRST FLOOR FINISH PLAN

AI201 INTERIOR ELEVATIONS

AI202 INTERIOR ELEVATIONS

AI401 ENLARGED FINISH PLANS AND ELEVATIONS

AI402 ENLARGED RESTROOM FINISH PLANS AND ELEVATIONS

AI501 INTERIOR SECTIONS AND DETAILS

AI601 FINISHES SCHEDULE

Chicago, IL 60612

10-01-17

00 01 15 - 2

QH101 FIRST FLOOR OVERALL EQUIPMENT FLOOR PLAN

QH102 FIRST FLOOR EQUIPMENT PLAN - A

QH103 FIRST FLOOR EQUIPMENT PLAN - B

QH201 TYPICAL EQUIPMENT PLANS AND ELEVATIONS

MH001 MECHANICAL LEGEND, GENERAL NOTES AND SCHEDULES

MH002 MECHANICAL DETAILS

MH003 MECHANICAL DETAILS

MH004 MECHANICAL DETAILS

MH005 MECHANICAL DETAILS

MD101 FIRST FLOOR AIR DISTRIBUTION PLAN – OVERALL DEMOLITION

MD201 FIRST FLOOR HYDRONICS PLAN – OVERALL DEMOLITION

MH101 FIRST FLOOR AIR DISTRIBUTION PLAN – OVERALL NEW WORK

MH102 SECOND FLOOR AIR DISTRIBUTION PLAN – OVERALL NEW WORK

MH103 ROOF AIR DISTRIBUTION PLAN – OVERALL NEW WORK

MH201 ENLARGED MECHANICAL ROOM PLANS

MP101 FIRST FLOOR HYDRONICS PLAN – OVERALL NEW WORK

FP100 FIRST FLOOR FIRE PROTECTION PLAN

PL001 PLUMBING LEGEND, SCHEDULES AND GENERAL NOTES

PL002 PLUMBING DETAILS

PD101 UNDERSLAB PLUMBING PLAN – OVERALL DEMOLITION

PD201 FIRST FLOOR PLUMBING PLAN – OVERALL DEMOLITION

PD301 FIRST FLOOR MEDICAL GAS PLAN – OVERALL DEMOLITION

PL101 UNDERSLAB PLUMBING PLAN – OVERALL NEW WORK

PL201 FIRST FLOOR PLUMBING PLAN – OVERALL NEW WORK

PG101 FIRST FLOOR MEDICAL GAS PLAN – OVERALL NEW WORK

PL301 DOMESTIC WATER RISER

PG201 MEDICAL GAS RISER

PW101 WASTE AND VENT RISER

EJ001 ELECTRICAL LEGEND

EJ100 LIGHT FIXTURE SCHEDULE AND DETAILS

EJ101 ELECTRICAL DETAILS

EJ200 POWER RISER DIAGRAM

Chicago, IL 60612

10-01-17

00 01 15 - 3

ED101 PARTIAL FIRST FLOOR PLAN - LIGHTING DEMOLITION

ED201 PARTIAL FIRST FLOOR PLAN - POWER DEMOLITION

ED301 PARTIAL FIRST FLOOR PLAN - SYSTEMS DEMOLITION

EL101 PARTIAL FIRST FLOOR PLAN - LIGHTING

EL101A PARTIAL FIRST FLOOR PLAN - LIGHTING ALTERNATE

EL200 PARTIAL FIRST FLOOR PLAN - PHOTOMETRIC

EP101 PARTIAL FIRST FLOOR PLAN - POWER

EP301 PARTIAL ROOF PLAN - POWER

ET101 PARTIAL FIRST FLOOR PLAN - SYSTEMS

FA100 FIRE ALARM RISER DIAGRAM AND DETAILS

FA101 PARTIAL FIRST FLOOR PLAN - FIRE ALARM

Chicago, IL 60612

10-01-17 100% Construction Documents

May 30, 2020 i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 RESTORATION

1.10 AS-BUILT DRAWINGS

1.11 USE OF ROADWAYS

1.12 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.13 TEMPORARY USE OF EXISTING ELEVATORS

1.14 TEMPORARY TOILETS

1.15 AVAILABILITY AND USE OF UTILITY SERVICES

1.16 NEW TELEPHONE EQUIPMENT

1.17 TESTS

1.18 INSTRUCTIONS

1.19 GOVERNMENT-FURNISHED PROPERTY

1.20 RELOCATED EQUIPMENT ITEMS

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for the renovation of the

Emergency Department as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the

Medical Center Engineering Officer.

C. Offices of Guidon Design, as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. Before placement and installation of work subject to tests by testing laboratory retained by Department of Veterans Affairs, the Contractor shall notify the COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection. Such prior notice shall be not less than three work days unless otherwise designated by the COR.

E. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -2

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Renovate Emergency Department First

Floor: Work includes general construction, alterations, roads, walks, grading, drainage and construction and certain other items.

ITEM II, Electrical Work: Work includes all labor, material, equipment and supervision to perform the required electrical construction work on this project.

ITEM III, Mechanical Work: Work includes all labor, material, equipment and supervision to perform the required Mechanical construction work on this project.

B. DEDUCT ALTERNATE NO.1: Delete demolition of existing Exam Room corridor walls and door and installation of new full opening wide ICU style break away doors.

C. DEDUCT ALTERNATE NO. 2: Delete the work associated with the replacement and expansion of the main nurse station. No new work.

D. DEDUCT ALTERNATE 3: Delete all work associated with the replace of all flooring in the main Emergency Departments.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -3

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work, the General Contractor shall give one week’s notice to the Contracting Officer so that security can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

D. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting officers representative (COR) for the purpose of security inspections of every area of project including tool boxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See Section 08 71

00, DOOR HARDWARE and coordinate.

E. Document Control:

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of

“sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -4

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”.

Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting Officer upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting

Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the

EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

F. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of (2 to 5) permits shall be issued for General

Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -5 the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The

Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

C. Working space and space available for storing materials shall be as determined by the COR.

D. Workmen are subject to rules of Medical Center applicable to their conduct.

E. Phasing:

The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur.

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

To insure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -6 site, building or portion thereof. Arrange such phasing dates to insure accomplishment of this work in successive phases mutually agreeable to

COR and Contractor, as follows and as shown on the construction :

Phase 1: is the majority of work related to the MH unit in the area north of the Emergency Department and the south of Comp & Pen. At the completion of this phase the area will be available for patients.

Phase 2: is the renovate of the new medication room and an exam room.

Phase 3: is the remainder of the renovation to relocate the east corridor and connector between the existing ED and the Phases 1 and 2.

Phase 4: is the replacement of the swing doors to 4 exam rooms with

ICU type sliding doors. Renovation/replacement of the northern half of the primary Nurse Station. Renovation of the staff lounge and on call spaces. All new finishes in the affected area.

Phase 5: is the replacement of the swing doors to 5 exam rooms with ICU type sliding doors. Renovation/replacement of the southern half of the primary Nurse Station. All new finishes in the affected area.

Phase 6: is the flooring and wall finishes at the primarily entrance to the ED.

F. Building No. 1A will be occupied during performance of work, but immediate areas of alterations will be vacated.

Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical Centers operations will not be hindered. Contractor shall permit access to Department of

Veterans Affairs personnel and patients through other construction areas which serve as routes of access to such affected areas and equipment. These routes whether access or egress shall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc to facilitate patient and staff access.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -7

Coordinate alteration work in areas occupied by Department of

Veterans Affairs so that Medical Center operations will continue during the construction period.

2. Immediate areas of alterations not mentioned in preceding

Subparagraph 1 will be temporarily vacated while alterations are performed.

G. Utilities Services: Maintain existing utility services for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized.

When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR

COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON WORK RESULTS FOR

ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request to interrupt any such services to

COR, in writing, 7 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -8

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

H. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

1. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR of areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by both the Contracting Officer. This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -9 shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by Contractor with new items in accordance with specifications which will be furnished by Government.

Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR

52.243-4 and VAAR 852.236-88).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of

Contractor to restore damage caused by Contractor's workmen in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -10

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are identified by as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

4. PCB Transformers and Capacitors : The Contractor shall be responsible for disposal of the Polychlorinated Biphenyl (PCB) transformers and capacitors. The transformers and capacitors shall be taken out of service and handled in accordance with the procedures of the Environmental Protection Agency (EPA) and the

Department of Transportation (DOT) as outlined in Code of Federal

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -11

Regulation (CFR), Titled 40 and 49 respectively. The EPA's Toxic

Substance Control Act (TSCA) Compliance Program Policy Nos. 6-PCB-6 and 6-PCB-7 also apply. Upon removal of PCB transformers and capacitors for disposal, the "originator" copy of the Uniform

Hazardous Waste Manifest (EPA Form 8700-22), along with the Uniform

Hazardous Waste Manifest Continuation Sheet (EPA Form 8700-22A) shall be returned to the Contracting Officer who will annotate the contract file and transmit the Manifest to the Medical Center's

Chief.

a. Copies of the following listed CFR titles may be obtained from the Government Printing Office:

40 CFR 261 .......Identification and Listing of Hazardous Waste

40 CFR 262 .......Standards Applicable to Generators of Hazardous

Waste

40 CFR 263 .......Standards Applicable to Transporters of

Hazardous Waste

40 CFR 761 .......PCB Manufacturing, Processing, Distribution in

Commerce, and use Prohibitions

49 CFR 172 .......Hazardous Material tables and Hazardous

Material Communications Regulations

49 CFR 173 .......Shippers - General Requirements for Shipments and Packaging

49 CRR 173 .......Subpart A General

49 CFR 173 .......Subpart B Preparation of Hazardous Material for

Transportation

49 CFR 173 .......Subpart J Other Regulated Material; Definitions and Preparation

TSCA .............Compliance Program Policy Nos. 6-PCB-6 and 6-

PCB-7

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -12

1.9 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the

COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workmen to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING SITE CONDITIONS" (FAR

52.236-2).

1.10 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To insure compliance, as-built drawings shall be made available for the COR review, as often as requested.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -13

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.11 USE OF ROADWAYS

A. For hauling, use only established public roads and roads on Medical

Center property and, when authorized by the COR, such temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed and restoration performed by the Contractor at Contractor's expense. When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.12 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical equipment to provide heat, ventilation, plumbing, light and power will be permitted subject to written approval and compliance with the following provisions:

1. Permission to use each unit or system must be given by COR in writing. If the equipment is not installed and maintained in accordance with the written agreement and following provisions, the

COR will withdraw permission for use of the equipment.

2. Electrical installations used by the equipment shall be completed in accordance with the drawings and specifications to prevent damage to the equipment and the electrical systems, i.e. transformers, relays, circuit breakers, fuses, conductors, motor controllers and their overload elements shall be properly sized, coordinated and adjusted.

Installation of temporary electrical equipment or devices shall be in accordance with NFPA 70, National Electrical Code, (2014

Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be correct and it shall be determined that motors are not overloaded. The electrical equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuum cleaning and wiping clean interior and exterior surfaces.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -14

3. Units shall be properly lubricated, balanced, and aligned.

Vibrations must be eliminated.

4. Automatic temperature control systems for preheat coils shall function properly and all safety controls shall function to prevent coil freeze-up damage.

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elements shall be replaced at completion of construction and prior to testing and balancing of system.

6. All components of heat production and distribution system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the Government.

B. Prior to final inspection, the equipment or parts used which show wear and tear beyond normal, shall be replaced with identical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the mechanical and electrical specifications sections.

D. Any damage to the equipment or excessive wear due to prolonged use will be repaired replaced by the contractor at the contractor’s expense.

1.13 TEMPORARY USE OF EXISTING ELEVATORS

A. Use of existing elevators for handling building materials and

Contractor's personnel will be permitted subject to following provisions:

1. Contractor makes all arrangements with the COR for use of elevators.

The COR will ascertain that elevators are in proper condition.

Contractor may use elevators as directed by the COR in Building No.1 for daily use and for special nonrecurring time intervals when permission is granted. Personnel for operating elevators will not be provided by the Department of Veterans Affairs.

2. Contractor covers and provides maximum protection of following elevator components:

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -15

a. Entrance jambs, heads soffits and threshold plates.

b. Entrance columns, canopy, return panels and inside surfaces of car enclosure walls.

c. Finish flooring.

1.14 TEMPORARY TOILETS

A. Contractor may have for use of Contractor's workmen; such toilet accommodations as may be assigned to Contractor by Medical Center.

Contractor shall keep such places clean and be responsible for any damage done thereto by Contractor's workmen. Failure to maintain satisfactory condition in toilets will deprive Contractor of the privilege to use such toilets.

1.15 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the Government. The Contractor shall carefully conserve any utilities furnished without charge.

B. The Contractor, at Contractor's expense and in a workmanlike manner, in compliance with code and as satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of electricity used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia and repair restore the infrastructure as required.

C. Contractor shall install meters at Contractor's expense and furnish the

Medical Center a monthly record of the Contractor's usage of electricity as hereinafter specified.

D. Heat: Furnish temporary heat necessary to prevent injury to work and materials through dampness and cold. Use of open salamanders or any temporary heating devices which may be fire hazards or may smoke and

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -16 damage finished work, will not be permitted. Maintain minimum temperatures as specified for various materials:

1. Obtain heat by connecting to Medical Center heating distribution system.

E. Electricity (for Construction and Testing): Furnish all temporary electric services.

1. Obtain electricity by connecting to the Medical Center electrical distribution system. The Contractor shall meter and pay for electricity required for electric cranes and hoisting devices, electrical welding devices and any electrical heating devices providing temporary heat. Electricity for all other uses is available at no cost to the Contractor.

F. Water (for Construction and Testing): Furnish temporary water service.

1. Obtain water by connecting to the Medical Center water distribution system. Provide reduced pressure backflow preventer at each connection as per code. Water is available at no cost to the

Contractor.

2. Maintain connections, pipe, fittings and fixtures and conserve water-use so none is wasted. Failure to stop leakage or other wastes will be cause for revocation (at COR discretion) of use of water from Medical Center's system.

1.16 NEW TELEPHONE EQUIPMENT

The contractor shall coordinate with the work of installation of telephone equipment by others. This work shall be completed before the building is turned over to VA.

1.17 TESTS

A. As per specification section 23 05 93 the contractor shall provide a written testing and commissioning plan complete with component level, equipment level, sub-system level and system level breakdowns. The plan will provide a schedule and a written sequence of what will be tested, how and what the expected outcome will be. This document will be submitted for approval prior to commencing work. The contractor

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -17 shall document the results of the approved plan and submit for approval with the as built documentation.

B. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such systems before requesting final tests. Final test will not be conducted unless pre-tested.

C. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Contracting Officer.

Contractor shall furnish all labor, materials, equipment, instruments, and forms, to conduct and record such tests.

D. Mechanical and electrical systems shall be balanced, controlled and coordinated. A system is defined as the entire system which must be coordinated to work together during normal operation to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provides comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, controls and electricity, etc. Another example of a system which involves several components of different disciplines is a boiler installation. Efficient and acceptable boiler operation depends upon the coordination and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

E. All related components as defined above shall be functioning when any system component is tested. Tests shall be completed within a reasonably period of time during which operating and environmental conditions remain reasonably constant and are typical of the design conditions.

F. Individual test result of any component, where required, will only be accepted when submitted with the test results of related components and of the entire system.

1.18 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals (hard copies and electronic) and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -18

B. Manuals: Maintenance and operating manuals and one compact disc (four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidental with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include "exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed training to assigned

Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment. All such training will be at the job site. These requirements are more specifically detailed in the various technical sections. Instructions for different items of equipment that are component parts of a complete system, shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed.

This is to assure proper instruction in the operation of inter-related systems. All instruction periods shall be at such times as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough coverage. The contractor shall submit a course outline with associated material to the COR for review and approval prior to scheduling training to ensure the subject

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -19 matter covers the expectations of the VA and the contractual requirements. The Department of Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in the opinion of the COR , does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.19 GOVERNMENT-FURNISHED PROPERTY

A. The Government shall deliver to the Contractor, the

Government-furnished property shown on the Schedule drawings.

B. Equipment furnished by Government to be installed by Contractor will be furnished to Contractor at the Medical Center Cemetery.

C. Storage space for equipment will be provided by the Government and the

Contractor shall be prepared to unload and store such equipment therein upon its receipt at the Medical Center.

D. Notify Contracting Officer in writing, 60 days in advance, of date on which Contractor will be prepared to receive equipment furnished by

Government. Arrangements will then be made by the Government for delivery of equipment.

1. Immediately upon delivery of equipment, Contractor shall arrange for a joint inspection thereof with a representative of the Government.

At such time the Contractor shall acknowledge receipt of equipment described, make notations, and immediately furnish the Government representative with a written statement as to its condition or shortages.

2. Contractor thereafter is responsible for such equipment until such time as acceptance of contract work is made by the Government.

E. Equipment furnished by the Government will be delivered in a partially assembled (knock down) condition in accordance with existing standard commercial practices, complete with all fittings, fastenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the like) necessary to make the connection between the Government furnished equipment item and the utility stub-up shall be furnished and installed by the contractor at no additional cost to the Government.

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -20

F. Completely assemble and install the Government furnished equipment in place ready for proper operation in accordance with specifications and drawings.

G. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

1.20 RELOCATED EQUIPMENT

A. Contractor shall disconnect, dismantle as necessary, remove and reinstall in new location, all existing equipment and items indicated by symbol "R" or otherwise shown to be relocated by the Contractor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR.

C. Suitably cap existing service lines, such as steam, condensate return, water, drain, gas, air, vacuum and/or electrical, at the main whenever such lines are disconnected from equipment to be relocated. Remove abandoned lines in finished areas and cap as specified herein before under paragraph "Abandoned Lines".

D. Provide all mechanical and electrical service connections, fittings, fastenings and any other materials necessary for assembly and installation of relocated equipment; and leave such equipment in proper operating condition.

E. Contractor shall employ services of an installation engineer, who is an authorized representative of the manufacturer of this equipment to supervise assembly and installation of existing equipment, required to be relocated.

F. All service lines such as noted above for relocated equipment shall be in place at point of relocation ready for use before any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

1.21 SAFETY SIGN

A. Provide a Safety Sign where directed by COR. Face of sign shall be 19 mm (3/4 inch) thick exterior grade plywood. Provide two 100 mm by 100 mm (four by four inch) posts extending full height of sign and 900 mm

Chicago, IL 60064

May 30, 2020 100% Construction Documents

10-01-17

01 00 00 -21

(three feet) into ground. Set bottom of sign level at 1200 mm (four feet) above ground.

B. Paint all surfaces of Safety Sign and posts with one prime coat and two coats of white gloss paint. Letters and design shall be painted with gloss paint of colors noted.

C. Maintain sign and remove it when directed by COR.

D. Standard Detail Drawing Number SD10000-02(Found on VA TIL) of safety sign showing required legend and other characteristics of sign is on the drawings.

E. Post the number of accident free days on a daily basis.

- - - E N D - - -

Chicago, IL 60612

02-01-15 !00% Construction Documents

May 30, 2020

01 32 16.15 - 1

SECTION 01 32 16.15

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path…