Amendment_2.pdf

ACQR5489062

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment is:

1. CORRECT the solicitation number in Block 10 of the SF 1442 dated 8 May 2019. The correct solicitation number is N40085-18-R-0644.

2. Incorporate FAR Clause 52.211-12, Liquidated Damages Construction in FULL TEXT.

3. Provide responses to PPIs.

Proposal due date remains 18 June 2019 2:00 p.m.

1. CONTRACT ID CODE PAGE OF PAGES

1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 21-May-2019

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008518R0644

X 9B. DATED (SEE ITEM 11)

08-May-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

21-May-2019

CODE

NAVFAC MID ATLANTIC

ACQUISITION CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

N40085 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008518R0644

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

PPI RESPONSES

PRE‐PROPOSAL INQUIRY ATTACHMENT (5.3)

Solicitation Number: N40085‐18‐R‐0644

Contractor Name:

Contractor POC (Name and email):

Instructions: DO NOT submit in PDF format. DO submit as a word document

Contractor

PPI#

Section of RFP or Page Number

Paragraph Reference

Drawing Number

Question RESPONSE

1 FAR‐52.211‐

52.211‐12 Liquidated Damages‐‐ Construction is referenced but no clause has been provided. Please provide this clause in full text with the calculated Liquidated Damages per day.

FAR Clause 52.211‐12 has been added full text ‐

2 4.2 Proposal Delivery Information (Page 24)

Paragraph 2 On Page 24 it states for Non‐ price proposal (Phase 1) contain a CD with price and non‐price proposal, but no price information is listed.

Please confirm if any Solicitation Submittal Requirements on page 7 should be provided with the Phase 1

REVISE the following section of the solicitation as follows to add acknowledgment of Amendments on the Cover Page information:

Page 9 –

b. Non‐price factors

(1) Solicitation Submittal Requirements Non Price Binder Cover page with Solicitation Number, Solicitation Title, Prime Contractor Name, Address, Phone Number, Fax Number, DUNS, CAGE Code, Point submission such as a SF1442, acknowledge of Amendments, etc.

of Contact, Phone Number, and Email Address AND ACKNOWLEDGEMENT of

AMENDMENTS

3 Factor 2 Please confirm if construction experience where the design is complete and construction is more than 50% complete will be considered for aircraft hangar experience?

The current RFP requires that projects submitted under Factor 2

– Experience (both design and construction) must have been completed within 10 years of issuance of the RFP. Pages 12 ‐13.

4 Factor 2 (Page 14)

Factor 2 states to provide applicable documentation on project that were validated and/or certified through USCGB.

Please confirm this documentation is not included in the 2 page limit for each project sheet.

This document is not considered as a part of the two page limit;

however any documentation submitted for this may not exceed 20 pages.

Section 3, 2 N/A The sentence reads “Offerors shall not incorporate by reference into their proposal PPQs previously submitted for other RFP’s”. For project experience included in this proposal, do we need to have the owner complete a PPQ, even if we have one on file with them?

Offerors may submit PPQ’s from clients that correspond to projects submitted under Factor 2 Experience. There is no need to get another PPQ if the project has previously been evaluated.

Page 12 3 N/A Are we able to submit a project in Factor 2 Experience, if the project meets the

Factor 2 ‐ Experience requires that “Projects submitted shall have been completed within ten (10) years prior to the date of issuance of the RFP.”

requirements outlined;

however, it is in‐ progress with a completed mid‐ term evaluation from USACE?

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following were previously included by reference and are now included by full text:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ 105,850.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)