Attachment_4_C-12_Deliveries or Performance.pdf

Contract: FA8134-25-R-B002

C-12 Contractor Logistics Support Services

PART I - THE SCHEDULE

SECTION F

DELIVERIES OR PERFORMANCE

Page F-1 Contract: FA8134-25-R-B002

ATTACHMENT 4 - DELIVERIES OR PERFORMANCE

F-1. PERIOD OF PERFORMANCE

The supplies and services as referenced below shall be delivered or performed in accordance with the following schedule.

NOTE: Deliveries or performance are subject to change on date of award and length of transition/base period.

ITEM DELIVERIES OR PERFORMANCE

Phase-In Period of One (1) Year Transition/Base Period 01 Nov 25 – 31 Oct 26 Option Year One 01 Nov 26 – 31 Oct 27 Option Year Two 01 Nov 27 – 31 Oct 28 Option Year Three 01 Nov 28 – 31 Oct 29 Option Year Four 01 Nov 29 – 31 Oct 30 Option Year Five 01 Nov 30 – 31 Oct 31 Option Year Six 01 Nov 31 – 31 Oct 32 Option Year Seven 01 Nov 32 – 31 Oct 33 Option Year Eight 01 Nov 33 – 31 Oct 34 Option Year Nine 01 Nov 34 – 30 Apr 35 (Includes Phase-Out) Ext of Services IAW FAR 52.217-8 01 May 35 – 31 Oct 35

F-2. F.O.B. POINT FOR DELIVERY

CLIN F.O.B. POINT

X001 – X007 Base Operations Support Destination X008 – X017 Flying Hour Support Destination X018 – X024 Propeller Overhaul Destination X025 – X031 Aircraft Condition Inspection (ACI) Destination X032 – X038 Engine Overhaul Destination X039 – X045 Engine Tear-Down and Inspection (TD&I) - Repair Only Destination X046 – X049 Aircraft Labor (Depot) Destination X050 – X055 Aircraft Labor (Non-Depot) Destination X056 –X059 Engine Repair Labor Destination X060 – X065 Over and Above (O&A) Modifications Destination X066 – X071 Travel and Per Diem Destination X072 – X077 Parts and Material (Aircraft) Destination X078 – X083 Parts and Material (Engines) Destination X084 – X089 Other Efforts Destination X090 – X094 CBA Adjustment X095– X100 Phase-In Destination X101 – X106 Phase-Out Destination X107– X109 Incentive

CUI

PART I - THE SCHEDULE

SECTION F

DELIVERIES OR PERFORMANCE

Page F-2 Contract: FA8134-25-R-B002

F-3. AIRCRAFT CONDITION INSPECTION (ACI) DELIVERY SCHEDULE

(a) Definitions:

(1) Input - The delivery by the Government of an aircraft to the designated rework site, which enables the Contractor to accept physical custody of the aircraft.

(2) Induction Date - The date by which the Contractor must have commenced the work required by Sections 5 and 6 of Attachment 1, Performance Work Statement, on a particular aircraft. This date shall be deemed to be the first day of in-process time for that particular aircraft. The aircraft must arrive prior to 0700 hours on the scheduled induction date. The induction date will be established by the Government and included in the contract modification/delivery order.

(3) In-Process Time - The number of consecutive calendar days, excluding Federal Government holidays, allowed from induction date through the completion date of the ACI, including all over-and-above maintenance actions required.

(4) Scheduled Completion Time - The calendar date by which the particular aircraft will have completed its in-process time. This date may be extended in accordance with the provisions of subparagraph (c) and (e) below.

(5) Acceptance - Government acceptance of the ACI by the authorized on-site Government representative of the ACO as evidenced by signed acceptance on the DD Form 250. Final acceptance is subject to inspection, including Functional Check Flights (FCF) on the particular aircraft. Final acceptance marks the actual completion date of the ACI on a particular aircraft.

(b) ACI Induction/Inspection: The Government, at its sole discretion and at no increase in contract price, may input aircraft up to ten (10) calendar days prior to the induction date established in each modification. The Contractor shall be allowed to debrief pilots, inventory aircraft contents, ground run, compressor wash, defuel and hangar the aircraft, with no impact to the induction date or in-process time.

(c) In-process Work:

(1) The in-process time per aircraft for ACI and over and above work is ninety-eight (98) calendar days unless extended in accordance with paragraphs (3) or (e) below.

(2) The estimated aircraft induction schedule for aircraft for all fiscal year periods of performance is as follows:

FY27 FY28 FY29 FY30 FY31 FY32 FY33 FY34 FY35

1 C/D 4 C/D 3 C/D 3 C/D 5 C/D 5 C/D 2 C/D 1 C/D 4 C/D

1 F 0 F 0 F 1 F 0 F 0 F 1 F 1 F 0 F

2 J 1 J 0 J 1 J 1 J 0 J 0 J 2 J 1 J

This schedule represents the Government’s best estimate and is provided for planning and budgeting purposes and to permit the Contractor to schedule resources accordingly. Failure of the Government to order ACIs in the estimated quantities described above will not entitle the Contractor to an equitable adjustment in price under the Government Property clause of this contract. The ACO shall issue a modification to authorize the Contractor to proceed with the ACI and to establish the induction date and completion date for the particular aircraft.

(3) Within fifteen calendar days after the induction date of each aircraft for ACI, the Contractor shall submit to the Government a written estimate of the total number of man-hours required to complete all over and above repair actions discovered as a result of the ACI inspection.

PART I - THE SCHEDULE

SECTION F

DELIVERIES OR PERFORMANCE

Page F-3 Contract: FA8134-25-R-B002

NOTE: Any discrepancies discovered during ACI that can be accomplished in the field will not be approved as an over and above requirement to be performed during the ACI effort.

(4) The in-process time per aircraft for strip and paint and over-and-above work is 25 calendar days unless extended in accordance with paragraph (5) or (e) below.

(5) Within ten calendar days after the induction date of each aircraft for strip and paint, the Contractor shall submit to the Government, a written estimate of the total number of man-hours required to complete all over and above repair actions discovered as a result of the fuselage inspection after stripping.

(6) The Government and the Contractor will agree, within five (5) working days after Government receipt of the written estimate, to the total number of man-hours required to complete any authorized over-and-above maintenance actions. If the total over-and-above maintenance man-hours agreed to exceeds 400 man-hours, the ACO shall extend the in-process time for the aircraft on the basis of the following formulas:

Agreed hours - 400 hours = Number of additional hours/aircraft technician(s) Number of aircraft technician(s) assigned

NOTE: If there are multiple O&A repairs and they can be worked concurrently then the longest O&A repair will be used to extend the ACI time frame, if there are sequential major repairs then they will be added together to extend the ACI time frame.

EXAMPLE

If a repair requires 180 hours and has 2 aircraft technicians assigned to accomplish it, then the formula for calculating the allowable calendar day extension is:

180 hours = 90 hours/ aircraft technician(s) 2 aircraft technician(s)

90 hours/ aircraft technician(s) = 11.3* Days** of Allowable Delivery Ext 8 hours/day/ aircraft technician(s)

* Fractions of days will be converted to whole days when calculating the delivery due date (Example 11.3=12).

** Days = Work Days

(7) The ACO shall issue a modification establishing an adjusted (revised) schedule completion date for the ACI and strip and repaint efforts as necessary.

(8) Should the Government and the Contractor be unable to agree on the estimate of the number of agreed to over and above hours to complete any aircraft, the ACO will unilaterally determine the in-process time/scheduled completion date for the aircraft. The Contractor shall then be obligated to meet the schedule, but may exercise its rights under the “Disputes” clause of the contract.

(d) Completion of Work: The work ordered shall be completed no later than the scheduled completion dates defined in paragraph (a)(4) above.

(e) Extensions of Scheduled Completion Date: If delays for causes beyond the control and without fault or negligence of the Contractor arise subsequent to the establishment of the completion date arrived at under paragraph (c) above, the Contractor may request an extension of the scheduled completion date. The Contractor shall initiate a written request to the Government within 24 hours of the recognition of the delay(s), containing justification for the extension as a result of the delay(s). The ACO may grant such a request in whole or in part, if warranted, by verbal notification to the Contractor with in 1 day of receipt of the extension request. The ACO will promptly execute a modification to revise the scheduled completion date as necessary.

PART I - THE SCHEDULE

SECTION F

DELIVERIES OR PERFORMANCE

Page F-4 Contract: FA8134-25-R-B002

F-4. REPLACEMENT ENGINE DELIVERY SCHEDULE

The Government’s required delivery schedule for replacement engines is set forth below:

TYPE OF REPLACEMENT DELIVERY ALLOWANCE

Replacement for Engines Requiring Overhaul 0 Hours

Replacement for Engines Requiring Repair 72 Hours (CONUS Sites) 144 Hours (OCONUS Sites)

NOTE: All NRT for the shipment of engines will be negotiated on a case-by-case basis, but at no time will the NRT exceed the values listed in the table above.

F-5. AIRCRAFT STATUS CONDITION

The Contractor shall provide the operational status of each aircraft covered by this contract 60 days prior to contract expiration, along with projected completion dates for any aircraft undergoing repair, ACI, modification, etc. At the completion of the contract, the Contractor shall return all aircraft to the Government in accordance with AF requirements for Mission Capability (i.e. MESL). The Contractor shall have Mission Capable (MC) aircraft available for Government inspection not later than 30 days prior to contract completion. For those aircraft not in a MC state, the Contractor shall provide the aircraft for inspection and acceptance in accordance with the requirements of this contract, upon completion of the effort, or as directed by the Government.

F-6. DEFENSE TRANSPORTATION SYSTEM (DTS)

The Contractor is authorized to utilize the Defense Transportation System (DTS), to include shipment of unserviceable components to repair facilities, whenever approved by the Administrative Contracting Officer (ACO).

Shipment priorities up to and including transportation Priority 1 is authorized for movement within the DTS. Higher priority may be utilized only when specifically authorized and verified in writing by the ACO or the cognizant transportation officer. Priorities assigned under this part are applicable only to movement within DTS between CONUS and overseas sites.

The Contractor shall reimburse the Government for these costs and shall apply directly to the Air Mobility Command (AMC) headquarters for their own billing transportation account code (TAC). The cognizant transportation office will assist the Contractor in obtaining this special billing code.

F-7. AIR MOBILITY COMMAND (AMC) SHIPMENTS

(a) The Contractor is responsible for all transportation and packaging of materials.

(b) If the Contractor elects, shipment via AMC is authorized for all parts and material between CONUS sites;

however, the contractor shall reimburse the Government for these costs and assume all risk associated with the use of this method of transportation. The Contractor shall obtain a reimbursable TAC Code from the Administrative Contracting Officer for use with these shipments.

(c) When directed by the Government to ship via AMC, material that has not been delivered to the receiving site within 20 days from the date of acceptance of the material by AMC shall be considered lost. The Contractor shall immediately ship a replacement for the lost material via established AMC shipment procedures if the part is still required. The cost for replacement of lost shipments will be considered over-and-above and an equitable adjustment will be made to the contract price.

(d) Shipment via military air or military surface/water transportation is authorized on a cost reimbursable basis for parts and material being shipped to any of the C-12 OCONUS sites.

The Contractor shall use Transportation Account Code (TAC): TBD for these military air

PART I - THE SCHEDULE

SECTION F

DELIVERIES OR PERFORMANCE

Page F-5 Contract: FA8134-25-R-B002 shipments and TBD for military surface/water transportation to the C-12 OCONUS sites. The C-12 OCONUS sites include the following locations:

Accra, Ghana Gaborone, Botswana Ankara, Turkey Manila, Philippines Bangkok, Thailand Nairobi, Kenya Bogota, Columbia Oslo, Norway Brasilia , Brazil Rabat, Morocco Budapest, Hungary Riyadh, Saudi Arabia Buenos Aires, Argentina Tegucigalpa, Honduras Cairo, Egypt Yokota AFB, Japan Elmendorf, Alaska

F-8. MILITARY STANDARD TRANSPORTATION AND MOVEMENT PROCEDURE (MILSTAMP)

The Contractor shall comply with joint MILSTAMP Regulation (DOD 4500.9-R) which prescribes uniform procedures for the control of shipment moving wholly or in part within the Department of Defense Transportation System. The Contractor shall comply with the requirements relating to documentation, marking, advance notification of shipment dates, and terminal clearances. The Contractor shall not ship directly to a military air or water port terminal without authorization. Government contract administration activities will provide instructions, assistance, and/or authorization to the Contractor as required to fully satisfy MILSTAMP requirements.

F-9. ENVIRONMENTAL CHEMICAL-OIL SPILL RESPONSE AND CONTAINMENT

The contractor shall take action in compliance with requirements set forth under the Code of Federal Regulations, Title 40, Protection of the Environment, and supporting state and local regulations. Incidents less than Title 40 reportable quantities are considered within the management capability of the originator unless aggravating circumstances exist. Incidents exceeding the aforementioned parameters warrant emergency spill response assistance from the supporting air station. In all cases, the Contractor shall be responsible for initial containment, absorption, and waste management.