Attachment 3 - Fort Hamilton CDC-5.pdf

This is an attachment form for demonstrating specialized experience in a federal construction solicitation for the Child Development Center at Fort Hamilton, NY (Contract Number W912DS26RA011).

The form requests prime contractors or key subcontractors to provide project history demonstrating relevant experience constructed within the past seven years. For each project submitted, respondents must document: facility type, company name, project name and location, owner information, general construction scope, the contractor's role and self-performed work percentage, total construction cost, LEED certification level if applicable, subcontracted work details, construction timeline (begin and completion dates), owner performance evaluation, any terminations or liquidated damages assessments, and owner reference contact information with current telephone numbers. If the contractor was terminated or assessed liquidated damages, an explanation must be attached. One form should be completed per project example to establish the firm's capability and experience with similar construction projects of comparable type and scope.