36C26126R0009 0003.docx

5. PROJECT NUMBER (if applicable)

CODE

7. ADMINISTERED BY

2. AMENDMENT/MODIFICATION NUMBER

CODE

6. ISSUED BY

8. NAME AND ADDRESS OF CONTRACTOR

4. REQUISITION/PURCHASE REQ. NUMBER

3. EFFECTIVE DATE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED

PAGE OF PAGES

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED

BPA NO.

1. CONTRACT ID CODE

FACILITY CODE

CODE

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

E. IMPORTANT:

is extended,

(a) By completing Items 8 and 15, and returning __________ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY is not extended.

12. ACCOUNTING AND APPROPRIATION DATA

(REV. 11/2016)

is required to sign this document and return ___________ copies to the issuing office.

is not, A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

15C. DATE SIGNED

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER

Contractor

16C. DATE SIGNED

14. DESCRIPTION OF AMENDMENT/MODIFICATION

16B. UNITED STATES OF AMERICA

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER

16A. NAME AND TITLE OF CONTRACTING OFFICER

15B. CONTRACTOR/OFFEROR

STANDARD FORM 30

PREVIOUS EDITION NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.243 (Type or print) (Type or print) (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

(Number, street, county, State and ZIP Code) (If other than Item 6) (Specify type of modification and authority) (such as changes in paying office, appropriation date, etc.)

(If required)

(SEE ITEM 11)

(SEE ITEM 13)

(X)

CHECK

ONE

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

(Signature of person authorized to sign) (Signature of Contracting Officer)

01-28-2026

612A4-25-004 36C2621 Department of Veterans Affairs VA Sierra Pacific Network (VISN 21) VA Sierra Nevada Health Care System 975 Kirman Avenue Reno NV 89502-2597

36C261 Department of Veterans Affairs VA Sierra Pacific Network (VISN 21) VA Sierra Nevada Health Care System 975 Kirman Avenue Reno NV 89502-2597 To all Offerors/Bidders

36C26126R0009

36C26126R0009

X

X

** HOUR & DATE for Receipt of Offers is EXTENDED to: 02-12-2026 10:00 PST

The purpose of this amendment is outlined on page 2 of this solicitation amendment.

Charee Harris Contracting Officer NCO 21

PAGE NO.

CONTRACT NO.

ORDER NO.

MODIFICATION NO.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (CONTINUED)

STANDARD FORM 30 (CONTINUATION)

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

CONTINUATION PAGE

36C26126R0009

The purpose of this amendment is as follows:

1) Announce a second site visit is scheduled for Wednesday, February 4, 2026 at 10:00 AM Pacific Time. Participants to meet at the the flagpoles fron entrance building 600.

2) Post responses for request for Information (RFI) along with attachments to some responses as noted in the spreadsheet

3) Proivde updated scope of work dated January 27, 2026.

4) Incorporate the clause 52.211-11 Liquidated Damages.

5) Extend the proposal due date to Februry 12, 2026 at 10:00 AM Pacifc Time.

All other terms and conditions shall remain unchanged.

A.1 52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,500.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of Clause)

ATTACHMENTS

See attached document: SOW Hybrid OR Revised 01.27.2026.

See attached document: Hybrid OR RFIs Amendment 003.

See attached document: Attachment RFI 006.

See attached document: Attachment RFI 008.

See attached document: Attachment RFI No. 009.

See attached document: Attachment RFI NO. 15.

See attached document: Attachment RFI No. 17.

See attached document: Attachment RFI 104.

See attached document: Attachment RFI 76-78 Electrical Gear Locations.

See attached document: Attachment RFI 135 OR Laydown Area.