1737010spc1of2.pdf

WORK ORDER NO.

at the

PREPARED BY:

Mechanical:

Electrical:

Architectural:

Civil:

Structural:

APPROVED BY:

Specifications:

For Commander, NAVFAC:

Date:

Submitted By: Date:

Structural: Vernon Anderson, EIT Geotechnical: Frank DeMascio, P.E.

Landscape Arch: William Speidel, CLA nancy.wroten Line william.j.white7 Text Box Amy Tilghman, CLA

P-171 WEAPONS MAGAZINES 1737010

NWS YORKTOWN

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 08/15, CHG 2: 08/21 SUMMARY OF WORK

01 14 00 11/22, CHG 1: 02/23 WORK RESTRICTIONS

01 20 00 11/20, CHG 3: 02/23 PRICE AND PAYMENT PROCEDURES

01 30 00 11/20, CHG 3: 08/23 ADMINISTRATIVE REQUIREMENTS

01 31 23.13 20 08/23 ELECTRONIC CONSTRUCTION AND FACILITY

SUPPORT CONTRACT MANAGEMENT SYSTEM

(eCMS)

01 32 17.00 20 11/23 COST-LOADED NETWORK ANALYSIS SCHEDULES

(NAS)

01 33 00 08/18, CHG 4: 02/21 SUBMITTAL PROCEDURES

01 33 29 02/21 SUSTAINABILITY REQUIREMENTS AND

REPORTING

01 35 26 11/20, CHG 4: 08/23 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 02/19, CHG 1: 08/23 SOURCES FOR REFERENCE PUBLICATIONS

01 44 00.00 22 07/25 ARCHAEOLOGICAL MONITORING

01 45 00 08/23 QUALITY CONTROL

01 45 25.00 22 02/20 QUALITY ASSURANCE FIELD INSPECTION

01 45 35 11/20 SPECIAL INSPECTIONS

01 50 00 11/20, CHG 2: 08/22 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 57 19 08/22 TEMPORARY ENVIRONMENTAL CONTROLS

01 58 00 08/19, CHG 5: 08/22 PROJECT IDENTIFICATION

01 74 19 02/19, CHG 3: 11/21 CONSTRUCTION WASTE MANAGEMENT AND

DISPOSAL

01 78 00 05/19, CHG 1: 08/21 CLOSEOUT SUBMITTALS

01 78 23 05/23 OPERATION AND MAINTENANCE DATA

01 78 24.00 20 05/23, CHG 1: 11/23 FACILITY DATA WORKBOOK (FDW)

01 78 30.00 22 01/23 GIS DATA DELIVERABLES

01 91 00.15 22 08/24 TOTAL BUILDING COMMISSIONING

01 91 19.00 22 05/23, CHG: 1: 02/26 BUILDING ENCLOSURE COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 08/22 DEMOLITION AND DECONSTRUCTION

02 83 00 11/18 LEAD REMEDIATION

DIVISION 03 - CONCRETE

03 30 00 02/19, CHG 6: 11/23 CAST-IN-PLACE CONCRETE

DIVISION 04 - MASONRY

04 20 00 11/15, CHG 2: 05/19 UNIT MASONRY

DIVISION 05 - METALS

05 05 20 05/22 POST-INSTALLED CONCRETE AND MASONRY

ANCHORS

05 12 00 08/18, CHG 2: 05/21 STRUCTURAL STEEL

05 30 00 05/15, CHG 2: 08/18 STEEL DECKS

05 40 00 05/15, CHG 1: 08/18 COLD-FORMED METAL FRAMING

05 50 13 05/17, CHG 1: 08/18 MISCELLANEOUS METAL FABRICATIONS

05 50 15 08/18 CIVIL WORKS FABRICATIONS

05 51 33 02/16, CHG 2: 02/18 METAL LADDERS

05 52 00 08/23 METAL RAILINGS

PROJECT TABLE OF CONTENTS Page 1

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 08/16, CHG 2: 11/18 ROUGH CARPENTRY

06 41 16.00 10 08/10, CHG 1: 11/18 PLASTIC-LAMINATE-CLAD ARCHITECTURAL

CABINETS

06 61 16 08/20 SOLID SURFACING FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 13 53 02/16, CHG 1: 08/17 ELASTOMERIC SHEET WATERPROOFING

07 14 00 08/23 FLUID-APPLIED WATERPROOFING

07 21 13 08/23 BOARD AND BLOCK INSULATION

07 21 16 08/23 MINERAL FIBER BLANKET INSULATION

07 22 00 08/23 ROOF AND DECK INSULATION

07 27 10 08/23 BUILDING AIR BARRIER SYSTEM

07 27 19.01 08/23 SELF-ADHERING AIR BARRIERS

07 27 26 08/23 FLUID-APPLIED MEMBRANE AIR BARRIERS

07 42 13 05/11, CHG 2: 02/18 METAL WALL PANELS

07 52 00 05/12, CHG 5: 11/19 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 60 00 08/23 FLASHING AND SHEET METAL

07 61 15.00 20 08/16, CHG 2: 11/18 ALUMINUM STANDING SEAM ROOFING

07 84 00.00 22 07/24 FIRESTOPPING

07 92 00 08/23 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 08/20 STEEL DOORS AND FRAMES

08 31 00 05/17, CHG 1: 08/18 ACCESS DOORS AND PANELS

08 33 23 08/20, CHG 1: 02/22 OVERHEAD COILING DOORS

08 39 55.00 20 11/24 NAVY STANDARD EARTH-COVERED MAGAZINE

DOORS

08 71 00 02/16, CHG 4: 02/22 DOOR HARDWARE

08 91 00 08/20 METAL WALL AND DOOR LOUVERS

DIVISION 09 - FINISHES

09 22 00 02/10, CHG 2: 08/18 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 08/16, CHG 4: 02/20 GYPSUM BOARD

09 30 10 08/20 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 08/20 ACOUSTICAL CEILINGS

09 67 23.13 11/19 STANDARD RESINOUS FLOORING

09 90 00 02/21 PAINTS AND COATINGS

09 97 13.27 02/21, CHG 1: 08/22 HIGH PERFORMANCE COATING FOR STEEL

STRUCTURES

DIVISION 10 - SPECIALTIES

10 11 00 08/20 VISUAL DISPLAY UNITS

10 14 00.10 08/17, CHG 1: 11/18 EXTERIOR SIGNAGE

10 14 00.20 08/20 INTERIOR SIGNAGE

10 14 53 02/15, CHG 1: 05/17 TRAFFIC SIGNAGE

10 26 00 08/20 WALL AND DOOR PROTECTION

10 28 13 08/20 TOILET ACCESSORIES

10 44 16 11/19 FIRE EXTINGUISHERS

10 51 13 05/11 PLASTIC LOCKERS

DIVISION 11 - EQUIPMENT

PROJECT TABLE OF CONTENTS Page 2

11 13 19.13 08/09, CHG 1: 05/19 LOADING DOCK LEVELERS

DIVISION 12 - FURNISHINGS

12 00 01.00 20 02/23 FURNITURE, FIXTURES AND EQUIPMENT

(FF&E) PACKAGE

DIVISION 21 - FIRE SUPPRESSION

21 13 13 08/20 WET PIPE SPRINKLER SYSTEMS, FIRE

PROTECTION

DIVISION 22 - PLUMBING

22 00 00 11/15, CHG 4: 05/21 PLUMBING, GENERAL PURPOSE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 03 00.00 20 08/10, CHG 3: 08/18 BASIC MECHANICAL MATERIALS AND METHODS

23 05 93 05/25 TESTING, ADJUSTING, AND BALANCING FOR

HVAC

23 07 00 02/13, CHG 7: 05/20 THERMAL INSULATION FOR MECHANICAL

SYSTEMS

23 09 00.00 22 08/20, CHG 1: 03/22 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13.00 22 08/20, CHG 1: 03/22 INSTRUMENTATION AND CONTROL DEVICES

FOR HVAC

23 09 23.02 22 08/20, CHG 1: 03/22 BACNET DIRECT DIGITAL CONTROL FOR HVAC

AND OTHER BUILDING CONTROL SYSTEMS

23 30 00 05/20, CHG 1: 02/22 HVAC AIR DISTRIBUTION

23 81 00 05/18, CHG 1: 02/21 DECENTRALIZED UNITARY HVAC EQUIPMENT

23 82 00.00 20 02/16, CHG 1: 08/18 TERMINAL HEATING UNITS

DIVISION 25 - INTEGRATED AUTOMATION

25 05 11.01 05/21, CHG 1: 08/23 CYBERSECURITY FOR FACILITY-RELATED

CONTROL SYSTEMS - NAVAL WEAPONS

STATION YORKTOWN UTILITY MONITORING

AND CONTROL SYSTEM (UMCS)

25 05 11.02 05/21, CHG 1: 08/23 CYBERSECURITY FOR FACILITY-RELATED

CONTROL SYSTEMS - HEATING,

VENTILATION, AIR CONDITIONING (HVAC)

CONTROL

25 05 11.03 05/21, CHG 1: 08/23 CYBERSECURITY FOR FACILITY-RELATED

CONTROL SYSTEMS - LIGHTING CONTROL

SYSTEMS

25 05 11.04 05/21, CHG 1: 08/23 CYBERSECURITY FOR FACILITY-RELATED

CONTROL SYSTEMS - AMI METERING CONTROL

SYSTEMS

DIVISION 26 - ELECTRICAL

26 05 73 08/23 POWER SYSTEM STUDIES

26 08 00 11/22 APPARATUS INSPECTION AND TESTING

26 12 19 05/24 PAD-MOUNTED, LIQUID-FILLED,

MEDIUM-VOLTAGE TRANSFORMERS

26 13 00 05/21, CHG 1: 05/22 SF6/HIGH-FIREPOINT FLUIDS INSULATED

PAD-MOUNTED SWITCHGEAR

26 20 00 05/25, CHG 1: 08/25 INTERIOR DISTRIBUTION SYSTEM

26 27 14.00 20 02/21, CHG 1: 05/21 ELECTRICITY METERING

PROJECT TABLE OF CONTENTS Page 3

26 41 00 08/23 LIGHTNING PROTECTION SYSTEM

26 51 00 05/20, CHG 2: 11/21 INTERIOR LIGHTING

26 56 00 08/21 EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 08/11 BUILDING TELECOMMUNICATIONS CABLING

SYSTEM

27 53 19.13 05/20 FIRST RESPONDER DISTRIBUTED ANTENNAE

SYSTEMS (DAS)

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 31 70 08/20 INTERIOR FIRE ALARM SYSTEM, ADDRESSABLE

DIVISION 31 - EARTHWORK

31 00 00 08/23 EARTHWORK

31 11 00 11/18 CLEARING AND GRUBBING

31 31 16.13 08/22 CHEMICAL TERMITE CONTROL

31 32 19.16 02/21 GEOTEXTILE SOIL STABILIZATION AND

SEPARATION

31 35 19.13 02/21 GEOGRID REINFORCEMENT

31 36 00 02/21 GABIONS

31 62 13.20 11/20, CHG 1: 05/22 PRECAST/PRESTRESSED CONCRETE PILES

31 62 60.00 22 02/26 RIGID INCLUSION GROUND IMPROVEMENT

SYSTEM

31 63 29 11/19 DRILLED CONCRETE PIERS AND SHAFTS

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19.61 11/19 SEALING OF JOINTS IN RIGID PAVEMENT

32 05 33 08/17 LANDSCAPE ESTABLISHMENT

32 11 20 05/22 BASE COURSE FOR RIGID AND SUBBASE FOR

FLEXIBLE PAVEMENT

32 12 13 05/17 BITUMINOUS TACK AND PRIME COATS

32 12 16.16 11/20 ROAD-MIX ASPHALT PAVING

32 13 13.06 05/20 PORTLAND CEMENT CONCRETE PAVEMENT FOR

ROADS AND SITE FACILITIES

32 16 19 05/18 CONCRETE CURBS, GUTTERS AND SIDEWALKS

32 17 23 08/16, CHG 5: 11/18 PAVEMENT MARKINGS

32 31 13.53 11/21 HIGH-SECURITY FENCES (CHAIN LINK AND

ORNAMENTAL) AND GATES

32 92 19 08/17, CHG 1: 08/21 SEEDING

32 92 23 04/06, CHG 1: 08/21 SODDING

32 93 00 08/17, CHG 1: 08/21 EXTERIOR PLANTS

DIVISION 33 - UTILITIES

33 11 00 02/18, CHG 1: 02/22 WATER UTILITY DISTRIBUTION PIPING

33 30 00 05/18 SANITARY SEWERAGE

33 40 00 11/21 STORMWATER UTILITIES

33 46 13 05/20 MAGAZINE UNDERDRAIN SYSTEM

33 46 16 05/18 ROADWAY EDGEDRAINS

33 71 01 05/19, CHG 1: 11/19 OVERHEAD TRANSMISSION AND DISTRIBUTION

33 71 02 08/21 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 04/06 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 4

PROJECT TABLE OF CONTENTS Page 5

THIS PAGE INTENTIONALLY LEFT BLANK

PROJECT TABLE OF CONTENTS Page 6

SECTION 01 11 00

SUMMARY OF WORK

08/15, CHG 2: 08/21

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals Salvage Plan; G

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes construction of five (5) Containerized Long Weapon Storage Double Bay (CLWS-2B) type earth-covered, high-explosive magazines, and two (2) Segregation Facilities buildings, a Forklift Charging Station, and incidental related work. The project demolishes a total of 8 magazines. Magazine construction will consist of foundations, walls, reinforced concrete floors, entrance and loading aprons, and ordnance bonding, grounding and lightning protection systems, intrusion detection systems (IDS), and earth-covering. Site preparations include clearing, excavation, grading and fill. A stream crossing involves wetland permit restrictions and mitigation. Special foundation features include rigid inclusions and load transfer platforms at the magazine locations and pile foundations on the segregation buildings. Paving and site improvements include access roads, paved truck loading/unloading areas, a forklift loading ramp, security fencing, and landscaping. Electrical utilities include primary and secondary distribution systems, and incidental related work.

1.2.2 Location

The work is located at the Naval Weapons Station Yorktown, off of Turkey Road and Lee Road, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

Buildins will not be occupied during performance of work under this Contract. Existing magazines to be demolished will be empty.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

SECTION 01 11 00 Page 1

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.5 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities.

Contact local utility locating service prior to excavating, to mark utilities, within sufficient time required. Verify existing utility locations indicated on contract drawings, within area of work.

Identify and mark all other utilities not managed and located by the local utility companies. Scan the construction site with Ground Penetrating Radar (GPR), electromagnetic, or sonic equipment, and mark the surface of the ground or paved surface where existing underground utilities are discovered. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated, or specified to be removed, that is indicated or discovered during scanning, in locations to be traversed by piping, ducts, and other work to be conducted or installed.

Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.5.1 Notification Prior to Excavation

Notify the Contracting Officer at least 15 days prior to starting excavation work.

1.6 GOVERNMENT-FURNISHED MATERIAL AND EQUIPMENT

Pursuant to Contract Clause FAR 52.245-1 Government Property, the Government will furnish the following materials and equipment for installation by the Government:

DESIGNATION

NO.

DESCRIPTION QUANTITY NOTES

Internal Lock Device (ILD)

Magazine Door Lock

10 Internal Lock. Contractor to supply all door boltwork components with the exception of the ILD. Complete the Contractor Magazine Bid Information: Door Locking System form and submit to the DoD Lock Program.

Quantities indicated for the above-listed items marked with an asterisk are estimates. It is the intention of the Government to furnish all quantities of the asterisk items required to complete the work as specified, and the various quantities will be adjusted when necessary.

Quantities stated for the above items not marked with an asterisk are all that will be furnished by the Government. Provide any additional quantities that are required.

SECTION 01 11 00 Page 2

1.6.1 Delivery Schedule

Notify the Contracting Officer in writing at least __60__ calendar days in advance of the date on which the materials and equipment are required.

Pick up materials and equipment no later than 30 calendar days after such date.

1.6.2 Delivery Location

The materials and equipmentwill be delivered to the job site.

1.7 NAVY AND MARINE CORPS INTRANET( NMCI) COORDINATION REQUIREMENTS

1.7.1 NMCI Contractor Access

Allow the NMCI Contractor access to the facility towards the end of construction (finishes 90 percent complete, rough-in 100 percent complete, Inside Plant (ISP)/Outside Plant (OSP) infrastructure in place) to provide equipment in the telecommunications rooms and make final connections.

Coordinate efforts with the NMCI Contractor to facilitate joint use of building spaces during the final phases of construction. After the Contracting Officer has facilitated coordination meetings between the two contractors, within one week, incorporate the effort of additional coordination with the NMCI Contractor into the construction schedule to demonstrate a plan for maintaining the contract duration.

1.8 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged remain the property of the Government. Segregate, itemize, deliver and off-load the salvaged property at the Government designated storage area located within 5 miles of the construction site.

Provide a salvage plan, listing material and equipment to be salvaged, and their storage location. Maintain property control records for material or equipment designated as salvage. Provide a system for property control in the salvage plan. Store and protect salvaged materials and equipment until disposition by the Contracting Officer.

1.9 FIRST RESPONDER DISTRIBUTED ANTENNA SYSTEMS (DAS)

Preform an RF survey of facility by a qualified First Responder DAS system integrator to evaluate the extent that the building construction will interfere with first responder radio communications once the building shell is completed. RF survey results must show that the minimum signal strengths are in accordance with NFPA 101 and NFPA 1225 requirements.

Otherwise, provide a DAS based on RF survey results in accordance with Section 27 53 19.13 First Responder Distributed Antenna Systems.

Design drawings and product specifications for wireless and antenna system installed in facilities that handle ordnance must be submitted to the Naval Surface Warfare Center, Electromagnetic Measurements and Engineering Branch for a RADHAZ review of system. Coordinate submittal requirements with Contracting Officer. Submittals for RADHAZ review must be made in a timely manner to provide sufficient time for review and design revisions based on review, and as not to interfere with Beneficial Occupancy of

SECTION 01 11 00 Page 3 facility.

1.10 EXTENDED LANDSCAPE ESTABLISHMENT WARRANTY PERIOD

Reforestation seedlings require an extended two year establishment and warranty period in accordance with the landscape specifications.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 4

SECTION 01 14 00

WORK RESTRICTIONS

11/22, CHG 1: 02/23

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel

1.2 SPECIAL SCHEDULING REQUIREMENTS

a. Cutting, stumping, and/or prunning of trees is prohibited between 01 APRIL and 15 NOVEMBER of any given year to protect known endangered species (Northern Long-Eared Bat and the tricolored bat) present on the Installation. Disturbance of trees outside within this window is not permitted.

No removal and/or disturbance (within 50 ft) of culverts 36 inches and greater in diameter and 23 feet or greater in length is permited between 01 APRIL and 15 NOVEMBER of any given year to protect known endangered species (Northern Long-Eared Bat and the tricolored bat) present on the Installation. Prior to any distubance within 50 ft of culverts 36 inches and greater in diameter and 23 feet (and greater) in length is permited, the culvert must be surveyed by the Installation Natural Resource Manager for presence or absence of endangered species. No disturbance of and in the vicinity of the culverts that meet this criteria may proceed unless authorized by the NWS Yorktown Natural Resource Manager through the CO.

b. No work within and in the vicinity of wetlands and streams may occur until the wetland and stream permits are approved by the regulatory agencies. The contractor must sign on as a co-permitee upon receipt of the permits and is solely responsible for any natural resource damages and/or notices of violation issued by regulatory agencies. The contractor is responsible for paying the application and mitigation fees required by the permits.

All areas where milkweed is identified should reamin undisturbed to protect the Monarch Butterfly. Coordinate with the Natural Resource Manager if milkweed is identified at the project site.

c. The design requires approval from the Department of Defense Safety Board (DDESB); no mobilization to the site is permitted until the DDESB approval is received unless otherwise authorized by the Contracting Officer.

d. Archeological monitoring is required for all land disturbance activities inside and within 100 feet of known archeological sites and within 100 ft of known or suspected burial and/or cemetary sites. The

SECTION 01 14 00 Page 1 archeological monitor must be a licensed professional with a minimum of 5 years of experience.

1.3 CONTRACTOR ACCESS AND USE OF PREMISES

1.3.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear appropriate personal protective equipment (PPE) in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. A separate Restricted Area badge is required for personnel to enter the Restricted Area where construction work is to be performed. Ensure all Contractor equipment, include delivery vehicles, are clearly identified with their company name.

1.3.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.3.1.2 Installation Access

Obtain access to Navy installations through participation in the Defense Biometrics Identification System (DBIDS). Requirements for Contractor employee registration, and transition for employees currently under Navy Commercial Access Control System (NCACS), are available at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/.

No fees are associated with obtaining a DBIDS credential.

Participation in the DBIDS is not mandatory, and Contractor personnel may apply for One-Day Passes at the Base Visitor Control Office to access an installation.

1.3.1.2.1 Registration for DBIDS

Registration for DBIDS is available at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/.

Procedure includes:

a. Present a letter or official award document (i.e. DD Form 1155 or SF 1442) from the Contracting Officer, that provides the purpose for access, to the base Visitor Control Center representative.

b. Present valid identification, such as a passport or Real ID Act-compliant state driver's license.

c. Provide completed SECNAV FORM 5512/1 to the base Visitor Control Center representative to obtain a background check. This form is available for download at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/.

d. Upon successful completion of the background check, the Government will complete the DBIDS enrollment process, which includes Contractor

SECTION 01 14 00 Page 2 employee photo, fingerprints, base restriction and several other assessments.

e. Upon successful completion of the enrollment process, the Contractor employee will be issued a DBIDS credential, and will be allowed to proceed to worksite.

1.3.1.2.2 DBIDS Eligibility Requirements

Throughout the length of the contract, the Contractor employee must continue to meet background screen standards. Periodic background screenings are conducted to verify continued DBIDS participation and installation access privileges. DBIDS access privileges will be immediately suspended or revoked if at any time a Contractor employee becomes ineligible.

An adjudication process may be initiated when a background screen failure results in disqualification from participation in the DBIDS, and Contractor employee does not agree with the reason for disqualification.

The Government is the final authority.

1.3.1.2.3 DBIDS Notification Requirements

a. Immediately report instances of lost or stolen badges to the Contracting Officer.

b. Immediately collect DBIDS credentials and notify the Contracting Officer in writing under the following circumstances:

(1) An employee has departed the company without having properly returned or surrendered their DBIDS credentials.

(2) There is a reasonable basis to conclude that an employee, or former employee, might pose a risk, compromise, or threat to the safety or security of the Installation or anyone therein.

1.3.1.2.4 One-Day Passes

Personnel applying for One-Day passes at the Base Visitor Control Office are subject to daily mandatory vehicle inspection, and will have limited access to the installation. The Government is not responsible for any cost or lost time associated with obtaining daily passes or added vehicle inspections incurred by non-participants in the DBIDS.

1.3.1.3 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.3.2 Working Hours

Regular working hours will consist of an 8 1/2 hour period as established by the Contracting Officer, between 7 a.m. and 3:30 p.m., Monday through Friday , , excluding Government holidays.

SECTION 01 14 00 Page 3

1.3.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer. Make utility cutovers after normal working hours or on Saturdays, Sundays, and Government holidays unless directed otherwise.

1.3.4 Occupied Buildings

The Contractor shall be working around existing buildings which are occupied or contain ordnance. Do not enter the buildings without prior approval of the Contracting Officer.

The existing buildings and their contents must be kept secure at all times. Provide temporary closures as required to maintain security as directed by the Contracting Officer.

1.3.5 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in paragraph WORK OUTSIDE REGULAR HOURS.

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, and telecommunications and natural gas are considered utility cutovers pursuant to the paragraph WORK OUTSIDE REGULAR HOURS.

d. Operation of Station Utilities: The Contractor must not operate nor disturb the setting of control devices in the station utilities system, including water, sewer, electrical, and steam services. The Government will operate the control devices as required for normal conduct of the work. The Contractor must notify the Contracting Officer giving reasonable advance notice when such operation is required.

e. Connection to Existing Sanitary Sewer Line: Provide positive verification that the existing line conveys sanitary sewer; verify line is not incorrectly connected to a storm drain. Obtain Installation's Sanitary Sewer Connection Permit 2 weeks prior to connection and in accordance with Section 33 30 00 SANITARY SEWERAGE.

1.4 SECURITY REQUIREMENTS

Contract Clause FAR 52.204-2 Security Requirements and Alternate II and the following apply:

SECTION 01 14 00 Page 4

1.4.1 Naval Weapons Station, Yorktown, VA

a. Personnel information. No less than 45 working days prior to start of work, the Contractor will furnish to the Naval Weapons Station (NWS), Yorktown, Security Department, via the Contracting Officer, the following information for Contractor and subcontractor personnel required to enter the station:

(1) Name of company

(2) Name of the employee

(3) Social Security Number

(4) Proof of U.S. citizenship

(5) Completed Contractor/Vendor Criminal History Record Request

(6) Completed application for gate badge

b. Proof of citizenship. Proof of citizenship may consist of copies of birth certificate, military dependent identification card (ID), or naturalization papers, which will be returned once entered into the security computer system. The Security Department will run a criminal history check on Contractor employees and, as a condition of employment, each employee must willingly sign an authorization form allowing the Security Department to conduct the criminal history check. Subject authorization form will be maintained on file by the Security Officer. Based on proof of U.S. citizenship and results of the criminal history check, the Security Officer will or will not grant entry to the station. If entry is denied, the Contractor will be immediately notified.

c. Contractor responsibility for employees. The Contractor is responsible for employees under his employment. Ensure that employees are familiar with and obey station traffic, safety, and security regulations.

d. Motor vehicle operation. Ingress and egress of personnel are subject to the security regulations of the station. Motor vehicles operated within the NWS, Yorktown, must comply with the vehicle codes of Virginia which are incorporated into NWS Instruction 5510.5G, "Security and Traffic Regulations." Copies may be obtained from the Resident Officer in Charge of Construction, NWS, Yorktown, VA.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 14 00 Page 5

SECTION 01 14 00 Page 6

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

11/20, CHG 3: 02/23

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EP 1110-1-8 (2021) Engineering and Design -- Construction Equipment Ownership and Operating Expense Schedule

1.2 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Earned Value Report; G

1.3 EARNED VALUE REPORT

1.3.1 Data Required

This Contract requires the use of a cost-loaded Network Analysis Schedule (NAS). Schedule of Prices must not be used with cost-loaded Network Analysis Schedule (NAS). Use Earned Value Report derived from cost-loaded NAS. Within 15 calendar days of Contract Award, prepare and deliver to the Contracting Officer a Earned Value Report (construction Contract) as directed by the Contracting Officer. Schedule of Prices must have cost summarized and totals provided for each construction category. Provide a detailed breakdown of the Contract price, giving quantities for each of the various kinds of work, unit prices and extended prices. Contractor overhead and profit including salaries for field office personnel, if applicable, must be proportionately spread over all pay items and not included as individual pay items.

1.3.2 Payment Schedule Instructions

Payments will not be made until the Earned Value Report from the cost-loaded NAS has been submitted to and accepted by the Contracting Officer.

Additionally, the Earned Value Report must be separated as follows:

a. Primary Facilities Cost Breakdown:

Defined as work on the primary facilities out to the 5 foot line.

SECTION 01 20 00 Page 1

Work out to the 5 foot line includes construction encompassed within a theoretical line 5 foot from the face of exterior walls and includes attendant construction, such as pad mounted HVAC cooling equipment, cooling towers, and transformers placed beyond the 5 foot line.

b. Supporting Facilities Cost Breakdown:

Defined as site work, including incidental work, outside the 5 foot line.

1.3.3 Schedule Requirements for HVAC TAB

The field work requirements in Section 23 05 93 TESTING, ADJUSTING, AND BALANCING FOR MECHANICAL SYSTEMS must be broken down in the Earned Value Report from the cost-loaded NAS by separate line items which reflect measurable deliverables. The value for each pay item listed below will be established on a case by case basis for each Contract. The line items are as follows:

a. Approval of Design Review Report: The TABS Agency is required to conduct a review of the project plans and specifications to identify any feature, or the lack thereof, that would preclude successful testing and balancing of the project HVAC systems. Submit the resulting findings to the Government to allow correction of the design. The progress payment will not be issued until the report is reviewed and approved.

b. Approval of the pre-field engineering report: The TABS Agency submits a report which outlines the scope of field work. The report must contain details of what systems will be tested, procedures to be used, sample report forms for reporting test results and a quality control checklist of work items that must be completed before TABS field work commences.

c. Season I field work: Incremental payments are issued as the TABS field work progresses. The TABS Agency mobilizes to the project site and executes the field work as outlined in the pre-field engineering report. The HVAC water and air systems are balanced and operational data must be collected for one seasonal condition (either summer or winter depending on project timing).

d. Approval of Season I report: On completion of the Season I field work, the data is compiled into a report and submitted to the Government. The report is reviewed, and approved, after ensuring compliance with the pre-field engineering report scope of work.

e. Completion of Season I field QA check: Contract QC and Government representatives meet the TABS Agency at the jobsite to retest portions of the systems reported in the Season I report. The purpose of these tests are to validate the accuracy and completeness of the previously submitted Season I report.

f. Approval of Season II report: The TABS Agency completes all Season II field work, which is normally comprised mainly of taking heat transfer temperature readings, in the season opposite of that under which Season I performance data was compiled. Compile this data into a report and submit to the Government. On completion of submittal review to ensure compliance with the pre-field engineering report scope, progress payment is issued. Progress payment is less than that

SECTION 01 20 00 Page 2 issued for the Season I report since most of the water and air balancing work effort is completed under Season I.

1.4 CONTRACT MODIFICATIONS

In conjunction with the Contract Clause DFARS 252.236-7000 Modification Proposals-Price Breakdown, and where actual ownership and operating costs of construction equipment cannot be determined from Contractor accounting records, base equipment use rates upon the applicable provisions of the

EP 1110-1-8.

1.5 CONTRACTOR'S INVOICE AND CONTRACT PERFORMANCE STATEMENT

1.5.1 Content of Invoice

Requests for payment will be processed in accordance with the Contract Clause FAR 52.232-27 Prompt Payment for Construction Contracts and FAR 52.232-5 Payments Under Fixed-Price Construction Contracts. Invoices not completed in accordance with contract requirements will be returned to the Contractor for correction of the deficiencies. The requests for payment shall include the documents listed below.

a. The Contractor's invoice, on NAVFAC Form 7300/30 furnished by the Government, showing in summary form, the basis for arriving at the amount of the invoice. Form 7300/30 must include certification by Quality Control (QC) Manager as required by the Contract.

b. The Earned Value Report from the cost-loaded NAS.

c. Contractor's Monthly Estimate for Voucher and Contractors Certification (NAVFAC Form 4330) with Subcontractor and supplier payment certification. Other documents, including but not limited to, that need to be received prior to processing payment include the following submittals as required. These items are still required monthly even when a pay voucher is not submitted.

d. Monthly Work-hour report.

e. Updated Construction Progress Schedule and tabular reports required by the contract.

f. Contractor Safety Self Evaluation Checklist.

g. Updated submittal register.

h. Solid Waste Disposal Report.

i. Certified payrolls.

j. Updated testing logs.

k. Other supporting documents as requested.

1.5.2 Submission of Invoices

If DFARS Clause 252.232-7006 Wide Area WorkFlow Payment Instructions is included in the Contract, provide the documents listed in above paragraph CONTENT OF INVOICE in their entirety as attachments in Wide Area Work Flow (WAWF) for each invoice submitted. The maximum size of each WAWF

SECTION 01 20 00 Page 3 attachment is two megabytes, but there are no limits on the number of attachments. If a document cannot be attached in WAWF due to system or size restriction, provide it as instructed by the Contracting Officer.

Monthly invoices and supporting forms for work performed through the anniversary award date of the Contract must be submitted to the Contracting Officer within 5 calendar days of the date of invoice. For example, if Contract award date is the 7th of the month, the date of each monthly invoice must be the 7th and the invoice must be submitted by the 12th of the month.

1.5.3 Final Invoice

a. A final invoice must be accompanied by the certification required by DFARS 252.247.7023 Transportation of Supplies by Sea, and the Contractor's Final Release. If the Contractor is incorporated, the Final Release must contain the corporate seal. An officer of the corporation must sign and the corporate secretary must certify the Final Release.

b. For final invoices being submitted via WAWF, the original Contractor's Final Release Form and required certification of Transportation of Supplies by Sea must be provided directly to the respective Contracting Officer prior to submission of the final invoice. Once receipt of the original Final Release Form and required certification of Transportation of Supplies by Sea has been confirmed by the Contracting Officer, the Contractor must then submit final invoice and attach a copy of the Final Release Form and required certification of Transportation of Supplies by Sea in WAWF.

c. Final invoices not accompanied by the Contractor's Final Release and required certification of Transportation of Supplies by Sea will be considered incomplete and will be returned to the Contractor.

1.6 PAYMENTS TO THE CONTRACTOR

Payments will be made on submission of itemized requests by the Contractor which comply with the requirements of this section, and will be subject to reduction for overpayments or increase for underpayments made on previous payments to the Contractor.

1.6.1 Obligation of Government Payments

The obligation of the Government to make payments required under the provisions of this Contract will, at the discretion of the Contracting Officer, be subject to reductions and suspensions permitted under the FAR and agency regulations including the following in accordance with FAR

32.103 Progress Payments Under Construction Contracts:

a. Reasonable deductions due to defects in material or workmanship;

b. Claims which the Government may have against the Contractor under or in connection with this Contract;

c. Unless otherwise adjusted, repayment to the Government upon demand for overpayments made to the Contractor; and

d. Failure to maintain accurate "as-built" or record drawings in accordance with FAR 52.236.21.

SECTION 01 20 00 Page 4

1.6.2 Payment for Onsite and Offsite Materials

Progress payments may be made to the Contractor for materials delivered on the site, for materials stored off construction sites, or materials that are in transit to the construction sites under the following conditions:

a. FAR 52.232-5(b) Payments Under Fixed Price Construction Contracts.

b. Materials delivered on the site but not installed, including completed preparatory work, and off-site materials to be considered for progress payment must be major high cost, long lead, special order, or specialty items, not susceptible to deterioration or physical damage in storage or in transit to the construction site. Examples of materials acceptable for payment consideration include, but are not limited to, structural steel, non-magnetic steel, non-magnetic aggregate, equipment, machinery, large pipe and fittings, precast/prestressed concrete products, plastic lumber (e.g., fender piles/curbs), and high-voltage electrical cable. Materials not acceptable for payment include consumable materials such as nails, fasteners, conduits, gypsum board, glass, insulation, and wall coverings.

c. Materials to be considered for progress payment prior to installation must be specifically and separately identified in the Contractor's estimates of work submitted for the Contracting Officer's approval in accordance with Earned Value Report requirement of this Contract.

Requests for progress payment consideration for such items must be supported by documents establishing their value and that the title requirements of the clause at FAR 52.232-5 Payments Under Fixed-Price Construction Contracts have been met.

d. Materials are adequately insured and protected from theft and exposure.

e. Provide a written consent from the surety company with each payment request for offsite materials.

f. Materials to be considered for progress payments prior to installation must be stored either in Hawaii, Guam, Puerto Rico, or the Continental United States. Other locations are subject to written approval by the Contracting Officer.

g. Materials in transit to the job site or storage site are not acceptable for payment.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 20 00 Page 5

SECTION 01 20 00 Page 6

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

11/20, CHG 3: 08/23

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety -- Safety and Health Requirements Manual

1.2 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

View Location Map

Progress and Completion Pictures

1.3 VIEW LOCATION MAP

Submit, prior to or with the first digital photograph submittals, a sketch or drawing indicating the required photographic locations. Update as required if the locations are moved.

1.4 PROGRESS AND COMPLETION PICTURES

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, 1600x1200x24 bit true color minimum resolution in JPEG file format showing the sequence and progress of work. Take a minimum of 20 digital photographs each week throughout the entire project from a minimum of ten different viewpoints selected by the Contractor unless otherwise directed by the Contracting Officer. Submit with the monthly invoice two sets of digital photographs, each set on a separate compact disc (CD) or data versatile disc (DVD), cumulative of all photos to date. Indicate photographs demonstrating environmental procedures.

Provide photographs for each month in a separate monthly directory and name each file to indicate its location on the view location sketch. Also provide the view location sketch on the CD or DVD as a digital file.

Include a date designator in file names. Photographs provided are for unrestricted use by the Government.

1.5 MINIMUM INSURANCE REQUIREMENTS

Provide the minimum insurance coverage required by FAR 28.307-2 Liability, SECTION 01 30 00 Page 1 during the entire period of performance under this contract. Provide other insurance coverage as required by law.

1.6 SUPERVISION

1.6.1 Superintendent Qualifications

Provide project superintendent with a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

1.6.2 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of Contract work.In addition, if a Quality Control (QC) representative is required on the Contract, then that individual must also have fluent English communication skills.

1.6.3 Duties

The project superintendent is primarily responsible for managing subcontractors and coordinating day-to-day production and schedule adherence on the project. The superintendent is required to attend Red Zone meetings, partnering meetings, and quality control meetings. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.6.4 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to ensure timely completion.

Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.7 PRECONSTRUCTION MEETING

Immediately after award, prior to commencing any work at the site, coordinate with the Contracting Officer a time and place to meet for the Preconstruction Meeting. The meeting must take place within 35 calendar days after award of the contract, but prior to commencement of any work at the site. The purpose of this meeting is to discuss and develop a mutual understanding of the administrative requirements of the Contract including but not limited to: daily reporting, invoicing, value engineering, safety, base-access, outage requests, hot work permits, schedule requirements, quality control, schedule of prices or earned value report, shop drawings, SECTION 01 30 00 Page 2 submittals, cybersecurity, prosecution of the work, government acceptance, final inspections and contract close-out. Contractor must present and discuss their basic approach to scheduling the construction work and any required phasing.

1.7.1 Attendees

Contractor attendees must include the Project Manager, Superintendent, Site Safety and Health Officer (SSHO), Quality Control Manager and major subcontractors.

1.8 FACILITY TURNOVER PLANNING MEETINGS (Red Zone Meetings)

Meet with the Government to identify strategies to ensure the project is carried to expeditious closure and turnover to the Client. Start planning the turnover process at the Pre-Construction Conference meeting with a discussion of the Red Zone process and convene at regularly scheduled NAVFAC Red Zone Meetings beginning at approximately 75 percent of project completion. Include the following in the facility Turnover effort:

1.8.1 Red Zone Checklist

a. Contracting Officer's Technical Representative (COTR) will provide the Contractor a copy of the Red Zone Checklist template.

b. Prior to 75 percent completion, modify the Red Zone Checklist template by adding or deleting critical activities applicable to the project and assign planned completion dates for each activity. Submit the modified Red Zone Checklist to the Contracting Officer. The Contracting Officer may request additional activities be added to the Red Zone Checklist at any time as necessary.

1.8.2 Meetings

a. Conduct regular Red Zone Meetings beginning at approximately 75 percent project completion, or three to six months prior to Beneficial Occupancy Date (BOD), whichever comes first.

b. The Contracting Officer will establish the frequency of the meetings, which is expected to increase as the project completion draws nearer.

At the beginning, Red Zone meetings may be every two weeks then increase to weekly towards the final month of the project.

c. Using the Red Zone Checklist as a Plan of Action and Milestones (POAM) and basis for discussion, review upcoming critical activities and strategies to ensure work is completed on time.

d. During the Red Zone Meetings discuss with the COTR any upcoming activities that require Government involvement.

e. Maintain the Red Zone Checklist by documenting the actual completion dates as work is completed and update the Red Zone Checklist with revised planned completion dates as necessary to match progress.

Distribute copies of the current Red Zone Checklist to attendees at each Red Zone Meeting.

1.9 PARTNERING

Contractor shall host the partnering session within 45 calendar days of

SECTION 01 30 00 Page 3 contract award. To most effectively accomplish this Contract, the Contractor and Government must form a cohesive partnership with the common goal of drawing on the strength of each organization in an effort to achieve a successful project without safety mishaps, conforming to the Contract, within budget and on schedule. The partnering team must consist of personnel from both the Government and Contractor including project level and corporate level leadership positions. Key Personnel from the supported command, end user, NAVFAC, PWD, FEAD/ROICC, Contractor, key subcontractors and the Designer of Record are required to participate in the Partnering process.

1.9.1 Facilitated (Formal) Partnering

a. Within 35 calendar days after award and prior to the start of work, host a Formal Partnering session with key personnel from the project team including both Contractor and Government personnel. All costs associated with the Partnering session including the third-party independent Facilitator Consultant, meeting room and other incidental items are the responsibility of the Contractor.

b. Before the Facilitated (Formal) Partnering session, coordinate with the Facilitator all requirements for incidental items (such as audio-visual equipment, easels, flipchart paper, colored markers, note pads, pens/pencils, colored flash cards) and have these items available at the Partnering session. Provide copies of any documents required for distribution to all attendees. Participants will bear their own costs for meals, lodging and transportation associated with Partnering.

c. The Initial Partnering Session must be a duration of one day and be held at a location off base as agreed to by the Contracting Officer.

Partn…