Amendment_No__0010_to_140R2021R0004_0010.pdf

(x)

140R2021R0004 x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Sacramento CA 95825-1898 2800 Cottage Way, Room E-1815

R20

Division of Acquisition Services Regional Office Mid-Pacific Region Bureau of Reclamation

20-C090902/24/20220010

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

09/20/2021

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

A. TITLE: B.F. Sisk Dam SOD Modifications, Phase I

B. PURPOSE: The purpose of this amendment is to incorporate various changes to solicitation documents.

C. DESCRIPTION: This amendment hereby incorporates the following:

1) Temporary office trailers and lab are acceptable.

2) Temporary use of power is acceptable.

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Erik M. Danger

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 2

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

140R2021R0004/0010

3) Deleted Specification limit of 5 submittals:

Section 01 33 00 6 Part 1.06.B.3. Amendment 10

4) Change the assumed Notice to Proceed Date from

March 28, 2022 to April 25, 2022, for Evaluation

Factor 1A, Coordinated Construction Schedule.

(Section L WBR1452.215-81(f)(1a)(b)1. Amendment

10)

5) Remove Attachment J1, Davis-Bacon Act General

Decision Number CA20210018 dated 9/17/2021 and replace with Attachment J1, Davis-Bacon Act

General Decision Number CA20220018 dated 2/17/22, Amendment 10

6) See block 11 for acknowledgement requirements.

7) Acknowledgement of this amendment confirms the

Contractor price is valid for 90 days from date of submission of Final Revised Proposal.

8) Final Revised Proposals are due to the

Contract Specialist and Contracting Officer by

March 7, 2022, at 5:00 pm local time and must be transmitted via Kiteworks. Request the Kiteworks link by emailing Roxana Ahola at rahola@usbr.gov and cc Erik Danger at edanger@usbr.gov by 4:00pm on March 4, 2022.

9) A fully conformed specification sections included in this amendment will be provided at time of award.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

B. F. Sisk Dam SOD Modifications, Phase 1 San Luis Unit, West San Joaquin Division, Central Valley Project, California Specifications No. 20-C0909

Submittals 01 33 00 - 6

3. Responsible code.

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals other than approved or accepted:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 14 days after receiving the comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

1.06 REVIEW OF SUBMITTALS

A. Submittals will be returned Approved (A), Conditionally Approved (CA), or Not Approved (NA), with the following exceptions:

1. Baseline Schedule, Updated Schedule Reports, Safety Data Sheets, Safety

Program, Contractor’s Onsite Safety Personnel, Weekly Safety Reports, Monthly Safety Summary Reports, Weekly Safety Inspection Reports, Fire Prevention and Protection Plan, and Tule Elk Herd Biologist Resume will be returned Accepted (Acc), Conditionally Accepted (CAcc), or Not Accepted (NAcc).

B. Time Required:

1. Submittal review will require 21 days for review of each submittal or resubmittal, unless otherwise specified, with the following exceptions:

a. Division 26 Submittals, 45 Days

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return via CDMS or mailing postmark date. Submittals uploaded to CDMS after normal business hours will be marked received the next business day.

3. More than 5 submittals submitted within one week shall be prioritized by the Contractor and additional time will be required for the review process. Seven days will be added to review time for each submittal submitted over the 5-submittal limit.

C. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time.

a. Time extension will be to extent that excess review time caused delay to contract completion date.

Amendment 0010 rahola Cross-Out

Solicitation No. 140R2021R0004 – BF SISK Safety of Dams (SOD) Modifications

1. A gantt chart schedule that includes such detail to show the sequencing of the principal and critical components of work contained in the solicitation; in addition, any other activities or information needed to accurately portray the offeror’s proposed schedule shall be included. The schedule shall include critical submittals allowing for submittal preparation time and associated Government reviews/approvals. The contractor shall assume a Notice to Proceed date of February 7 March 28, 2022 April 25, 2022 for development of the schedule.

In addition, the contractor shall clearly indicate their assumptions in development of the schedule in relation to the specification requirements related to as a minimum reservoir operation, work restrictions, and shear key excavations.

Format: The gantt chart schedule shall be formatted so that it can be printable on 11x17 sized paper (one sided) and have columns that display the following information in the following order: activity ID and name, planned duration, calendar ID, early start, late start, early finish, late finish and total float. The schedule shall meet the requirements of specification section 01 32 10 – Part 1.06.A, Schedules. The schedule shall be in format compatible with Primavera Professional Project Management. Include electronic copies of the .xer schedule date file and the .plf schedule layout file in accordance with the Instructions to Offerors in the solicitation. The gantt chart schedule shall have no page count restrictions.

2. Schedule Organization Statement: To help facilitate a more efficient and consistent Government review, provide a brief statement that describes how the schedule was organized and summarizes the following information:

a) A listing of the site-specific calendar names and function of the calendars (i.e. 5 day with holiday, 7 day, etc.). List any assumptions used in developing the calendars. The listing of site-specific calendar names and function of calendars and assumptions used in developing calendars shall not exceed 2 pages as defined in part C of this provision.

3. Description of the work-breakdown-structure categories used to organize the Schedule format. The description of the work-breakdown-structure categories used to organize the schedule shall not exceed 2 pages as defined in part C of this provision.

4. Additional pertinent information statement format. The format for any other pertinent information that will facilitate a more efficient review and provide a better understanding of the schedule’s organization. The information included to facilitate a more efficient review and better understanding of the schedule’s organization shall not exceed 2 pages as defined in part C of this provision.

5. Early Completion Statement format. If the proposal offers an early final completion date, the narrative shall clearly indicate the proposed early completion date and any assumptions associated with those dates. This statement shall not exceed 2 pages as defined in part C of this provision.

1b) Factor 1B: Narrative of Construction Sequence: The construction schedule shall relate to items in the Coordinated Construction Schedule and description. Provide the following information for each principle and critical work component listed below:

a) Contents:

1. Contractor(s) responsible for the component of work.

Amendment 0010 rahola Cross-Out rahola Cross-Out

"General Decision Number: CA20220018 02/18/2022

Superseded General Decision Number: CA20210018

State: California

Construction Types: Building, Heavy (Heavy and Dredging) and Highway

Counties: Alameda, Calaveras, Contra Costa, Fresno, Kings, Madera, Mariposa, Merced, Monterey, San Benito, San Francisco, San Joaquin, San Mateo, Santa Clara, Santa Cruz, Stanislaus and Tuolumne Counties in California.

BUILDING CONSTRUCTION PROJECTS; DREDGING PROJECTS (does not include hopper dredge work); HEAVY CONSTRUCTION PROJECTS (does not include water well drilling); HIGHWAY CONSTRUCTION PROJECTS

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that aresubject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.l(a)(2)-(60).

If the contract is entered into on or after January 30, 2022, or the contract is renewed or extended (e.g., an option is exercised) on or after January 30, 2022, Executive Order 14026 generally applies to the contract. The contractor must pay all covered workers at least $15.00 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on that contract in 2022.

If the contract was awarded on or between January 1, 2015 and January 29, 2022, and the contract is not renewed or extended on or after January 30, 2022, Executive Order 13658 generally applies to the contract. The contractor must pay all covered workers at least $11.25 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on that contract in 2022.

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at www.dol.gov/whd/govcontracts.

Modification Number

ASBE0016-004 01/01/2021

Publication Date 01/07/2022

01/14/2022

01/21/2022

02/18/2022

Amendment 0010