Attachment N - Revised Specs.pdf

Building 195 Demolition 1606626 Norfolk Naval Shipyard, Portsmouth, VA

SECTION 01 57 19.00 22

TEMPORARY ENVIRONMENTAL CONTROLS FOR NNSY

08/22

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN SOCIETY OF SANITARY ENGINEERING (ASSE)

ASSE SERIES 5000 (2015) Professional Qualifications Standard for Backflow Prevention Assembly Testers, Repairers and Surveyors

FOUNDATION FOR CROSS-CONNECTION CONTROL AND HYDRAULIC RESEARCH

(FCCCHR)

FCCCHR List (continuously updated) List of Approved Backflow Prevention Assemblies

ASTM INTERNATIONAL (ASTM)

ASTM E2356 (2018) Standard Practice for Comprehensive Building Asbestos Surveys

NAVAL SUPPLY SYSTEMS COMMAND (NAVSUP)

OSHECM CH 320 Consolidated Hazardous Material Reutilization and Inventory Management Program (Latest Revision)

NAVAL DIRECTIVES (ND OPNAVINST)

ND OPNAVINST 5090.1B CH 8 (Change 4) Safe Drinking Water Act Compliance Ashore

ND OPNAVINST 5090.1B CH 12 (Change 4) Non-Bulk Recovery Material Control

NORFOLK NAVAL SHIPYARD INSTRUCTIONS (NNSI)

NNSI P5090.2 VOL II CH 38 Non-Bulk Recovery Material Control

NNSI P5090.2 VOL II CH 40 Emergency and Hazardous Materials Discharge Contingency Plan

NNSI P5090.2 VOL II CH 41 Polychlorinated Biphenyls (PCB) Program

STATE OF VIRGINIA ADMINISTRATIVE CODE (VAC)

12 VAC 5-590-240 Revisions of Approved Plans

12 VAC 5-590-250 Statement Required Upon Completion of

SECTION 01 57 19.00 22 Page 1

Construction

9 VAC 25-840 Title 9, Agency 25, Chapter 840: Erosion And Sediment Control Regulations

9 VAC 25-850 Title 9, Agency 25, Chapter 850: Erosion And Sediment Control And Stormwater Management Certification Regulations

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910.120 Hazardous Waste Operations and Emergency Response

29 CFR 1910.1053 Respirable Crystalline Silica

29 CFR 1926.1153 Respirable Crystalline Silica

40 CFR 50 National Primary and Secondary Ambient Air Quality Standards

40 CFR 60 Standards of Performance for New Stationary Sources

40 CFR 61.145 Standard for Demolition and Renovation

40 CFR 63 National Emission Standards for Hazardous Air Pollutants for Source Categories

40 CFR 64 Compliance Assurance Monitoring

40 CFR 82 Protection of Stratospheric Ozone

40 CFR 112 Oil Pollution Prevention

40 CFR 241 Guidelines for Disposal of Solid Waste

40 CFR 243 Guidelines for the Storage and Collection of Residential, Commercial, and Institutional Solid Waste

40 CFR 258 Subtitle D Landfill Requirements

40 CFR 260 Hazardous Waste Management System: General

40 CFR 261 Identification and Listing of Hazardous Waste

40 CFR 261.7 Residues of Hazardous Waste in Empty Containers

40 CFR 262 Standards Applicable to Generators of Hazardous Waste

40 CFR 263 Standards Applicable to Transporters of Hazardous Waste

40 CFR 264 Standards for Owners and Operators of Hazardous Waste Treatment, Storage, and

SECTION 01 57 19.00 22 Page 2

Disposal Facilities

40 CFR 265 Interim Status Standards for Owners and Operators of Hazardous Waste Treatment, Storage, and Disposal Facilities

40 CFR 266 Standards for the Management of Specific Hazardous Wastes and Specific Types of Hazardous Waste Management Facilities

40 CFR 268 Land Disposal Restrictions

40 CFR 273 Standards for Universal Waste Management

40 CFR 273.2 Standards for Universal Waste Management - Batteries

40 CFR 273.4 Standards for Universal Waste Management - Mercury Containing Equipment

40 CFR 273.5 Standards for Universal Waste Management - Lamps

40 CFR 273.6 Applicability - Aerosol Cans

40 CFR 279 Standards for the Management of Used Oil

40 CFR 300 National Oil and Hazardous Substances Pollution Contingency Plan

40 CFR 300.125 National Oil and Hazardous Substances Pollution Contingency Plan - Notification and Communications

40 CFR 355 Emergency Planning and Notification

40 CFR 403 General Pretreatment Regulations for Existing and New Sources of Pollution

40 CFR 745 Lead-Based Paint Poisoning Prevention in Certain Residential Structures

40 CFR 761 Polychlorinated Biphenyls (PCBs) Manufacturing, Processing, Distribution in Commerce, and Use Prohibitions

49 CFR 171 General Information, Regulations, and Definitions

49 CFR 172 Hazardous Materials Table, Special Provisions, Hazardous Materials Communications, Emergency Response Information, and Training Requirements

49 CFR 173 Shippers - General Requirements for Shipments and Packagings

49 CFR 178 Specifications for Packagings

SECTION 01 57 19.00 22 Page 3

49 CFR 179 Specifications for Tank Cars

1.2 DEFINITIONS

1.2.1 CERCLA

Comprehensive Environmental Response, Compensation and Liability Act of 1980.

1.2.2 Class I and II Ozone Depleting Substance (ODS)

Class I ODS is defined in Section 602(a) of The Clean Air Act. A list of Class I ODS can be found on the EPA website at the following weblink.

https://www.epa.gov/ozone-layer-protection/ozone-depleting-substances .

Class II ODS is defined in Section 602(s) of The Clean Air Act. A list of Class II ODS can be found on the EPA website at the following weblink.

https://www.epa.gov/ozone-layer-protection/ozone-depleting-substances .

1.2.3 Contracting Officer

Government employee who administers contract work, and is the point of contact regarding process performance or OSHE control conflict with the Contractor.

1.2.4 Contractor Generated Hazardous Waste

Contractor generated hazardous waste is materials that, if abandoned or disposed of, may meet the definition of a hazardous waste. These waste streams would typically consist of material brought on site by the Contractor to execute work, but are not fully consumed during the course of construction. Examples include, but are not limited to, excess paint thinners (i.e., methyl ethyl ketone, toluene), waste thinners, excess paints, excess solvents, waste solvents, excess pesticides, and contaminated pesticide equipment rinse water.

1.2.5 Discharge

Discharge means the deposit, injection, dumping, leaking, or placing of any solid, liquid, or gas into the environment.

1.2.6 Disposal

Disposal means placing of any solid or hazardous waste, on or into any land or water, so that such solid or hazardous waste, or any constituent thereof, may not enter the environment.

1.2.7 Electronics Waste

Electronics waste is discarded electronic devices intended for salvage, recycling, or disposal.

1.2.8 Empty Container

Is defined as removal of all free flowing liquid, as can be reasonably expected, or the discharge of material within the container, and not exceeding one inch (1") of residual solid material.

SECTION 01 57 19.00 22 Page 4

1.2.9 Environmental Coordinator (EC)

A person appointed by the Contractor, to be trained by the NNSY Environmental Department (Code 106) in NNSY waste management requirements and processes. This person must provide oversight and management for the planning and execution of compliant waste management processes of the Contractor, and serve as the primary point of contact for the Contractor, in matters concerning Hazardous Waste (HW), Polychlorinated Biphenyls (PCBs), Non-Hazardous Regulated Waste (NHRW), and Solid Wastes (SW). Prior to the commencement of work, the EC will be trained and qualified by Code 106 personnel.

1.2.10 Environmental Pollution and Damage

Environmental pollution and damage is the presence of chemical, physical, or biological elements or agents which adversely affect human health or welfare; unfavorably alter ecological balances of importance to human life; affect other species of importance to humankind; or degrade the environment aesthetically, culturally or historically.

1.2.11 Environmental Protection

Environmental protection is the prevention/control of pollution and habitat disruption that may occur to the environment during construction.

The control of environmental pollution and damage requires consideration of land, water, and air; biological and cultural resources; and includes management of visual aesthetics; noise; solid, chemical, gaseous, and liquid waste; radiant energy and radioactive material as well as other pollutants.

1.2.12 Hazardous Materials

Hazardous materials as defined in 49 CFR 171 and listed in 49 CFR 172 .

Hazardous material is any material that: Is regulated as a hazardous material in accordance with 49 CFR 173 ; requires a Safety Data Sheet (SDS) in accordance with 29 CFR 1910.120 ; or during end use, treatment, handling, packaging, storage, transportation, or disposal that meets, has components that meet, or has the potential to meet, the definition of a hazardous waste, as defined by 40 CFR 261 Subparts A, B, C, or D.

Designation of a material by this definition, when separately regulated or controlled by other sections or directives, does not eliminate the need for adherence to that hazard-specific guidance, which takes precedence over this section for "control" purposes. Such material includes ammunition, weapons, explosive actuated devices, propellants, pyrotechnics, chemical and biological warfare materials, medical and pharmaceutical supplies, medical waste and infectious materials, bulk fuels, radioactive materials, and other materials such as asbestos, mercury, and polychlorinated biphenyls (PCBs).

1.2.13 Hazardous Waste

Hazardous Waste is any material that meets the definition of a solid waste and exhibits a hazardous characteristic (ignitability, corrosivity, reactivity, or toxicity) as specified in 40 CFR 261 , Subpart C, or contains a listed hazardous waste as identified in 40 CFR 261 , Subpart D.

SECTION 01 57 19.00 22 Page 5

1.2.14 Land Application

Land Application means spreading or spraying discharge water at a rate that allows the water to percolate into the soil. No sheeting action, soil erosion, discharge into storm sewers, discharge into defined drainage areas, or discharge into the "waters of the United States" must occur.

Comply with federal, state, and local laws and regulations.

1.2.15 National Pollutant Discharge Elimination System (NPDES)

The NPDES permit program controls water pollution by regulating point sources that discharge pollutants into waters of the United States.

1.2.16 Oily Waste

Oily waste are those materials that are, or were, mixed with Petroleum, Oils, and Lubricants (POLs) and have become separated from that POLs.

Oily wastes also means materials, including wastewaters, centrifuge solids, filter residues or sludges, bottom sediments, tank bottoms, and sorbents which have come into contact with and have been contaminated by, POLs and may be appropriately tested and discarded in a manner which is in compliance with other state and local requirements.

This definition includes materials such as oily rags, "kitty litter" sorbent clay and organic sorbent material. These materials may be land filled provided that: It is not prohibited in other state regulations or local ordinances; the amount generated is "de minimus" (a small amount);

it is the result of minor leaks or spills resulting from normal process operations; and free-flowing oil has been removed to the practicable extent possible. Large quantities of this material, generated as a result of a major spill or in lieu of proper maintenance of the processing equipment, are a solid waste. As a solid waste, perform a hazardous waste determination prior to disposal. As this can be an expensive process, it is recommended that this type of waste be minimized through good housekeeping practices and employee education.

1.2.17 Processed Water

Any water used in industrial activities including, but not limited to, testing, cleaning, and preparing surfaces or equipment.

1.2.18 RCRA

Resource Conservation and Recovery Act. RCRA is the primary source of regulation of solid wastes and hazardous wastes in the United States

1.2.19 Responsible Land Disturber (RLD)

An individual holding a certificate issued by the VDEQ who is responsible for carrying out the land-disturbing activity in accordance with the approved ESC plan. The RLD may be the owner, applicant, permittee, designer, superintendent, project manager, contractor, or any other project or development team member. The RLD must be designated on the ESC plan or permit as a prerequisite for engaging in land disturbance.

1.2.20 Sediment

Sediment is soil and other debris that have eroded and have been transported by runoff water or wind.

SECTION 01 57 19.00 22 Page 6

1.2.21 Solid Waste

Solid waste is a solid, liquid, semi-solid or contained gaseous waste. A solid waste can be a hazardous waste, non-hazardous waste, or non-Resource Conservation and Recovery Act (RCRA) regulated waste as defined in NNSI P5090.2 VOL II CH 52 or 9 VAC 20-81-630.

1.2.21.1 Debris

Debris is non-hazardous solid material generated during the construction, demolition, or renovation of a structure that exceeds 2.5-inch particle size that is: a manufactured object; plant or animal matter; or natural geologic material (for example, cobbles and boulders), broken or removed concrete, masonry, and rock asphalt paving; ceramics; roofing paper and shingles. Inert materials may or may not be reinforced with or contain ferrous wire, rods, accessories and weldments. A mixture of debris and other material such as soil or sludge is also subject to regulation as debris if the mixture is comprised primarily of debris by volume, based on visual inspection.

1.2.21.2 Green Waste

Green waste is the vegetative matter from landscaping, land clearing and grubbing, including, but not limited to, grass, bushes, scrubs, small trees and saplings, tree stumps and plant roots. Marketable trees, grasses and plants that are indicated to remain, be re-located, or be re-used are not included.

1.2.21.3 Material Not Regulated As Solid Waste

Material not regulated as solid waste is nuclear source or byproduct materials regulated under the Federal Atomic Energy Act of 1954 as amended; suspended or dissolved materials in domestic sewage effluent or irrigation return flows, or other regulated point source discharges;

regulated air emissions; and fluids or wastes associated with natural gas or crude oil exploration or production.

1.2.21.4 Non-Hazardous Waste

Any non-radioactive, non-RCRA hazardous waste generated from a Contractor or work operations that requires controlled treatment/disposal in accordance with Navy/NNSY policy, and/or local, state, or federal regulations. As examples, wastes that qualify as NHRW may include (but is not limited to):

Waste items prohibit from being disposed into dumpsters

Waste items that require special packaging/handling per DOT requirements

1.2.21.5 Recyclables

Recyclables are materials, equipment and assemblies such as doors, windows, door and window frames, plumbing fixtures, glazing and mirrors that are recovered and sold as recyclable, wiring, insulated/non-insulated copper wire cable, and structural components. It also includes commercial-grade refrigeration equipment with Freon removed, household appliances where the basic material content is metal, clean polyethylene terephthalate bottles, cooking oil, used fuel oil, textiles, high-grade

SECTION 01 57 19.00 22 Page 7 paper products and corrugated cardboard, stackable pallets in good condition, clean crating material, and clean rubber/vehicle tires. Metal meeting the definition of lead contaminated or lead based paint contaminated may not be included as recyclable if sold to a scrap metal company. Paint cans that meet the definition of empty containers in accordance with 40 CFR 261.7 may be included as recyclable if sold to a scrap metal company.

1.2.21.6 Surplus Soil

Surplus soil is existing soil that is in excess of what is required for this work, including aggregates intended, but not used, for on-site mixing of concrete, mortars, and paving. Contaminated soil meeting the definition of hazardous material or hazardous waste is not included and must be managed in accordance with paragraph HAZARDOUS MATERIAL MANAGEMENT.

1.2.21.7 Scrap Metal

This includes scrap and excess ferrous and non-ferrous metals such as reinforcing steel, structural shapes, pipe, and wire that are recovered or collected and disposed of as scrap. Scrap metal meeting the definition of hazardous material or hazardous waste is not included.

1.2.21.8 Wood

Wood is dimension and non-dimension lumber, plywood, chipboard, hardboard. Treated or painted wood that meets the definition of lead contaminated or lead based contaminated paint is not included. Treated wood includes, but is not limited to, lumber, utility poles, crossties, and other wood products with chemical treatment.

1.2.22 Surface Discharge

Surface discharge means discharge of water into drainage ditches, storm sewers, or creeks meeting the definition of "waters of the United States". Surface discharges from construction sites are discrete, identifiable sources and require a permit from the governing agency.

Comply with federal, state, and local laws and regulations.

1.2.23 Wastewater

Wastewater is the used water and solids that flow through a sanitary sewer to a treatment plant.

1.2.23.1 Stormwater

Stormwater is any precipitation in an urban or suburban area that does not evaporate or soak into the ground, but instead collects and flows into storm drains, rivers, and streams.

1.2.24 Waters of the United States

Waters of the United States means Federally jurisdictional waters, including wetlands, that are subject to regulation under Section 404 of the Clean Water Act or navigable waters, as defined under the Rivers and Harbors Act.

SECTION 01 57 19.00 22 Page 8

1.2.25 Wetlands

Wetlands are those areas that are inundated or saturated by surface or groundwater at a frequency and duration sufficient to support, and that under normal circumstances do support, a prevalence of vegetation typically adapted for life in saturated soil conditions.

1.2.26 Universal Waste

The universal waste regulations streamline collection requirements for certain hazardous wastes in the following categories: aerosol cans, batteries, pesticides, mercury-containing equipment (for example, thermostats), and lamps (for example, fluorescent bulbs). The rule is designed to reduce hazardous waste in the municipal solid waste (MSW) stream by making it easier for universal waste handlers to collect these items and send them for recycling or proper disposal. These regulations can be found at 40 CFR 273 .

1.2.27 TCLP

Toxicity Characteristic Leaching Procedure. Testing is required to determine hazardous characteristics of the waste stream. For waste disposal, a total metals analysis is not a substitute for TCLP testing.

1.2.28 Treatment

Treatment means any method, technique, or process (including neutralization), designed to change the physical, chemical, or biological character or composition of any hazardous waste; so as to neutralize such waste, recover energy or material resources from such wastes, or reduced such waste in volume; so as to render non-hazardous; safer to transport, store, or dispose of; or amenable for recovery.

1.2.29 TSCA

Toxic Substance Control Act, 40 CFR 761 .

1.2.30 Waste Hazardous Material

WHM is defined as a hazardous material by the Shipyard Environmental Department and shall be handled as such. A careful assessment shall be made to ensure these materials are disposed of properly due to their potential to pollute the environment. WHM shall not be disposed of in any Shipyard dumpsters or containers without prior approval of Shipyard Environmental Department (Code 106.32). Examples are work related excess materials that may be used for their intended purpose such as, but not limited to, hydraulic oil, grease, paint and thinners, adhesives, solvents, cutting fluids, corrosion preventive compounds, corrosion removing compounds, aerosol, and batteries. This will also include non-hazardous solid and liquid waste generated from the use of the above materials where applicable

1.3 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00.05 20 CONSTRUCTION SUBMITTAL PROCEDURES and Section

01 33 10.05 20 DESIGN SUBMITTAL PROCEDURES:

SECTION 01 57 19.00 22 Page 9

SD-01 Preconstruction Submittals

Preconstruction Survey and Controls; G

Environmental Manager Qualifications; G

Contractor Employee Training and Records; G

Regulatory Notifications; G

Hazardous Waste/Debris Management; G

Construction General Permit; G

Environmental Protection Plan; G

Dirt and Dust Control Plan; G

Solid Waste Management Permit; G

Dewatering Utility Form; G

Discharge/Flush Authorization Form

Construction General Permit; G

Dewatering Plan; G

Excavated Soils Management Plan; G

SD-06 Test Reports

Monthly Solid Waste Disposal Report; G

Inspection Reports; G

Laboratory Analysis of Abrasive Blasting; G

Backflow Preventer Test Report; G

Laboratory Analysis Reports for Waste Determination; G

SD-07 Certificates

Contractor Employee Training and Records; G

Responsible Land Disturber (RLD); G

Backflow Prevention Training Certificate; G

Laboratory Qualifications; G

SD-11 Closeout Submittals

Contractor Regulatory Contact; G

Solid Waste Management Permit; G

SECTION 01 57 19.00 22 Page 10

Project Solid Waste Disposal Documentation Report; G

Sales Documentation; G

Contractor Hazardous Material Inventory Log; G

Backflow Preventer Manufacturer's Certificate of Full Approval; G

Construction Completion Report; G

1.4 ENVIRONMENTAL PROTECTION REQUIREMENTS

Provide and maintain, during the life of the contract, environmental protection as defined. Plan for and provide environmental protective measures to control pollution that develops during construction repair/demolition activities. Plan for and provide environmental protective measures required to correct conditions that develop during the construction of permanent or temporary environmental features associated with the project. Protect the environmental resources within the project boundaries and those affected outside the limits of permanent work during the entire duration of this Contract. Comply with federal, state, and local regulations pertaining to the environment, including water, air, solid waste, hazardous waste and substances, oily substances, and noise pollution.

Tests and procedures assessing whether construction operations comply with Applicable Environmental Laws may be required. Analytical work must be performed by qualified laboratories; and where required by law, the laboratories must be certified.

1.4.1 Conformance with the Environmental Management System

Perform work under this contract consistent with the policy and objectives identified in the installation's Environmental Management System (EMS).

Perform work in a manner that conforms to objectives and targets of the environmental programs and operational controls identified by the EMS.

Support Government personnel when environmental compliance and EMS audits are conducted by escorting auditors at the Project site, answering questions, and providing proof of records being maintained. Provide monitoring and measurement information as necessary to address environmental performance relative to environmental, energy, and transportation management goals. In the event an EMS nonconformance or environmental noncompliance associated with the contracted services, tasks, or actions occurs, take corrective and preventative actions. In addition, employees must be aware of their roles and responsibilities under the installation EMS and of how these EMS roles and responsibilities affect work performed under the contract.

Coordinate with the NNSY Environmental Department (Code 106), via the Contracting Officer, to identify training needs associated with environmental aspects and the EMS, and arrange training or take other action to meet these needs. Provide training documentation to the Contracting Officer. The NNSY Environmental Department (Code 106) will retain associated environmental compliance records. Make EMS Awareness training completion certificates available to Government auditors during EMS audits and include the certificates in the Employee Training Records. See paragraph CONTRACTOR EMPLOYEE TRAINING AND RECORDS herein.

SECTION 01 57 19.00 22 Page 11

1.5 Contractor Liabilities for Environmental Protection Requirements

The Contractor is responsible for the management, appropriate storage, documentation, and offsite transport and disposal of hazardous material.

NNSY NAVSEA (Code 106) is the generator of hazardous waste; therefore, NAVSEA (Code 106) must review, approve, and sign the hazardous waste manifest prior to the removal of hazardous waste from the site. The Contractor is not relieved of CERCLA or RCRA liability for the disposal of generated hazardous wastes or wastes generated solely by the Contractor, including subcontractors. Nothing contained herein will serve to establish CERCLA liability.

1.6 Heavy Metal Exposure

NNSY Safety Office requires special procedures to protect personnel from airborne exposure to metals of toxic significance; specifically the Occupational Safety and Health Administration's (OSHA) substance specific metals, i.e. Lead, Cadmium, Hexavalent Chromium, and Arsenic.

Contractor's Environmental Coordinators and employees must comply with all applicable Navy Occupational Safety and Health (NAVOSH) and OSHA standards and Contract requirements. Contract requirements are contained herein.

1.7 SPECIAL ENVIRONMENTAL REQUIREMENTS

Comply with the special environmental requirements listed here.

1.7.1 Mid-Atlantic

Comply with the following state, regional, and local requirements.

1.7.1.1 Virginia

1.7.1.1.1 Definition and Disposal Requirements of Empty Paint Cans

Paint Cans: Paint cans that are empty (free of liquids and as defined in 40 CFR 261.7 ) of paints, solvents, thinners and adhesives must be managed as Solid Waste by the Contractor. Manage paint cans with liquid or more than one inch of solidified oil-based paint as a hazardous waste and label properly. Manage paint cans with excess water-based paint as non-hazardous waste provided that they do not contain free liquids or contain any substance with a hazardous characteristic as defined in 40 CFR 261 .

1.7.1.1.2 Erosion and Sediment Control Measures and Stormwater Management

1.7.1.1.2.1 Erosion and Sediment Control

Submit an erosion and sediment control plan, and comply with the requirements specified in the Virginia Erosion and Sediment Control Law and Regulations. (Virginia Code: 9 VAC 25-840 ). Obtain a Certificate of Competency in accordance with 9 VAC 25-850 .

1.7.1.1.2.2 Construction Dewatering

Construction site stormwater runoff must be treated using proper erosion control measures or stormwater management practices prior to release from the construction site. Pollutants, including but not limited to chemicals, fuels, lubricants, sewage, paints, sedimentation, and other harmful materials must not be discharged into or alongside any river, stream, or impoundment, or into any channels leading to them. Implement

SECTION 01 57 19.00 22 Page 12 appropriate erosion and sediment control measures to all disturbed areas or bare soils to prevent unauthorized offsite sedimentation. Apply stabilization measures to denuded portions of a project that are at final grade or where work has temporarily ceased within 7 days. Containerize all dewatering fluids generated on-site from excavation activities and characterize for disposal in accordance with Code 106, US EPA and Virginia DEQ requirements.

1.7.1.1.3 Asbestos Abatement and Notification Procedures

Structures must be surveyed for the presence of asbestos prior to demolition or renovation in accordance with 40 CFR 61.145 . A structure is defined as including any load-bearing portion of a structure. The survey must be performed by a licensed, certified, accredited asbestos inspector in accordance with ASTM E2356.

Notify EPA and Virginia Department of Labor and Industry (VADOLI) at least 20 calendar days before start of asbestos abatement if asbestos is expected to total at least 260 linear feet, 160 square feet, or 35 cubic feet. Provide copies of notifications to the environmental office (Air Manager) through the Contracting Officer prior to beginning work. Make notifications for any project that includes asbestos abatement (and for all demolition projects, regardless of whether asbestos containing materials are present in the structure or facility) in accordance with paragraph DEMOLITION. Notification is not required if asbestos is nonfriable asbestos containing roofing, flooring, or siding materials that when installed, encapsulated, or removed do not become friable. If the material is damaged, the matrix binding the asbestos fibers has deteriorated, or mechanical removal results in more-than-incidental breakage, then notification is required. Activities such as grinding, mechanical chipping, sawing or drilling can make the asbestos containing material friable and would require notification.

1.7.1.1.3.1 Best Management Practices

Use BMPs to ensure EPA and VADOLI requirements are met, including:

preventing airborne emissions via wetting asbestos prior to removal; using glove bags or containment; using HEPA-filtered vacuum or ventilation systems; restricting access to asbestos-control areas until thoroughly cleaned and inspected, and acceptable air-samples have been received.

Consideration should be given to other environmental program requirements such as Clean Water Act (CWA) requirements when making decisions regarding BMPs.

1.7.1.1.3.2 Asbestos Waste Disposal

Refer to the paragraph entitled, "CONTROL AND MANAGEMENT OF ASBESTOS-CONTAINING MATERIAL (ACM)" herein.

1.7.1.1.4 Hazardous Waste Requirements for NNSY

1.7.1.1.4.1 Hazardous and Universal Waste Generation at NNSY

Hazardous and Universal Waste includes fluorescent bulbs, PCB ballast, lead paint, and mercury-containing equipment. Manage waste in a satellite accumulation area (SAA), hazardous waste central accumulation area (HWAA CAA), or universal waste accumulation area (UWAA) as directed by the NNSY Environmental Department (Code 106.3). Keep containers securely closed unless adding or removing material and waste. Ensure the Environmental

SECTION 01 57 19.00 22 Page 13

Coordinator (EC) has been designated and received training from the NNSY Environmental Department (Code 106.33). Keep copies of training records and certificates on site.

1.7.1.1.4.2 Excavation

Store excavated soil in a manner that prevents rain from infiltrating the soil matrix and preventing runoff into the surrounding soil or pavement in lined, covered dumpsters. Sampling and laboratory analysis is required for all excavated soils for disposal. See Section 3.12 Excavation of Soils. If soil is to be shipped to a destination outside the fire ant quarantine area (outside of James City County, York County, Chesapeake, Hampton, Newport News, Norfolk, Poquoson, Portsmouth, Suffolk, Virginia Beach, or Williamsburg) it MUST have a valid inspection certificate issued by an Officer of the Plant Protection and Quarantine Program (PPQ) of the U.S. Department of Agriculture. Contact the EV Pest Management Coordinator for additional information.

1.7.1.1.4.3 Painting and Paint Removal

Keep all paint or solvent containers closed and secured when not adding or removing material or waste. Waste paint chips and debris must be collected and sampled to determine the proper disposal method. Contact the Environmental Department (Code 106.3) for sampling requirements. If waste paint is determined to be hazardous, waste must be managed as hazardous and an appropriate accumulation area must be established.

At all times, to the extent practicable, operations shall be performed in a manner consistent with air pollution control practices for minimizing emissions. If any VOHAP (Volatile Organic Hazardous Air Pollutants) containing materials are being used, containers shall be free of all defects and remain closed unless materials are being added to or removed from them and material is handled in a manner that minimizes spills. Only VOC (Volatile Organic Compounds) compliant coatings permitted to be used.

NO THINNING OF COATINGS PERMITTED.

1.7.1.1.4.4 Dumpsters

Label trash containers to appropriately describe the contents. Dumpsters shall be maintained in a condition that prevents the release of construction trash, debris, etc. to the environment. Dumpsters shall be equipped with a secure cover.

1.7.1.1.5 Air Requirements

1.7.1.1.5.1 Concrete Crushing

Secure an air permit for the crusher from the regulatory agency where the equipment is home-based (in Virginia contact VADEQ). Provide a copy of the permit to the EV Office (Air Program Manager) through the Contracting Officer at least 30 days prior to bringing crusher onsite.

1.7.1.1.6 Spill Response and Reporting

Report spills to the Regional Dispatch Center (RDC) at 757-396-3333 immediately upon discovery. After notifying the installation RDC, notify the Contracting Officer. Refer to the Installation Hazardous Material Reutilization, Hazardous Waste Minimization and Disposal Guide Appendix 3 for spill contact procedures. Refer to Table 1 - Spill Reporting Contact

SECTION 01 57 19.00 22 Page 14

Number for the appropriate point of contact.

1.8 QUALITY ASSURANCE

1.8.1 Preconstruction Survey, Controls and Protection of Features

This paragraph supplements the Contract Clause PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS. Prior to start of any onsite construction activities, perform a Preconstruction Survey and Controls of the project site with the Contracting Officer, and take photographs via the Contracting Officer, showing existing environmental conditions in and adjacent to the site. Submit a report for the record. Include in the report a plan describing the features requiring protection under the provisions of the Contract Clauses, which are not specifically identified on the drawings as environmental features requiring protection along with the condition of trees, shrubs and grassed areas immediately adjacent to the site of work and adjacent to the Contractor's assigned storage area and access route(s), as applicable.

The Contractor and the Contracting Officer will sign this survey report upon mutual agreement regarding its accuracy and completeness. Protect those environmental features included in the survey report and any indicated on the drawings, regardless of interference that their preservation may cause to the work under the Contract.

In the event that the unusual nature or volume of a given waste may exceed the NNSY's expectation, it will be necessary to make special arrangements for the waste(s) in question, prior to generating the waste(s). Where such special arrangements necessitate a change in the scope of this contract, a reasonable and appropriate contractual adjustment will be made pursuant to FAR 52.243-4, "Changes".

1.8.2 Contractor Regulatory Contact

No regulatory agencies will be allowed onto the NNSY without notification to and approval from the NNSY Environmental Department (Code 106), via the Contracting Officer. No information concerning Navy property or operations, or operations performed under a contract with the Navy, must be released to regulatory agencies without approval of the Contracting Officer and the NNSY Environmental Department (Code 106). NNSY Code 106 is the only group with authority to contact regulatory agencies in reference to NNSY permits.

1.8.3 Environmental Brief

Attend an environmental brief to be included in the preconstruction meeting. Provide the following information: types, quantities, and use of hazardous materials that will be brought onto the installation; and types and quantities of wastes/wastewater that may be generated during the Contract. Discuss the results of the Preconstruction Survey at this time.

Prior to initiating any work on site, meet with the Contracting Officer and installation Environmental Office to discuss the proposed Environmental Protection Plan (EPP) or equipment local requirement.

Develop a mutual understanding relative to the details of environmental protection, including measures for protecting natural and cultural resources, required reports, required permits, permit requirements (such as mitigation measures), and other measures to be taken.

SECTION 01 57 19.00 22 Page 15

1.8.4 Environmental Manager

Appoint in writing an Environmental Manager for the project site. The Environmental Manager is directly responsible for coordinating contractor compliance with federal, state, local, and NNSY requirements. The Environmental Manager must ensure compliance with Hazardous Waste Program requirements (including hazardous waste handling, storage, manifesting, and disposal); implement the EPP; ensure environmental permits are obtained, maintained, and closed out; ensure compliance with Stormwater Program requirements; ensure compliance with Hazardous Materials (storage, handling, and reporting) requirements; and coordinate any remediation of regulated substances (lead, asbestos, PCB transformers). This can be a collateral position with the Environmental Coordinator; however, the person in this position must be trained to adequately accomplish the following duties: ensure waste segregation and storage compatibility requirements are met; inspect and manage Satellite Accumulation areas;

ensure only authorized personnel add wastes to containers; ensure Contractor personnel are trained in 40 CFR requirements in accordance with their position requirements; coordinate removal of waste containers; and maintain the Environmental Records binder and required documentation, including environmental permits compliance and close-out. Submit Environmental Manager Qualifications to the Contracting Officer.

1.8.5 Environmental Coordinator

The person in this position must be trained by Code 106 to adequately accomplish the following duties: ensure waste segregation and storage compatibility requirements are met; inspect and manage Satellite Accumulation areas; ensure only authorized personnel add wastes to containers; ensure Contractor personnel are trained in 40 CFR requirements in accordance with their position requirements; coordinate removal of waste containers; and maintain the Environmental Records binder and required documentation, including environmental permits compliance and close-out.

1.8.6 Contractor Employee Training and Records

All employees who handle, store, or transport WHM/HW and solid wastes shall be trained for their respective functions. Prepare and maintain Training Records throughout the term of the contract meeting applicable 40 CFR requirements. Provide Employee Training Records in the Environmental Records Binder. Ensure every employee completes a program of classroom instruction or on-the-job training that teaches them to perform their duties in a way that ensures compliance with federal, state and local regulatory requirements for RCRA Large Quantity Generator. Provide a Position Description for each employee, by subcontractor, based on the Davis-Bacon Wage Rate designation or other equivalent method, evaluating the employee's association with hazardous and regulated wastes. This Position Description will include training requirements as defined in 40 CFR 265 for a Large Quantity Generator facility. Submit these Assembled Contractor Employee Training and Records to the Contracting Officer at the conclusion of the project, unless otherwise directed.

Train personnel to meet EPA and state requirements. Conduct environmental protection/pollution control meetings for personnel prior to commencing construction activities. Conduct additional meetings for new personnel and when site conditions change. Include in the training and meeting agenda: methods of detecting and avoiding pollution; familiarization with statutory and contractual pollution standards; installation and care of

SECTION 01 57 19.00 22 Page 16 devices, vegetative covers, and instruments required for monitoring purposes to ensure adequate and continuous environmental protection/pollution control; anticipated hazardous or toxic chemicals or wastes, and other regulated contaminants; recognition and protection of archaeological sites, artifacts, waters of the United States, and endangered species and their habitat that are known to be in the area.

1.8.7 Non-Compliance Notifications

The Contracting Officer will notify the Contractor in writing of any observed noncompliance with federal, state or local environmental laws or regulations, permits, and other elements of the Contractor's EPP. After receipt of such notice, inform the Contracting Officer of the proposed corrective action and take such action when approved by the Contracting Officer. The Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. FAR 52.242-14 Suspension of Work provides that a suspension, delay, or interruption of work due to the fault or negligence of the Contractor allows for no adjustments to the contract for time extensions or equitable adjustments. In addition to a suspension of work, the Contracting Officer may use additional authorities under the contract or law.

1.8.8 Backflow Preventer Test Report

ND OPNAVINST 5090.1B CH 8 , A certified tester(s) must perform testing of backflow preventer(s) for proper installation and operation, and provide subsequent tagging. Backflow preventer tests must be performed using test equipment and procedures conforming to ASSE SERIES 5000 , latest edition.

Test forms must conform to requirements of local purveyor. Test and tag each backflow preventer upon initial installation and prior to use. Tag must contain the following information: make, model, serial number, dates of tests, results, license number, and signature of tester. Record test results on certification form conforming to requirements cited above.

Form is located at the end of this section

Backflow prevention devices must be inspected and tested by a locally approved and certified backflow assembly tester. Prior to placing the domestic water system in operation, or no later than 5 days after the test, a copy of the test report must be provided to the Contracting Officer. Tester must not be affiliated with any company participating in any other phase of this Contract.

1.8.9 Backflow Preventer Manufacturer's Certificate

Certificate of Full Approval from FCCCHR List , University of Southern California (most current list), attesting that the design, size, and make of each backflow preventer has satisfactorily passed the complete sequence of performance testing and evaluation, for the respective level of approval. Certificate of Provisional Approval will not be acceptable.

Certificates must attest that tests, set forth in each applicable referenced publication, have been performed, whether specified in that publication to be mandatory or otherwise, and that publication control tests have been performed, at the intervals or frequency specified in that publication. Other tests must be performed within 3 years of the date of submittal of certificates on the same type, class, grade, and size of material as is being provided for the project.

SECTION 01 57 19.00 22 Page 17

1.8.10 Backflow Prevention Training Certificate

Prior to testing, submit to the Contracting Officer certification issued by the state, federal or local regulatory agency, attesting that the backflow preventer tester has successfully completed a certification course sponsored by the regulatory agency. Tester must not be affiliated with any company participating in any other phase of this contract.

ND OPNAVINST 5090.1B CH 8 . The Contractor must submit a certificate recognized by the City of Portsmouth and/or the Virginia Department of Health, that states the Contractor has completed at least 10 hours of training in backflow preventer installations. The certificate must be current.

1.8.11 Construction Completion Report

Within 15 days after completion of an approved water system project, submit a Construction Completion Report in accordance with Virginia Department of Health ( 12 VAC 5-590-250 ). A Virginia Department of Health registered professional engineer must sign the report. This report is required for new construction on exterior building potable water system components. Any significant changes from the approved water system design must receive written approval from the Contracting Officer and the Virginia Department of Health per 12 VAC 5-590-240 , prior to use.

1.9 ENVIRONMENTAL PROTECTION PLAN

The purpose of the EPP is to present an overview of known or potential environmental issues that must be considered and addressed during construction. Incorporate construction related objectives and targets from NNSY's EMS into the EPP. Include in the EPP measures for protecting natural and cultural resources, required reports, and other measures to be taken. Prior to initiating any work on site, the Environmental Manager and the Environmental Coordinator will meet with the Contracting Officer and the NNSY Environmental Department (Code 106), to discuss the EPP and develop a mutual understanding relative to the details for environmental protection including measures for protecting natural resources, required reports, and other measures to be taken. Submit the EPP within 15 days after Contract award and not less than 10 days before the pre-construction meeting. Revise the EPP throughout the project to include any reporting requirements, changes in site conditions, or contract modifications that change the project scope of work in a way that could have an environmental impact. No requirement in this section will relieve the Contractor of any applicable federal, state, or local environmental protection laws or regulations. During construction, identify, implement, and submit for approval, any additional requirements to be included in the EPP. Maintain the current version onsite.

Within fourteen days after the environmental protection meeting, revise the EPP to incorporate comments and deficiencies noted at the meeting.

Submit the revised Environmental Protection Plan for further discussion, review, and approval. Commencement of work must not begin until the Environmental Protection Plan has been approved.

The EPP includes, but is not limited to, the following elements:

SECTION 01 57 19.00 22 Page 18

1.9.1 General Overview and Purpose

1.9.1.1 Descriptions

A brief description of each specific plan required by the environmental permit or elsewhere in this Contract such as stormwater pollution prevention plan; dewatering plan; spill control plan; solid waste management plan; wastewater management plan; air pollution control plan;

contaminant prevention plan; a historical, archaeological, cultural resources, biological resources, and wetlands plan; traffic control plan;

Hazardous, Toxic, and Radioactive Waste (HTRW) Plan, and Non-Hazardous Solid Waste Disposal Plan.

1.9.1.2 Duties

The duties and level of authority assigned to the person(s) on the job site who oversee environmental compliance, such as who is responsible for adherence to the EPP, who is responsible for spill cleanup and training personnel on spill response procedures, who is responsible for manifesting hazardous waste to be removed from the site (if applicable), and who is responsible for training the Contractor's environmental protection personnel.

1.9.1.3 Procedures

A copy of any standard or project-specific operating procedures that will be used to effectively manage and protect the environment on the project site.

1.9.1.4 Communications

Communication and training procedures that will be used to convey environmental management requirements to Contractor employees and subcontractors.

1.9.1.5 Contact Information

Emergency contact information (office phone number, cell phone number, and e-mail address).

1.9.2 General Site Information

1.9.2.1 Drawings

Drawings showing locations of proposed temporary excavations or embankments for haul roads, stream crossings, jurisdictional wetlands, material storage areas, structures, sanitary facilities, storm drains and conveyances, and stockpiles of excess soil.

1.9.2.2 Work Area

Work area plan showing the proposed activity in each portion of the area and identify the areas of limited use or nonuse. Include measures for marking the limits of use areas, including methods for protection of features to be preserved within authorized work areas and methods to control runoff and to contain materials on site, and a traffic control plan.

Show where any fuels, hazardous substances, solvents, or lubricants will

SECTION 01 57 19.00 22 Page 19 be stored. Provide a spill plan to address any releases of those materials.

1.9.2.3 Documentation

A letter signed by an officer of the firm appointing the Environmental Manager and stating that person is responsible for managing and implementing the Environmental Program as described in this contract.

Include in this letter the Environmental Manager's authority to direct the removal and replacement of non-conforming work.

1.9.3 Management of Natural Resources

a. Land resources

b. Tree protection

c. Replacement of damaged landscape features

d. Temporary construction

e. Stream crossings

f. Fish and wildlife resources

g. Wetland areas

1.9.4 Protection of Historical and Archaeological Resources

a. Objectives

b. Methods

1.9.5 Stormwater Management and Control

a. Ground cover

b. Erodible soils

c. Temporary and Permanent measures

(1) Structural Practices

(2) Temporary and permanent stabilization

d. Effective selection, implementation and maintenance of Best Management Practices (BMPs).

e. Stormwater Pollution Prevention Plan (SWPPP).

1.9.6 Protection of the Environment from Waste Derived from Contractor Operations

Control and disposal of solid and sanitary waste.

Control and disposal of hazardous waste.

This item consist of the management procedures for hazardous waste to be generated. The elements of those procedures will coincide with the

SECTION 01 57 19.00 22 Page 20

Installation Hazardous Waste Management Plan when within an installation.

The Contracting Officer will provide a copy of the Installation Hazardous Waste Management Plan as…