Amendment 0013.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

N4008523R2527-NOAA OMAO SHIP & SUPPORT FACILITY RELOCATION AT NAVAL STATION NEWPORT, RI

Contact POC: Amanda Bricker, Email: amanda.l.bricker.civ@us.navy.mil

See continuation pages

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 09-Aug-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008523R2527

X 9B. DATED (SEE ITEM 11)

24-Jan-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

09-Aug-2023

CODE

NAVFACSYSCOM MID-ATLANTIC

CONTRACTING CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

N40085 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008523R2527

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0013

This amendment is issued to incorporate the following:

1. Update Section 00 21 16 - Instructions to Proposers

1. Update Section 00 21 16 -Instructions to Proposers-

3. EVALUATION FACTORS FOR AWARD

3. Basis of Evaluation and Submittal Requirements for Each Factor.

(2) Basis of Evaluation:

(b) Non-price Factors:

(2) Factor 2 - Management Approach and Schedule:

(i)Solicitation Submittal Requirements:

From:

The schedule shall include, but not limited to: Provide a Critical Path Method (CPM) construction schedule that illustrates your ability to achieve the schedule and meet all the requirements of the RFP (850 calendar days, including 15 days for bond approval). The schedule shall be based on a contract award date of 1 August 2023.

This date is for proposal purposes only and is not intended to indicate an anticipated/planned award date.

To:

The schedule shall include, but not limited to: Provide a Critical Path Method (CPM) construction schedule that illustrates your ability to achieve the schedule and meet all the requirements of the RFP (850 calendar days, including 15 days for bond approval). The schedule shall be based on a contract award date of 15 November 2023. This date is for proposal purposes only and is not intended to indicate an anticipated/planned award date.

(ii) Basis of Evaluation:

From:

Offerors will be evaluated on the extent to which they demonstrate a clear understanding of the requirements of the RFP. A narrative work plan that identifies areas of risk in logistics and resource management, and provides a comprehensive contingency plan that addresses mitigation of any identified risks with potential solutions, may be considered more favorably. A schedule that proposes a realistic contract duration shorter than the required duration indicated in the RFP may be considered more favorably. A schedule that proposes a contract duration longer than indicated in the RFP will be rated UNACCEPTABLE.

N4008523R2527

To:

Offerors will be evaluated on the extent to which they demonstrate a clear understanding of the requirements of the RFP. A narrative work plan that identifies areas of risk in logistics and resource management, and provides a comprehensive contingency plan that addresses mitigation of any identified risks with potential solutions, may be considered more favorably. A schedule that proposes a realistic contract duration shorter than the required duration indicated in the RFP may be considered more favorably. If unable to meet the milestone dates of the RFP, the Offeror shall submit the best possible schedule.

(End of Summary of Changes)