AMENDMENT 0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

SOLICITATION NO. N40085-21-R-0052, DBB P-1043 WATER TREATMENT PLANT, HADNOT POINT, MCB, CAMP LEJEUNE, NC

The purpose of this amendment is to provide Site Visit information, update Liquidated Damages, and provide an updated Price Proposal Form.

The proposal due date has been extended from 24 June 2021 to 08 July 2021, NLT 2:00 PM EST.

See Continuation Page(s).

1. CONTRACT ID CODE PAGE OF PAGES

J 1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 17-May-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008521R0052

X 9B. DATED (SEE ITEM 11)

10-May-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-May-2021

CODE

NAVFACSYSCOM MID-ATLANTIC

ACQUISITION CORE

9324 VIRGINIA AVENUE

NORFOLK VA 23511-3095

N40085 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008521R0052

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 0001

Site Visit Details

A site visit is scheduled for Tuesday, 08 June 2021 at 1:30 PM EST.

(Please note, only one (1) site visit for this project will be coordinated.)

All participants shall submit a list of attendees to Tony Benson via email at tony.d.benson1@navy.mil no later than 1:00 PM EST on Tuesday, 1 June 2021. This list should also indicate whether each attendee has Base access or will require sponsorship at the Visitor’s Center on the day of the site visit. All participants without DBIDS access to MCB Camp Lejeune shall list the name of each attendee exactly as it appears on the ID to be presented at the Visitor’s Center. Participants requiring sponsorship should be aware that wait times at the Visitor’s Center vary, but can be as long as two hours, and that the site visit will begin promptly at 1:30 PM EST without delay.

Meeting Location: Participants shall meet at Building 1005, Michael Road, Camp Lejeune no later than 1:30 P.M

EST.

Site Visit Point of Contact: Tony Benson, (910-451-2582), tony.d.benson1@navy.mil. Tony Benson will meet site visit attendees at the meeting location.

All attendees shall be prepared to show valid Government-Issued Driver’s License or Photo ID to enter the facility.

PPI’s

Contractor

PPI#

Section of RFP or Page Number

Paragraph Reference

Drawing Number

Question RESPONSE

1 Page 5 of 63 1.1.4 N/A The RFP notes that the estimated magnitude of construction is $25- 100M. The range provided is not adequate for Offerors to determine the budget available for this complex project.

Typically in NAVFAC MILCON proposals, Offerors are provided a Construction Cost Limitation for the Base Bid Item and any Option Items. These values allow Offerors to perform an internal parametric cost estimate to determine if they can deliver the project requirements for the budgeted amount. Since this is the third time that this procurement has been solicited, and given the extreme volatility of the construction materials market, Offerors need to know if this project is awardable prior to investing significant resources in preparation of a response. Please provide a CCL or IGE for this project.

No Government estimate will be provided.

2 Attachment H, Supplemental Instructions

Entire Document

N/A We have made multiple attempts to download Attachment H using various internet browsers and updated Adobe Acrobat software, but we are unable to read the document.

Please provide a document with readable content. Thank you.

A revised Attachment H has been provided with this Amendment

3 Page 1 of 63 13. D N/A The RFP states that we must guarantee our bid for no less than 120 calendar days. Given the recent extreme commodity price volatility will the government consider decreasing the number of days we must guarantee our bid?

Propose per RFP.

4 Page 17 of 63 4.1 N/A Given that the site walk has not yet been scheduled, will the government extend the bid submission date by at least 30 days?

Site visit has been scheduled for 08 June 2021 per Amendment 0001.

Proposal due date has been extended to 08 July 2021, NLT 2:00 PM EST.

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 24-Jun-2021 02:00 PM to 08-Jul-2021 02:00 PM.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $5,983.95 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)