AMD0001.pdf

ACQR5969918

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See revised SOW attached IAW specification SR#21828261/ePro#1740518 for PREVENTIVE MAINTENANCE (PM) AND SERVICE ORDERS FOR VARIOUS ELECTRIC SYSTEMS AT KANTO PLAIN BY COMBINATION CONTRACT OF RECURRING WORK & NON-RECURRING WORK /

INDEFINITE DELIVERY INDEFINITE QUANTITY (IDIQ) CONTRACT.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 23-May-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008423B0405

X 9B. DATED (SEE ITEM 11)

18-May-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

24-May-2023

CODE

NAVFAC FAR EAST

FEAD YOKOSUKA

PSC 473 BOX 13

FPO AP 96349-0013

N40084 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008423B0405

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMD#0001

1. Revised SOW attached to add the new Security Camera PMI at YSK-1969 and scheduled repair work at Third Option Period of Auxiliary Generator at YSK-3849 (SHOBU).

2. The bid proposal due date (June 20, 2023, 10:30 AM) will be unchanged.

3. All other terms & conditions remain unchanged.

SECTION SF 1449 - CONTINUATION SHEET

TABLE OF CONTENTS

The Table of Contents has changed from:

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 23B0405B (S&Ds) 1349 04-JAN-2023 Attachment 2 23B0405C (NOTICE) 8 05-APR-2023 to:

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 AMD#0001-S 139 19-MAY-2023

(End of Summary of Changes)

Section C – 0200000

Management and Administration

0200000 – Management and Administration Spec Item Title

2 Management and Administration

2.1 Definitions and Acronyms

2.2 General Information

2.2.1 Government Regular Working Hours

2.2.1.1 Observed Federal Holidays

2.2.1.2 Restriction to Contractor Working Hours

2.2.2 Wage Determinations

2.2.3 Requirements Hierarchy

2.3 General Administrative Requirements

2.3.1 Required Conferences and Meetings

2.3.2 Training for Maintenance and Operation of New and Replacement Systems and Equipment

2.3.3 Partnering

2.3.3.1 Informal Partnering

2.3.3.2 Contract Partnering Administration

2.3.3.3 Contract Partnering Session Attendees

2.3.4 Permits and Licenses

2.3.5 Insurance

2.3.5.1 Certificate of Insurance

2.3.5.2 Minimum Insurance Amounts

2.3.6 Protection of Government Property

2.3.7 Directives, Instructions, and References

2.3.8 Invoicing Procedures

2.3.9 Forms

2.3.10 Performance Evaluation

2.4 Government-Furnished Items

2.4.1 Government-Furnished Property (GFP)

2.4.2 Government-Furnished Facilities (GFF)

2.4.3 Government-Furnished Vehicles and Equipment

2.4.4 Government-Furnished Utilities

2.5 Contractor-Furnished Items

2.6 Management

2.6.1 Safeguarding Information

2.6.2 Dissemination of Information

2.6.3 Work Reception

2.6.4 Work Control

2.6.5 Work Schedule

2.6.6 Deliverables

2.6.7 Service Interruptions

2.6.8 NAVFAC MAXIMO

2.6.8.1 NAVFAC MAXIMO Data

2.6.8.2 NAVFAC MAXIMO Method of Data Entry

2.6.9 Quality Management System (QMS)

2.6.9.1 Quality Management (QM) Plan

2.6.9.2 Quality Inspection and Surveillance

2.6.9.3 Quality Inspection and Surveillance Report

2.6.10 Property Management Plan

2.6.11 System and Equipment Replacement

2.6.12 Mobilization

2.6.12.1 Mobilization / Phase-In

2.6.12.2 Demobilization / Phase-Out

2.7 Personnel Requirements

2.7.1 Key Personnel

2.7.1.1 Project Manager (PM)

2.7.1.2 Quality Manager

2.7.1.2.1 Quality Control Personnel

2.7.1.3 Site Safety and Health Officer (SSHO)

2.7.1.4 Environmental/Energy Manager

2.7.2 Employee Requirements

2.7.2.1 Employee Certification and Training

2.7.2.2 Employee Appearance

2.7.2.3 Employee Conduct

2.7.2.4 Identification as Contractor Employee

2.7.2.5 Removal of Employees

2.7.2.6 Proof of Legal Residency

2.7.3 Service Contract Reporting (SCR)

2.8 Security Requirements

2.8.1 Employee List

2.8.2 Vehicles

2.8.3 Passes and Badges

2.8.4 Access to Installation

2.8.4.1 DBIDS Program

2.8.4.2 DBIDS Credentials

2.8.5 Access to Buildings

2.8.6 Access Arrangements

2.8.6.1 Escort Arrangement for Secured Areas

2.8.7 Security Clearances

2.8.8 Access to Controlled Unclassified Information

2.8.8.1 Information Security

2.8.8.2 Information Safeguarding Requirements

2.8.8.3 Disclosure of Information Requirements

2.8.8.4 Operations Security (OPSEC) Requirements

2.8.8.5 Violation of the Information Security Requirement

2.8.9 Access to Government Information Technology (IT), Operation Technology (OT), and Facility

Related Control Systems (FRCS)

2.8.10 Access to Navy Marine Corps Intranet (NMCI)

2.8.11 Employee Status

2.9 Contractor Safety Program

2.9.1 Contractor Safety Requirements

2.9.1.1 Experience Modification Rate (EMR)

2.9.1.2 OSHA Days Away From Work, Restricted Duty, or Job Transfer (DART) Rate

2.9.2 Accident Prevention Plan (APP)

2.9.3 Activity Hazard Analysis (AHA)

2.9.4 Safety and Occupational Health (SOH) Risks and Compliance Plans

2.9.4.1 Alcohol and Drug Abuse Prevention Plan

2.9.4.2 Chemical Hazard Communication Program

2.9.4.3 Confined Space Program

2.9.4.4 Critical Lift Plan

2.9.4.5 Fall Prevention and Protection Plan

2.9.4.6 Pathogen Exposure

2.9.4.7 Control of Hazardous Energy (lockout/tagout)

2.9.5 Crane Operations

2.9.5.1 Crane Inspections

2.9.5.2 Rigging Gear

2.9.5.3 Crane Operators

2.9.6 Accident and Damage Reporting

2.9.6.1 Accident Reporting and Notification Criteria

2.9.6.2 CFAY Accident Reporting Notification

2.9.7 Fire Protection

2.9.8 Monthly On-Site Labor Report

2.9.9 OSHA Citations and Violations

2.9.9 Japanese Labor Standards Inspection Office (LSIO) Citations and Violations

2.9.10 Safety Inspections and Monitoring

2.9.11 Safety Certification

2.9.12 Safety Apparel on Jobsites

2.9.13 Emergency Medical Treatment

2.9.14 Excavations

2.10 Environmental Management and Sustainability

2.10.1 Energy Management Program

2.10.1.1 Water Conservation Plan

2.10.1.2 Energy Efficient Products

2.10.2 Environmental Protection

2.10.2.1 Sampling, Testing and Laboratory Services

2.10.2.2 ODS Requirements for Refrigerant Recycling

2.10.2.3 Solid Waste Management and Recycling

2.10.2.4 Non-Regulated Waste Disposal

2.10.2.5 Regulated Waste Disposal

2.10.2.6 Universal Waste

2.10.2.7 Spill Prevention, Containment, and Clean-up

2.10.2.8 Hazardous Material Management

2.10.2.9 Protection of Endangered and Threatened Species (Flora and Fauna)

2.10.2.10 Noise Control

2.10.2.11 Salvage

2.10.2.12 Asbestos Containing Material (ACM)

2.10.2.13 Air Quality

2.10.3 Sustainable Procurement and Practices

2.10.3.1 Environmentally Preferable Products

2.10.3.2 Use of Recovered Materials

2.10.3.3 Use of Biobased Products

2.11 Disaster Preparedness

2.12 Technical Library

2.13 Warranty Management

2.14 Recurring Work Procedures

2.14.1 Recurring Work Preparation of Proposals

2.14.2 Notification to the Government for Work Above the Recurring Work Limitations

2.14.3 Recurring Work Exhibit Line Item Numbers (ELINs)

2.15 Non-Recurring Work

2.15.1 Unit Priced Task (UPT) Work (Non-Negotiated)

2.15.1.1 Acceptance and Performance

2.15.1.2 Invoicing and Receiving Payment

2.15.2 Unit Priced Labor (UPL)Work (Negotiated)

2.15.2.1 Non-recurring Work Preparation of Proposals

2.15.2.1.1 Labor Requirements

2.15.2.1.2 Direct Material and Construction Equipment Requirements

2.15.2.2 Issuance of Final Task Order

2.15.3 Non-recurring work ELINs

2.16 Performance Evaluation

0200000 - Management and Administration Spec Item Title Description 2 Management and

Administration

2.1 Definitions and

Acronyms

Definitions and Acronyms are listed in J-0200000-01.

2.2 General

Information

2.2.1 Government

Regular Working Hours

The Government's regular working hours are from 0800-1645, five days per week, Monday through Friday, except observed Federal holidays. Exceptions to the regular hours of operation are detailed in subsequent sections of this performance work statement (PWS). Work in certain annexes or sub-annexes require Contractor continuous operations, 24 hours a day, every day of the year including holidays. The performance of other work requirements shall be accomplished within the Government’s regular working hours unless the specific work requirement specified herein necessitates otherwise. Any other work outside Government regular working hours must be authorized by the Contracting Officer (KO) prior to commencement of work.

2.2.1.1 Observed Federal

Holidays

The Government observes the following holidays: New Year’s Day, Martin Luther King Jr.’s Birthday, President’s Day, Memorial Day, Juneteenth, Independence Day, Labor Day, Columbus Day, Veterans’ Day, Thanksgiving Day, and Christmas Day.

2.2.1.2 Restriction to

Contractor Working Hours

If the Contractor wishes to work outside of the Government's regular working hours for the Contractor’s convenience, the Contractor shall submit a written Request to Work Outside Government’s Regular Working Hours per Section F. Excludes work to be performed during specified hours.

Unless otherwise specified, the Contractor’s normal working days for performing contract requirements are from Monday through Friday except federal holidays during the Government Regular Working Hours above.

During the carrier is staying at Berth 12, the following onsite PM and/or repair work needed to take outage will not be allowed.

• Extra High Voltage Receiving & Distribution Systems at Yokosuka area

• Power Receiving System of Land Cranes LC-47 & 48

During the ships are staying at Berths and/or Dry Docks, the following onsite PM and/or repair work needed to take outage will not be allowed.

• Extra High Voltage Sub-station (Transformer)

The work needed to take electrical power outage for the Ikego Housing Area will not be allowed on summer season and winter season in general.

2.2.2 Wage

Determinations

N/A.

2.2.3 Requirements

Hierarchy

Requirements or definitions specified in each spec item of this contract apply to subordinate paragraphs. For example, requirements shown in spec item 3.1 would apply to spec items 3.1.1, 3.1.2, 3.1.2.1 and so on.

Likewise, Performance Standards specified at a lower digit level (i.e. spec item 3.1.1, 3.1.2, 3.1.2.1) apply when performance is assessed at a higher tier (i.e., spec item 3.1) based on the composite work requirements.

2.3 General

Administrative Requirements

2.3.1 Required

Conferences and Meetings

The Contractor shall attend administrative and coordination meetings. The Pre-Performance Conference meeting shall be held within 14 calendar days after the date of award. The Contractor shall attend meetings as shown in J- 0200000-02. Submit request for the pre-performance conference per Section F.

The Contractor shall provide sign-in sheets and prepare minutes of all meetings and submit per Section F for review and comments. Comments received within two working days shall be incorporated into the minutes and a copy of the final revision shall be submitted per Section F for concurrence.

Required meetings may be held remotely as directed by KO.

2.3.2 Training for

Maintenance and Operation of New and Replacement Systems and Equipment

When construction, renovation, or repair work is performed by means other than this contract, the Contractor shall attend Government provided training, as applicable, for maintenance and operation of new and replacement systems and equipment at no additional cost to the Government.

2.3.3 Partnering The Government requires cohesive partnerships with its Contractors and subcontractors. Key stakeholders, including the supported commands who may receive services, principal individuals from Naval Facilities Engineering Systems Command (NAVFAC), the performance assessment team, and representative(s) of the installation(s) will be invited to participate in the partnering process. Key members of the prime and sub-contractor teams, including senior management personnel must participate. The partnership will draw on the strength of each organization in an effort to achieve quality contract services done right the first time, within the contract price, as scheduled, and without any safety mishaps.

- The goal of Partnering is to develop a cohesive team with common purpose, commitment and established communication processes.

2.3.3.1 Informal

Partnering

The KO shall organize the initial Partnering Meeting with key personnel of the project team, including Contractor's personnel and Government personnel.

The initial session will be scheduled concurrent with the Pre-Performance Conference and held no later than 30 days after award and will be held at a Government provided facility as designated by the KO.

The Initial Informal Partnering Session will be conducted and facilitated by the KO. The senior Government stakeholder present will lead the meeting, however, the Contractor’s Project Manager (PM) or senior representative is encouraged to participate as co-lead.

The Partners will determine the frequency of the follow-on sessions.

2.3.3.2 Contract

Partnering Administration

Upon award, the Administrative Contracting Office (ACO) will contact the Contractor, supported command(s), Region, and Installation(s) stakeholders, and the performance assessment team to discuss implementation of partnering.

The Core Management Team consisting of the attendees below must be present during the initial and all follow-on partnering sessions. These are the core mandatory attendees. Other stakeholders may attend if they desire or as recommended by the partners.

2.3.3.3 Contract

Partnering Session Attendees

The Contractor shall bring the necessary personnel to successfully partner on this contract. Asterisk indicates mandatory personnel.

President/Vice President

* Project Manager (PM)

* Quality Manager (QM) Site Safety and Health Officer (SSHO)

2.3.4 Permits and

Licenses

The Contractor shall obtain all required permits, licenses, and authorizations to perform work under this contract and comply with all the applicable Federal, host nation (Japanese), prefecture, and local laws and regulations.

The Contractor shall submit copies of Permits and Licenses per Section F.

2.3.5 Insurance The Contractor shall submit a Certificate of Insurance per Section F as evidence of the existence of the following insurance coverage in amounts not less than the amounts specified below in accordance with the FAR Clause

52.228-5, INSURANCE – WORK ON A GOVERNMENT

INSTALLATION. This insurance must be maintained during the performance period.

2.3.5.1 Certificate of

Insurance

The Certificate of Insurance shall provide for at least 30 calendar days written notice to the KO by the insurance company prior to cancellation or material change in policy coverage. Other requirements and information are contained in the aforementioned insurance clause.

2.3.5.2 Minimum

Insurance Amounts

The Contractor shall procure and maintain, during the entire period of performance under this contract, the following minimum insurance coverage:

Comprehensive General Liability: ¥50,000,000 per occurrence

Automobile Liability: ¥20,000,000 per person, ¥50,000,000 per occurrence for bodily injury, ¥3,000,000 per occurrence for property damage

Workmen's Compensation: As required by Japanese worker's compensation and occupational disease statutes

Employer's Liability coverage: ¥10,000,000

Other as required by Japanese Law

2.3.6 Protection of

Government Property

During execution of the work, the Contractor shall protect Government property. The Contractor shall return areas damaged as a result of Contractor negligence under this contract to their original condition at no cost to the Government.

2.3.7 Directives, Instructions, and References

Department of Defense (DoD), Secretary of the Navy (SECNAV), Chief of Naval Operations (OPNAV), and other applicable Directives, Instructions, and References are listed in J-0200000-03. The Contractor shall comply with the most current version of directives, instructions, and references including versions published during the term of the contract.

2.3.8 Invoicing

Procedures

Refer to Section G for invoicing instructions. Refer to Invoice Form in J- 0200000-04.21 for sample, and following accessible address of WAWF's website: https://piee.eb.mil/ Login address of above:

https://piee.eb.mil/xhtml/unauth/home/login.xhtml

Invoices shall be submitted in a format compatible with the most recent Government installed Microsoft Office Version (currently 2016). Invoice data shall be capable of being sorted by CLIN, annex/sub-annex, spec item, spec item title, and Exhibit Line Item Numbers (ELIN)/Sub-ELIN.

Non-recurring services as issued of task order, or One time contract invoices required performance record, unless otherwise direction by the KO.

https://piee.eb.mil/ https://piee.eb.mil/xhtml/unauth/home/login.xhtml

2.3.9 Forms Forms referenced in this Annex, e.g. accident reporting, and damage reporting are included among the Forms in J-0200000-04.

2.3.10 Performance

Evaluation The Contractor’s performance will be evaluated using the Contractor Performance Assessment Reporting System (CPARS) located on the website https://www.cpars.gov. On-line training for Contractor personnel is available on the website.

Prior to commencement of work the Contractor is required to provide the Government with the name, phone number and e-mail address of the “Contractor’s Representative” that will be responsible for receipt and review of draft performance evaluations prepared by the Government. It is the Contractor’s responsibility to keep this contact information current and provided changes to the KO.

2.4 Government-

Furnished Items

Except for items identified below as Government-Furnished, the Contractor shall furnish all labor, supervision, management, tools, materials, equipment, facilities, transportation, incidental engineering, and other items necessary to provide the services described in this PWS.

Government-Furnished Items will be provided in "AS-IS" condition and their use is at the option of the Contractor. The total or partial breakdown or failure of Government-Furnished Items shall not relieve the Contractor of the responsibility to perform the requirements of this contract.

The Contractor shall provide periodic servicing, maintenance, and repair of the Government-Furnished Items accepted for use at no additional cost to the Government. Servicing, maintenance, and repair shall be provided in accordance with the manufacturer’s recommendations. The Contractor shall generate work orders in NAVFAC Maximo per Spec Item 2.6.8 for all servicing, maintenance, and repair activities performed on Government- Furnished Items.

At the completion of the contract, all Government-Furnished Items shall be returned to the Government in the same condition as received, except for reasonable wear and tear. Government-Furnished Items, which becomes worn out due to normal wear and tear, shall be returned to the Government and its replacement shall be the responsibility of the Contractor at no additional cost to the Government. The Contractor shall be responsible for the cost of any repairs or replacement caused by Contractor negligence or abuse.

The Government may inspect Government-Furnished Items at any time and without notice.

2.4.1 Government-

Furnished Property

(GFP)

None.

2.4.2 Government-

Furnished Facilities (GFF)

None.

2.4.3 Government-

Furnished Vehicles and Equipment

None.

2.4.4 Government-

Furnished Utilities

The Government will make available water and electricity at existing outlets required for the work to be performed under the contract. The Contractor shall provide and maintain, at its expense, the necessary service lines from the existing Government outlets to the work site. Provide and maintain backflow prevention devices on connections to domestic water lines and electrical transformer provisions on connections to electric lines. Meet all Federal, State, local, and installation codes and regulations for backflow prevention devices and electrical transformer provisions. Services required by the Contractor, for which there are no available Government outlets, shall be provided by the Contractor at no cost to the Government.

2.5 Contractor-

Furnished Items

Except for items identified as Government Furnished, the Contractor shall provide all equipment, materials, parts, supplies, components, and facilities to perform the requirements of this contract. The KO may inspect Contractor-furnished items for adequacy and compliance with contract requirements.

Inadequate or unsafe items shall be removed and replaced by the Contractor at no cost to the Government. Materials containing asbestos, lead, and polychlorinated biphenyls (PCBs) shall not be brought onsite. Energy efficient tools and equipment shall be used when available. The KO may at any time require Samples, Safety Data Sheets (SDS) or Manufacturer’s Data Cut Sheets of Materials used in this contract.

2.6 Management The Contractor shall manage the total work effort associated with the services required herein to meet the performance objectives and standards. Such management includes but is not limited to planning, scheduling, cost accounting, report preparation, establishing and maintaining records, and quality assurance. The Contractor shall provide a staff with the necessary management expertise to ensure performance objectives and standards are met.

2.6.1 Safeguarding

Information

The Contractor shall safeguard controlled unclassified information and information associated with Government property in accordance with the latest revision of CNSSI 1253, DoDI 8582.01, NIST SP 800-53, NIST SP 800-171, SECNAV Defense Industrial Base (DIB) Memo, and applicable contract clauses. At a minimum, this information shall be protected at the moderate confidentiality level as defined in NIST SP 800-171. Refer to Spec Item 2.8.8.3 Disclosure of Information Requirements, and DI-MGMT-82247 Contractor’s System Security Plan and Associated Plans of Action to Implement NIST SP 800-171 on a Contractor’s Internal Unclassified Information System, for more detailed information.

Contractor information and data systems that contain information associated with Government property shall comply with DoD Risk Management Framework (RMF).

The Contractor shall develop Plans of Action and Milestones (POA&Ms) per NIST SP 800-171, track accomplishment, and submit to the Government per Section F.

If a cybersecurity incident is encountered or suspected related to any (Contractor or Government) Information Technology (IT) or Operating Technology (OT) systems, including Monitoring and Control Systems, the Contractor shall notify the Government per Section F.

2.6.2 Dissemination of

Information

DoD policy limits the dissemination of certain information. Instructions, Directives, and References not releasable to the public, e.g., Floor Plans, Maps, Post Orders, and Standard Operating Procedures, will be made available after contract award to the successful offeror with appropriate credentials and a need to know.

2.6.3 Work Reception Unless otherwise specified hereinafter, the Contractor shall provide the capability to receive, prioritize, correspond, and respond to trouble/service calls/order and task orders during Government regular working hours and provide a point of contact at a local or toll free number who can perform the above function during other than Government regular working hours from 0800-1645, five days per week, Monday through Friday, except observed Federal holidays.

2.6.4 Work Control The Contractor shall implement all necessary work control procedures to ensure timely accomplishment of work requirements, as well as to permit tracking and reporting of work in progress. The Contractor shall plan and schedule work to assure material, labor, and equipment are available to complete work requirements within the specified time limits and in conformance with the quality standards established herein. Verbal scheduling and work status updates shall be provided when requested by the Government. A status update of any item of work must be provided within two hours of the inquiry during regular working hours, and by 0800 the following work day for inquiries after regular working hours.

The Contractor shall provide work schedules for both Recurring and Non- Recurring Work per Section F. At a minimum, work schedules shall include:

• Description of service(s) to be accomplished

• Location

• Date service(s) are scheduled to be accomplished

2.6.5 Work Schedule The Contractor's work shall not interfere with normal Government business.

In those cases where some interference is unavoidable, the Contractor shall minimize the impact and effects of the interference. The Contractor shall provide advance access of all of its work schedules to the Government. The Contractor shall provide written notification of any difficulty in scheduling work due to Government controls per Section F. At a minimum, the notification shall include the following:

• The date and time the work was initially coordinated.

• The name and phone number of the Government person with whom the work was initially coordinated.

• The name and phone number of the Government person who prevented the work from being performed as previously coordinated.

• The alternative date and time, the Government person requested the work be accomplished.

2.6.6 Deliverables Except where otherwise stated, deliverable requirements are specified in

Sections C, F, H, I, J, and within the Directives, Instructions, and References.

The Contractor shall submit accurate and complete documents within the specified timeframes. The Contractor shall revise/modify deliverables, as directed by the KO, at no additional cost to the Government. All Contractor submittals shall be in English or may be submitted in Japanese with English translations.

Except where otherwise specified, all deliverables shall be submitted electronically in a Microsoft Office 2016 or Current Version compatible format. Deliverables shall include the company name, contract number, contract title, date, and shall be unprotected and capable of being sorted by CLIN, work order number, asset number, section, annex/sub-annex, spec item and ELIN/Sub-ELIN or clause. All formulas shall be traceable. Refer to DoDI 5200.48 for marking requirements (as applicable).

Government acceptance of deliverables shall not relieve the Contractor of the responsibility for any error or omission which may exist in the deliverable, as the Contractor is responsible for all requirements of this contract.

The Government shall take ownership of all the Management and Administration submittals to include but not limited to those listed in Section F. The Contractors including relating OEM, agency and personnel shall not claim any ownership of the submittals to the Government.

2.6.7 Service

Interruptions

If any utilities or other services must be discontinued (even temporarily) due to scheduled contract work, the Contractor shall notify the KO, COR, affected tenants, and customers in accordance with local procedures.

If the discontinued service is due to an emergency breakdown the Contractor shall notify the KO, COR, affected tenants, and customers as soon as practicable and provide the status of repairs, as directed by the KO, until normal operation is restored.

Unless otherwise specified hereinafter, the Contractor shall shutdown, restart, and perform operational checks on all equipment affected by both scheduled and unscheduled utility outages and service interruptions, at no additional cost to the Government.

Note:

1) Outage of extra high voltage needs to be approved by all related party, and the Contractor shall assist the coordination.

2) Extra high voltage effected to TEPPCO: The Contractor shall submit the required effective date and two auxiliary effective dates to the Utility Department at least four months in advance through COR.

3) Outage of extra high voltage Sub-station (transformer) for Berths: The Contractor shall submit the required outage date and two auxiliary outage dates to the Utility Department at least two weeks in advance through

COR.

4) Outage of extra high voltage Sub-station (transformer) for Dry Docks:

The Contractor shall submit the required outage date and two auxiliary outage dates to the Utility Department at least two weeks in advance through COR.

5) Electrical outage at Ikego Housing Area: The Contractor shall submit the required outage date and two auxiliary outage dates to the Utility Department at least three months in advance through COR.

Unless otherwise specified hereinafter, the Contractor shall request approval of service interruptions in writing per Section F. As soon as the request is approved by the KO/Security/Fire Department or other Department, the Contractor shall notify the affected tenants, and customers of the outage or closure. Depending on the scale of the work, the Contractor may have to submit the request much earlier than per Section F prior to the requested date.

The Contractor shall consult with the KO for scheduling through the COR in advance of service interruption. The Contractor shall consult with the Fire Department for any fire protection system outage and shall obtain permission and instruction from the Fire Department per J-0200000-04 through the COR.

Fire protection system outage required during any of the Contractor’s work shall not exceed four hours in a 24 hour period. If more than a four hour system outage is needed, the Contractor shall obtain prior permission from Base Fire Department by providing an approved alternate protection including but not limited to, adequate fire watch during the outage period (exceeding the four hour period) in accordance with NFPA 101, Chapter 9.

2.6.8 NAVFAC

MAXIMO

Work order, asset, specification, and condition assessment data created by the Contractor is recorded in NAVFAC MAXIMO for all work performed in 1501000 Facility Management, 1502000 Facility Investment, Annex 16 Utilities sub-annexes and Annex 1700000 Transportation. This spec item should be included in all FSC/BOS contracts above the SAP threshold at Navy PWDs per BMS B-24.8 Facility Support Contractor Data in NAVFAC MAXIMO. Consult with your local PWD FMD, UEM Director and BSVE Director or FEC FM&S PLC, UEM PLC, and BSVE PLC for further guidance.

The information and format for data submission provided in Section J supports long term asset management and facilitates transfer to NAVFAC MAXIMO. These requirements and data format are managed by the FM&S Product Line at the NAVFAC HQ level.

NAVFAC MAXIMO is the Computerized Maintenance Management System (CMMS) used by the Government for work order history, asset management, and condition assessment. The Contractor shall provide all required data for NAVFAC MAXIMO as identified below:

Informational Note:

Not all supported commands’ assets are included in NAVFAC Maximo. Not all of the modules available within the Maximo application are utilized by NAVFAC and the modules utilized may not be fully implemented.

NAVFAC Maximo does not include a detailed inventory of all assets, components, and equipment that the Contractor is required to service under this contract and may include inaccuracies, omissions, and redundancies.

2.6.8.1 NAVFAC

MAXIMO Data

Required data fields for work orders are indicated in the Service Provider Information provided in J-0200000-04. Asset inventory data requirements are indicated in the Asset Information provided in J-0200000-04, including additional data for Utilities assets listed in Specification Information in J- 0200000-04. Required data for documenting condition assessments is indicated in the Characteristic Meter Reading Information provided in J- 0200000-04.

Specified data shall be provided for all work performed in 1502000 Facility Investment. Further instructional information detailing the process for submitting the specified information for NAVFAC MAXIMO Data Reporting is provided in J-0200000-04.

The Service Provider, Asset, Specification, and Characteristic Meter Reading Interfaces are used in multiple processes for loading data into MAXIMO by the Government and the format may be updated periodically.

As part of the update the Contractor may be asked to modify the file to add/move columns in their submission. The Contractor also shall provide up to 10 extra data elements or columns with as many as 150 characters per element for the Government to define during contract performance at no additional cost to the Government. The Government will provide the Contractor 60 calendar days’ notice of modifications to the Service Provider, Asset, Specification, or Characteristic Meter Reading Interfaces file format.

2.6.8.2 NAVFAC

MAXIMO Method of Data Entry

The Contractor shall provide data for NAVFAC MAXIMO using the methods detailed below:

The Contractor shall electronically record and report compiled service performance data for exportation of work order, asset, specification, and condition assessment data to NAVFAC MAXIMO.

The Contractor shall submit work order and condition assessment data in a pipe delimited flat-file following the NAVFAC MAXIMO Data Reporting process described in J-0200000-04 per Section F. Any failures in processing of the pipe delimited flat-file shall be corrected and resubmitted by the Contractor. In order to demonstrate the ability to properly format the pipe delimited flat-file, the Contractor shall provide a Sample Pipe Delimited Flat-file prior to contract performance per Section F.

The Contractor shall submit asset and specification data in a spreadsheet flat-file following the NAVFAC MAXIMO Data Reporting process described in J-0200000-04 per Section F.

2.6.9 Quality

Management System (QMS)

The Contractor shall establish and maintain a complete QMS program in accordance with the provisions specified herein. The Contractor’s QMS program shall provide an effective and efficient means of identifying and correcting problems throughout the entire scope of operations. The Contractor's QMS program shall address:

• Accurate documentation of work processes, procedures, and output measures.

• A systematic procedure for assessing compliance with performance objectives and standards.

• Accurate documentation of quality inspections and surveillance conducted throughout the execution of work.

• Assessment-driven corrective actions and process adjustments as appropriate in a timely manner.

The Contractor QMS Pre-Performance Review Checklist for compliance with this requirement is provided in J-0200000-04.

2.6.9.1 Quality

Management (QM) Plan

The Contractor shall develop and submit a QM Plan per Section F. The QM Plan shall describe the QMS methodology and approaches used under this contract. If any changes are made during the period of performance, the Contractor shall submit the revised QM Plan for acceptance per Section F.

The Contractor’s QM Plan shall include, at a minimum, the following:

• Policy and objectives of Quality Management System (QMS)

• Quality organization o List of personnel/employee o Organization chart o Responsibilities & lines of authority o Training and qualifications o Quality manager resume

• Approach to assuring quality of services provided and conformance with performance objectives and standards

• Methods and procedures for effective planning, operation and control of processes and performance of work

• Procedures for inspection and surveillance of services to include all contractual requirements.

o Scheduling and performance of inspection and surveillance o Measurement, data collection and analysis o Corrective action, preventive action, and continuous improvement o Oversight of subcontracted work

• Documentation and records management

• Communication with government (customers)

2.6.9.2 Quality Inspection

and Surveillance

The Contractor shall establish and maintain an inspection and surveillance system in accordance with the FAR Clause 52.246-4, INSPECTION OF SERVICES – FIXED PRICE, to ensure that the work performed conforms to the contract requirements. The Contractor shall document and maintain a file of all scheduled and performed inspections and surveillances, inspection and surveillance results, and dates and details of corrective and preventive actions. The quality inspection and surveillance file shall be the property of the Government and made available during the Government’s regular working hours. The file shall be submitted to the COR after completion/termination of the contract per Section F.

2.6.9.3 Quality Inspection

and Surveillance Report

The Contractor shall submit a copy of the Contractor Quality Inspection and Surveillance Report per Section F.

The Contractor Quality Inspection and Surveillance Report shall include a narrative of events, a tabulated summary and results of the quality inspection and surveillance events performed, inspection-driven corrective actions taken and the results attained, and management process adjustments during the previous month. E.g. Updates for incorrect or missing information discovered in maintenance inventories provided.

The Government may adjust the frequency of the submittal based on the Contractor’s quality of performance.

2.6.10 Property

Management Plan

The Contractor shall establish and maintain a plan that meets the contract clause requirements of Specification Item 2.4, Government-Furnished Items, of this Annex. This plan shall identify the Contractor’s policies, procedures, and practices in receiving and performing physical inventories, key control, repairing and maintaining, preserving and protecting, and reporting the disposition of accepted government property in its possession. The Property Management Plan shall be submitted per Section F.

2.6.11 System and

Equipment Replacement

The Contractor shall maintain the integrity and performance of existing energy saving, water conservation or other sustainability design features of systems and equipment in the performance of repair and replacement work.

Except where otherwise specified, replacement components shall be of the same model/style or equivalent as the component being replaced. Substitutes for replacement components must be accepted by the KO prior to use. The KO will furnish available information for the existing systems and equipment.

2.6.12 Mobilization

2.6.12.1 Mobilization /

Phase-In The Contractor shall develop and submit a Mobilization / Phase-In Plan per Section F for Government review and acceptance. The plan shall include at a minimum, a time line on how the Contractor will mobilize/phase-in, 60 calendar days prior to full contract performance. The Contractor shall phase-in in accordance with the Government-accepted Mobilization Plan and in partnership with the outgoing Contractor so as to minimize disruption to the mission of BOSC clients. The new Contractor shall be allowed access to Government facilities to familiarize key personnel and top functional managers with property, existing operations, and procedures. However, to preclude interference with the work efforts of the incumbent Contractor, arrangements for access to Government facilities shall be made with the KO.

2.6.12.2 Demobilization /

Phase-Out

The Contractor shall submit a Demobilization/Phase-Out Plan per Section F for Government review and acceptance. The plan shall include at a minimum, a time line on how the Contractor will demobilize/phase-out, 60 calendar days prior to contract end. The Contractor shall phase out in accordance with the Government-accepted Demobilization Plan and in partnership with the incoming Contractor so as to minimize disruption to the mission of BOS clients. The plan shall include the Contractor’s plan to familiarize the incoming Contractor’s key personnel and top functional managers with existing operations, property, and procedures, completing a Reconciliation Survey, and the Contractor’s strategy for transferring work-in-progress to the new Contractor. The plan shall also provide for Contractor contingency services during the Demobilization/Phase-Out period in the event of:

(1) a work disruption or stoppage or

(2) the incumbent’s inability to fill a vacated position during the

Demobilization/Phase-Out period.

During the Demobilization/Phase-Out period, the Contractor shall be responsible for full performance of all sub-annexes through the last day of the contract.

The Government reserves the right to conduct site visits in all Contractor operated facilities in conjunction with the solicitation of offers for the follow-on contract. In the event the follow-on contract is awarded to other than the incumbent, the incumbent Contractor shall cooperate to permit an orderly changeover to the successor Contractor. A recruitment notice may be placed by the successor Contractor in each facility during the Phase-In period of the follow-on contract.

2.7 Personnel

Requirements

The Contractor shall comply with the personnel requirements stated below.

2.7.1 Key Personnel The Contractor shall submit a List of Key Personnel and Qualifications per Section F. The Contractor shall provide any additional information requested by the KO or COR necessary to validate their qualifications.

The Contractor shall submit an Organizational Chart per Section F showing lines of authority of the key personnel and on-site supervisor(s) for this contract. The chart shall include names of personnel and their position title in this contract. As a minimum, include the PM, Quality Manager, SSHO, and on-site supervisor(s) and who they will report directly to for this contract.

The key personnel shall be revised as applicable for the contract.

The Contractor shall provide complete resumes for proposed substitutes and any additional information requested by the KO. Proposed substitutes shall have comparable qualifications to those of the persons being replaced. The KO will notify the Contractor within 15 calendar days after receipt of all required information of the consent on substitutions. No change in fixed unit prices may occur as a result of key personnel substitutions.

Key personnel shall be able to speak, read and comprehend English to the extent that they can perform the contract requirements and comply with installation emergency procedures or an interpreter shall be made available at no additional cost to the Government.

2.7.1.1 Project Manager

(PM)

The Contractor shall provide a PM and designated alternate, as applicable, who shall have full authority to act for the Contractor on all contract matters relating to this contract.

The PM or alternate shall be available on-site within 24 hours after the Government requests.

The PM shall have at least five years of experience in managing a workforce providing services on contracts of similar size, scope and complexity.

2.7.1.2 Quality Manager The Contractor shall provide a Quality Manager or designated alternate who shall be available on-site within 24 hours after the Government request.

The Quality Manager or designated alternate shall report directly to a senior corporate official and shall not report directly to the PM. The Quality Manager shall not be the same person as the Project Manager.

The Quality Manager or designated alternate shall have fulfilled the following pre-requisite training and experiences before being hired as the Quality Manager under this contract: The Quality Manager or designated alternate shall have a current CMQ/OE certification and at least five years of experience in preparing and enforcing QMS programs on contracts of similar size, scope and complexity. The Quality Manager or designated alternate shall not be the same person as the SSHO. The Quality Manager may be the same person as the SSHO but shall have fulfilled the pre-requisite qualification and experience.

2.7.1.2.1 Quality Control

Personnel

The Contractor shall provide Quality Control personnel whose primary duty and responsibility is to enforce the Contractor’s Quality Management System on this contract. The Quality Control personnel shall be on-site at all times when the Contractor is performing work during the Government's regular working hours. The Quality Control personnel shall report directly to the Quality Manager and shall not report directly to the PM.

Quality Control personnel shall have fulfilled the following pre-requisite training and experiences before being hired as Quality Control under this contract:

Quality Control personnel shall meet or exceed the qualifications, technical knowledge and experience requirements specified for the personnel performing the work, which they will be inspecting, and have at least three years of experience in enforcing QMS programs on contracts of similar size, scope and complexity.

2.7.1.3 Site Safety and

Health Officer

(SSHO)

The SSHO must meet the requirements of EM 385-1-1 Section 1 and ensure that the requirements of 29 Code of Federal Regulations (CFR) 1926.16 are met for the project. Provide a Safety oversight team that includes a minimum of one Competent Person at each project site to function as the Site Safety and Health Officer (SSHO). The SSHO or an equally-qualified Designated Representative/alternate shall be on-site at all times when work is being performed to implement and administer the Contractor's safety program and government-accepted Accident Prevention Plan. The SSHO's training, experience, and qualifications shall be as required by EM 385-1-1 paragraph 01.A.17, entitled SITE SAFETY AND HEALTH OFFICER (SSHO), and all associated sub-paragraphs.

A Competent Person shall be provided for all of the hazards identified in the Contractor's Safety and Health Program in accordance with the accepted

Accident Prevention Plan, and shall be on-site at all times when the work that presents the hazards associated with their professional expertise is being performed. Provide the credentials of the Competent Persons(s) to the KO for acceptance in consultation with the Safety Office.

The Contractor shall provide a SSHO whose primary duty and responsibility is to prepare and enforce the Contractor’s safety program on this contract.

The SSHO shall have fulfilled the following pre-requisite training and experiences before being hired as the SSHO under this contract:

The SSHO shall have completed five years of satisfactory experience in preparing and enforcing safety programs on contracts of similar size and complexity in the past or three years’ experience if he possesses a Certified Safety Professional (CSP) or safety and health degree. The SSHO shall have completed the OSHA 30-hour construction safety class or equivalent and maintain competency through 24 hours of formal safety and health related coursework every five years. The SSHO shall not be the same person as the

PM.

Note: Host Nation Safety training may be considered equivalent to 30 hour OSHA Construction safety class training requirement. The Japan Construction Occupational Safety and Health Association (JCOSHA) provides the construction site safety and health management course “KOUJI SHUNIN COURSE”, or “SYOCHOU COURSE”, which is as acceptable equivalent to the 30-hours OSHA safety class. This training can be viewed at the JCOSHA website.

http://www.kensaibou.or.jp or https://www.kensaibou.or.jp/eng/index.html

“KOUJI SHUNIN COURSE”

https://www.kensaibou.or.jp/seminar/center013_01.html?page=1

“SYOCHOU COURSE”

https://www.kensaibou.or.jp/seminar/center012.html?page=1

These training courses have five years of validated date. The SSHO shall maintain renewal of certificate. The refresher course is also an equivalent course after the initial training course has been completed. The information for the SSHO refresher course can be viewed at the website below.

“SSHO REFRESHER COURSE”

https://www.kensaibou.or.jp/seminar/center021_01.html?page=1

2.7.1.4…