P719 AMENDMENT 0007.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

SOLICITATION N40080205249 - MILITARY CONSTRUCTION P-719, DESIGN-BID-BUILD OF WARGAMING CENTER, MARINE CORPS BASE

QUANTICO, VIRGINIA

SEE SF 30 BLOCK 14 CONTINUATION PAGE

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 01-Dec-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N4008020R5249

X 9B. DATED (SEE ITEM 11)

07-May-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

01-Dec-2020

CODE

NAVAL FACILITIES ENG COMMAND WASHINGTON

1314 HARWOOD ST

WASHINGTON DC 20374

N40080 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N4008020R5249

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0007

The purpose of this amendment is to provide the following:

1. Phase II RFI Responses

2. Attachment

All other terms and conditions remain unchanged.

PHASE II RFI RESPONSES

94. Reference: Price Schedule

CLIN 0008 refers to note 10 which allows the government 365 calendar days after the contract award to award CLIN 0008 - Parking Garage. In order to ensure timely completion of CLIN 0008, please confirm that the cost of all of the submittals, shop drawings, engineering, and coordination for CLIN 0008 - Parking Garage will be included under CLIN 0001.

GOVERNMENT RESPONSE: If funding is available, the Government intends on awarding CLIN 0008 at time of award. Please include the costs identified in the RFI in CLIN 0008.

95. Section 52.211-12 of the solicitation indicates liquidated damages as $35,000 per calendar day per each CLIN. This value is significantly higher than what would be expected on similar government projects.

Please confirm that the liquidated damages should be $3,500 per calendar day and not $35,000 per calendar day. Also, please confirm that the liquidated damages are the same for each CLIN.

GOVERNMENT RESPONSE: : The Liquidated Damages rate has been reduced to $20,000 and applies to each CLIN.

ATTACHMENTS

Please utilized the attached “Checklist for Reviewing Subk Plans” when developing your Small Businss Subcontracting Plan.

SECTION 00700 - CONTRACT CLAUSES

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

N4008020R5249

(a) If the Contractor fails to complete the work within the time specified in the contract for each CLIN, the Contractor shall pay liquidated damages to the Government in the amount of $20,000 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)