Attachment J.4 - Non-Discrimination.pdf
PDF 31 KB Posted
- Solicitation number
- DCSC-24-RFP-0170
- Issued by
- District of Columbia Government
About this file
This document includes an attachment outlining non-discrimination requirements for federal contractors and a related federal contract opportunity notice. The Courts is seeking a qualified contractor to provide Construction Management and Quality Assurance services to improve project performance, prevent cost overruns and schedule delays, and promote an integrated team approach across the Courts' facility capital projects program-wide. The selected contractor will manage all projects throughout initiation, planning, design, permitting, construction, furniture installation, tenant move-in, closeout, and transition to operations, ending after a one year warranty period. Services must be fully integrated across individual interrelated projects of varying scale and complexity. The non-discrimination attachment stipulates that contractors over $10,000 shall not discriminate in employment and must include non-discrimination provisions in subcontracts over $10,000.
View the file
Other files
Show all 31
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
ATTACHMENT J.4
NON DISCRIMINATION
Employment discrimination by contractor is prohibited.
Every contract over $10,000.00 shall include or incorporate by reference the following provisions:
1. During the performance of this contract, the Contractor agrees as follows:
a. The Contractor will not discriminate against any employee or applicant for employment because of race, religion, color, sex, or national origin, except where religion, sex, or national origin is a bona fide occupational qualification reasonably necessary to the normal operation of the Contractor. The Contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices setting forth the provisions of this nondiscrimination clause.
b. The Contractor, in all solicitations or advertisements for employees placed by or on behalf of the Contractor, will state that such Contractor is an equal opportunity employer.
c. Notices, advertisements, and solicitations placed in accordance with federal law, rule, or regulation shall be deemed sufficient for the purpose of meeting the requirements of this section.
2. The Contractor will include the provisions of the foregoing paragraphs, a, b, and c in every subcontract or purchase order of over $10,000.00, so that the provisions will be binding upon each subcontract or vendor.
BY:
COMPANY
File details come from the government source that posted it. Updated .