Attachment J.11 CPFMD Standard Operating Procedures (CPFMD SOP) to be provided upon award.pdf

This file attachment provides the Standard Operating Procedures for the Construction Project and Facilities Management Division of the District of Columbia Courts that will be provided upon award of the related federal contract opportunity.

The related solicitation seeks qualified sources to provide Construction Management and Quality Assurance services to the Courts as an integrated part of the existing Construction Project and Facilities Management Division team. The selected contractor shall manage all facility projects and activities of the Courts throughout all phases from project initiation through occupancy and warranty closeout. This includes formulating a Project Management Office to improve overall performance in planning, funding, and executing capital projects on time, within budget and scope. The contractor shall also develop strategies to resolve issues and prevent cost overruns and delays, promote an integrated team approach, and manage individual project scopes, schedules, budgets, quality and safety across the Courts' program of multiple interrelated projects varying in scale and complexity.