6973GH-20-R-00087-0005.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

5. PROJECT NO. (If applicable)2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ.NO.

PAGE OF PAGES

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6)

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

CODE

9A. AMENDMENT OF SOLICITATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

Items 8 and 15, and returning is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required.)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(x) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO THE AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14.

E. IMPORTANT: Contractor is not, is required to sign this document and return

ORDER NO. IN ITEM 10A.

1 2

0005 05/12/2020

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ0731-AFN

OKLAHOMA CITY OK 73125

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ731-AFN

OKLAHOMA CITY OK 73125

x

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

separate letter or telegram which includes a reference to the solicitation and amendment number. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By ___________ 1 x x

6973GH-20-R-00087

1 copies to the issuing office.

04/14/2020

(x)

WO#18-021538

ARB Restroom Renovation

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. CONTRACT AUTHORITY 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Stephanie Riddle

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

The purpose of amendment 0005 is to add clause 3.2.2.8-5 Liquidated Damages - Construction (October 2019), add Attachment 13 Revision 2 Questions and Answers, add Attachment A - Pictures, add Attachment B - Arch Drawings, add Attachment C - Plumbing Piping Insulation, and add Attachment D - 015900.

FIRST: Clause 3.2.2.8-5 Liquidated Damages - Construction (October 2019) is hereby added.

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor must pay to FAA as liquidated damages, the sum of $831.63 for each day of delay.

(b) If FAA terminates the Contractor's right to proceed, the resulting damage will consist of liquidated damages until such reasonable time as may be required for final completion of the work, together with any increased costs to FAA in completing the work.

(c) If FAA does not terminate the Contractor's right to proceed, the resulting damage will consist of liquidated damages until the work is completed or accepted.

SECOND: Attachment 13 Revision 2 Questions and Answers is hereby added.

THIRD: Attachment A - Pictures is hereby added.

FOURTH: Attachment B - Arch Drawings is hereby added.

FIFTH: Attachment C - Plumbing Piping Insulation is hereby added.

SIXTH: Attachment D - 015900 is hereby added.

SEVENTH: The Proposal Due Date remains as Tuesday, May 19, 2020 at 2:00 p.m. CT.

EIGHTH: All other terms and conditions remain unchanged and in full force and effect.