6973GH-20-R-00087.pdf

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

AC-20-02797

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ0731-AFN

OKLAHOMA CITY OK 73125

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

BLDG 014-AHQ, ROOM 233A

OKLAHOMA CITY, OK 73125

Stephanie Riddle 405-954-7805 x 71

PURCHASE REQUEST NO.

6973GH-20-R-00087

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

THIS PROCUREMENT IS 100% A SET-ASIDE FOR COMPETITION LIMITED TO 8(a) BUSINESSES.

(a) Specifications, "Aviation Records Building 22 Mike Monroney Aeronautical Center

Oklahoma City, OK ARB Building 22 Restroom Renovation Upgrades", 3 March 2020, 448 pages

(b) Drawings, "FAA ARB Building 22 Restroom Renovation Upgrades", March 4, 2020, 62 pages

THE ESTIMATED PRICE RANGE: $1,000,000 TO $4,000,000

The Line Items listed on this SF30 (cover and continuation pages) are for Government use only. Please reference Section B/Pricing of this instrument for the contract line items.

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

15 400 calendar days and complete it within ________________ ________________ calendar days after receiving

1 1400

05/12/2020 x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ731-AFN

OKLAHOMA CITY OK 73125

Stephanie Riddle

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 71

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

6973GH-20-R-00087

(A) (B) (C) (D) (E) (F)

WO#18-021538

ARB Restroom Renovation

Delivery: 400 Days After Award

Delivery Location Code: A6973M4F

A6973M4F

6973M4 FAA AERO CENTER AMP 1

OFC OF FACILITY MGMT HDQS RM 316

6500 S MACARTHUR BLVD

OKLAHOMA CITY OK 731696901 US

FOB: Destination

00001 Construction for the renovation of the restrooms on all four floors of the ARB Building to bring the restrooms to ADA code compliance including new fixtures and finishes.

00002 Option 1: Wall Paneling - Provide and install new wall paneling at designated corridor walls.

00003 Option 2: Wall Paneling - Provide and install new wall paneling at additional designated corridor walls.

00004 Option 3: Demolish ceiling tiles and grid system, HVAC diffusers, light fixtures and temporarily remove ceiling mounted fire and safety fixtures at designated basement corridors. Provide new ceiling panels and grid system with new HVAC diffusers.

00005 Option 4: Provide an 8 foot diameter epoxy terrazzo floor logo (compass rose with aircraft linework) within the approximate 8-foot by 8-foot first floor corridor central area.

00006 Option 5: Provide a floor applied logo (compass rose with aircraft image) within the 8-foot x

8-foot first floor corridor central area.

Section B - Supplies or Services/Prices Section B - Schedule

See Section J, Attachment 1 for the Section B Contract Line Items/Pricing applicable to this instrument.

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

C.1 Statement of Work (SOW) The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project set forth below, in accordance with the specifications and drawings, and the other terms, conditions, and provisions as set forth herein. All work performed and any materials and equipment used will be subject to approval by the Contracting Officer Representative (COR) and Contracting Officer (CO). This shall include but not be limited to testing, inspection, scheduling, reporting, and submittals.

C.2 Bid vs. Offer References to the terms "bid", "bidder", et. throughout the specification are intended to mean "offer", "offeror", etc.

C.3 Alternate vs. Option References to "alternate or "alternates" in accordance with Section 01 23 00 Alternates throughout the specification and drawings are intended to mean "option" or "options."

C.4 Specifications and/or Drawings The following specifications and/or drawings are applicable to this acquisition.

(a) Specifications, "Aviation Records Building 22 Mike Monroney Aeronautical Center Oklahoma City, OK ARB Building 22 Restroom Renovation Upgrades", 3 March 2020, 448 pages

(b) Drawings, "FAA ARB Building 22 Restroom Renovation Upgrades", March 4, 2020, 62 pages

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE AT

THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Not Applicable

Section E - Inspection and Acceptance Clause List

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

3.10.4-11 INSPECTION - DISMANTLING, DEMOLITION, OR REMOVAL OF IMPROVEMENTS (APR

1996)

Section F - Deliveries or Performance Clause List

F.1 Working Hours All renovations work shall be restricted to be performed between 6:00 p.m. and 6:00 a.m. on normal government workdays and weekends and holiday hours between 6:00 p.m. and 6:00 a.m. of the next FAA work day unless approved by the Contracting Officer seven (7) days in advance.

F.2 Utility Outages and Shutdown Utility outages and shutdown shall be coordinated with the Contracting Officer and Project Manager. Outages affecting FAA operations are required to be accomplished at night, on weekends or designated government holidays. Prior to any outage or shutdown, twenty-one (21) working days notification must be made to coordinate scheduling of any work to be performed during any hours.

F.3 Contractor Use of Premises

(a) General: Limit use of site and premises to allow:

(1) Owner occupancy

(2) Work by others

(b) Access to Site: Limited to area required for construction.

F.4 Contractor's Construction Schedule and Material Submittals The contractor shall prepare and submit the construction work schedule to the Contracting Officer (CO) for approval within fifteen (15) days of the date established for "Commencement of Work" in accordance with Clause 3.2.2.3-56, which is incorporated by reference.

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

Section G - Contract Administration Data Clause List

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within 10 calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

AC0135 INVOICING PROCEDURES - GENERAL (JAN 2017)

(a) In addition to the requirements set forth at AMS Clause 3.3.1-17, Prompt Payment, for the submission of a proper invoice, the contractor shall submit a separate invoice for (1) each month of performance of services, or (2) those items of supplies furnished, as follows:

(1) The original to: 9-AMC-AMZ-FAA-APInvoices@faa.gov (Preferred) or mail to:

DOT/FAA AMK-311/314

P.O. Box 25710

Oklahoma City, OK 73169-0710

(2) One Copy to stephanie.riddle@faa.gov or:

FAA, Mike Monroney Aeronautical Center

Office of Acquisition Services (AAQ-(insert routing symbol))

P.O. Box 25082

Oklahoma City, OK 73l25

(3) One Copy to harold.stong@faa.gov or:

FAA, Mike Monroney Aeronautical Center

Harold (Brook) Stong, AMP-400

P.O. Box 25082

Oklahoma City, OK 73l25

(b) Each invoice shall highlight the following information:

(1) Contract number and applicable Delivery Order number.

(2) Noun description of services and/or supplies, including applicable line item number(s) and quantity(s) that were provided.

(3) Extended totals for invoiced quantities.

(c) All contractors invoicing services to the FAA in labor hours shall maintain on file, and submit when required for verification or audit, certified time logs showing a daily start and ending work times, the daily total of productive hours charged to the contract, a daily entry for any non-productive work-hours and cumulative totals for each pay period.

AC1227 RELEASE FORM (JAN 1997)

The contractor will be required to execute Contractor's Release Form DOT F 4220.4 (2-71) prior to final payment under the contract. (Note: A copy of Form DOT F 4220.4 (2-71) is attached hereto for information purposes.)

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL 2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

H.1 Exercise of Optional Contract Line Item (CLINs) The Government may exercise none or the Option item at the prices established in Section B, CLINs 00002-00006.

Exercise of the option CLINs must be made in writing by the Contracting Officer within 90 days of contract award.

H.2 Permits and Responsibilities The contractor shall secure and pay for all permits, licenses, special inspections, certificates, etc... required by Federal, State, and City/Town officials as necessary to perform the work, prior to starting construction, and in a timely manner to avoid delays in starting the job. The Contractor shall abide by all requirements dictated by the municipality for such permits without any additional cost.

H.3 Submission of Contract Performance and Payment Bonds

(a) Pursuant to AMS Clauses 3.4.1-4, Performance Bond Requirements, and 3.4.1-5, Payment Bond Requirements, incorporated herein by reference, the contractor shall within 15 calendar days after the award of the contract deliver to the Contracting Officer -

(1) A Performance Bond on Standard Form 25 in a penal sum equal to 100 percent of the contract price; and

(2) A Payment Bond on Standard Form 25-A in a penal sum equal to 100 percent of the contract price.

(b) Copies of Standard Form 25 and Standard Form 25-A are attached and listed at Section J.

(c) Each bond shall be accompanied by a Power of Attorney whereby the surety company authorized the execution of the bond by its agent or employee.

(d) Each bond shall remain in full force and effect through the entire term of the contract, including extensions and warranty/guarantee periods, if any.

H.4 Time Extension Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order may also provide an equitable readjustment of liquated damages under the new completion schedule.

H.5 Accident and Fire Reporting

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment; or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.6 Construction Safety Program

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities. Chapter 33 Construction Safety (Section J, Attachment 3) establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

H.7 Notification Requirements When Friable Asbestos Material is Disturbed If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2018)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in

29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC1231 NOTIFICATION REQUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS

REMOVED/DISTURBED (JAN 1997)

(a) Prior to any planned and/or scheduled disturbance of friable asbestos material, mainly CAFCO ceilings, the contractor shall present a written plan to the Contracting Officer. The plan shall include, but not be limited to, location, type facility, size of area to be disturbed or removed, method of containment to be used, disposal procedures, clean-up procedures, number of employees involved, protective clothing/equipment to be used, the date and time removal/disturbance is planned and any other information requested by the Contracting Officer. The contractor shall not proceed with any removal or disturbance of friable asbestos material without written approval from the Contracting Officer.

(b) If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4556 PERSONNEL AND SUPERVISION (JUL 2015)

The contractor shall designate sufficient supervisory personnel to meet task outcomes. Contract supervisors will provide day-to-day supervision of contract personnel including, but not limited to, work monitoring, payroll records, leave, etc. At no time will FAA personnel assume any responsibility for the supervision of contractor personnel.

Government assistance will be available to provide technical and policy guidance through the assigned Contracting Officer’s Representative (COR).

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses Clause List

I.1 Subcontractors and Outside Associates and Consultants

Any subcontractors and outside associates or consultants required by the Contractor in connection with the services covered by the contract will be limited to individuals or firms that were specifically identified and agreed to during Screening Information Request (SIR) communications. The contractor shall obtain the Contracting Officer's written consent before making any substitution for these subcontractors, associates, or consultants.

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JUL 2018)

3.2.2.3-33 ORDER OF PRECEDENCE (MAR 2009)

3.2.2.3-42 DIFFERING SITE CONDITIONS (JUL 2004)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (JUL 2004)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-48 OTHER CONTRACTS (MAR 2009)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2004)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2004)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2004)

3.2.2.3-58 LAYOUT OF WORK (MAR 2009)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-62 PRECONSTRUCTION CONFERENCE (JUL 2004)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2004)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-69 SUBCONTRACTS - CONSTRUCTION (JUL 2004)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2019)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2019)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2019)

3.2.5-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE FAA (OCT 2019)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-9 INTEREST (JUL 2018)

3.3.1-15 ASSIGNMENT OF CLAIMS (JUL 2018)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (OCT

2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD MANAGEMENT

(JUL 2018)

3.3.2-1 FAA COST PRINCIPLES (OCT 2019)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-7 NOTICE TO PROCEED (OCT 2019)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2019)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT 1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (JUL 2019)

3.5-1 AUTHORIZATION AND CONSENT (JAN 2019)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JAN

2009)

3.5-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS (JAN 2009)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (JUL 2019)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (OCT 2019)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME COMPENSATION

(OCT 2018)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-9 EQUAL OPPORTUNITY (OCT 2018)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (OCT 2018)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2018)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (OCT 2018)

3.6.2-18 DAVIS BACON ACT (OCT 2018)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (JUL 2017)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2017)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (JAN 2019)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (JAN 2019)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (JAN 2019)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (OCT 2018)

3.6.2-39 TRAFFICKING IN PERSONS (APR 2019)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JAN 2019)

3.6.2-46 PAID SICK LEAVE (JUL 2019)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (JAN 2020)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (JAN 2020)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-19 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (JAN 2020)

3.6.3-21 EFFICIENCY IN WATER CONSUMING PRODUCTS AND SERVICES (JAN 2020)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (JAN 2020)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.4-5 BUY AMERICAN - STEEL AND MANUFACTURED PRODUCTS (JUL 2010)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.4-23 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (OCT 2019)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 1996)

3.10.1-16 CHANGES AND CHANGED CONDITIONS (APR 1996)

3.10.1-20 WARRANTY-CONSTRUCTION (JUL 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-26 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (APR 2013)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV 1997)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT 1996)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(JAN 2018)

3.2.2.3-41 PERFORMING WORK (JUL 2004)

The Contractor (you) must perform, using your own organization, work equivalent to at least fifteen (15) percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if you request a reduction and the CO determines that it would be to the Government's advantage to do so.

(End of clause)

3.2.2.3-44 PHYSICAL DATA (JUL 2004)

Data and information the FAA (we, us) provides or refers to below is for the Contractor's (your) information. We are not responsible for your interpretation of or conclusions based on the data or information. Further, we do not warrant construction methodology which may be included in these documents.

(a) The descriptions of physical conditions on the drawings and in the specifications are the result of site investigations by N/A.

(b) Other relevant information N/A.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 15 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 400 calendar days after receipt of notice to proceed. The time allowed for completion must include final cleanup of the premises.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004) -

ALTERNATE I (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 15 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 400 calendar days after receipt of notice to proceed. The time allowed for completion must include final cleanup of the premises.

(d) The completion date assumes that the successful offeror will receive the notice to proceed by 30 calendar days.

The CO will extend the completion date by the number of calendar days after the above date that you receive the notice to proceed, except to the extent that the delay in issuing the notice to proceed results from your failure to execute the contract and give the required performance and payment bonds to FAA within the time specified.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (JUL 2018)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete.