6973GH-27-R-00005.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NO.

5. REQUISITION/PURCHASE REQUEST NO.

CODE

6. PROJECT NO.

8. ADDRESS OFFER TO

4. CONTRACT NO.

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF

SEALED BID (IFB)

9. FOR

INFORMATION CALL

PAGES

6973GH-27-R-00005

AAQ-730 FAC. & AVIATION SAFETY ACQ

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

OKLAHOMA CITY OK 73125

AC-27-00018

AAQ730-AFN

Andre Casiano 405-954-7850

10/20/2026

11/19/2026

10 730

This procurement is a Total Small Business Set-Aside

(a) Specifications

Attachment 1a FAA MMAC IWTP_Specifications_IFC Volume I Rev 2026 09 29, 09/29/2026, 139 pages

Attachment 1b FAA MMAC IWTP_Specifications_IFC Volume II_2026 06 10, 06/10/2026, 384 pages

Attachment 1c FAA MMAC IWTP_Specifications_IFC Volume III_2026 06 10, 06/10/2026, 983 pages

(b) Drawings

Attachment 1d 13289-007_MMAC IWTP Drawings, 06/10/2026, 139 pages

The Estimate Price Range: Between $10,000,000 to $20,000,000

The Line item listed on continuation page is for Government use only. Please reference the Section

B/Schedule B pricing of this instrument for the contract line items and additional information

1 75

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. AWARD DATE31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

20b. SIGNATURE 20c. OFFER DATE

Continued...

AMENDMENT

NUMBER

DATE.

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

ITEM NO.

(A)

QUANTITY

(C)

6973GH-27-R-00005

Delivery: 11/06/2026

Delivery Location Code: A6973M4F

A6973M4F

6973M4 FAA AERO CENTER AMP 1

OFC OF FACILITY MGMT HDQS RM 316

6500 S MACARTHUR BLVD

OKLAHOMA CITY OK 731696901 US

00001 Provide all labor and materials to complete

IWTP Construction Project at the MMAC, in accordance with

Attachment 1a FAA MMAC IWTP_Specifications_IFC

Volume I Rev 2026 09 29

Attachment 1b FAA MMAC IWTP_Specifications_IFC

Volume II_2026 06 10

Attachment 1c FAA MMAC IWTP_Specifications_IFC

Volume III_2026 06 10

Attachment 1d 13289-007_MMAC IWTP Drawings

Electronic & IT: 03

Section B - Supplies or Services/Prices Section B - Schedule

This is a Firm-Fixed Price Contract. The contractor shall furnish all labor, tools, materials, equipment, and supplies necessary to accomplish the construction project, IWTP AND COLLECTION SYSTEM UPGRADE, at the Mike Monroney Aeronautical Center, Oklahoma City, OK set forth below and in accordance with the attached specifications, drawings, and the other terms, conditions, and provisions set forth herein.

Provide all labor and materials to complete IWTP AND COLLECTION SYSTEM UPGRADE in accordance with Section J Attachments as Applicable for Construction. All other attachments in Section J are incorporated into this solicitation/SIR and should be taken into account in an offeror's pricing as appropriate.

1. Base Bid:

CLIN 0001 - NEW IWTP BUILDING AND PROCESSING EQUIPMENT

CLIN 00001 Price: $__________________________

2. Bid Options:

a. Bid Option 1 - DEMOLITION OF EXISTING IWTP

- Demolition and Decommissioning of Existing IWTP structure and components. Refer to Drawing C-001 : Phase C

– Demolition of Existing IWTP both Phase C1 and Phase C2 drawing notes

Bid Option #1 Price: $___________________________

b. Bid Option 2 - DEMOLITION AND RENOVATION OF THE EXISTING LIFTSTATIONS

- Demolition and Lift Station Construction, refer to Drawing C-001: Phase A2 – Lift Station Construction and corresponding drawing sheets with lift station details

Bid Option #2 Price: $___________________________

c. Bid Option 3 - DEMOLITION OF THE EXISTING LIFT STATIONS #2

- Demolition of Lift Station #2, refer to Drawing CD-103 : Detail D6. Demo any existing tributary forcemain from the lift station to the main forcemain (approximately five feet (5’)). Existing 4” influent from the building to be removed back to 5’ from the building exterior and capped

- Removal to consist of the steps indicated under Drawing C-001: Phase A2 steps #1 through #8. Once removed, backfill excavation with appropriate fill material and restore per construction documents

Bid Option #3 Price: $___________________________

d. Bid Option 4 - DEMOLITION AND REPLACEMENT OF EXISTING FORCEMAINAND ASSOCIATED

TRENCH

- Demolition and Replacement of the Existing forcemain and associated trench, refer Drawing C-001: Phase A1 – Trench Demolition and corresponding drawing sheets with trench demo and replacement details

Bid Option #4 Price: $___________________________

e. Bid Option 5 - CLERESTORY WINDOWS AND ENTRY CANOPY

- Provide and install glazing W-3 through W-8 and associated aluminum window framing on East and West elevations

- Provide and install Entrance Awning (Drawing A-612 : Detail D7)

Bid Option #5 Price: $___________________________

f. Bid Option 6 - FINISHES

- In base bid, all floor finishes to be sealed concrete (SC-1), except for Room 106 Lab and Room 110 Restroom which will be chemical resistant epoxy flooring (CREF- 1) and Vestibule 102 will be walk-off carpet (WOC-1).

This Option #6 is to upgrade floor finishes in Rooms 103, 104, 105, and 107 to be chemical resistant epoxy flooring in place of the sealed concrete.

- In base bid, walls to have fiber reinforced panel (FRP-1) at Restroom east and south elevations, Water Fountain west elevation, and Office/Kitchenette west elevation. This Option #6 is to upgrade the fiber reinforced panel to ceramic wall tile (PCT-1 and PCT-2) at these locations

Bid Option #6 Price: $___________________________

The FAA's decision to award bid options will be made at time of the base bid award. The FAA reserves the right to award all, none, or some of the bid options. The total evaluated price will be the sum of the base bid and the bid options the FAA elects to award.

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

C.1 Description The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project, in accordance with the specifications and drawings, and the other terms, conditions, and provisions as set forth herein. All work performed and any materials and equipment used will be subject to approval by the Contracting Officer Representative (COR) and Contracting Officer (CO). This shall include but not be limited to testing, inspection, scheduling, reporting, and submittals.

C.2 Bid vs. Offer References to the terms "bid", "bidder", et. throughout the specification are intended to mean "offer", "offeror", etc.

Clause List

AC4548 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

(JUL 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel not being subject to the direction and control of Government personnel when performing non-personal contract services in FAA facilities.

(b) All contractor personnel at a FAA work site or facility during an actual emergency shall conform to the procedures posted or directed by FAA officials responsible for emergency response at that site or facility. Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, etc.

(c) Contractor personnel shall participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions and based on advance arrangements that are then announced at the time of an exercise, contractor personnel will be excused from evacuations.

(d) Contractor management/supervisors shall ensure that each contractor employee assigned work in FAA facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Information on emergency procedures may be requested from the Contracting Officer’s Representative (COR) or a designated FAA contact point at the work site.

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

3.10.4-11 INSPECTION - DISMANTLING, DEMOLITION, OR REMOVAL OF IMPROVEMENTS

(APR 1996)

Section F - Deliveries or Performance Clause List

F.1 Contractor's Construction Schedule and Material Submittals The contractor shall prepare and submit the construction work schedule to the Contracting Officer (CO) for approval within fourteen (14) days of the date established for "Commencement of Work" in accordance with Clause 3.2.2.3- 56 which is incorporated by reference.

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

Section G - Contract Administration Data Clause List

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within 14 calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

AC1227 RELEASE FORM (JAN 1997)

The contractor will be required to execute Contractor's Release Form DOT

F 4220.4 (2-71) prior to final payment under the contract. (Note: A copy of

Form DOT F 4220.4 (2-71) is attached hereto for information purposes.)

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

H.1 FAA Compliance with Executive Orders FAA shall comply with all Presidential directives. If any clause, provision, term, or condition in this SIR or contract is inconsistent with any Executive Order or Presidential Memoranda issued on or after January 20, 2025, or implementing guidance thereof, FAA will take action it deems appropriate and as permitted by law to correct any such inconsistency to include finding a provision or clause invalid. Applicable Executive Orders include, but are not limited to:

- Executive Order 14148 of January 20, 2025, Initial Recissions of Harmful Executive Orders and Actions.

- Executive Order 14151 of January 20, 2025, Ending Radical and Wasteful Government DEI Programs and Preferencing.

- Executive Order 14154 of January 20, 2025, Unleashing American Energy.

- Executive Order 14168 of January 20, 2025, Defending Women From Gender Ideology Extremism and Restoring Biological Truth to the Federal Government - Executive Order 14173 of January 21, 2025, Ending Illegal Discrimination and Restoring Merit-Based Opportunity.

H.2 ACCIDENT AND FIRE REPORTING

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment;

or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The Contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.3 CONSTRUCTION SAFETY PROGRAM

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities.

Chapter 33 Construction Safety establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

H.4 AWARD OF BID OPTIONS

The FAA's decision to award bid options will be made at time of the base bid award. The FAA reserves the right to award all, none, or some of the bid options. The total evaluated price will be the sum of the base bid and the bid options the FAA elects to award.

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

3.8.2-17 KEY PERSONNEL AND FACILITIES (JUL 2019)

(a) The personnel and/or facilities as specified below are considered essential to the work being performed hereunder and may, with the consent of the contracting parties, be changed from time to time during the course of the contract.

(b) Prior to removing, replacing, or diverting any of the specified personnel and/or facilities, the Contractor must notify in writing, and receive consent from, the Contracting Officer reasonably in advance of the action and must submit justification (including proposed substitutions) in sufficient detail to permit evaluation of the impact on this contract.

(c) No diversion will be made by the Contractor without the written consent of the Contracting Officer.

(d) The key personnel and/or facilities under this contract are:

Project Manager Superintendent

(List key personnel and/or facilities)

(End of clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course #

FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses Clause List

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.2.2.3-33 ORDER OF PRECEDENCE (APR 2024)

3.2.2.3-42 DIFFERING SITE CONDITIONS (APR 2024)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 2024)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2024)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2024)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2024)

3.2.2.3-48 OTHER CONTRACTS (JUL 2024)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (JUL 2024)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (JUL 2024)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2024)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2024)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2024)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2024)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2024)

3.2.2.3-58 LAYOUT OF WORK (JUL 2024)

3.2.2.3-62 PRECONSTRUCTION CONFERENCE (JUL 2024)

3.2.2.3-64 DISMANTLING AND DEMOLISHING OF PROPERTY (JUL 2024)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2024)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2024)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2024)

3.2.5-4 CONTINGENT FEES (OCT 2024)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2024)

3.2.5-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE FAA (OCT 2024)

3.2.5-7 DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (OCT 2024)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.3.1-9 INTEREST (APR 2023)

3.3.1-15 ASSIGNMENT OF CLAIMS (JUL 2018)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2021)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (OCT 2024)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-7 NOTICE TO PROCEED (OCT 2019)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2020)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (APR 2025)

3.5-1 AUTHORIZATION AND CONSENT (APR 2023)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT

(JAN 2009)

3.5-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS (JAN 2009)

3.6.1-1 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (OCT 2019)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED, WOMEN-OWNED, SERVICE-

DISABLED VETERAN OWNED, AND HUBZONE SMALL BUSINESS CONCERNS (APR 2025)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (JUL 2021)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (JUL 2023)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME

COMPENSATION (OCT 2018)

3.6.2-2 CONVICT LABOR (APR 2025)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (APR 2022)

3.6.2-13 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (APR 2022)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (APR 2025)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2025)

3.6.2-21 APPRENTICES AND TRAINEES (APR 2025)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (APR 2025)

3.6.4-5 FAA BUY AMERICAN PREFERENCE - STEEL AND MANUFACTURED GOODS (APR

2022)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.8.9-2 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JUL 2023)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-20 WARRANTY-CONSTRUCTION (JUL 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-28 CHANGES REQUIRED BY AMS (JAN 2024)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV

1997)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (APR 2025)

3.2.2.3-41 PERFORMING WORK (APR 2024)

The Contractor must perform, using its own organization, work equivalent to at least 15 percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if the Contractor requests a reduction and the CO determines that it would be to the FAA's advantage to do so.

(End of clause)

3.2.2.3-50 PROPERTY PROTECTION (JUL 2024)

(a) The Contractor must construct and maintain any temporary fences, gates and other facilities needed to preserve crops, control livestock, and protect property. Before cutting a fence, the Contractor must take necessary precautions to prevent livestock from straying. The Contractor must prevent loss of tension in or damage to adjacent portions of the fence. The Contractor must immediately replace all fencing and gates cut, removed, damaged, or destroyed with new materials to the original standard. Undamaged gates may be reused.

(b) The Contractor must comply with the property owner's requests to leave gates open or closed.

(c) The Contractor must use all necessary precautions to avoid destroying surveying markers such as section corners, witness trees, property corners, mining claim markers, bench markers, triangulation stations, and the like. If the Contractor must destroy any marker, the Contractor must first notify the agency responsible for the marker, as well as the Contracting Officer's (CO) representative, and replace the markers.

(d) The Contractor must use care to prevent unnecessary damage to property in or near the work area caused by the Contractor's work. Unnecessary damage is that which the Contractor can avoid through efficient and careful performance of the work, considering the Contractor's land rights. If the Contractor damages any property, the Contractor must at once notify the owner or custodian and make or arrange to make prompt and full restitution.

(e) Maps and specifications the FAA provides may not give the location of all water supply, drainage, irrigation, and other underground facilities. Before entering a tract of land for contract purposes, the Contractor must determine from the property owner (or other reasonably available source) the location of any irrigation system, domestic water system, source of water, and drainage system existing on the property, whether serving that property or other property. The Contractor must avoid damaging or obstructing these facilities or polluting water supplies.

(f) The Contractor must hold the FAA harmless from any and all suits, actions, and claims for damages, including environmental impairment, to property arising from any of the Contractor's acts or omissions, the Contractor's subcontractors, or any of the Contractor's employees or subcontractor employees, in any way related to the work or operations under this contract.

(g) The Contractor must indemnify and hold harmless the property owners or parties lawfully in possession against all claims or liabilities asserted by third parties, including all governmental agencies, resulting directly or indirectly from the Contractor's wrongful or negligent acts or omissions.

(End of clause)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (JUL 2024)

(a) If either the specifications or the drawings (but not both) mention tasks, the Contractor must assume that the tasks are in both. If the drawings and specifications differ, the specifications govern. If there is a discrepancy in the figures, in the drawings, or in the specifications, the Contractor must submit the matter promptly to the Contracting Officer (CO), who will promptly determine which governs, and notify the Contractor in writing. Any adjustment made by the Contractor without the CO's determination is at the Contractor's own risk and expense. As needed, the CO will provide necessary detailed drawings and other information, unless otherwise provided.

(b) Wherever in the specifications or the drawings, the FAA uses "directed," "required," "ordered," "designated," "prescribed," or similar words, they refer to the CO's requirements. Similarly, "approved," "acceptable," "satisfactory," or similar words refer to the CO's approval, unless otherwise expressly stated. The Contractor must have a complete set of plans and specifications on-site and available for the FAA's use.

(c) Where the FAA uses "as shown," "as indicated," "as detailed," or similar words, they refer to the drawings accompanying this contract, unless stated otherwise. The word "provided" means "provided and installed."

(d) Omissions from the drawings and specifications or the erroneous description of details of work which are necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing those omitted or erroneously described details of the work. The Contractor must perform them as if fully and correctly set forth and described in the drawings and specifications.

(e) The Contractor must check all drawings the FAA provides before starting work and must promptly notify the CO of any discrepancies. In general, the Contractor should follow figures marked on drawings, rather than scale measurements. In general, large-scale drawings have precedence over small-scale drawings. The Contractor must compare all drawings and verify the figures before laying out the work. If the Contractor does not verify the figures, the Contractor will be responsible for any errors that might have been avoided had it verified them.

(f) "Shop drawings" means drawings, the Contractor or any subcontractor submit to the FAA under a construction contract, showing in detail the proposed fabrication and assembly of structural elements and the installation (that is, form, fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials the Contractor provided to explain in detail specific portions of the work the contract requires.

The FAA may duplicate, use, and disclose in any manner and for any purpose shop drawings you deliver under this contract.

(g) If this contract requires material offers (for example, shop drawings, catalog cuts, certificates of conformance), the Contractor must coordinate all of its offers, and review them for accuracy, completeness, and compliance with contract requirements. The Contractor must provide evidence that it approves the submittals. If the Contractor submits materials to the FAA without this evidence, the FAA may return them and ask the Contractor to resubmit the materials. The CO will indicate whether he or she approves or disapproves the offer, and if the CO does not approve it as submitted, will indicate the reasons for rejecting it. Any work done before the CO's approval is at the Contractor's risk. The CO's approval does not relieve the Contractor from responsibility for any errors or omissions in the submittals, nor from responsibility for complying with the contract requirements, except as described under (h).

(h) If the submittals vary from the contract requirements, the Contractor must describe the variations in writing, separate from the submittal, when it submits them. Send this description, a copy of the offer, and a proposal to incorporate it into the contract directly to the CO. If the CO approves a variation, the CO must issue an appropriate contract modification, unless the variation is minor or does not involve a change in price or in time of performance.

(i) The Contractor must submit to the CO for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. The CO will keep three sets (unless otherwise indicated) of all offers and will return one set to the Contractor.

(j) The Contractor must insert this clause, with appropriate changes in the designation of the parties, in all subcontracts.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2024)

The Contractor must (a) begin work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) perform the work diligently, and (c) complete the entire work ready for use not later than 730 calendar days. The time stated for completion must include final cleanup of the premises.

(End of clause)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (OCT 2024)

(a) The FAA will pay the Contractor the contract price as provided in this contract.

(b) The FAA will make financing payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer (CO), on estimates of work accomplished that meets the standards of quality established under the contract, as approved by the CO. The Contractor must furnish a breakdown of the total contract price showing the amount included therein for each principal category of the work, which must substantiate the payment amount requested in order to provide a basis for determining financing payments, in such detail as requested by the CO.