SATCOM_13-R-0009_Amend_0014_Atch1_Revised_Price_Schedule_26Sep2013.pdf

REVISED PRICE SCHEDULE

Solicitation W912GB-13-R-0009 – Amendment 0014 Attachment 1

SATCOM-WSOC Landstuhl, Germany

26 September 2013

The Offeror shall propose on all base and optional items. Provide completion of all award items from the Notice to

Proceed (NTP) as described in the contract FAR Clause 52.211-10 “COMMENCEMENT, PROSECUTION AND

COMPLETION OF WORK” according to the following schedule. The maximum contract period of performance is

510 calendar days from NTP, including the Site Inspection - Submittal Phase and Construction Phase under the base items and optional items, if awarded, from the issuance of the NTP. The contractor shall have the project fully functional to include commissioning of the SATCOM WSOC facility and available for normal regular use no later than 410 calendar days from the Construction NTP.

See FAR Clause 52.211-12 for Liquidated Damages. Liquidated damages (LD) apply to any completion date specified in the contract or Price Schedule including interim completion dates for individual facilities. LDs for all base items and exercised options shall be assessed at €2,340.00 for each calendar day of contractor delay until the work is completed or accepted. L.

Base Line Items Period of Performance (PoP): The base period of performance is broken into two (2) phases.

The total PoP is 510 calendar days. Separate NTPs will be issued for each Phase. Phase 1 is the Site Inspection and Submittal Phase and has a PoP of 100 calendar days from the issuance of the NTP to complete the inspection and submittal requirements prior to construction start. Phase 2 is the Construction Phase and has a PoP of 410 calendar days and consists of the construction and contract close-out period of 410 calendar days.

Award of Options and PoP: The Government reserves the right to award any or all options up to 90 calendar days following issuance of Submittal Phase NTP for the base items work. Any optional work awarded shall be completed within the time frame as indicated in the Line Item(s) period of performance and as described in contract

FAR Clause 52.211-10 “COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK”.

Validity Period of Contractor’s Proposal: The contractor’s proposal prices to include base and all options become effective at the time of award. Contractors are reminded to evaluate and submit prices giving consideration in the projected delay in the NTP for the Construction Phase as addressed in Amendment 0014.

Defense Base Act (DBA) Insurance Coverage Requirements: DBA insurance is required as described in FAR

52.228-3 Workers’ Compensation Insurance (Defense Base Act). However, the mandatory DBA insurance requirement through the Continental Insurance Company (CNA) is hereby removed in its entirety and is converted to commercially available DBA insurance coverage from carriers and self-insured employers authorized by the

Department of Labor (DOL). The DOL table of authorized carriers and self-insured employers is available at http://www.dol.gov/owcp/dlhwc/lscarrier.htm. If applicable, the contractor is to include the price of DBA insurance in their price proposal.

Allowable Work Hours: The allowable working hours are from 0800-1630, Monday through Friday. Work on holidays and outside of these hours shall not be performed without prior approval from the Contracting Officer.

Office hours for coordination with Government representatives are from 0730-1600 hours, except U.S. holidays.

Prices: All prices are to be proposed in Euros.

http://www.dol.gov/owcp/dlhwc/lscarrier.htm

BASE ITEMS: The base items include all labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements, with the exception of the Optional Items, in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended.

ITEM 0001 – Site Inspection and Submittals (100 Calendar Days)

0001 All labor, transportation, equipment, materials, and any other services necessary for the completion of the project site inspection and submittal requirements prior to construction start for the SATCOM-WSOC Facility in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. Only limited mobilization to support the site inspection and submittal process shall be permitted during this period. €____________

ITEM 0002 - SATCOM-WSOC Facility (410 Calendar Days)

0002 All labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements for the SATCOM-WSOC Facility in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. €____________

ITEM 0003 – Technical Building (410 Calendar Days)

0003 All labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements for the Technical Building Complex in

ITEM 0004 – Exterior Facilities & Site Work (410 Calendar Days)

0004 All labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements for the Exterior Facilities and Site Work in

ITEM 0005 – Demolition Work - Bunkers at Rhine Ordnance Barracks (410 Calendar Days)

0005 All labor, transportation, equipment, materials, and any other services necessary for the completion of all demolishing activities for the 21 bunkers at the Rhine Ordnance

Barracks in accordance with the 100% Technical Specification Revised paragraph

6.2.10 and the Revised Bunker Demolition Drawing provided with Amendment 0014.

TOTAL OF ALL BASE ITEMS €_________________

OPTIONAL ITEMS: The optional items include all labor, transportation, equipment, materials, and any other services necessary for the completion of the optional requirements in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. Any option(s) which is/are exercised shall be completed within the Construction Phase base period of performance.

ITEM 0006 – (Option) Additional Emergency Diesel Generator

0006 All labor, transportation, equipment, materials, and any other services necessary to provide an additional Emergency Diesel Generator in accordance with the 100%

Design Specification Paragraphs 3.49.90; 3.49.100 and 3.49.110, USACE

Specifications, drawings and all other documents provided with the solicitation and as amended. €____________

ITEM 0007 – (Option) Additional Sealed Oil Transformer

0007 All labor, transportation, equipment, materials, and any other services necessary to provide an additional Sealed Oil Transformer in accordance with the 100% Design

Specification Paragraph 3.48.220 and USACE Specifications, drawings and all other documents provided with the solicitation and as amended. €____________

ITEM 0008 – (Option) Illuminated Ceiling in Hallway

0008 All labor, transportation, equipment, materials, and any other services necessary to provide an Illuminated Ceiling in the Hallway in accordance with the 100% Design

Specification Paragraph 2.11.510 through 2.11.600, and USACE Specifications, drawings and all other documents provided with the solicitation and as amended. €____________

TOTAL OF ALL OPTIONAL ITEMS €__________________

TOTAL OF ALL BASE AND ALL OPTIONAL ITEMS €__________________

- End of Document -