Amend_0005_Atch1_Revised_Price_Schedule_22_Feb13.pdf

REVISED PRICE SCHEDULE

Solicitation W912GB-13-R-0009

SATCOM-WSOC Landstuhl, Germany

20 February 2013

The Offeror shall propose on all base and optional items. Provide completion of all award items from the Notice to

Proceed (NTP) as described in the contract FAR Clause 52.211-10 “COMMENCEMENT, PROSECUTION AND

COMPLETION OF WORK” according to the following schedule. The maximum contract period of performance is

490 calendar days from NTP, including base and optional items, if awarded, from the issuance of the NTP. The contractor shall have the project fully functional to include commissioning of the SATCOM WSOC facility and available for normal regular use no later than 410 calendar days from NTP. The Period of Performance is as indicted in each Line Item.

See FAR Clause 52.211-12 for Liquidated Damages. Liquidated damages (LD) apply to any completion date specified in the contract or Price Schedule including interim completion dates for individual facilities. LDs for all base items and exercised options except Line Item 0005 shall be assessed at €2,340.00 for each calendar day of contractor delay until the work is completed or accepted. LDs for Base Line Item 0005 shall be assessed

€1,270.00 for each calendar day of contractor delay until the work is completed or accepted.

Base Items Period of Performance (PoP): The base period of performance is 410 calendar days from issuance of the notice to proceed (NTP) with the exception of the work required under Line Item 0005, which is 80 calendar days. The contractor shall have the project fully functional to include commissioning of the SATCOM WSOC facility and available for normal regular use no later than 410 calendar days from NTP.

Award of Options and PoP: The Government reserves the right to award any or all options up to 90 calendar days following issuance of NTP for the base items work. Any optional work awarded shall be completed within the

Base Items period of performance as described in contract FAR Clause 52.211-10 “COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK”.

Validity Period of Contractor’s Proposal: The contractor’s proposal shall be valid for 90 calendar days after

NTP for base items of work for potential award of optional items.

Allowable Work Hours: The allowable working hours are from 0800-1630, Monday through Friday. Work on holidays and outside of these hours shall not be performed without prior approval from the Contracting Officer.

Office hours for coordination with Government representatives are from 0730-1600 hours, except U.S. holidays.

Prices: All prices are to be proposed in Euros.

BASE ITEMS: The base items include all labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements, with the exception of the Optional Items, in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended.

ITEM 0001 - SATCOM-WSOC Facility (410 Calendar Days)

0001AA All labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements for the SATCOM-WSOC Facility in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended.

W912GB-13-R-0009 Amendment 0005 Attachment 1

0001AB Defense Base Act Insurance for Sub-Item 0001AA above (See FAR clauses 52.000-

4106, 52.000-4132 and 52.228-3) €____________

ITEM 0002 – Technical Building (410 Calendar Days)

0002AA All labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements for the Technical Building Complex in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. €____________

0002AB Defense Base Act Insurance for Sub-Item 0002AA above (See FAR clauses 52.000-

4106, 52.000-4132 and 52.228-3) €____________

ITEM 0003 – Exterior Facilities & Site Work (410 Calendar Days)

0003AA All labor, transportation, equipment, materials, and any other services necessary for the completion of the project requirements for the Technical Building Complex in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. €____________

0003AB Defense Base Act Insurance for Sub-Item 0003AA above (See FAR clauses 52.000-

4106, 52.000-4132 and 52.228-3) €____________

ITEM 0004 – Demolition Work - Bunkers at Rhine Ordnance Barracks (410 Calendar Days)

0004AA All labor, transportation, equipment, materials, and any other services necessary for the completion of all demolishing activities for Building 3373, ASCT and Eagle Sentry antenna foundations at Landstuhl USAG and the bunkers at the Rhine Ordnance

Barracks in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. €____________

0004AB Defense Base Act Insurance for Sub-Item 0004AA above (See FAR clauses 52.000-

4106, 52.000-4132 and 52.228-3) €____________

ITEM 0005 – Demolition Work – Building 3373 and Satellite Antenna Foundations at

Landstuhl USAG and Contract Close-out (Not to Exceed 80 Calendar Days)

0005AA All labor, transportation, equipment, materials, and any other services necessary for the completion of all demolishing activities for Building 3373, ASCT and Eagle Sentry antenna foundations at Landstuhl USAG and all contract close-out activities in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. The work under this Line Item is to start after the successful commissioning of the new SATCOM WSOC building. €____________

0005AB Defense Base Act Insurance for Sub-Item 0005AA above (See FAR clauses 52.000-

TOTAL OF ALL BASE ITEMS €_________________

OPTIONAL ITEMS: The optional items include all labor, transportation, equipment, materials, and any other services necessary for the completion of the optional requirements in accordance with all specifications, drawings and all other documents provided with the solicitation and as amended. Any option(s) which is/are exercised shall be completed within the base period of performance.

ITEM 0006 – Additional Emergency Diesel Generator (410 Calendar Days)

0006AA All labor, transportation, equipment, materials, and any other services necessary to provide an additional Emergency Diesel Generator in accordance with the 100%

Design Specification Paragraphs 3.49.90; 3.49.100 and 3.49.110, USACE

Specifications, drawings and all other documents provided with the solicitation and as amended. €____________

0006AB Defense Base Act Insurance for Sub-Item 0006AA above (See FAR clauses 52.000-

ITEM 0007 – Additional Sealed Oil Transformer (410 Calendar Days)

0007AA All labor, transportation, equipment, materials, and any other services necessary to provide an additional Sealed Oil Transformer in accordance with the 100% Design

Specification Paragraph 3.48.220 and USACE Specifications, drawings and all other documents provided with the solicitation and as amended. €____________

0007AB Defense Base Act Insurance for Sub-Item 0007AA above (See FAR clauses 52.000-

ITEM 0008 – Illuminated Ceiling in Hallway (410 Calendar Days)

0008AA All labor, transportation, equipment, materials, and any other services necessary to provide an Illuminated Ceiling in the Hallway in accordance with the 100% Design

Specification Paragraph 2.11.510 through 2.11.600, and USACE Specifications, drawings and all other documents provided with the solicitation and as amended. €____________

0008AB Defense Base Act Insurance for Sub-Item 0008AA above (See FAR clauses 52.000-

TOTAL OF ALL OPTIONAL ITEMS €__________________

TOTAL OF ALL BASE AND ALL OPTIONAL ITEMS €__________________