Attachment_2_-_Revised_Supplemental_Contract_Requirements.pdf

Attachment 2 Replace POL Facilities Hill AFB, UT July 30, 2018

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to FAR 52.211-10, Commencement, Prosecution, And Completion of Work. The time duration of performance period is 730 calendar days after Notice to Proceed date.

2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction.

3. Authorities. Only a warranted Contracting Officer acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract.

If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer. The Government Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer to the Contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision Numbers UT180104, 02/09/2018, Building; and UT180028, 04/06/2018, Heavy, Davis County, Utah, or their most current modifications at the time of award are hereby applicable to work performed under this contract. The most current decision or its modification can be found by clicking on hyperlink http://www.wdol.gov/dba.aspx for such information.

5. Subcontractors and Outside Associates and Consultants. Any subcontractors and outside associates or consultants required by the Contractor in connection with the services covered by the contract will be limited to individuals or firms that were specifically identified and agreed to during negotiations. The Contractor shall obtain the Contracting Officer’s written consent before making any substitution for these subcontractors, associates, or consultants.

5. Time Extensions For Unusually Severe Weather. Refer to FAR 52.249-10, Default (Fixed- Priced Construction). All weather delays will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(22) (17) (13) (08) (05) (03) (01) (02) (03) (05) (12) (22) http://www.wdol.gov/dba.aspx

SUPPLEMENTAL CONTRACT REQUIREMENTS