Amended_RFP_W5168W23R0002_0002_DPG_BASOPS_27APR2023.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to change the closing date of the solicitation to June 9, 2023 at 2:00PM CST and include some additional administrative changes as show n on change page. All other terms and conditions remain the same.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 6

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 27-Apr-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W5168W23R0002

X 9B. DATED (SEE ITEM 11)

27-Jan-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

27-Apr-2023

CODE

FDO FSH IRC

2371 INFANTRY POST RD, BLDG 602

FORT SAM HOUSTON TX 78234

W5168W 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W5168W23R0002

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION A - SOLICITATION/CONTRACT FORM

The required response date/time has changed from 05-May-2023 02:00 PM to 09-Jun-2023 02:00 PM.

SECTION B - SUPPLIES OR SERVICES AND PRICES

CLIN 1022

This CLIN has been renumbered to CLIN 1023.

CLIN 2022

This CLIN has been renumbered to CLIN 2023.

CLIN 3022

This CLIN has been renumbered to CLIN 3023.

CLIN 4022

This CLIN has been renumbered to CLIN 4023.

SECTION F - DELIVERIES OR PERFORMANCE

The following Delivery Schedule for CLIN 1023 has been added:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 21-DEC-2024 TO

20-DEC-2025

N/A N/A

FOB: Destination

The following Delivery Schedule for CLIN 2023 has been added:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

POP 21-DEC-2025 TO

20-DEC-2026

The following Delivery Schedule for CLIN 3023 has been added:

CAGE

POP 21-DEC-2026 TO

20-DEC-2027

The following Delivery Schedule for CLIN 4023 has been added:

CAGE

POP 21-DEC-2023 TO

20-DEC-2024

SECTION I - CONTRACT CLAUSES

The following have been modified:

52.243-7 NOTIFICATION OF CHANGES (JAN 2017)

(a) Definitions.

"Contracting Officer," as used in this clause, does not include any representative of the Contracting Officer.

"Specifically authorized representative (SAR)," as used in this clause, means any person the Contracting Officer has so designated by written notice (a copy of which shall be provided to the Contractor) which shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority.

(b) Notice. The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change to this contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing, within one calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state--

(1) The date, nature, and circumstances of the conduct regarded as a change;

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

(3) The identification of any documents and the substance of any oral communication involved in such conduct;

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including--

(i) What line items have been or may be affected by the alleged change;

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;

(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be caused by the alleged change;

(iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and

(6) The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.

(c) Continued performance. Following submission of the notice required by (b) above, the Contractor shall diligently continue performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance; provided, however, that if the Contractor regards the direction or communication as a change as described in (b) above, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing and copies furnished to the Contractor and to the Contracting Officer. The Contracting Officer shall countermand any action which exceeds the authority of the SAR.

(d) Government response. The Contracting Officer shall promptly, within three calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either--

(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;

(2) Countermand any communication regarded as a change;

(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or

(4) In the event the Contractor's notice information is inadequate to make a decision under (1), (2), or (3) above, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.

(e) Equitable adjustments.

(1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made--

(i) In the contract price or delivery schedule or both; and

(ii) In such other provisions of the contract as may be affected.

(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.

Note: The phrases “contract price” and “cost” wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof.

(End of clause)

The following have been deleted:

52.247-5 Familiarization With Conditions APR 1984 52.247-8 Estimated Weights or Quantities Not Guaranteed APR 1984 52.247-14 Contractor Responsibility for Receipt of Shipment APR 1984 52.247-15 Contractor Responsibility for Loading and Unloading APR 1984 52.247-16 Contractor Responsibility for Returning Undelivered Freight APR 1984 52.247-21 Contractor Liability for Personal Injury and/or Property

Damage

APR 1984

52.247-22 Contractor Liability for Loss of and/or Damage to Freight Other Than Household Goods

APR 1984

52.247-27 Contract Not Affected by Oral Agreement APR 1984 52.247-63 Preference For U.S. Flag Air Carriers JUN 2003 52.249-14 Excusable Delays APR 1984 52.250-1 Indemnification Under Public Law 85-804 APR 1984 252.245-7000 Government-Furnished Mapping, Charting, and Geodesy

Property

APR 2012

252.247-7023 Transportation of Supplies by Sea FEB 2019

The following were previously included by reference and are now included by full text:

252.237-7024 NOTICE OF CONTINUATION OF ESSENTIAL CONTRACTOR SERVICES (OCT 2010)

(a) Definitions. Essential contractor service and mission-essential functions have the meanings given in the clause at 252.237-7023, Continuation of Essential Contractor Services, in this solicitation.

(b) The offeror shall provide with its offer a written plan describing how it will continue to perform the essential contractor services listed in attachment --, Mission Essential Contractor Services, dated --------, during periods of crisis. The offeror shall--

(1) Identify provisions made for the acquisition of essential personnel and resources, if necessary, for continuity of operations for up to 30 days or until normal operations can be resumed;

(2) Address in the plan, at a minimum--

(i) Challenges associated with maintaining essential contractor services during an extended event, such as a pandemic that occurs in repeated waves;

(ii) The time lapse associated with the initiation of the acquisition of essential personnel and resources and their actual availability on site;

(iii) The components, processes, and requirements for the identification, training, and preparedness of personnel who are capable of relocating to alternate facilities or performing work from home;

(iv) Any established alert and notification procedures for mobilizing identified ``essential contractor service'' personnel; and

(v) The approach for communicating expectations to contractor employees regarding their roles and responsibilities during a crisis.

(End of provision)

(End of Summary of Changes)