N6945013R7999-0013.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

N69450-13-R-7999 GTMO BASE OPERATING SUPPORT SERVICES

*** THIS AMENDMENT IS ONLY APPLICABLE TO THOSE OFFERORS IN THE COMPETITIVE RANGE ***

See BLOCK 14 CONTINUATION PAGE on page 2.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 17-Mar-2014

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N69450-13-R-7999

X 9B. DATED (SEE ITEM 11)

18-Jul-2013

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Mar-2014

CODE

NAVFAC SOUTHEAST

FSC-BOS

BUILDING 903, PO BOX 30

JACKSONVILLE FL 32212-0030

N69450 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N69450-13-R-7999

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

AMENDMENT 0013

**THIS AMENDMENT IS ONLY APPLICABLE TO THOSE OFFERORS IN THE

COMPETITIVE RANGE**

The purpose of this amendment is to:

a. Revise Change of Occupancy Maintenance (COM) LDs per day in NFAS Clause 5252.246- 9303, Consequences of Contractor’s Failure Perform Required Services (OCT 2004).

Note: Changes are annotated in red colored font.

The due date and time for revised proposals REMAINS 2:00 PM EDT, Tuesday, 25 March 2014.

SUMMARY OF CHANGES

SECTION E - INSPECTION AND ACCEPTANCE

The following have been modified:

5252.246-9303 CONSEQUENCES OF CONTRACTOR'S FAILURE TO PERFORM

REQUIRED SERVICES (OCT 2004)

The Contractor shall perform all of the contract requirements. The Government will inspect and assess Contractor performance in accordance with FAR 52.246-4, INSPECTION OF SERVICES - FIXED PRICE

The Government will require re-performance, withhold payment, or seek other suitable consideration for unsatisfactory or non-performed work. When defects can’t be corrected by re-performance, the Government may reduce the price to reflect the reduced value of services performed.

(a) PROCEDURES. In the case of unsatisfactory or non-performed work, the Government:

(1) may give the Contractor written notice of observed deficiencies prior to withholding payment for unsatisfactory or non-performed work and/or assessing liquidated damages. Such written notice shall not be a prerequisite for withholding payment for non-performed work. The Government may specify, as provided for below, that liquidated damages can be assessed against the Contractor. Such liquidated damages are to compensate the Government for administrative costs and other expenses resulting from the unsatisfactory or non-performed work.

(2) may, at its option, allow the Contractor an opportunity to re-perform the unsatisfactory or non-performed work, at no additional cost to the Government. In the case of daily work, corrective action must be completed within __4____ hours of notice to the Contractor. In the case of other work, corrective action must be completed within __24____ hours of notice. In addition, the Government can assess liquidated damages, as referenced above, in the amount of ___10___ percent of the value of all observed defects. The original inspection results of the Contractor’s work will not be modified upon re-inspection. However, the Contractor will be paid for satisfactorily re-performed work.

N69450-13-R-7999

(3) shall withhold from the Contractor’s invoice all amounts associated with the unsatisfactory or non-performed work at the prices set out in the Schedule or provided by other provisions of this contract, unless the Contractor is required to re-perform and satisfactorily complete the work. In addition, the Government can assess liquidated damages, as referenced above, in the amount of __20____ percent of the value of all observed defects.

(4) may, at its option, perform the work by Government personnel or by other means. The Government will reduce the amount of payment to the Contractor, by the amount paid to any Government personnel (based on wages, retirement and fringe benefits) plus material, or by the actual costs incurred to accomplish the work by other means.

If the actual costs cannot be readily determined, the prices set out in the Schedule will be used as the basis for the deduction. In addition, the Government can assess liquidated damages, as referenced above, in the amount of __10__ percent of the computed cost.

(b) The Contractor is responsible for maintaining an effective Quality Control Program during the course of the contract. Failure to maintain adequate quality control may result in Termination for Default.

(c) Re-performance by the Contractor does not waive the Government’s right to terminate for nonperformance in accordance with FAR clause 52.249-8, DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) of Section I and all other remedies for default as may be provided by law.

(d) When WATCHSTANDING SERVICES apply. If the Contractor fails to provide qualified personnel or allows any post to be unmanned for a total of __10____ minutes in any shift, the Government may assign other persons to perform such work or withhold payment as specified below;

(1) When Watchstanding Services are performed by Government employees, withholdings shall be computed based on the current Federal Pay Schedule including wages, retirement and fringe benefits of the Government employees (civilian or military) who actually performed the work. In addition, the Government can assess liquidated damages, as referenced above, in the amount of __10____ percent of the computed cost.

(2) When non-performed Watchstanding Services are obtained under another contract, the Government will withhold an amount equal to the cost to the Government under that contract. In addition, the Government can assess liquidated damages, as referenced above, in the amount of __10___ percent of the cost.

(3) If no guard replacement is furnished by the Government and the work is not performed, the Government will withhold an amount equal to the cost to the Government of having a Government employee perform the work.

In addition, the Government can assess liquidated damages, as referenced above, in the amount of __10___ percent of the computed cost.

(4) The Contractor will be held liable for property losses sustained by the Government as a direct, consequential result of a failure to furnish the required personnel.

(5) Computations of the costs for Government employees to perform work not performed by the Contractor shall be in conformance with FAR 52.222-42, STATEMENT OF EQUIVALENT RATE FOR FEDERAL HIRES.

(e) Change of Occupancy Maintenance (COM). In the event the contractor fails to complete change of occupancy maintenance within the number of days allowed, the Government may assess the COM liquidated damages shown below in addition to the liquidated damages set forth above. COM liquidated damages are based on the prevailing average daily Basic Allowance for Quarters (BAQ) with dependents, plus the average Variable Housing Allowance (VHA). Current applicable rates are shown below; however, actual charges shall be based on the prevailing rates in effect at the time.

COM Liquidated Damages

Type of Unit LDs Per Calendar Day

4 BR, 2.5 bath $100

3 BR, 2 bath $100

3 BR, 1 bath $100

2 BR, 1.5 bath $100

2 BR, 1 bath $100

1 BR, 1 bath $100

(End of Summary of Changes)