FARM III RFP SF30 Amendment 2.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

J

2. AMENDMENT/MODIFICATION NUMBER

3. EFFECTIVE DATE

18 May 2026

4. REQUISITION/PURCHASE

REQUISITION NUMBER

5. PROJECT NUMBER (if applicable)

TBD

6. ISSUED BY CODE FA9101

FA9101 AEDC PKP PROCRMNT BR

CP 931 454 7841, 100 KINDEL DR STE A332

ARNOLD AFB, TN 37389-1332

UNITED STATES

ANDREW WAGGONER, Email: robert.mosley.3@us.af.mil Telephone: 340-6706 ROBERT MOSLEY, Email: robert.mosley.3@us.af.mil Telephone: 340-6706

7. ADMINISTERED BY (if other than Item 6)

CODE

SCD: PAS:

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code)

CODE: FACILITY CODE:

9A. AMENDMENT OF SOLICITATION NUMBER

FA910126RB011

9B. DATED (SEE ITEM 11)

24 Apr 2026

10A. MODIFICATION OF CONTRACT/ORDER

NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; 1 or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required) See Section G - Contract Administration Data

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK

ONE

A.THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.)

SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of this amendment is to:

1. Clarify the Liquidated Damages amount in clause 52.211-12

2. Provide updated Atch 6_L-4 HTRO Scoring Matrix

3. Provide updated Atch 6_L-5 Past Performance Rating Form

4. Provide RFP questions and answers

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

ROBERT T. MOSLEY

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

18 May 2026

Computer generated. Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA-FAR (48 CFR) 53.243

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Section I - Contract Clauses

Additional Regulation or Supplemental Clauses Incorporated by Full Text

The following Clause modifications were made:

52.211-12 Liquidated Damages-Construction. Sep 2000 hereby reads as follows:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of for each calendar day of delay until the work is completed or accepted.$240.49

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

FA910126RB0110002