FA5205-15-R-0007-0005_Atch._RFP_(Revised).pdf

See Schedule.

Additional Information to Offerors:

1. Description of Work/Estimated Cost: This project is Repair Main Wastewater Treatment Plant (WWTP), Bldg. 1190 for Misawa Air Base, Japan.

Refer to Section B for “Description”. The magnitude of the estimate construction is between $10,000,000.00 and $25,000,000.00.

2. Pre-proposal conference/job site visit will be held on 15 May 15 at 35th Contracting Squadron conference room. See AFFARS 5352.215-9001, “Notice of Pre-Bid/Pre-Proposal Conference”, and FAR 52.236-27, “Site Visit (Construction)-Alternate I”, for more detail information.

3. Penal amount of performance bond: Refer to Section H, para. H-902, “Performance Bond”, and Section I, FAR 52.228-15, “Performance and Payment Bonds – Construction”.

4. Funds are not presently available for this project. No award will be made under this solicitation until funds are available. The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse an offeror for any costs.

This solicitation includes clauses authorized for the purpose of construction effort in Japan: DFARS 252.225-7042-the offeror has been duly authorized to operate and to do business in the host nation country where the contract is to be performed, and FAR 52.236-7 (modified IAW AFFARS 5336.507)- The contractor shall be responsible for obtaining any necessary licenses and permits, and for complying with any host government and political subdivisions laws, codes, and regulations applicable.

MIYAKO FUJIMOTO DSN:226-2171 / COM:(81)0176-77-2171

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within ____*__ calendar days and complete it within ____*___ calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See *Section F, para. F-901

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________ 0 copies to perform the work required are due at the place specified in Item 8 by __01:00 PM___ local time _12 Feb 16__ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 330 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION,

AND

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

35 CONS/LGC

DODAAC:

BLDG. 656, MISAWA AIR

MISAWA-SHI, AOMORI-KEN 033-

FA5205

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

(hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

FA5205-15-R-0007-0005 40

QKKA 07-1054

28 Apr 15

FA5205-15-R-0007

Section F - Deliveries or Performance

CLAUSES INCORPORATED BY REFERENCE

52.211-13 Time Extensions SEP 2000

CLAUSES INCORPORATED BY FULL TEXT

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of ¥130,622 + ¥15,454 for the first calendar day of delay and ¥130,622 for each additional calendar day of delay and thereafter for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

F-13 PLACE OF PERFORMANCE

Services under this contract are required to be performed at the following location(s):

Bldg. 1190, Misawa Air Base, Japan, as indicated on the drawings attached.

F-901 PERFORMANCE PERIOD

(a) Performance Period. Allowable maximum performance period to complete the entire work (CLIN 0001) is 1,260 calendar days (CD), including 30 CD for the mobilization.

(b) Notice to Proceed (NTP). For the commencement of the contractor’s performance under this contract, the Contracting Officer will issue NTP within 30 CD after the date of contract award. The contractor shall begin the performance within 30 CD after receipt of the NTP and complete all work by the date established in the NTP.