B08_140P2024R0048_SLBE_318729_Solicitation_Package.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION CALL

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

NPS, DSC Contracting Services Div

12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Jeanna Manseau 7205034666

1x 07/08/2024

140P2024R0048

INVITATION FOR BID

REQUEST FOR PROPOSAL

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

SLBE 318729 - Sleeping Bear Dunes National Lakeshore - Comprehensive Facility

Rehabilitation on Manitou Islands- GAOA

a) This acquisition is being conducted as an Unrestricted Full and Open Competition.

The North American Industrial Classification System (NAICS) code and the associated small business size standard are noted in FAR 52.204-8 in Section "K" of this solicitation.

b) Magnitude of Construction: More than $10,000,000

c) Refer to Section "L" for information regarding a pre-proposal site visit.

d) Information and requirements stated in Sections "B" through "J" and attachments noted in Section "J" apply to this solicitation and subsequent contract.

e) Refer to Section "L" for proposal submittal requirements.

f) This is currently an unfunded requirement with a high expectation that funds will be available. When and if funds become available a contract will be awarded at that time.

g) Offerors shall submit proposals and questions and acknowledge solicitation amendments as stated in Section "L" of this solicitation.

h) All Federal, State and Local taxes must be included in your proposal. This project is not tax exempt.

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 ________________ calendar days and complete it by __12/31/2026______________ after receiving

52.211-10

08/21/2024

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 12/2022)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

NPS, DSC Contracting Services Div 12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Edwin Berry

28. NEGOTIATED AGREEMENT 29. AWARD

and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations,certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

10 U.S.C. 3204(a) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 12/2022) BACK

and return

(Contractor is not required to sign this document.) Your offer on this

Solicitation 06/28/2024

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

SECTION B – BID SCHEDULE

SECTION C – SPECIFICATIONS / DRAWINGS

SECTION D – PACKING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246-11 HIGHER LEVEL CONTRACT QUALITY REQUIREMENT(DEC 2014)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR

1984)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT

REPORTING SYSTEM (DEC 2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT

PLATFORM (FEB 2021)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT: OPTION FOR ADDITIONAL SERVICES—SEPARATELY

PRICED LINE ITEMS

SPECIAL REQUIREMENT : KEY PERSONNEL

SPECIAL REQUIREMENT: KEY TRADES

CONSTRUCTION CONTRACT ADMINISTRATION

SPECIAL REQUIREMENT: PUBLICITY

SPECIAL REQUIREMENT: ORGANIZATIONAL CONFLICTS OF INTEREST

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

1452.224-11 PRIVACY ACT NOTIFICATION (JUL 1996) DEVIATION

52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND

SERVICES DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED

ENTITIES (DEC 2023)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS

AND VIDEO SURVEILLANCE SERVICES AND EQUIPMENT (NOV 2021)

52.204-30 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT ORDERS –

PROHIBITION (DEC 2023)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR

(APR 1984)

52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL

BUSINESS CONCERNS (OCT 2022)

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR

EPA- DESIGNATED PRODUCTS (MAY 2008)

52.225-11 BUY AMERICAN – CONSTRUCTION MATERIALS UNDER TRADE

AGREEMENTS (NOV 2023)

52.228-11 PLEDGES OF ASSETS (FEB 2021) (DEVIATION MAY 2023)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN

2020)(DEVIATION MAY 2023)

1452.228-70 LIABILITY INSURANCE. (JUL 1996)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-17 LAYOUT OF WORK. (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION ALT 1 (FEB 1997)

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

1452.236-70 PROHIBITION AGAINST USE OF LEAD-BASED PAINT (JUL 1996)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES. (NOV 2020)

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J – LIST OF ATTACHMENTS

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF

OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2024)

52.204-24 REPRESENTATIONS REGARDING CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES AND EQUIPMENT (NOV 2021)

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES-

REPRESENTATION (OCT 2020)

52.204-29 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT ORDERS –

REPRESENTATION AND DISCLOSURES (DEC 2023)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-

CERTIFICATION (NOV 2021)

52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS — NOTICE AND

REPRESENTATION (JUN 2020)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF

FEDERAL SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS.

(JUNE 1988)

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT

OF THE INTERIOR (APR 1984)

52.216-1 TYPE OF CONTRACT (APR 1984)

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE

EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

52.228-1 BID GUARANTEE (SEP 1996)

52.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (JUL 1996)

(DEVIATION)

52.236-27 SITE VISIT (CONSTRUCTION) – ALTERNATE 1 (FEB 1995)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION –

COMPETITIVE SOURCE SELECTION

SECTION M – EVALUATION FACTORS FOR AWARD

SPECIAL PROVISION 1: EVALUATION OF OPTIONS

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

Solicitation, Offer, and Award (SF-1442) - pages 1- 2 of this package

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

SECTION B – BID SCHEDULE

Contract Price Schedule Template National Park Service (NPS) - Denver Service Center (DSC) | 3-13-18

Solicitation Number:

PARK - PMIS: SLBE 318729

(Project Management Information System)

Developed Area: North & South Manitou Islands Project Title: Comprehensive Facility Rehabilitation on Manitou Islands

Notice: Offerors are required to submit, a minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars.

Contract Line Item Number (CLIN) Contract Line Item (CLI)

Title Quantity Unit of

Measure Total Price

1 NMI - Dock Replacement (LRF) 1 LS $ -

2 NMI - Dredging, Sorting & Placement

(LRF)

1 LS $ -

3 SMI - Dock Replacement (LRF) 1 LS $ -

4 SMI - Replace-In-Kind Electrical & PV System (LRF)

1 LS $ -

TOTAL BASE PRICE (LRF FUNDS) (Contract Line Item Number 1 through 4) ----------------------------

Contract Line Item Number (CLIN) Contract Line Item (CLI) Title Quantity Unit of

Measure Total Price

5 OPTION #1 - NMI - Replace-In-Kind Electrical & PV System (LRF) 1 LS $

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

6 OPTION #2 - NMI - Replace-In-Kind Septic System (LRF) 1 LS $

7 OPTION #3 - NMI - Replace-In-Kind Water System (LRF) 1 LS $

8 OPTION #4 - NMI - Replace-In-Kind Fuel System (LRF) 1 LS $

9 OPTION #5 - SMI - Replace-In-Kind Septic System (LRF) 1 LS $

10 OPTION #6 - SMI - Replace-In-Kind Water System (LRF) 1 LS $

11 OPTION #7 - SMI - Replace-In-Kind Fuel System (LRF) 1 LS $

OPTION #8 - NMI - Preservation Maintenance of External Envelopes of Historic Structures - Roofing (LRF)

1 LS $

OPTION #9 - SMI - Preservation Maintenance of External Envelopes of Historic Structures - Roofing (LRF)

1 LS $

14 OPTION #10 - NMI - Temporary Access During Construction (Fund Source TBD) 1 LS $

15 OPTION #11 - NMI - Preservation Maintenance of External Envelopes of Historic Structures (LRF)

1 LS $

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

Contract Line Item Number (CLIN) Contract Line Item (CLI)

Title Quantity Unit of

Measure Total Price

OPTION #12 - NMI - Preservation Maintenance of External Envelopes of Historic Structures - Roofing (Repair Rehab/Cyclic)

1 LS $

OPTION #13 - NMI - Preservation Maintenance of External Envelopes of Historic Structures (Repair Rehab/Cyclic)

1 LS $

18 OPTION #14 - NMI - Rehabilitation of Trude Cottage (LRF) 1 LS $

19 OPTION #15 - NMI - Remediation of Contaminated Soils (WASO ECCD Funds)

1 LS $

20 OPTION #16 - SMI - Dock Support Infrastructure (CFF or Repair Rehab/Cyclic)

1 LS $

21 OPTION #17 - SMI - Preservation Maintenance of External Envelopes of Historic Structures (LRF)

1 LS $

OPTION #18 - SMI - Preservation Maintenance of External Envelopes of Historic Structures - Roofing (Repair Rehab/Cyclic)

1 LS $

OPTION #19 - SMI - Preservation Maintenance of External Envelopes of Historic Structures (Repair Rehab/Cyclic)

1 LS $

TOTAL PRICE FOR ALL OPTIONS (Contract Line Item Number 5 through 23) -----------------------------------------

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (Contract Line Item Number 1 through 23) -----------

All measurement and payment information is included in Division 01 Specifications Section 01 27 00 Definition of Contract Line Items.

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

SECTION C – SPECIFICATIONS / DRAWINGS

This project provides for the construction services in support of the SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands located at North and South Manitou Island, Leelanau County, Michigan.

The Comprehensive Facility Rehabilitation on Manitou Islands is meant to address a maintenance backlog spread over 35 historic structures, two ferry docks, and utility infrastructure.

This project includes demolition of the existing docks on North and South Manitou Islands and construction of new docks at historic locations. Limited dredging will be required to achieve dock placement. Utility Infrastructure Repairs: Sewer / Septic, Water and Electrical infrastructure needs repair and replacement due to failure in the existing systems, antiquated parts that are no longer supported, and requirements to meet health and safety regulations and current building codes.

New wells will be drilled on both North and South Manitou Islands. A new chlorination building will be constructed on North Manitou Island and new chlorination systems will be installed on both islands. New water service distribution systems will be installed on both islands, serving 11 buildings on North Manitou Island and 12 buildings on South Manitou Island. Septic systems will be upgraded to 10 buildings on North Manitou Island and 9 buildings on South Manitou Island.

Electrical upgrades will include repairs and partial replacement of the existing off-grid microgrid system. Historic Building exterior envelope repairs to approximately 35 structures (i.e. roofing, siding, window, door, structural improvements and similar repairs) to maintain the integrity of these structures. Contaminated soils will also be removed.

Specifications and drawings are attached and incorporated herein by reference. Refer to section J.

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

SECTION D – PACKING AND MARKING

No Clauses Included

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

SECTION E – INSPECTION AND ACCEPTANCE

52.246-11 HIGHER LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

(a) The Contractor shall comply with the higher-level quality standard(s) listed below. The Historic Preservation Standards and Guidelines located on the National Park Service website:

Historic Preservation Standards and Guidelines - Historic Preservation (U.S. National Park Service) (nps.gov)

(b) The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts, in

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require-

(i) Control of such things as design, work operations, in-process control, testing and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the https://www.nps.gov/subjects/historicpreservation/standards.htm https://www.nps.gov/subjects/historicpreservation/standards.htm https://www.nps.gov/subjects/historicpreservation/standards.htm

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK ALTERNATE I (APR

1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 12/31/2026. The time stated for completion shall include final cleanup of the premises. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by Feb 1, 2025. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,029.82 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

(2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the

Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority.

The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts.

The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report.

Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.cpars.gov/ https://www.cpars.csd.disa.mil/ https://www.cpars.gov/

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of Notice)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM

(FEB 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

The contractor shall submit a draft Invoice Package, including copies of the following documents, to the National Park Service’s (NPS) Construction Management Representative (CMR) a minimum of 5 working days prior to submittal of the formal Invoice through IPP. Within 5 working days of receipt, the CMR shall provide an acceptability recommendation to both the NPS Contracting Officer’s Representative (COR) and the contractor. If the CMR recommends acceptance, the contractor shall submit a copy of the final version of the CMR’s checklist and the Invoice Package to the NPS through IPP.

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP)

2. Completed copy of the Pay Estimate Form (including signed certification of subcontractor payments)

3. Completed copy of the Limitations on Subcontracting Report (Include if acquisition is being set-aside and clause 52.219-14 is included)

4. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts

5. A copy of the current construction schedule (refer to project specification section 013216)

6. A copy of the current Schedule of Values. (refer to project specification section 013216)

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of https://www.ipp.gov/

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email IPPCustomerSupport@fiscal.treasury.gov or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Clause) mailto:IPPCustomerSupport@fiscal.treasury.gov

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

SECTION H – SPECIAL CO00NTRACT REQUIREMENTS

SPECIAL REQUIREMENT: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED LINE

ITEMS

The Government may require the delivery of the numbered line items identified in the Schedule as option items at the price stated in the Schedule. The Contracting Officer may unilaterally exercise the option by written notice to the Contractor within 90 days after contract award. Performance of added line item tasks shall be at the price negotiated in the contract Schedule.

(End of clause)

SPECIAL REQUIREMENT : KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Project Manager:

Project Superintendent:

Quality Control Specialist:

Safety Specialist:

Roofing Foreman:

Wildlife Biologist:

Historical Architect:

(b) During the first 120 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 120-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

SPECIAL REQUIREMENT: KEY TRADES

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

(a) The Contractor shall identify firms that will perform the following KEY TRADES under this contract. If Key Trades will be self-performed, note “self-performed” in the appropriate trade;

otherwise provide the name(s) of assigned subcontractors.

Marine Construction:

Historic Structures Preservation Maintenance:

(b) The assignments above are permanent for the contract duration. The Contractor shall make no substitutions of the above listed Key Trade assignments unless the substitution is approved or directed by the Contracting Officer. The Contractor shall send requests for substitutions to the Contracting Officer a minimum of 15 calendar days prior to any substitution and provide the information required by paragraph (c) below.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete qualification statements for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes shall have comparable qualifications to the firm being replaced. The Contracting Officer will approve or deny substitution requests within 15 calendar days after receipt of all required information. This clause will be modified to reflect any approved changes.

(End of clause)

CONSTRUCTION CONTRACT ADMINISTRATION

Federal Acquisition Regulation (FAR) 36.211(b) requires agencies provide description of policies and procedures that apply to definitization of equitable adjustments for change orders under construction contracts and data on the time required to definitize equitable adjustments for change orders under construction contracts. This information can be found at:

https://www.doi.gov/pam/acquisition/policy/constructioncontract.

SPECIAL CONTRACT REQUIREMENT: PUBLICITY

(a)Except with the prior approval of the Contracting Officer, the consultant shall not release or publication any drawing, rendering, perspective, sketch, photograph, report, specification, cost estimate, or other material of any nature pertaining to the facilities for which services are performed under the terms of this contract.

(b) The provision of this article shall extend also to the release of any such material to any person not so authorized by the Contracting Officer.

(End of clause)

SPECIAL CONTRACT REQUIREMENT: ORGANIZATIONAL CONFLICTS OF INTEREST

https://www.doi.gov/pam/acquisition/policy/constructioncontract

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

(a) Purpose. The purpose of this clause is to ensure that the contractor and its subcontractors:

(1) Are not biased because of their financial, contractual, organizational, or other interests which relate to the work performed under this contract, and

(2) Do not obtain any unfair competitive advantage over other parties by virtue of their performance of this contract.

(b) Scope. The restrictions described herein shall apply to performance or participation by the contractor, its parents, affiliates, divisions and subsidiaries, and successors in interest (hereinafter collectively referred to as “contractor”) in the activities covered by this clause as a prime contractor, subcontractor, co-sponsor, joint venturer, consultant, or in any similar capacity. For the purpose of this clause, affiliation occurs when a business concern is controlled by or has the power to control another or when a third party has the power to control both.

(c) No contract for the construction of a project shall be awarded to the firm (including its subsidiaries or affiliates) that designed the project (except with the approval of the head of the agency or authorized representative).

(d) Warrant and Disclosure. The warrant and disclosure requirements of this paragraph apply with full force to both the contractor and all subcontractors. The contractor warrants that, to the best of the contractor's knowledge and belief, there are no relevant facts or circumstances which would give rise to an organizational conflict of interest, as defined in FAR Subpart 9.5, and that the contractor has disclosed all relevant information regarding any actual or potential conflict. The contractor agrees it shall make an immediate and full disclosure, in writing, to the Contracting Officer of any facts that may cause a reasonably prudent person to question the contractor's impartiality because of the appearance or existence of bias or an unfair competitive advantage. Such disclosure shall include a description of the actions the contractor has taken or proposes to take in order to avoid, neutralize, or mitigate any resulting conflict of interest.

e) Remedies. The Contracting Officer may terminate this contract for convenience, in whole or in part, if the Contracting Officer deems such termination necessary to avoid, neutralize or mitigate an actual or apparent organizational conflict of interest. If the contractor fails to disclose facts pertaining to the existence of a potential or actual organizational conflict of interest or misrepresents relevant information to the Contracting Officer, the Government may terminate the contract for default, suspend or debar the contractor from Government contracting, or pursue such other remedies as maybe permitted by law or this contract.

(f) Subcontracts. The contractor shall include a clause substantially similar to this clause, including paragraphs (f) and(g), in any subcontract or consultant agreement at any tier expected to exceed the simplified acquisition threshold. The terms “contract,” “contractor,” and “Contracting Officer” shall be appropriately modified to preserve the Government's rights.

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are incorporated by reference (by Citation Number, Title, and Date) per the clause at FAR “52.252-2 CLAUSES INCORPORATED BY REFERENCE” in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to a clause’s full text.

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN

2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RECESSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS

(JUN 2020)

52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (NOV 2021)

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO

INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (NOV 2023)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY

AGREEMENTS OR STATEMENTS (JAN 2017)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (OCT 2016)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND

CERTIFICATIONS (DEC 2014)

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS

(NOV 2021)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUNE 2023)

52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUB-CONTRACTING WITH

CONTRACTOR’S DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT

(NOV 2021)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING

RESPONSIBILITY MATTERS (OCT 2018)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(NOV 2015)

Document No.

140P2024R0048

Document Title SLBE 318729 Comprehensive Facility Rehabilitation on Manitou Islands

52.210-1 MARKET RESEARCH (NOV 2021)

52.215-2 AUDIT AND RECORDS-NEGOTIATIONS (JUN 2020)

52.215-8 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST AND PRICING DATA

(AUG 2011)

52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA—

MODIFICATIONS (JUN 2020)

52.215-12 SUBCONTRACTOR CERTIFIED COST AND PRICING DATA (JUN 2020)

52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA—MODIFICATIONS (JUN

2020)

52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS

(PRB) OTHER THAN PENSIONS (JUL 2005)

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

52.215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER

THAN CERTIFIED COST OR PRICING DATA (NOV 2021)

52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER

THAN CERTIFIED COST OR PRICING DATA—MODIFICATIONS (NOV 2021)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (FEB 2024)

52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN, ALTERNATE II (SEP 2023)

52.219-16 LIQUIDATED DAMAGES—SUBCONTRACTING PLAN (SEP 2021)

52.219-28 POST AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (SEP 2023)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME

COMPENSATION (MAR 2018)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (AUG 2018)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (JUL 2021)

52.222-9 APPRENTICES AND TRAINEES (JUL…