Attachment 2 - Specifications - DIV 21-32.pdf

19 June 2023, ADDENDUM #1 - 19 July 2023

EHRM

INFRASTRUCTURE

UPGRADES

PROJECT #: 589-21-700

KANSAS CITY VA MEDICAL CENTER,

KANSAS CITY, MISSOURI

SPECIFICATIONS

Book 2 of 2

Divisions 21 - 32

100% CONSTRUCTION

DOCUMENTS

EHRM INFRASTRUCTURE UPGRADES PROJECT #: 589-21-700

KANSAS CITY VA MEDICAL CENTER – KANSAS CITY, MISSOURI PUB. DATE: 06-01-22

TABLE OF CONTENTS 00 01 10 - 01

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 05-20

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 11-21 01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 11-21 01 33 23 Shop Drawings, Product Data, and Samples 06-21 01 35 26 Safety Requirements 11-21 01 42 19 Reference Standards 11-20 01 45 00 Quality Control 02-21 01 45 29 Testing Laboratory Services 11-18 01 45 35 Special Inspections 06-21 01 57 19 Temporary Environmental Controls 01-21 01 74 19 Construction Waste Management 10-21 01 81 13 Sustainable Construction Requirements 10-17 01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17 02 82 11 Traditional Asbestos Abatement 01-21 02 82 13.13 Glovebag Asbestos Abatement 01-21 02 82 13.19 Asbestos Floor Tile and Mastic Abatement 01-21 02 82 13.21 Asbestos Roofing Abatement 01-21 02 83 33.13 Lead-Based Paint Removal and Disposal 01-21

DIVISION 03 – CONCRETE

03 30 00 Cast-in-Place Concrete 01-21

DIVISION 04 – MASONRY

DIVISION 05 – METALS

05 40 00 Cold-Formed Metal Framing 01-21

TABLE OF CONTENTS 00 01 10 - 02

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17 06 20 00 Finish Carpentry 01-21

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 13 Thermal Insulation 01-21 07 22 00 Roof and Deck Insulation 01-21 07 27 26 Fluid-Applied Membrane Air Barrier, Vapor Permeable 01-21 07 42 13.23 Metal Composite Material Wall Panels 07 51 00 Built-Up Bituminous Roofing 12-21 07 54 23 Thermoplastic Polyolefin (TPO) Roofing 01-21 07 84 00 Firestopping 01-21 07 92 00 Joint Sealants 10-17

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 01-21 08 14 00 Interior Wood Doors 01-21 08 31 13 Access Doors and Frames 04-22 08 71 00 Door Hardware 04-22

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 01-21 09 06 00 Schedule for Finishes 01-21 09 22 16 Non-Structural Metal Framing 06-18 09 29 00 Gypsum Board 04-20 09 51 00 Acoustical Ceilings 12-18 09 65 13 Resilient Base and Accessories 01-21 09 66 00 Static Dissipative Sealer for Concrete Substrates 09 91 00 Painting 01-21

DIVISION 10 – SPECIALTIES

10 26 00 Wall and Door Protection 01-21

DIVISION 13 - SPECIAL CONSTRUCTION

13 05 41 Seismic Restraint Requirements for Non-Structural Components 01-21

TABLE OF CONTENTS 00 01 10 - 03

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 21- FIRE SUPPRESSION

21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 09-20 22 07 11 Plumbing Insulation 09-19 22 11 00 Facility Water Distribution 05-21 22 13 00 Facility Sanitary and Vent Piping 09-20 22 40 00 Plumbing Fixtures 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 02-20 23 05 12 General Motor Requirements for HVAC and Steam Generation Equipment 02-20 23 05 41 Noise and Vibration Control for HVAC Piping and Equipment 02-20 23 05 93 Testing, Adjusting, and Balancing for HVAC 02-20 23 07 11 HVAC and Boiler Plant Insulation 02-20 23 08 00 Commissioning of HVAC Systems 02-20 23 09 23 Direct-Digital Control System for HVAC 08-20 23 21 13 Hydronic Piping 02-20 23 21 23 Hydronic Pumps 02-20 23 23 00 Refrigerant Piping 02-20 23 25 00 HVAC Water Treatment 02-20 23 31 00 HVAC Ducts and Casings 02-20 23 34 00 HVAC Fans 02-20 23 36 00 Air Terminal Units 02-20 23 37 00 Air Outlets and Inlets 02-20 23 40 00 HVAC Air Cleaning Devices 03-20 23 74 13 Packaged, Outdoor, Central-Station Air-Handling Units 03-20 23 81 00 Decentralized Unitary HVAC Equipment 03-20 23 82 16 Air Coils 03-20

DIVISION 25 – INTEGRATED AUTOMATION

25 10 10 Advanced Utility Metering System 02-10

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17 26 05 26 Grounding and Bonding for Electrical Systems 01-17

TABLE OF CONTENTS 00 01 10 - 04

SECTION NO. DIVISION AND SECTION TITLES DATE

26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 05 41 Underground Electrical Construction 01-17 26 05 73 Overcurrent Protective Device Coordination Study 01-18 26 08 00 Commissioning of Electrical Systems 11-16 26 09 23 Lighting Controls 01-18 26 22 00 Low-Voltage Transformers 01-18 26 24 16 Panelboards 01-18 26 26 00 Power Distribution Units for Static Uninterruptible Power Systems 01-18 26 27 26 Wiring Devices 01-18 26 29 21 Enclosed Switches and Circuit Breakers 01-17 26 33 53 Static Uninterruptible Power Supply 01-17 26 43 13 Surge Protective Devices 01-17 26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19 27 05 26 Grounding and Bonding for Communications Systems 11-21 27 05 33 Conduits and Backboxes for Communications Systems 11-21 27 05 36 Cable Trays for Communications Systems 11-21 27 05 53 Identification for Communications Systems 07-21 27 10 00 Structured Cabling 11-21 27 11 00 Telecommunications Room Fittings 06-15 27 11 16 Communications Cabinets, Racks, Frames, and Enclosures 11-21 27 11 19 Communications Termination Blocks and Patch Panels 11-21 27 11 26 Communications Rack Mounted Power Protection and Power Strips 11-21 27 13 23 Communications Optical Fiber Backbone Cabling 11-31 27 15 13 Communications Copper Horizontal Cabling 11-21 27 15 13.13 Communications Optical Fiber Splicing and Terminations 11-21 27 16 19 Communications Patch Cords, Station Cords, and Cross Connect Wire 11-21 27 78 00 Closeout Submittals for Communications 03-23

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 04-18 28 05 13 Conductors and Cables for Electronic Safety and Security 10-18 28 05 26 Grounding and Bonding for Electronic Safety and Security 09-11 28 13 00 Physical Access Control System 10-11 28 23 00 Video Surveillance 09-11

DIVISION 31 – EARTHWORK

31 20 11 Earthwork (Short Form) 10-12

TABLE OF CONTENTS 00 01 10 - 05

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 05 23 Cement and Concrete for Exterior Improvements 08-16 32 12 16 Asphalt Paving 09-15 32 84 00 Planting Irrigation 08-16 32 90 00 Planting 08-16

KANSAS CITY VA MEDICAL CENTER – KANSAS CITY, MISSOURI PUB. DATE: 06-01-15

WET-PIPE SPRINKLER SYSTEMS 21 13 13 - 01

SECTION 21 13 13

WET-PIPE SPRINKLER SYSTEMS

PART 1 - GENERAL

1.1 DESCRIPTION

A. Design, installation and testing shall be in accordance with

a. NFPA 13.

B. Modification of the existing sprinkler system as indicated on the drawings and as further required by these specifications.

1.2 RELATED WORK

A. Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.

B. Section 07 84 00, FIRESTOPPING.

1.3 DESIGN CRITERIA

A. Design Basis Information: Provide design, materials, equipment, installation, inspection, and testing of the automatic sprinkler system in accordance with the requirements of NFPA 13.

1.4 SUBMITTALS

A. Submit as one package in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES. Prepare detailed working drawings that are signed by a NICET Level III or Level IV

Sprinkler Technician or stamped by a Registered Professional Engineer licensed in the field of

Fire Protection Engineering. As the Government review is for technical adequacy only, the installer remains responsible for correcting any conflicts with other trades and building construction that arise during installation. Partial submittals will not be accepted. Material submittals shall be approved prior to the purchase or delivery to the job site. Suitably bind submittals in notebooks or binders and provide an index referencing the appropriate specification section. In addition to the hard copies, provide submittal items in Paragraphs

1.4(A)1 through 1.4(A)5 electronically in pdf format on a compact disc or as directed by the COR.

Submittals shall include, but not be limited to, the following:

1. Qualifications:

a. Provide a copy of the installing contractors fire sprinkler and state contractor’s license.

WET-PIPE SPRINKLER SYSTEMS 21 13 13 - 02

b. Provide documentation showing that the installer has been actively and successfully engaged in the installation of commercial automatic sprinkler systems for the past ten years.

2. Manufacturer’s Data Sheets: Provide data sheets for all materials and equipment proposed for use on the system. Include listing information and installation instructions in data sheets.

Where data sheets describe items in addition to those proposed to be used for the system, clearly identify the proposed items on the sheet.

1.5 QUALITY ASSURANCE

A. Installer Reliability: The installer shall possess a valid State of Missouri) fire sprinkler contractor’s license. The installer shall have been actively and successfully engaged in the installation of commercial automatic sprinkler systems for the past ten years.

B. Materials and Equipment: All equipment and devices shall be of a make and type listed by UL or approved by FM, or other nationally recognized testing laboratory for the specific purpose for which it is used. All materials, devices, and equipment shall be approved by the VA. All materials and equipment shall be free from defect. All materials and equipment shall be new unless specifically indicated otherwise on the contract drawings.

1.6 APPLICABLE PUBLICATIONS

A. The publications listed below form a part of this specification to the extent referenced. The publications are referenced in the text by the basic designation only.

B. National Fire Protection Association (NFPA):

13-13 .......................................... Installation of Sprinkler Systems

25-14 .......................................... Inspection, Testing, and Maintenance of Water-Based Fire

Protection Systems

101-15 ........................................ Life Safety Code

170-15 ........................................ Fire Safety Symbols

C. Underwriters Laboratories, Inc. (UL):

Fire Protection Equipment Directory (2011)

D. Factory Mutual Engineering Corporation (FM):

Approval Guide

WET-PIPE SPRINKLER SYSTEMS 21 13 13 - 03

PART 2 - PRODUCTS

2.1 PIPING & FITTINGS

B. Piping and fittings for sprinkler systems shall be in accordance with NFPA 13.

1. Plain-end pipe fittings with locking lugs or shear bolts are not permitted.

2. Piping sizes 50 mm (2 inches) and smaller shall be black steel Schedule 40 with threaded end connections.

3. Plastic piping shall not be permitted except for drain piping.

4. Flexible sprinkler hose shall be FM Approved and limited to hose with threaded end fittings with a minimum inside diameter or 1-inch and a maximum length of 6-feet.

2.4 SPRINKLERS

A. except Provide FM approved quick response sprinklers in all areas, except that standard response sprinklers shall be provided in telecomunication rooms and data centers.

B. Temperature Ratings: In accordance with NFPA 13 except that sprinklers in elevator shafts and elevator machine rooms shall be no less than intermediate temperature rated and sprinklers in generator rooms shall be no less than high temperature rated.

C. Provide sprinkler guards in accordance with NFPA 13 and when the elevation of the sprinkler head is less than 7 feet 6 inches above finished floor. The sprinkler guard shall be UL listed or FM approved for use with the corresponding sprinkler.

2.9 PIPE HANGERS, SUPPORTS AND RESTRAINT OF SYSTEM PIPING

Pipe hangers, supports, and restraint of system piping shall be in accordance with NFPA 13.

PART 3 - EXECUTION

3.1 INSTALLATION

A. Installation shall be accomplished by the licensed contractor. Provide a qualified technician, experienced in the installation and operation of the type of system being installed, to supervise the installation and testing of the system.

B. Installation of Piping: Accurately cut pipe to measurements established by the installer and work into place without springing or forcing. In any situation where bending of the pipe is required, use a standard pipe-bending template. Concealed piping in spaces that have finished ceilings.

WET-PIPE SPRINKLER SYSTEMS 21 13 13 - 04

Where ceiling mounted equipment exists, such as in operating and radiology rooms, install sprinklers so as not to obstruct the movement or operation of the equipment. Sidewall heads may need to be utilized. Piping shall not obstruct the minimum means of egress clearances required by NFPA 101. Pipe hangers, supports, and restraint of system piping, shall be installed accordance with NFPA 13.

C. Firestopping shall be provided for all penetrations of fire resistance rated construction.

Firestopping shall comply with Section 07 84 00, FIRESTOPPING.

D. Repairs: Repair damage to the building or equipment resulting from the installation of the sprinkler system by the installer at no additional expense to the Government.

E. Interruption of Service: There shall be no interruption of the existing sprinkler protection, water, electric, or fire alarm services without prior permission of the Contracting Officer. Contractor shall develop an interim fire protection program where interruptions involve occupied spaces.

Request in writing at least one week prior to the planned interruption.

KANSAS CITY VA MEDICAL CENTER – KANSAS CITY, MISSOURI PUB. DATE: 09-01-20

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 01

SECTION 22 05 11

COMMON WORK RESULTS FOR PLUMBING

A. The requirements of this Section shall apply to all sections of Division 22.

B. Definitions:

1. Exposed: Piping and equipment exposed to view in finished rooms.

2. Exterior: Piping and equipment exposed to weather be it temperature, humidity, precipitation, wind or solar radiation.

C. Abbreviations/Acronyms:

1. ABS: Acrylonitrile Butadiene Styrene

2. A/E: Architect/Engineer

3. AISI: American Iron and Steel Institute

4. ASJ: All Service Jacket

5. ASME: American Society of Mechanical Engineers

6. ASPE: American Society of Plumbing Engineers

7. AWG: American Wire Gauge

8. CD: Compact Disk

9. CDA: Copper Development Association

10. CGA: Compressed Gas Association

11. CFM: Cubic Feet per Minute

12. CI: Cast Iron

13. CLR: Color

14. CO: Contracting Officer

15. COR: Contracting Officer’s Representative

16. CPVC: Chlorinated Polyvinyl Chloride

17. DHW: Domestic Hot Water

18. DHWR: Domestic Hot Water Return

19. DHWS: Domestic How Water Supply

20. DN: Diameter Nominal

21. DVD: Digital Video Disc

22. DWG: Drawing

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 02

23. DWS: Domestic Water Supply

24. DWV: Drainage, Waste and Vent

25. EL: Elevation

26. EPA: Environmental Protection Agency

27. EPACT: Energy Policy Act

28. EPDM: Ethylene Propylene Diene Monomer

29. EPT: Ethylene Propylene Terpolymer

30. ETO: Ethylene Oxide

31. F: Fahrenheit

32. FAR: Federal Acquisition Regulations

33. FD: Floor Drain

34. FED: Federal

35. FG: Fiberglass

36. FNPT: Female National Pipe Thread

37. FPM: Fluoroelastomer Polymer

38. FSK: Foil-Scrim-Kraft Facing

39. FSS: VA Construction & Facilities Management, Facility Standards Service

40. FU: Fixture Units

41. GAL: Gallon

42. GCO: Grade Cleanouts

43. GPD: Gallons per Day

44. GPH: Gallons per Hour

45. GPM: Gallons per Minute

46. ID: Inside Diameter

47. IPC: International Plumbing Code

48. IPS: Iron Pipe Size

49. IW: Indirect Waste

50. lb: Pound

51. MAX: Maximum

52. MFG: Manufacturer

53. MIN: Minimum

54. NPTF: National Pipe Thread Female

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 03

55. NPS: Nominal Pipe Size

56. NPT: Nominal Pipe Thread

57. NTS: Not to Scale

58. PP: Polypropylene

59. ppb: Parts per Billion

60. ppm: Parts per Million

61. PSI: Pounds per Square Inch

62. PSIA: Pounds per Square Inch Atmosphere

63. PSIG: Pounds per Square Inch Gauge

64. PTFE: Polytetrafluoroethylene

65. PVC: Polyvinyl Chloride

66. PVDF: Polyvinylidene Fluoride

67. SAN: Sanitary Sewer

68. SPEC: Specification

69. SQFT/SF: Square Feet

70. SS: Stainless Steel

71. STD: Standard

72. TIL: Technical Information Library http//www.cfm.va.gov/til/indes.asp

73. T/P: Temperature and Pressure

74. TYP: Typical

75. USDA: U.S. Department of Agriculture

76. V: Vent

77. VA: Veterans Administration

78. VA CFM: VA Construction & Facilities Management

79. VA CFM CSS: VA Construction & Facilities Management, Consulting Support Service

80. VAMC: Veterans Administration Medical Center

81. VHA OCAMES: This has been replaced by HEFP.

82. VTR: Vent through Roof

83. W: Waste

1.2 RELATED WORK

A. Section 01 00 00, GENERAL REQUIREMENTS.

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 04

B. Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.

C. Section 01 74 19, CONSTRUCTION WASTE MANAGEMENT.

D. Section 01 81 13, SUSTAINABLE CONSTRUCTION REQUIREMENTS.

E. Section 07 92 00, JOINT SEALANTS.

F. Section 09 91 00, PAINTING.

G. Section 22 07 11, PLUMBING INSULATION.

1.3 APPLICABLE PUBLICATIONS.

A. The publications listed below shall form a part of this specification to the extent referenced. The publications are referenced in the text by the basic designation only. Where conflicts occur these specifications and the VHA standard will govern.

B. American Society of Mechanical Engineers (ASME):

ASME Boiler and Pressure Vessel Code -

BPVC Section IX ........................... Welding, Brazing, and Fusing Qualifications

C. American Society for Testing and Materials (ASTM):

A36/A36M .................................. Standard Specification for Carbon Structural Steel

A575-96e1 .................................. Standard Specification for Steel Bars, Carbon, Merchant Quality, M-Grades

E84 ............................................. Standard Test Method for Surface Burning Characteristics of

Building Materials

E119 ........................................... Standard Test Methods for Fire Tests of Building Construction and Materials

D. International Code Council, (ICC):

IBC .............................................. International Building Code

IPC .............................................. International Plumbing Code

E. Manufacturers Standardization Society (MSS) of the Valve and Fittings Industry, Inc:

SP-58 .......................................... Pipe Hangers and Supports - Materials, Design, Manufacture, Selection, Application and Installation

F. Military Specifications (MIL):

P-21035B .................................... Paint High Zinc Dust Content, Galvanizing Repair (Metric)

G. National Fire Protection Association (NFPA):

99 ............................................... Healthcare Facilities Code

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 05

H. NSF International (NSF):

61 ............................................... Drinking Water System Components – Health Effects

372 ............................................. Drinking Water System Components – Lead Content

I. Department of Veterans Affairs (VA):

PG-18-102014(R18) .................... Plumbing Design Manual

1.4 SUBMITTALS

A. Submittals, including number of required copies, shall be submitted in accordance with Section

01 33 23, SHOP DRAWINGS, PRODUCT DATA, and SAMPLES.

B. Information and material submitted under this section shall be marked "SUBMITTED UNDER

SECTION 22 05 11, COMMON WORK RESULTS FOR PLUMBING", with applicable paragraph identification.

C. If the project is phased, contractors shall submit complete phasing plan/schedule with manpower levels prior to commencing work. The phasing plan shall be detailed enough to provide milestones in the process that can be verified.

D. Contractor shall make all necessary field measurements and investigations to assure that the equipment and assemblies will meet contract requirements, and all equipment that requires regular maintenance, calibration, etc are accessable from the floor or permanent work platform.

It is the Contractor’s responsibility to ensure all submittals meet the VA specifications and requirements and it is assumed by the VA that all submittals do meet the VA specifications unless the Contractor has requested a variance in writing and approved by COR prior to the submittal. If at any time during the project it is found that any item does not meet the VA specifications and there was no variance approval the Contractor shall correct at no additional cost or time to the Government even if a submittal was approved.

E. If equipment is submitted which differs in arrangement from that shown, provide documentation proving equivalent performance, design standards and drawings that show the rearrangement of all associated systems. Additionally, any impacts on ancillary equipment or services such as foundations, piping, and electrical shall be the Contractor’s responsibility to design, supply, and install at no additional cost or time to the Government. VA approval will be given only if all features of the equipment and associated systems, including accessibility, are equivalent to that required by the contract.

F. Prior to submitting shop drawings for approval, Contractor shall certify in writing that manufacturers of all major items of equipment have each reviewed drawings and specifications, COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 06 and have jointly coordinated and properly integrated their equipment and controls to provide a complete and efficient installation.

G. Submittals and shop drawings for interdependent items, containing applicable descriptive information, shall be furnished together and complete in a group. Coordinate and properly integrate materials and equipment in each group to provide a completely compatible and efficient installation. Final review and approvals will be made only by groups.

H. Manufacturer's Literature and Data including: Manufacturer’s literature shall be submitted under the pertinent section rather than under this section.

1. Materials identification.

2. Firestopping materials.

3. Hangers, inserts, supports and bracing. Provide load calculations for variable spring and constant support hangers.

4. Wall, floor, and ceiling plates.

I. Coordination/Shop Drawings:

1. Submit complete consolidated and coordinated shop drawings for all new systems, and for existing systems that are in the same areas.

2. The coordination/shop drawings shall include plan views, elevations and sections of all systems and shall be on a scale of not less than 1:32 (3/8-inch equal to 1 foot). Clearly identify and dimension the proposed locations of the principal items of equipment. The drawings shall clearly show locations and adequate clearance for all equipment, piping, valves, control panels and other items. Show the access means for all items requiring access for operations and maintenance. Provide detailed coordination/shop drawings of all piping and duct systems. The drawings should include all lockout/tagout points for all energy/hazard sources for each piece of equipment. Coordinate lockout/tagout procedures and practices with local VA requirements.

3. Do not install equipment foundations, equipment or piping until coordination/shop drawings have been approved.

4. In addition, for plumbing systems, provide details of the following:

a. Mechanical equipment rooms.

b. Interstitial space.

c. Hangers, inserts, supports, and bracing.

d. Pipe sleeves.

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 07

e. Duct or equipment penetrations of floors, walls, ceilings, or roofs.

1.5 QUALITY ASSURANCE

A. Mechanical, electrical, and associated systems shall be safe, reliable, efficient, durable, easily and safely operable and maintainable, easily and safely accessible, and in compliance with applicable codes as specified. The systems shall be comprised of high quality institutional-class and industrial-class products of manufacturers that are experienced specialists in the required product lines. All construction firms and personnel shall be experienced and qualified specialists in industrial and institutional plumbing.

B. Products Criteria:

1. Standard Products: Material and equipment shall be the standard products of a manufacturer regularly engaged in the manufacture, supply and servicing of the specified products for at least 5 years. However, digital electronics devices, software and systems such as controls, instruments, computer work station, shall be the current generation of technology and basic design that has a proven satisfactory service record of at least 5 years.

2. Equipment Service: There shall be permanent service organizations, authorized and trained by manufacturers of the equipment supplied, located within 160 km (100 miles) of the project. These organizations shall come to the site and provide acceptable service to restore operations within 4 hours of receipt of notification by phone, e-mail or fax in event of an emergency, such as the shut-down of equipment; or within 24 hours in a non-emergency.

Names, mail and e-mail addresses and phone numbers of service organizations providing service under these conditions for (as applicable to the project): pumps, compressors, water heaters, critical instrumentation, computer workstation and programming shall be submitted for project record and inserted into the operations and maintenance manual.

3. All items furnished shall be free from defects that would adversely affect the performance, maintainability and appearance of individual components and overall assembly.

4. The products and execution of work specified in Division 22 shall conform to the referenced codes and standards as required by the specifications. Local codes and amendments enforced by the local code official shall be enforced, if required by local authorities such as the natural gas supplier. If the local codes are more stringent, then the local code shall apply. Any conflicts shall be brought to the attention of the Contracting Officers

Representative (COR).

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 08

5. Multiple Units: When two or more units of materials or equipment of the same type or class are required, these units shall be of the same manufacturer and model number, or if different models are required they shall be of the same manufacturer and identical to the greatest extent possible (i.e., same model series).

6. Assembled Units: Performance and warranty of all components that make up an assembled unit shall be the responsibility of the manufacturer of the completed assembly.

7. Nameplates: Nameplate bearing manufacturer's name or identifiable trademark shall be securely affixed in a conspicuous place on equipment, or name or trademark cast integrally with equipment, stamped or otherwise permanently marked on each item of equipment.

8. Asbestos products or equipment or materials containing asbestos is prohibited.

9. Bio-Based Materials: For products designated by the USDA’s bio-based Bio-Preferred

Program, provide products that meet or exceed USDA recommendations for bio-based content, so long as products meet all performance requirements in this specifications section. For more information regarding the product categories covered by the

Bio-Preferred Program, visit http://www.biopreferred.gov.

C. Welding: Before any welding is performed, Contractor shall submit a certificate certifying that welders comply with the following requirements:

1. Qualify welding processes and operators for piping according to ASME BPVC, Section IX, "Welding and Brazing Qualifications". Provide proof of current certification to CO.

2. Comply with provisions of ASME B31 series "Code for Pressure Piping".

3. Certify that each welder and welding operator has passed American Welding Society (AWS) qualification tests for the welding processes involved, and that certification is current.

4. All welds shall be stamped according to the provisions of the AWS or ASME as required herein and by the association code.

D. Manufacturer's Recommendations: Where installation procedures or any part thereof are required to be in accordance with the recommendations of the manufacturer of the material being installed, printed copies of these recommendations shall be furnished to the COR prior to installation. Installation of the item will not be allowed to proceed until the recommendations are received. Failure to furnish these recommendations can be cause for rejection of the material.

http://www.biopreferred.gov/

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 09

E. Execution (Installation, Construction) Quality:

1. All items shall be applied and installed in accordance with manufacturer's written instructions. Conflicts between the manufacturer's instructions and the contract documents shall be referred to the COR for resolution. Printed copies or electronic files of manufacturer’s installation instructions shall be provided to the COR at least 10 working days prior to commencing installation of any item.

2. All items that require access, such as for operating, cleaning, servicing, maintenance, and calibration, shall be easily and safely accessible by persons standing at floor level, or standing on permanent platforms, without the use of portable ladders. Examples of these items include but are not limited to: all types of valves, filters and strainers, transmitters, and control devices. Prior to commencing installation work, refer conflicts between this requirement and contract documents to COR for resolution. Failure of the Contractor to resolve or call attention to any discrepancies or deficiencies to the COR will result in the

Contractor correcting at no additional cost or time to the Government.

3. Installer Qualifications: Installer shall be licensed and shall provide evidence of the successful completion of at least five projects of equal or greater size and complexity.

Provide tradesmen skilled in the appropriate trade.

4. Workmanship/craftsmanship will be of the highest quality and standards. The VA reserves the right to reject any work based on poor quality of workmanship this work shall be removed and done again at no additional cost or time to the Government.

F. Upon request by Government, provide lists of previous installations for selected items of equipment. Include contact persons who will serve as references, with current telephone numbers and e-mail addresses.

G. Guaranty: Warranty of Construction, FAR clause 52.246-21.

H. Plumbing Systems: IPC, International Plumbing Code. Unless otherwise required herein, perform plumbing work in accordance with the latest version of the IPC. For IPC codes referenced in the contract documents, advisory provisions shall be considered mandatory, the word “should” shall be interpreted as “shall”. Reference to the “code official” or “owner” shall be interpreted to mean the COR.

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 10

I. Cleanliness of Piping and Equipment Systems:

1. Care shall be exercised in the storage and handling of equipment and piping material to be incorporated in the work. Debris arising from cutting, threading and welding of piping shall be removed.

2. Piping systems shall be flushed, blown or pigged as necessary to deliver clean systems.

3. The interior of all tanks shall be cleaned prior to delivery and beneficial use by the

Government. All piping shall be tested in accordance with the specifications and the

International Plumbing Code (IPC). All filters, strainers, fixture faucets shall be flushed of debris prior to final acceptance.

4. Contractor shall be fully responsible for all costs, damage, and delay arising from failure to provide clean systems.

1.6 DELIVERY, STORAGE AND HANDLING

A. Protection of Equipment:

1. Equipment and material placed on the job site shall remain in the custody of the Contractor until phased acceptance, whether or not the Government has reimbursed the Contractor for the equipment and material. The Contractor is solely responsible for the protection of such equipment and material against any damage or theft.

2. Damaged equipment shall be replaced with an identical unit as determined and directed by the COR. Such replacement shall be at no additional cost or additional time to the

Government.

3. Interiors of new equipment and piping systems shall be protected against entry of foreign matter. Both inside and outside shall be cleaned before painting or placing equipment in operation.

4. Existing equipment and piping being worked on by the Contractor shall be under the custody and responsibility of the Contractor and shall be protected as required for new work.

5. Protect plastic piping and tanks from ultraviolet light (sunlight) while in pre-construction.

Plastic piping and tanks shall not be installed exposed to sunlight without metal jacketing to block ultraviolet rays.

1.7 AS-BUILT DOCUMENTATION

A. Submit manufacturer’s literature and data updated to include submittal review comments and any equipment substitutions.

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 11

B. Submit operation and maintenance data updated to include submittal review comments, VA approved substitutions and construction revisions shall be in electronic version on CD or DVD inserted into a three─ring binder. All aspects of system operation and maintenance procedures, including applicable piping isometrics, wiring diagrams of all circuits, a written description of system design, control logic, and sequence of operation shall be included in the operation and maintenance manual. The operations and maintenance manual shall include troubleshooting techniques and procedures for emergency situations. Notes on all special systems or devices shall be included. A List of recommended spare parts (manufacturer, model number, and quantity) shall be furnished. Information explaining any special knowledge or tools the owner will be required to employ shall be inserted into the As-Built documentation.

C. The installing Contractor shall maintain as-built drawings of each completed phase for verification; and, shall provide the complete set at the time of final systems certification testing.

Should the installing Contractor engage the testing company to provide as-built or any portion thereof, it shall not be deemed a conflict of interest or breach of the ‘third party testing company’ requirement. Provide record drawings as follows:

1. Red-lined, hand-marked drawings are to be provided, with one paper copy and a scanned

PDF version of the hand-marked drawings provided on CD or DVD.

1.8 JOB CONDITIONS – WORK IN EXISTING BUILDING

A. Building Operation: Government employees will be continuously operating and managing all facilities, including temporary facilities that serve the VAMC.

B. Maintenance of Service: Schedule all work to permit continuous service as required by the

VAMC.

C. Phasing of Work: Comply with all requirements shown on contract documents. Contractor shall submit a complete detailed phasing plan/schedule with manpower levels prior to commencing work. The phasing plan shall be detailed enough to provide milestones in the process that can be verified.

D. Building Working Environment: Maintain the architectural and structural integrity of the building and the working environment at all times. Maintain the interior of building at 18 degrees C (65 degrees F) minimum. Limit the opening of doors, windows or other access openings to brief periods as necessary for rigging purposes. Storm water or ground water leakage is prohibited.

Provide daily clean-up of construction and demolition debris on all floor surfaces and on all equipment being operated by VA. Maintain all egress routes and safety systems/devices.

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 12

E. Acceptance of Work for Government Operation: As new equipment, systems and facilities are made available for operation and these items are deemed of beneficial use to the Government, inspections and tests will be performed. Based on the inspections, a list of contract deficiencies will be issued to the Contractor. After correction of deficiencies as necessary for beneficial use, the Contracting Officer will process necessary acceptance and the equipment will then be under the control and operation of Government personnel.

PART 2 - PRODUCTS

2.1 MATERIALS FOR VARIOUS SERVICES

A. Material or equipment containing a weighted average of greater than 0.25 percent lead shall not be used in any potable water system intended for human consumption and shall be certified in accordance with NSF 61 or NSF 372.

2.2 COMPATIBILITY OF RELATED EQUIPMENT

A. Equipment and materials installed shall be compatible in all respects with other items being furnished and with existing items so that the result will be a complete and fully operational system that conforms to contract requirements.

2.3 EQUIPMENT AND MATERIALS IDENTIFICATION

A. Use symbols, nomenclature and equipment numbers specified, shown in the drawings, or shown in the maintenance manuals. Coordinate equipment and valve identification with local

VAMC shops. In addition, provide bar code identification nameplate for all equipment which will allow the equipment identification code to be scanned into the system for maintenance and inventory tracking. Identification for piping is specified in Section 09 91 00, PAINTING.

B. Valve Tags and Lists:

1. Plumbing: All valves shall be provided with valve tags and listed on a valve list (Fixture stops not included).

2. Valve tags: Engraved black filled numbers and letters not less than 15 mm (1/2 inch) high for number designation, and not less than 8 mm (1/4 inch) for service designation on 19 gauge, 40 mm (1-1/2 inches) round brass disc, attached with brass "S" hook or brass chain.

3. Valve lists: Valve lists shall be created using a word processing program and printed on plastic coated cards. The plastic-coated valve list card(s), sized 215 mm (8-1/2 inches) by 275 mm (11 inches) shall show valve tag number, valve function and area of control for each service or system. The valve list shall be in a punched 3-ring binder notebook. An additional

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 13

copy of the valve list shall be mounted in picture frames for mounting to a wall. COR shall instruct Contractor where frames shall be mounted.

4. A detailed plan for each floor of the building indicating the location and valve number for each valve shall be provided in the 3-ring binder notebook. Each valve location shall be identified with a color-coded sticker or thumb tack in ceiling or access door.

2.4 FIRESTOPPING

A. Section 07 84 00, FIRESTOPPING specifies an effective barrier against the spread of fire, smoke and gases where penetrations occur for piping. Refer to Section 22 07 11, PLUMBING

INSULATION, for pipe insulation.

2.5 GALVANIZED REPAIR COMPOUND

A. Mil. Spec. DOD-P-21035B, paint.

2.6 ASBESTOS

A. Materials containing asbestos are prohibited.

PART 3 - EXECUTION

3.1 ARRANGEMENT AND INSTALLATION OF EQUIPMENT AND PIPING

A. Location of piping, sleeves, inserts, hangers, and equipment, access provisions shall be coordinated with the work of all trades. Piping, sleeves, inserts, hangers, and equipment shall be located clear of windows, doors, openings, light outlets, and other services and utilities.

Equipment layout drawings shall be prepared to coordinate proper location and personnel access of all facilities. The drawings shall be submitted for review.

B. Manufacturer's published recommendations shall be followed for installation methods not otherwise specified.

C. Minor Piping: Generally, small diameter pipe runs from drips and drains, water cooling, and other services are not shown but must be provided.

D. Protection and Cleaning:

1. Equipment and materials shall be carefully handled, properly stored, and adequately protected to prevent damage before and during installation, in accordance with the manufacturer's recommendations and as approved by the COR. Damaged or defective items in the opinion of the COR, shall be replaced at no additional cost or time to the Government.

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 14

E. Work in Existing Building:

1. Perform as specified in Article, OPERATIONS AND STORAGE AREAS, Article, ALTERATIONS, and Article, RESTORATION of the Section 01 00 00, GENERAL REQUIREMENTS for relocation of existing equipment, alterations and restoration of existing building(s).

2. As specified in Section 01 00 00, GENERAL REQUIREMENTS, Article, OPERATIONS AND

STORAGE AREAS, make alterations to existing service piping at times that will cause the least interfere with normal operation of the facility.

F. Work in bathrooms, restrooms, housekeeping closets: All pipe penetrations behind escutcheons shall be sealed with plumbers’ putty.

3.2 PIPE AND EQUIPMENT SUPPORTS

A. Where hanger spacing does not correspond with joist or rib spacing, use structural steel channels secured directly to joist and rib structure that will correspond to the required hanger spacing, and then suspend the equipment and piping from the channels. Holes shall be drilled or burned in structural steel ONLY with the prior written approval of the COR.

B. The use of chain pipe supports, wire or strap hangers; wood for blocking, stays and bracing, or hangers suspended from piping above shall not be permitted. Rusty products shall be replaced.

C. Hanger rods shall be used that are straight and vertical. Turnbuckles for vertical adjustments may be omitted where limited space prevents use. A minimum of 15 mm (1/2 inch) clearance between pipe or piping covering and adjacent work shall be provided.

D. For horizontal and vertical plumbing pipe supports, refer to the International Plumbing Code

(IPC) and these specifications.

E. Overhead Supports:

1. The basic structural system of the building is designed to sustain the loads imposed by equipment and piping to be supported overhead.

2. Provide steel structural members, in addition to those shown, of adequate capability to support the imposed loads, located in accordance with the final approved layout of equipment and piping.

3. Tubing and capillary systems shall be supported in channel troughs.

F. Floor Supports:

1. Provide concrete bases, concrete anchor blocks and pedestals, and structural steel systems for support of equipment and piping. Concrete bases and structural systems shall be

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 15

anchored and doweled to resist forces under operating and seismic conditions (if applicable) without excessive displacement or structural failure.

2. Bases and supports shall not be located and installed until equipment mounted thereon has been approved. Bases shall be sized to match equipment mounted thereon plus 50 mm (2 inch) excess on all edges. Structural drawings shall be reviewed for additional requirements.

Bases shall be neatly finished and smoothed, shall have chamfered edges at the top, and shall be suitable for painting.

3. All equipment shall be shimmed, leveled, firmly anchored, and grouted with epoxy grout.

Anchor bolts shall be placed in sleeves, anchored to the bases. Fill the annular space between sleeves and bolts with a grout material to permit alignment and realignment.

4. For seismic anchoring, refer to Section 13 05 41, SEISMIC RESTRAINT REQUIREMENTS FOR

NON-STRUCTURAL COMPONENTS.

3.3 PLUMBING SYSTEMS DEMOLITION

A. Rigging access, other than indicated in the drawings, shall be provided after approval for structural integrity by the COR. Such access shall be provided at no additional cost or time to the

Government. Where work is in an operating plant, approved protection from dust and debris shall be provided at all times for the safety of plant personnel and maintenance of plant operation and environment of the plant.

B. In an operating facility, cleanliness and safety shall be maintained. The facility shall be kept in an operating condition. Government personnel will be carrying on their normal duties of operating, cleaning and maintaining equipment and facility operation. Work shall be confined to the immediate area concerned; maintain cleanliness and wet down demolished materials to eliminate dust. Dust and debris shall not be permitted to accumulate in the area to the detriment of facility operation. All flame cutting shall be performed to maintain the fire safety integrity of this facility. Adequate fire extinguishing facilities shall be available at all times. All work shall be performed in accordance with recognized fire protection standards including NFPA

51B. Inspections will be made by personnel of the VAMC, and the Contractor shall follow all directives of the COR with regard to rigging, safety, fire safety, and maintenance of operations.

C. Unless specified otherwise, all piping, wiring, conduit, and other devices associated with the equipment not re-used in the new work shall be completely removed from Government property per Section 01 74 19, CONSTRUCTION WASTE MANAGEMENT. This includes all concrete equipment pads, pipe, valves, fittings, insulation, and all hangers including the top

COMMON WORK RESULTS FOR PLUMBING 22 05 11 - 16

connection and any fastenings to building structural systems. All openings shall be sealed after removal of equipment, pipes, ducts, and other penetrations in roof, walls, floors, in an approved manner and in accordance with plans and specifications where specifically covered. Structural integrity of the building system shall be maintained. Reference shall also be made to the drawings and specifications of the other disciplines in the project for additional facilities to be demolished or handled.

D. Asbestos Insulation Removal: Conform to Section 02 82 11, TRADITIONAL ASBESTOS

ABATEMENT.

3.4 CLEANING AND PAINTING

A. Prior to final inspection and acceptance of the plant and facilities for beneficial use by the

Government, the plant facilities, equipment and systems shall be thoroughly cleaned and painted. Refer to Section 09 91 00, PAINTING.

B. In addition, the following special conditions apply:

1. Cleaning shall be thorough. Solvents, cleaning materials and methods recommended by the manufacturers shall be used for the specific tasks. All rust shall be removed prior to painting and from surfaces to remain unpainted. Scratches, scuffs, and abrasions shall be repaired prior to applying prime and finish coats.

2. The final result shall be a smooth, even-colored, even-textured factory finish on all items.

The entire piece of equipment shall be repainted, if necessary, to achieve this. Lead based paints shall not be used.

- - - E N D - - -

KANSAS CITY VA MEDICAL CENTER – KANSAS CITY, MISSOURI PUB. DATE: 09-01-19

PLUMBING INSULATION 22 07 11 - 01

SECTION 22 07 11

PLUMBING INSULATION

A. Field applied insulation for thermal efficiency and condensation control for the following:

1. Plumbing piping.

2. Re-insulation of plumbing piping and equipment after asbestos abatement and or replacement of any part of existing insulation system (insulation, vapor retarder jacket, protective coverings/jacket) damaged during construction.

B. Definitions:

1. ASJ: All Service Jacket, Kraft paper, white finish facing or jacket.

2. Air conditioned space: Space having air temperature and/or humidity controlled by mechanical equipment.

3. All insulation systems installed within supply, return, exhaust, relief and ventilation air plenums shall be limited to uninhabited crawl spaces, areas above a ceiling or below the floor, attic spaces, interiors of air conditioned or heating ducts, and mechanical equipment rooms shall be noncombustible or shall be listed and labeled as having a flame spread indexes of not more than 25 and a smoke-developed index of not more than 50 when tested in accordance with ASTM E84 or UL 723. Note: ICC IMC, Section 602.2.1.

4. Cold: Equipment or piping handling media at design temperature of 15 degrees C (60 degrees F) or below.

5. Concealed: Piping above ceilings and in chases, interstitial space, and pipe spaces.

6. Exposed: Piping and equipment exposed to view in finished areas including mechanical equipment rooms or exposed to outdoor weather. Shafts, chases, interstitial spaces, unfinished attics, crawl spaces and pipe basements are not considered finished areas.

7. FSK: Foil-scrim-Kraft facing.

8. Hot: Plumbing equipment or piping handling media above 40 degrees C (104 degrees F).

9. Density: kg/m3 - kilograms per cubic meter (Pcf - pounds per cubic foot).

10. Thermal conductance: Heat flow rate through materials.

a. Flat surface: Watts per square meter (BTU per hour per square foot).

b. Pipe or Cylinder: Watts per linear meter (BTU per hour per linear foot) for a given outside diameter.

PLUMBING INSULATION 22 07 11 - 02

11. Thermal Conductivity (k): Watts per meter, per degree K (BTU - inch thickness, per hour, per square foot, per degree F temperature difference).

12. Vapor Retarder (Vapor Barrier): A material which retards the transmission (migration) of water vapor. Performance of the vapor retarder is rated in terms of permeance (perms). For the purpose of this specification, vapor retarders/vapor barriers shall have a maximum published permeance of .02 perms.

13. HWR: Hot water recirculating.

14. CW: Cold water.

15. SW: Soft water.

16. HW: Hot water.

17. PVDC: Polyvinylidene chloride vapor retarder jacketing, white.

1.2 RELATED WORK

A. Section 01 00 00, GENERAL REQUIREMENTS.

B. Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.

C. Section 01 81 13, SUSTAINABLE CONSTRUCTION REQUIREMENTS: Insulation material and insulation production method.

D. Section 02 82 11, TRADITIONAL ASBESTOS ABATEMENT: Insulation containing asbestos material.

E. Section 02 82 13.13, GLOVEBAG ASBESTOS ABATEMENT: Insulation containing asbestos material.

F. Section 22 05 11, COMMON WORK RESULTS FOR PLUMBING: General mechanical requirements and items, which are common to more than one section of Division 22.

1.3 APPLICABLE PUBLICATIONS

A. The publications listed below form a part of this specification to the extent referenced. The publications are referenced in the text by basic designation only.

B. American Society for Testing and Materials (ASTM):

B209 ........................................... Standard Specification for Aluminum and Aluminum-Alloy Sheet and Plate

C411 ........................................... Standard Test Method for Hot-Surface Performance of High-

Temp…