Amendment_3_SF30_with_changes_to_L_M_0003.pdf

(x)

140P2021R0127 x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

PDS

Denver CO 80225-0287 P.O. Box 25287 12795 W. Alameda Pkwy NPS, DSC Contracting Services Div

GRCA 22903508/03/20210003

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

07/15/2021

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

GRCA 229035 Phantom Ranch Wastewater Treatment

The solicitation due date is changed to NLT 1500 MT, August 23, 2021.

Amendment No. 003 provides the following:

1. Document entitled "Amendment 3 Schedule of Changes to the Specifications", 1 page, is added to the solicitation specifications.

2. The preproposal presentation 50 pages is attached to the amendment.

3. Solicitation, Section L, "Factor 4 Schedule" is changed to read as follows:

Submit your proposed construction schedule for this specific project showing completion within the required period of performance contained in this solicitation with accompanying

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Victoria Nosal

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 53

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

140P2021R0127/0003 schedule narrative. Submit your schedule in MS

Project Gantt Chart format; for evaluation purposes only assume a Notice to Proceed date of

October 1, 2021 FOR ALL DIVISION 1 SUBMITTALS AND

LONG LEAD PROCUREMENT ITEMS; USE REALISTIC TIMES

AND UPON APPROVAL OF ALL SUBMITTALS ASSUME A

NOTICE TO PROCEED IN JANUARY 2022 FOR

MOBILIZATION AND CONSTRUCTION. ACTUAL

CONSTRUCTION IS ESTIMATED TO BE APPROXIMATLEY 180

DAYS. Include specific activities required for this project and a clear critical path with major milestones and applicable predecessor activities.

The schedule should include anticipated approval, acquisition, and installation timeline for long lead items including influent screen, IFAS equipment, and automatic backwash filters.

In your accompanying narrative, explain schedule logic, critical path activities, and key considerations and constraints. Plan activities to account for seasonal fluctuation in water levels. Schedule narrative has a 2-page count limit.

4. Section M Factor 4 Schedule- the following is added to the evaluation criteria. DEMONSTRATING

PLANNING THAT ALLOWS ON-SITE CONSTRUCTION TO BE

COMPLETED IN A REALISTIC AND EFFICIENT TIME FRAME

WILL BE MORE FAVORABLY RATED.

5. Offerors are reminded drawings and specifications were provided in Amendment 2. The original solicitation drawings are not valid and should be discarded.

6. The proposal due date is extended to NTL 1500 Mountain Time, August 13, 2021.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110